Change Order No. 2 with Contractors Northwest for WWTP Fermentation and Odor Control}
§
It
ƒ.
LUI0R||
��£§!■#
LL M.
O■;
F�
Q
\
�
as
z
0
y
!;®.
jj
!2))
§
d(
}
§
It
City Of Meridian
Detailed Statement of Revenues and Expenditures - Rev and Exp Report - Keith - Unposted Transactions Included In
Report
3590 - WWTP Construction Projects
60 - Enterprise Fund
From 10/1/2013 Through 9/30/2014
Date: 4/17/14 12:35:07 em Page: 1
Percent
of
Budget with
Current Year
Budget
Budget
Amendments
Actual
Remaining
Remaining
Capital Outlay
96130
Fermentation Projects
10045
Primary 1/2 Fermentation
2,073,997.84
0.00
2,073,997.84
100.00%
10045.a
WWTP Fermentation & Odor
0.00
1,603,999.35
(1,603,999.35)
0.00%
Control Ph 1 Construction
10045.c
WWTP Fermentation & Odor
0.00
176,776.81
(176,776.81)
0.003
Control SDC
10045.e
WWTP Fermentation & Odor
0.00
130,975.00
(130,975.00)
0.00%
Control - Programming &
Integration
10045d
WWTP Fermentation & Odor
0.00
7,776.00
(7,776.00)
0.00%
Control Special Inspections
Total Capital Outlay
2,073,997.84
1,919,527.16
154,470.68
7.453
TOTAL EXPENDITURES
2,073,997.84
1,919,527.16
154,470.68
7.45%
Date: 4/17/14 12:35:07 em Page: 1
City Of Meridian
Detailed Statement of Revenues and Expenditures - Rev and Exp Report - Keith - Unposted Transactions Included In
Report
3590 - WWTP Construction Projects
60 - Enterprise Fund
From 10/1/2013 Through 9/30/2014
Date: 4/17/14 12:35:46 PM Page: 1
Percent
of
Budget with
Current Year
Budget
Budget
Amendments
Actual
Remaining
Remaining
Capital Outlay
92100
WWTP - Bldg improvements
10002
Odor Control Study Task
0.00
4,003.58
(4,003.58)
0.00&
Order 10002
10002.e
WWTP Odor Control Project
0.00
298,305.35
(298,305.35)
0.00%
- Construction
10002d
WWTP Odor Control Project
0.00
12,006.95
(12,006.95)
0.00%
- design
10045
Primary 1/2 Fermentation
611,596.69
0.00
611,596.69
100.00&
10045.e
WWTP Fermentation & Odor
0.00
20,000.00
(20,000.00)
0.00&
Control - Programming &
Integration
10158
Chemical Feed Building -
0.00
7,838.59
(7,838.59)
0.005
Design
10158g
WWTP Chem Feed Bldg
0.00
3,078.76
(3,078.76)
0.00&
Control System Software
Services
10163
Wastewater Facility
0.00
215,815.00
(215,815.00)
0.00%
Maintenance Shop
10381
WWTP Sampling Station
110,000.00
0.00
110,000.00
100.00W
Improvements
10381.a
WWTP Sampling Stn
0.00
18,807.50
(18,807.50)
0.005
Imprvmnts - Final Design &
Permitting
10381.b
WWTP Sampling Station
0.00
54,000.00
(54,000.00)
0.00&
Improvements -Construction
10381.c
WWTP Sampling Stn -
0.00
3,577.75
(3,577.75)
0.008
Special Inspections
10382
Fiber Optics
0.00
1.20
(1.20)
0.00$
10430
WWTP Frontage Improvements
295,000.04
19,336.24
275,663.80
93.451;
10430.a
WWTP Frontage Improvements
0.00
51,766.90
(51,766.90)
0.005
Headgate Construction
10430.b
WWTP Frontage Improvements
0.00
24,981.00
(24,981.00)
0.005
- Entrance Design
1043...
Cresson Lateral
0.00
19,982.00
(19,982.00)
0.005
Improvements
10454
WWTP Road Repair and
500,000.04
16,856.17
483,143.87
96.635
Asphalt & Stormwater
Retention
1045...
