Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Independent Contractor Agreement with Apex Integrated for Access Control for Fire Station 1-5
AGREEMENT FOR INDEPENDENT CONTRACTOR SERVICES ACCESS CONTROL FOR FIRE STATIONS 1 - 6 PROJECTS # 10464 THIS AGREEMENT FOR INDEPENDENT CONTRACTOR SERVICES is made this _day of June, 2014, and entered into by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho, hereinafter referred to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and Apex Integrated Security Systems, hereinafter referred to as "CONTRACTOR", whose business address is 109 South 4th Street, Boise, ID 83702 and whose Public Works Contractor License # is PWC -C-16018. INTRODUCTION Whereas, the City has a need for services involving Access Control System Equipment and Installation at Fire Stations 1 - 5; and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Agreement and receipt of the City's written notice to proceed, all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Attachment "A" and incorporated herein by this reference, together with any amendments that may be agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. If any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrighted by the Contractor, the City reserves a royalty -free, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. Access Control — For Fire Stations 1 - 5 page 1 of 23 Project 10464 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. The Contractor represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part of the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in a timely manner in accordance with a Schedule of Work, which the parties hereto shall agree to. The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall be compensated on a Not -To -Exceed basis as provided in Attachment B "Payment Schedule' attached hereto and by reference made a part hereof for the Not -To -Exceed amount of $50.197.58. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, of fees earned and costs incurred for services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. Access Control — For Fire Stations 1 - 5 page 2 of 23 Project 10464 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a) completion of the agreed upon work, (b) or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time of termination is listed in Attachment A. 3.2 Should Contractor default in the performance of this Agreement or materially breach any of its provisions, City, at City's option, may terminate this Agreement by giving written notification to Contractor. 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Attachment B of this Agreement on the date due, Contractor, at the Contractor's option, may terminate this Agreement if the failure is not remedied by the City within thirty (30) days from the date payment is due. 3.4 TIME FOR EXECUTING CONTRACT AND LIQUIDATED DAMAGES Upon receipt of a Notice to Proceed, the Contractor shall have 90 (ninety) calendar days to complete the work as described herein. Contractor shall be liable to the City for any delay beyond this time period in the amount of three hundred dollars ($300.00) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. 4. Termination: 4.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails to fulfill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen (15) days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty (60) days notice to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation for any work satisfactorily complete hereunder. Access Control — For Fire Stations 1 - 5 page 3 of 23 Project 10464 4.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to the CITY for damages sustained by the CITY by virtue of any breach of this Agreement by CONTRACTOR, and the CITY may withhold any payments to CONTRACTOR for the purposes of set-off until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR of its liability to the CITY for damages. Independent Contractor: 5.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided in Attachment A, Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 5.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 5.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of Contractor in fulfillment of this Agreement. If in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. Indemnification and Insurance: 6.1 CONTRACTOR shall indemnify and save and hold harmless CITY from and for any and all losses, claims, actions, judgments for damages, or injury to persons or property and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall maintain, and specifically agrees that it will maintain, throughout the term of this Agreement, liability insurance, in which the CITY shall be named an additional insured in the minimum amounts as follow: General Liability One Million Dollars ($1,000,000) per incident or occurrence, Automobile Liability Insurance One Million Dollars ($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in Access Control — For Fire Stations 1 - 5 page 4 of 23 Project 10464 the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or judgments for damages or injury to persons or property and other costs, including litigation costs and attorneys' fees, arising out of, resulting from , or in connection with the performance of this Agreement by the Contractor or Contractor's officers, employs, agents, representatives or subcontractors and resulting in or attributable to personal injury, death, or damage or destruction to tangible or intangible property, including use of. CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (10) days prior to the date Contractor begins performance of it's obligations under this Agreement. In the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. 6.2 Any deductibles, self-insured retention, or named insureds must be declared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 6.3 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City or the City's elected officers, officials, employees and volunteers shall be excess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 6.4 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 6.5 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 6.6 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 7. Bonds: Payment and Performance Bonds are required on all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Access Control — For Fire Stations 1 - 5 page 5 of 23 Project 10464 Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. 8. Warranty: All construction and equipment provided under this agreement shall be warranted for 2 years from the date of the City of Meridian acceptance per the ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items found to be defective during a warranty inspection and subsequently corrected will require an additional two (2) year warranty from the date of City's acceptance of the corrected work. Notices: Any and all notices required to be given by either of the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY CONTRACTOR City of Meridian Apex Integrated Security Systems Purchasing Manager Attn: Bill Atkinson 33 E Broadway Ave 109 South 4'" Street Meridian, ID 83642 Boise, ID 83702 208-888-4433 Phone: (208) 378-9650 Email: bill@apexboise.com Idaho Public Works License # PWC -C-16018 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 10. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. 11. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. 12. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent of CITY. Access Control — For Fire Stations 1 - 5 page 6 of 23 Project 10464 13. Discrimination Prohibited: In performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. 14. Reports and Information: 14.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 14.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement for a minimum of four (4) years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographic and every other means of recording upon any tangible thing, any form of communication or representation including letters, words, pictures, sounds or symbols or any combination thereof. 15. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. 16. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 17. Compliance with Laws: In performing the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 18. Changes: The CITY may, from time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the same formalities as this Agreement. 19. Construction and Severability: If any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other Access Control — For Fire Stations 1 - 5 page 7 of 23 Project 10464 part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 20. Waiver of Default: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. 21. Advice of Attorney: Each party warrants and represents that in executing this Agreement. It has received independent legal advice from its attorney's or the opportunity to seek such advice. 22. Entire Agreement: This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. 23. Order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted bid document. 24. Public Records Act: Pursuant to Idaho Code Section 9-335, et seq., information or documents received from the Contractor may be open to public inspection and copying unless exempt from disclosure. The Contractor shall clearly designate individual documents as "exempt" on each page of such documents and shall indicate the basis for such exemption. The CITY will not accept the marking of an entire document as exempt. In addition, the CITY will not accept a legend or statement on one (1) page that all, or substantially all, of the document is exempt from disclosure. The Contractor shall indemnify and defend the CITY against all liability, claims, damages, losses, expenses, actions, attorney fees and suits whatsoever for honoring such a designation or for the Contractor's failure to designate individual documents as exempt. The Contractor's failure to designate as exempt any document or portion of a document that is released by the CITY shall constitute a complete waiver of any and all claims for damages caused by any such release. 25. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 26. Approval Required: This Agreement shall not become effective or binding until approved by the City of Meridian. End of text. Signatures to follow on next page. Access Control — For Fire Stations 1 - 5 page 8 of 23 Project 10464 Signature Page Access Control for Fire Stations 1 — 5 Project 10461 Apex Integrated Security Systems, Inc L91 MONAJJI=10111F-11kil i Dated: 1- -IL1 Approved by Purchasing BY: KEIT ATTS, Pur a Ing Manager Dated:: Dated: G�If le 'Z" aiy or 5 \` IPle llp i SEAL Dei Dated:: (,- Z y -/y Access Control — For Fire Stations 1 - 5 page 9 of 23 Project 10464 IC. Attachment A 1,1616]»014rdX0714 Provide and install Lenel OnGuard Access Control System to Fire Station 1 - 5 buildings. Each station will receive a new Lenel OnGuard Access Control head -end which includes a Lenel Intelligent System Contorller, Power Supplies and Reader Interface Modules. Headend Location(s): Upper Level Communication/Storage Room. City of Meridian will supply the network connectivity to the Lenel controllers. Fire Stations are primarily hard -lid areas so some Wire Mold and/or Conduit will be used. FIRE STATION #1 (Franklin Rd); 4 Doors with Mullion Mounted Card Readers and Surface Mounted Electric Strikes. FIRE STATIONS 2, 3 AND 4: Each station will have three Doors with Mullion Mounted Card Readers and Surface Mounted Electric Strikes. FIRE STATION 5: 3 Doors with Mullion Mounted Card Readers and Surface Mounted Electric Strikes. 1 Door (Police Sub -station) with a wall mounted reader and a Cut -in Style electric strike Other included services Cable for a Surface Mounted Emergency "911" exterior phone at the front door and an Exterior Camera watching front door and emergency phone will be included in the base price and pulled at the same time as the access control components. Current push button locks will remain in place and de -programmed by the City of Meridian. Access Control — For Fire Stations 1 - 5 page 10 of 23 Project 10464 Fire Station # 1 Oty Description Installed Price Fire Station #1 Base Head -end Location (Controls Two ® Intelligent Dual Reader Conboller -12 VDC or 24 VDC @ 700mA, size ( 6" (152mm) W x 8' (203mm) L x 1" (25mm)H), (5 year lithium battery or 3 months full run) 6 MB standard cardholder flesh memory, 50,000 of Event memory, maximum of 32 devices, On -board Ethernet, onboard two door control, eight inputs, four outputs, cabinet tamper and power fault input monitors. RoHS, CE, (3 -Tick and UL 294 1 Leviton LV -61346005E _► eXtreme 6+ SlimUne Patch Cord, CAT 6, 5-W length, black 1 LifeSafety Power FPO750100DOPE4M LENEL - Multi -function all -inane system specifically engineered to power multi -door Lenel-based access systems. Supports up to 4 Doors (2x LNL-1320). PS/Charger and B100 provide two power outputs, one at 24VDC, the other at 12VDC. 4AN2V & 2A/24V. 2 Power Sonic IM -1270 12v 7A Hour Backup Battery Base Head -end Location (Controls Two Doors) Total., $3,092.45 Door 41: Front Door Front Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location. 125 Genesis WG -31151112 it - 16/4 Stranded Plenum 125 Genesis WG -32061112 - it - 22f6 Stranded OAS Plenum Data Cable 250 Genesis WG -51022106 It - CAT 6- 2314 C6 Plus CMP BI (Camera and Emergency Phone) 1 HES 960010401 Surface Mount strike (12f24v) 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand interrace,75 bit PIV [will also read cards encoded through OnGuard; Segue Mifare] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door V., Frond Door Total., $1,916.40 Access Control — For Fire Stations 1 - 5 page 11 of 23 Project 10464 4 r r $:fRr7V1� # 1 Kitchen Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied In Base Head -end Location. 200 Genesis WG -31151112 - it -1614 Stranded Plenum 200 Genesis WG -32061112 -- It - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12r24v) 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegsnd interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mifare] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory - Wiremold Accessory Pack, Metal, Ivory 1 Wiremold 9-9-10-11 ,A* Wiremold Accessory Pack, Metal, Ivory Door #2., Kitc/ren Door Total: $1,749.40 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - ft- 1614 Stranded Plenum 125 Genesis WG -32061112 - ft - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-1300 Single Reader Interface Module (Series 2 - Supports OSDP Readers) 12124 VDC, 1Reader interface, WIM, 2 inputs and 2 outputs relays (one of each, 2A and SA) and cabinet tamper pigtail, RoHS, CE, C -Tick and UL294 certi5ed. Door #3: Back Door (Apparatus) Total: $2,139.22 Access Control — For Fire Stations 1 - 5 page 12 of 23 Project 10464 1 Lenel LNL-CONY-4 Adapter plate to mount up to 4 LNL-1300s in any CTX enclosure, Maximum two per LNL-CTX enclosure 1 Lenel LNL-MT11 Multi Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mkars] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 - Wiremold Accessory Pack, Metal, Ivory Door #3: Back Door (Apparatus) Total: $2,139.22 Access Control — For Fire Stations 1 - 5 page 12 of 23 Project 10464 Door *4: Ergine Bay Back Door Engine Bay Back Door with a Mullion Reader and Surface Mounted Strike 150 Genesis WG -31151112 - t-1814 Stranded Plenum Door #4: Engine Bay Back Door Total., $2,190.23 Fire Station #1 Total: $11,086.70 Access Control - For Fire Stations 1 - 5 page 13 of 23 Project 10464 150 Genesis WG -32061112 It - 22/6 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-1300 Single Reader Interface Module (Series 2 - Supports OSOP Readers) 12124 VOC, 1Reader interface, WIM, 2 inputs and 2 outputs relays (ane of each, 2A and 5A) and cabinet tamper pigtall , RoHS, CE, C -Tick and UL294 certified. 1 Lenel LNL-CONV-4 Adapter plate to mount up to 4 LNL-13009 in any CTX enclosure, Maximum two per LNL-CTX enclosure 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wisgand interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mtarel 2 Wlremol5Foo Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 - Wiremold Accessory Pack, Metal, Ivory Door #4: Engine Bay Back Door Total., $2,190.23 Fire Station #1 Total: $11,086.70 Access Control - For Fire Stations 1 - 5 page 13 of 23 Project 10464 Fire Station #2 Fire Station #2 Installed Price Base Head -end Location (Controls Two Doors) Intelligent Dual Reader Controller - 12 VDC or 24 VDC @ 700mA, size 16" (152mm) W x 8' (203mm) L x 1" (25mm)H), (5 year lithium battery or 3 months full run) 6 MB standard cardholder flash memory, 50,000 of Event memory, maximum of 32 devices, On -board Ethernet, onboard two door control, eight inputs, four outputs, cabinet tamper and pourer fault input monitors. RoHS, CE, C -Tick and UL 294 1 Leviton LV -61346005E eXtreme 6+ SlimLine Patch Cord, CAT 6, 5 -foot length, black Front Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location. {'�/' 125 Genesis WG -31151112 - ft -18/4 Stranded Plenum 1 LlfeSafety Power FPO75B100D9PE4M - LENEL - Mulfi-function all -in -one system specifically engineered to power multi -door Lenel-based access systems. Supports up to 4 Doors (2x LNLA 320). PS/Charger and B100 provide two power outputs, one at 24VDC, the other at 12VDC. 4A/12V & 2A/24V. 2 Power Sonic IM -1270 12v 7A Hour Backup Battery 1 Lenel LNL-MT11 Base Head -end Location (Controls Two Doors) Total: $3,092.45 Door 91: Front Door Front Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location. {'�/' 125 Genesis WG -31151112 - ft -18/4 Stranded Plenum 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door Al., Front Door Total: $1,916.40 Access Control — For Fire Stations 1 - 5 page 14 of 23 Project 10464 125 Genesis WG -32061112 - It - 2216 Stranded OAS Plenum Data Cable 250 Genesis WG -51022106 it - CAT 6- 2314 C6 Plus CMP BI (Camera and Emergency Phone) 1 HES 960010401 Surface Mount Strike (12r24v) 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mifere) 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door Al., Front Door Total: $1,916.40 Access Control — For Fire Stations 1 - 5 page 14 of 23 Project 10464 Door #2: Kitchen Door Kitchen Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied In Base Head -end Location. 200 Genesis WG -31151112 - k-1814 Stranded Plenum Door Q., K/[chert Door Total., $1,816.86 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - 200 Genesis WG -32061112 - R - 2216 Stranded OAS Planum Data Cable --- 1 HES 960010401 Surface Mount Strike (1224v) 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Slack; Wisgand Intarface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mhare) 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory UL294 certified. 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door Q., K/[chert Door Total., $1,816.86 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - ft- 1814 Stranded Plenum 125 Genesis WG -32061112 --- it - 22J6 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (1224v) 1 Lane[ LNL-1300 Single Reader Interface Module (Series 2 - Supports OSDP Readers) 1224 VDC, 1 Reader interface, W1M, 2 inputs and 2 outputs relays (one of each, 2A and 5A) and cabinet tamper pigtail, RoHS, CE, C -Tick and UL294 certified. 1 Lenel LNL-CONV-4 Adapter plate to mount up to 4 LNL-1300o in any CTX enclosure, Maximum two per LNL- :TX enclosure 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand Interface;75 bit PIV (will also read cards encoded through OnGuard; Secure Mifarel 2 Wiremold B-1 Wiremold 5 Fact Wire Channel, Ivory 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door #3: Back Door (Apparatus) Total., $2,138.22 Fire Station #2 Total: $8,963.93 Access Control - For Fire Stations 1 - 5 page 15 of 23 Project 10464 Fire Station #3 Fire Station #3 Base Head -end Location (Controls Two ® Intelligent Dual Reader Controller - 12 VDC or 24 VOC C 700mA, adze ( 6" (152mm) W x 8" (203mm) L x 1" (25mm)H), (5 year lithium battery or 3 months full run) 6 MB standard cardholder flash memory, 56,000 of Event memory, maximum of 32 devices, On -board Ethernet, on -board two door control, eight inputs, four outputs, cabinet tomper and power Paull Input monitors. RoHS, CE, C -Tick and UL 294 1 Leviton LV-6D46005E �11ae eXtreme 6+ SIImUne Patch Cord, CAT 6, 5 -foot length, black ® 1 LifeSafety Power FPO75810008PE4M tENEL - Multi -function all -in -one system specifically engineered to power multi -door Lenel-baced access systems. Supports up to 4 Doors (2x W L-1320). PS/Charger and B100 provide two power outputs, one at 24VDC, the other at 12VDC. 4AI12V & 2A/24V. . 2 Power Sonic IM -1270 12v 7A Hour Backup Battery Base Head -end Location (Controls Two Doors) Total: $3,092.45 Door #1: Front Door Front Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location, 125 Genesis WG -31151112 - It -18/4 Stranded Plenum Door #1: Front Door Total: $1,916.49 Access Control — For Fire Stations 1 - 5 page 16 of 23 Project 10464 125 Genesis WG -32061112 - it - 2216 Stranded OAS Plenum Data Cable 250 Genesis WG -51022106 t - CAT 6- 23/4 C6 Plus CMP BI (Camera and Emergency Phone) 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-MT11 Multi -Technology Mullion Reeder. Designed to be mounted to a door mullion; Black; Wiegand interface -,75 bit PIV [will also read cards encoded through OnGuerd; Secure Mtare] 2 Wiremold 0-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door #1: Front Door Total: $1,916.49 Access Control — For Fire Stations 1 - 5 page 16 of 23 Project 10464 Door #2: Kitchen Door Kitchen Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location. 201) Genesis WG -31151112 "'A- ft -1814 Stranded Plenum 1 Wiremold 8-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door Q., Kitchen Door Total; $1,749A0 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - ft- 1814 Stranded Plenum 200 Genesis WG -32061112 - ft- 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiagsnd inWace;75 bit PIV [will also read cards encoded through OnGuard; Secure Mifare] 2 Wiremold 8-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold 8-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door Q., Kitchen Door Total; $1,749A0 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - ft- 1814 Stranded Plenum Door #1 Back Door (Apparatus) Total: $2,138.22 Fire Station #3 Total: $6,896.47 Access Control - For Fire Stations 1 - 5 page 17 of 23 Project 10464 125 Genesis WG -32061112 - It - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12f24v) 1 Lenel LNL-1300 Single Reader Interface Module (Series 2 - Supports OSOP Readers) 12124 VOC, 1Reader Interface, Wkd, 2 inputs and 2 outputs relays (one of each, 2A and 5A) and cabinet tamper pigtail , RoHS, CE, C -Tick and UL294 certified. 1 Lenel LNL-CONY-4 Adapter plate to mount up to 4 LNL-13009 in any CTX enclosure, Maximum two per LNL-CTX enclosure 1 Lenel LNL-MT11 MuXi-Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Milaro] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold 8-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door #1 Back Door (Apparatus) Total: $2,138.22 Fire Station #3 Total: $6,896.47 Access Control - For Fire Stations 1 - 5 page 17 of 23 Project 10464 Fire Station #4 Qty Description Installed Price Fire Station #4 Base Head -end Location (Controls Two Doors) ® Intelligent [)us] Reader Controller -12 VDC or 24 VDC @ 700ffA size ( 6" (152mm) W x 8' (203mm) L x 1" (25mm)H), (5 year lithium battery - or 3 months full run) 6 MB standard cardholder flash memory, 50,000 of Event memory, maximum of 32 devices, On -board Ethernet, on -board two door control, eight inputs, four outputs, cabinet tamper and power fault input monitors. RoHS, CE, C -Tick and UL 294 1 Leviton LV-6D46005E eXtreme 6+ SlimLine Patch Cord, CAT 6, 5 -foot length, black 1 LifeSafety Power FP075B100D8PE4M LENEL- Multi -function all -in -one system specifically engineered to power multi -door Lone[ -based access systems. Supports up to 4 Doors (2x LN41320). PS/Charger and B100 provide two power outputs, one at 24VDC, the other at 12VDC. 4AN2V 8 2A/24V. . 2 Power Sonic IM -1270 12v 7A Hour Backup Battery "--. Wiremold Accessory Pack, Metal, Ivory Base Head -end Location (Controls Two Doors) Total: $3,092.45 Door #1: Front Door Front Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location. 125 Genesis WG -31151112 - It -1814 Stranded Plenum 125 Genesis WG -32061112 - ft- 2216 Stranded OAS Plenum Data Cable 250 Genesis WG -51022106 it - CAT 6- 2314 C6 Plus CMP BI (Camera and Emergency Phone) 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-MT11 Muti-Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegond inledace;75 bit PIV [will also read cards encoded through OnGuard; Secure Milare) 2 Wiremold 8-1 Wiremold 5 Fool Wire Channel, Ivory 1 Wiremold 8-9-10-11 "--. Wiremold Accessory Pack, Metal, Ivory Door 91: Front Door Total: $1,916.40 Access Control - For Fire Stations 1 - 5 page 18 of 23 Project 10464 Door #2: Kitchen Door Kitchen Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied In Base Head -end Location. 200 Genesis WG -31151112 R- 1814 Stranded Plenum Door #2., Kitchen Door Total., $1,749.40 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - R - 1814 Stranded Plenum 200 Genesis WG -32061112 -- R - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12J24v) 1 Least LNL-MT11 Mufti -Technology Mullion Reader. Designed to be mounted to a door mullion; Black ; Wk*and interface;75 It PIV [will also read cards encoded through OnGuard; Secure Mifare] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Lenel LNL-CONV-4 1 Wiremold B-9-10-11 Y., Wiremold Accessory Pack, Metal, Ivory Door #2., Kitchen Door Total., $1,749.40 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - R - 1814 Stranded Plenum Door#3: Back Door (Apparatus) Total: $2,138.22 Fire Station #4 Total: $8,898.47 Access Control — For Fire Stations 1 - 5 page 19 of 23 Project 10464 125 Genesis WG -32061112 - R - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface hound Strike (12124v) 1 Lenel LNL-1300 Single Reader Interface Module (Series 2- Supports OSOP Readers) 1224 VDC, 1 Reader interface, W/M, 2 inputs and 2 outputs relays (one of each, 2A and 5A) and eabkrat tamper pigtail , RoHS, CE, C -Tick and UL294 certified. 1 Lenel LNL-CONV-4 Adapter plate to mount up to 4 LNL-1300s in any CTX enclosure, Maximum two per LNL-CTX enclosure 1 Lenel LNL-MT11 MuIO-Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand intedace;75 bit PIV [will also read cards encoded through OnGuard; Secure Mifare] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9.10-11 Wiremold Accessory Pack, Metal, Ivory Door#3: Back Door (Apparatus) Total: $2,138.22 Fire Station #4 Total: $8,898.47 Access Control — For Fire Stations 1 - 5 page 19 of 23 Project 10464 Fire Station #5 Fire Station #5 Base Head -end Location (Controls Two Doors) ® Intelligent Dual Reader Controller -12 VDC or 24 VDC Q 700mA, size - (6 n (152mm) W x 6' (203mm) L x 1" (25mm)H), (5 year lithium battery or 3 months full run) 6 MB standard cardholder (lash memory, 50,000 of /4 Event memory, maximum of 32 devices, On -board Ethernet, on -board two door control, eight inputs, four outputs, cabinet tamper and power fault input monitors. RoHS, CE, C -Tick and UL 294 1 Leviton LV -61346005E �^r eXtreme 6+ SlimDne Patch Cord, CAT 6, 5 -foot length, black 1 LifeSafety Power FP075B100D8PE4M LENEL - Multi -function all -In -one system specifically engineered to power mulbdoor Lanai -based access systems. Supports up to 4 Doors (2x W L-1320). PS/Chsrger and 6100 provide two power outputs, one at 24VDC, the other at 12VDC. 4Afl2V 8 2A/24V. . 2 Power Sonic IM -1270 12v 7A Hour Backup Battery Base Head -end Location (Controls Two Doors) Total., $3,092.45 Door #1: Front Door Front Door wilh Mullion Reader and Surface Mounted Electric Strike. Controller supplied in Base Head -end Location, 125 Genesis WG -31151112 .00A N- 1814 Stranded Plenum Door #1: Front Door Total: $1,916.40 Access Control — For Fire Stations 1 - 5 page 20 of 23 Project 10464 125 Genesis WG -32061112 - R - 22f6 Stranded OAS Plenum Data Cable 250 Genesis WG -51022106 /4 ft - CAT 6- 2314 C6 Plus CMP BI (Camera and Emergency Phone) 1 HES 960010401 Surface Mount Strike (12124v) 1 Lanai LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wh gaud inlerface;75 bit PIV twig also read cards encoded through OnGuard; Secure Mifare] 2 Wiremold B-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 Wiremold Accessory Pack, Metal, Ivory Door #1: Front Door Total: $1,916.40 Access Control — For Fire Stations 1 - 5 page 20 of 23 Project 10464 Ii 1 Door #2: Kitchen Door Kitchen Door with Mullion Reader and Surface Mounted Electric Strike. Controller supplied In Base Head -end Location. / 200 Genesis WG -31151112 - R - 1814 Stranded Plenum Door #2., Kltchan Door Total: $1,749,40 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - R- 18/4 Stranded Plenum 200 Genesis WG -32061112 - R - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-MT11 Mulli-Technology Mullion herder. Designed to be mounted to a door 1 Lenel LNL-1300 mullion; Black; WkWnd interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mifare] z Wiremold 8-1 Wiremold 5 Foot Wire Channel, Ivory 1224 VDC, lReader interface, W1M, 2 inputs and 2 outputs relays (one of each, 2A and 5A) and cabinet tamper pigtail , RoHS, CE, C -Tick and 1 Wiremold B-9-10-11 UL294 certified. Wiremold Accessory Pack, Metal, Ivory Door #2., Kltchan Door Total: $1,749,40 Door #3: Back Door (Apparatus) Back Door with Mullion Reader and Surface Mounted Electric Strike 125 Genesis WG -31151112 - R- 18/4 Stranded Plenum Access Control — For Fire Stations 1 - 5 Project 10464 Door #3: Back Door (Apparatus) Total: $2,138.22 page 21 of 23 125 Genesis WG -32061112 - R - 2216 Stranded OAS Plenum Data Cable 1 HES 960010401 Surface Mount Strike (12124v) 1 Lenel LNL-1300 Single Reader Interface Module (Series 2 - Supports OSDP Readers) 1224 VDC, lReader interface, W1M, 2 inputs and 2 outputs relays (one of each, 2A and 5A) and cabinet tamper pigtail , RoHS, CE, C -Tick and UL294 certified. 1 Lenel LNL-CONV4 Adapter plate to mound up to 4 LNL-13099 in any CTX enclosure, Maximum two per LNL-CTX enclosure 1 Lenel LNL-MT11 Multi -Technology Mullion Reader. Designed to be mounted to a door mullion; Black; Wiegand interface;75 bit PIV [wig also read tarda encoded through OnGuard; Secure Miran] 2 Wiremold 0-1 Wiremold 5 Foot Wire Channel, Ivory 1 Wiremold B-9-10-11 Wiremold Accessory Peck, Metal, Ivory Access Control — For Fire Stations 1 - 5 Project 10464 Door #3: Back Door (Apparatus) Total: $2,138.22 page 21 of 23 Door 94: Police Sub -Station Interior Door with a Wall Mounted Reader and Cutin Electric Strike 1 HES 100630443 HES 1006 Complete Strike. Includes the following faceplates: J, K. KM and KD 1 HES 1DD620571 E Faceplate Option - 630 Finish 1 Lenel LNL-1300 Single Reader Interface Module (Series 2 - Supports OSDP Readers) 12124 VDC, 1 Reader interface, WIM, 2 inputs and 2 outputs relays (one of each, 2A and 5A) and cabinet tamper piglall , RoHS, CE, C -Tick and UL294 certified. 1 Lenel LNL-CONV-4 Adapter plate to mount up to 4 LNL-1300s in any CTX enclosure, Maximum two per LNL-CTX enclosure 1 Lenel LNL-MT15 Mutti-Technology Single Gang Reader. Medium-sized reader designed to be mounted on a wall over a single gang junction box; Black; Wisgand interface;75 bit PIV [will also read cards encoded through OnGuard; Secure Mifare) Door 94: Police Sub-Sration Total: $1,67547 Fire Station #5 Total: $10,571.94 Project Total: $48,415.51 Misc. Costs: Shipping and Handling Fees $320.00 Performance and Payment Bond $1,462.07 Misc. Costs Total $1,782.07 Access Control — For Fire Stations 1 - 5 page 22 of 23 Project 10464 Attachment B MILESTONE / PAYMENT SCHEDULE A. Total and complete compensation for this Agreement shall not exceed $50,197.58. Milestone 1 Substantial Completion 20(twenty) days Milestone 2 Final Completion 90 (ninety) days Contract includes furnishing all labor, materials, equipment, and incidentals as required for the ACCESS CONTROL FOR FIRE STATIONS 1 — 5 project CONTRACT TOTAL ....................... ='I� Description Price Fire Station No 1 $11,086.70 Fire Station No 2 $8.963.93 Fire Station No 3 $8,896.47 Fire Station No 4 $8,896.47 Fire Station No 5 $10,571.94 Shipping & Handling Fees $320.00 Payment and Performance Bonds 1,462.07 FIRES TIONS1 —5 TOTAL $50,197.58 Travel expenses, if applicable, will be paid at no more than the City of Meridian's Travel and Expense Reimbursement Policy. Access Control — For Fire Stations 1 - 5 page 23 of 23 Project 10464 Client#: 1127978 APEXINT1 ACORDTn CERTIFICATE OF LIABILITY INSURANCEDATE(MMIDDIYYYY) 6/18/2014 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER USI Idaho, Kibble & Prentice 3295 Elder Street Boise, ID 83705 208 393-5212 CONTACT NAME: PHONE 208 3935212 FAX Ell: FAXNo): E-MAIL., ADDRESS: INSURER(S) AFFORDING COVERAGE NAICN INSURER A: Philadelphia Indemnity Insuranc 18058 INSURED INSURER B: Idaho State Insurance Fund NONAIC Apex Integrated Security 109 South 4th Street INsuRERc:. EACH�OCCCURRENCE $1,000,000 Boise, ID 83702 INSURER D: _ INSURERS: INSURE RF.: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD- INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,' EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. _ LTR TYPE OF INSURANCE IN RLSUB two POLICYNUMBER MMIDDIYEYYF MMIDDIYEYYY LIMITS A GENERAL LIABILITY x PHPK7111884 D1101112014 011011201E EACH�OCCCURRENCE $1,000,000 PREMISES Eaoccue0ence $100000 X COMMERCIALGENERALLIABILITY _. CLAIMS -MADE OCCUR M ED EXP (Any one person) $5,000 PERSONAL B ADV INJURY $1,000,000 - GENERAL AGGREGATE $2,000,000'. GEN'LAGGREGATE LIMIT APPLIES PER: PRODUCTS -COMPIOP AGO $2,000,000 X POLICY PRO LOC ECT $ A AUTOMOBILE LIABILITY x PHPK1111884 1101/2014 01/01/201 EaMardtlentSINGLE LIMIT 1,000,000 BODILY INJURY (Per person) $ ANY AUTO JX ALL OWNED SCHEDULED AUTOS AUTOS ,. BODILY INJURY (Per ardtlenQ S PROPERTY DAMAGE $ Peraccldenl HIRED AUTOS X NON-0WNED AUTOS (, E UMBRELLA LIAR OCCUR EACH OCCURRENCE $ _ AGGREGATE $ _ EXCESS LIAB CLAIMS -MADE DED I I RETENTION$ $ _ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITYUM1SER ANY PROPRIETORRARTNERIEXECUTIVEY/N OFFICERIMEMBER EXCLUDED? N]NIA (Mandatory In NH) 593154 110112014 01101/201E X WCSTATU- OTH- E. L. EACH ACCIDENT $1000000 E.L. DISEASE - EA EMPLOYEE $1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE -POLICY LIMIT $ DESCRIPTION OF OPERATIONS LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space is required) Certificate holder is added as additional insured per contract with Apex Integrated Security Solutions, Inc. on general liability and auto liability. Ci of Meridian SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVEREDIN 33 E Broadway Ste 106 ACCORDANCE WITH THE POLICY PROVISIONS. -. Meridian, ID 83642 ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) 1 of 1 The ACORD name and logo are registered marks of ACORD #S12710804/M12434600 TATJV I AIA Document A312 TM .2010 Performance Bond CONTRACTOR: (Name, legal status and address) Apex Integrated Security Solutions, Inc 109 South 4th Street Boise, Idaho 83702 OWNER: (Name, legal status and address) City of Meridian 33 E. Broadway Ave Meridian, Idaho 83642 CONSTRUCTION CONTRACT Date: June , 2014 Amount: $50,197.58 SURETY: (Name, legal status and principal place of business) Indemnity Company of California Five Centerpointe, Suite 530 Lake Oswego, Oregon 97035 Description: (Name and location) Access control for Fire Stations 1-5 Projects #10464 BOND Date: June 2014 (Not earlier than Construction Contract Date) Amount: $50,197.58 Modifications to this Bond: ® None ❑ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corpora( eal) Company: (Corp Apex Integrate a ur' SoJutj Indemnity Company f California Signature: `' Signature: Name Lti�f7 �%f1%�q/ Name Karyl Ricr, Atton and Ti e: and and Title: (Arty addrlional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Allied Bonding (Architect, Engineer or other party:) 5605 Overland Rd. Boise, ID 83705 Phone(208)345-4177 Fax(208)384-1677 Bond No. 755890P This document has important legal consequences. Consultation wilh an attorney Is encouraged with resped to its completion or modi0cadon. Any singular reference to Contractor, Surety, Owner or other party shall be considered Plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, Into one form. This Is not a single combined Performance and Payment Bond. 411110s1Y SEAL * -eeeeeer# lDAHO InIL MA aOeumsnt A712--2010. The American lnsatute of Awhbcts. oetnu § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise atter 1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5,2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable atter the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 5 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Ink. AIA Document A312--2010. The Am flcan Inataut9 of Amhaeeb. 2 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 81f the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 8 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or pan of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 142 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material tern of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Inn. ALA Document A312--2010. The American IncONte of A,oh"nects. § 16 Modifications to this bond are as follows: None (S)7ace is provided below for additional signatures ofadded parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address Signature: Name and Title: Address CAUTION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not be obscured. Init. AIA Document A312-- 2010. The American lnaffho W Architects. -- 4 #A1A Document A312 TM .2010 Payment Bond SURETY Bond No. 755890P CONTRACTOR: SURETY: Indemnity Compa (Name, legal status and address) (Name, legal status and principal place Name ��,4M��r� J 7tur Name Ka I A of business) and Title: Apex Integrated Security Solutions, Inc Indemnity Company of California A 109 South 4th Street Five Centerpointe, Suite 530 1 ' This document has Important legal Boise, Idaho 83702 Lake Oswego, Oregon 97035 consequences. Consultation with OWNER: an attorney Is encouraged with (Name, legal status and address) respect to Its completion or modification. City of Meridian Any singular reference to 33 E. Broadway Ave Contractor, Surety, Owner or Meridian, Idaho 83642 other party shell be considered CONSTRUCTION CONTRACT plural where applicable. Date: June ,2014 AIADocument A312-2010 combines two separate bonds, a Amount: $50,197.58 Performance Bond and a Payment Bond, into one form. Description: This Is not a single combined (Name and location) Access control for Fire Stations 1-5 Performance and Payment Bond. Projects #10464 BOND Date: June , 2014 (Not earlier than Construction Contract Date) Amount: $50,197.58 Modifications to this Bond: ® None O See Section IS CONTRACTOR AS PRINCIPAL SURETY Company: (Corpora Company: Apex Integrated S ri lutioo Indemnity Compa Si S1 Name ��,4M��r� J 7tur Name Ka I A and Title: �4Sip✓% and Title: (Any additional signatures appear on the last page of this Paymei (FOR /NFORMAT/ON ONLY— Name, address and telephone)4s1ar"IN1814 AGENT or BROKER: OWNER'S REPRESENTATIVE: � o' ultiry J see Allied Bonding (Architect, Engineer or other, party:) 5605 Overland Rd. a' *?Okollp Boise, ID 83705 4 Phone (208) 345-4177 f F 4Pe410 Fax (208) 384-1677 SEAL rw. ol\ InR AIA Doeumerd Asl2' - 2010. The Am rican lnetHute of Arehsecb. 01110 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment famished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have famished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 5 If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: 17.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor famishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. Init AIA Document A2[2--2010. The American Insatute of Architects. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf Of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which thein signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .6 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms `labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were famished. § 16.3 Construction Contract The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. lnit AIAuocument A312"'-2010. The Amedcan lnst0ute of Architects. § 18.4 Owner Debut Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 18.8 Conked Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be doomed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: None (Space is provided below for additional signatures ofadded parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address Signature: Name and Title: Address CAUTION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not be obscured. Inb. AIA Deoununt A312�- 2010. The Ma= lnaaWb of Mehaaah. POWER OF ATTORNEY FOR DEVELOPERS SURETYAND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box 19725, IRVINE, CA 92623 (949) 263-3300 KNOWALL BY THESE PRESENTS thatexcept as expressly limited, DEVELOPERS SURETYAND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, do each hereby make, constilule and appoint: ***Karyl A. Richter, Janet K. Holthaus, jointly or severally*** as their true and lawful Altorney(symn Fact, to make, execute, deliver and acknowledge, for and on behalf of said corporations, as sureties, bonds, undertakings and contracts of surety- ship giving and granting unto said Attaney(s)-in-Fact full power and authority to do and to perform every act necessary, requisite or proper to be done in connection therewith as each of said corporations could do, but reserving to each of said corporations full power of substitution and revocation, and all of the acts of said Attorney(s)-in-Fact, pursuant to these presents, are hereby rafified and confirmed, This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolutions adopted by the respective Boards of Directors of DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, effective as of January 1st, 2008. RESOLVED, that a combination of any two of the Chairman of the Board, the President, Executive Vice -President, Senior Vice -President or any Vice President of the corporations be, and that each of them hereby is, authorized to execute this Power of Attorney, qualifying the attorney(s) named in the Power of Attorney to execute, on behalf of the corporations, bonds, undertakings and contracts of suretyship; and that the Secretary or any Assistant Secretary of either of the corporations be, and each of [hem hereby is, authorized to attest the execution of any such Power of Attorney; RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attorney or to any. certificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures shall be valid and binding upon the corporations when so affixed and in the future with respect to any bond, undertaking or contract of suretyship to which it is attached. IN WITNESS WHEREOF, DEVELOPERS SURETYAND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA have severally caused these presents to be signed by their respective officers and attested by their respective Secretary or Assistant Secretary this November 21, 2013. By: Daniel Young, SeniorVce-President a �,rvQ KY"ypD 7%F`" pO�pgo VO,c �v�/ > "i S BATF ;$y i h-� v0P // CSG ewi OCT. 2 OCT By: c a `3 1 9 3 6 ,+3 a O n 1987 �. 2 Mark J. Lansdon, Vice -President ? ? �,_ State of California County of Orange "" . moos• On November 21 2013 before me, Antonio Alvarado Nn'-- Public Dale Here Insert Name and Title of the Officer personally appeared ming and Mark J. Lansdon Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that hershe/they executed the same in hislherhheir authorized capacity(ies), and that by hislherltheir signature(s) on the instrument the person(s), or the entity upon behalf of ANT010AAWARADO which the person(s) acted, executed the inslmment. COMM. A 20335 g NOTARY FSLIC - I certity under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is ORANC4E y true and correct. AlyoMml e�MesAug Q 2012 - - WITNESS my hand and official seal. Place Notary Seal Above Signature Antonio Nvarado, Notary Public CERTIFICATE The undersigned, as Secretary or Assistant Secretary of DEVELOPERS SURETY AND INDEMNITY COMPANY or INDEMNITY COMPANY OF CALIFORNIA, does hereby certify that the foregoing Power of Attorney remains in full force and has not been revoked and, furthermore, that the provisions of the resolutions of the respective Boards of Directors of said corporations set forth in the Power of Attorney are in force as of the dale of this Certificate. e This Certificate is executed in the City of Irvine, California, this day oljf � V„4 , a'00 By:�7W Cassie J. Bemsfe V , sistent Secretary V- ID.1380(Rev11113) Untitled Page Login, Public Contractor Search PERMITS LICENSE PUBLIC WORKS VIOLATIONS ELEVATORS Page 1 of 1 'fk'+vr`fldir}a�'�I Public Works Search i> Search Again Download Results Printable View Company Name License Number Work Catenorv(s) License Type I License CI; ;Apex Integrated Security Solutions, Inc. PWC -C-16018 13850, 16700, 16800 4 S First Prov - Page: 1 of 1 Hex[ LEt&t i Details - License Number: PWC -C-16018 Lic 11 Fees $900.00 Registration#: PWC -C-16018 Issue: 5128/2014 Expire: 5/31/2015 Type: PUBLIC WORKS Sub -Type: B Status: ACTIVE Comp/Name: Apex Integrated Security Solutions, Inc. Addressl: 109 S. 41h St. City, State, Zip: BOISE, ID 83702 Phone: (208) 378-9650 Cell: Pager: Fax: (208) 378-9660 Owner Name: Home I CONTACT US P�pnnr https://data.dbs.idaho.gov/etrakit2/ldaho PublieWorksSearchRslts.aspx 6/26/2014 ragc 1 ui 1 IDAHO SECRETARY OF STATE Search Results Ben Ysursa, Secretary of State Search Result Summary [ New Search ] Search Results 1 through 1 ( APEX INTEGRATED SECURITY SOLUTIONS, INC.... APEX INTEGRATED SECURITY SOLUTIONS, INC. ) APEX INTEGRATED SECURITY SOLUTIONS INC [view Details Organizational ID / Filing number: C153539 Filed 10 Mar 2004 CORPORATION 109 S 4TH BOISE, ID 83702 GOODSTANDING Idaho Secretary of State's Main Page State of Idaho Home Page Comments, questions or suggestions can be emailed to: sosinfoCalsos.idaho gov http://www.accessidaho.org/public/sos/corp/search.html 6/26/2014