WWTP Storm Drainage
0.00
24,950.00
(24,950.00)
0.00&
Improvements - Design
1045...
WWTP Paving & Grading
0.00
24,500.00
(24,500.00)
0.001;
Improvements Design
Total Capital Outlay
1,516,596.77
819,806.99
696,789.78
45.945
TOTAL EXPENDITURES
1,516,596.77
819,806.99
696,789.78
45.945
Date: 4/17/14 12:35:46 PM Page: 1
CITY OF. MERIDIAN
33 EAST BROADWAY
MERIDIAN, ID 83642
CONTRACT CHANGE ORDER
CHANGE ORDER NO. 3
PROJECT NO.
10045a
DATE:
3/12/2014'
EFFECTIVE DATE:
3/12/2014
CONTRACTOR: Contractors Northwest,. Inc.
PROJECT: W WTP Fermentation and Odor Control Project
The Contractor Is hereby directed to make the following changes from the Contract Documents and Plans.
Description:
For the addition of odor control to the secondary pump station, a shed for storage of the odor control
system, the replacement of the existing worn out fermenter tubes with stainless steel tubes, a new
foam roof on the fermentor tank and other related work.
Reason for Change Order:.
To replace worn out fermentor draft tubes and a worn out roof on the fermentor tank as well as add
odor control to the secondary pump station and construct a shed to protect the odor control system.
Attachments:
Pricing for COR 19, COR 20, COR 23A, COR 25, COR 26, COR 27 and COR 26
CHANGE IN CONTRACT PRICE:
'CHANGE IN CONTRACT TIMES:
Original Contract Price $ $2,221,500.00
Original Contract Times: 400
Net changes form previous Change Orders
Net changes form pravlous Change Orders
No.-1—to-2—
No _1_ to 2_ (calendar days)
$ 196,763.00
0
Contract Price Prior to this Change Order.
Contract Times prior to this Change Order.
(calandardeys)
$ 2,416,263.00
400
Net Increase (decrease) of this Change Order.
Not Increase (decrease) of this Change Order,
(calendar days)
$ 109,993.00
35
Contract Price with all Approved Change Orders;
Contract Times with all Approved Change Orders;
(celendardays)
$ 2,526,256.00
435
APPROVED: '(Clly Purchaeing Manager)
ACCEPTED: (Contractor)
Cau�,l,V
By: Keith Walls
Date;
Date:
RECOM ENDED: (Public, orita)
I rlu
By Clint Dolsby
/
Date: 3 11 S f q
Contractor, CONTRACTORS NORTHWEST, INC.
Project: Meridian W WTP Fermentation & Odor control - project # 424845
Reference:
Scope of change:
Change Order Request No: 19
Provide new stainless steel fermenter tubes at interior & exterior of tank 1/20/2014
Note: lube is a 1/4" thick, 27" OD diameter by 14' 10 1/2" length single wall construction.
( 3) Flanges to match existing are included.
9:39 AM 1/20/2014
Page 1 Sheet3Change Order Request 19 - SS tubes
Item #
Description
Quantity
Price
Unit
Cost
1
Western Waterworks
1.00
25161.00
Is
25161.00
2
labor - remove & replace roof system to allow for installation
48.00
45.00
hr
2160.00
3
allowance - replace roof membrane
1.00
1000.00
Is
1000.00
4 liabor
- remove existing -install new pipe
96.00
45.00
hr
4320.00
5
Boll kits & gaskets
1.00 1
225.00
IS
1 225.00
6
Scaffolding
1.00
124.00
Is
124.00
7
crane -including in & out
8.00
135.00
hr
1080.00
8
forklift
9.00
105.00
day
945.00
9
misc. materials
1.00
250.00
Is
250.00
10
Dumpster & removal offsite
1.00
375.00
Is
375.00
11
0.00
12
0.00
0.00
0.00
0.00
Sales tax @ 6%
0.06
25760.00
Is
1545.60
Project Manager
4.00
85.00
HR
340.00
Superintendent
12.00
80.00
HR
960.00
Clerical - office
1.00
40.00
HR
40.00
Labor - clean-up
0.00
32.00
HR
0.00
0.00
Sub -total
38525.60
Overhead & Profit: CNI provided @ 10%
0.10
3852.56
Bond rate
U42378.16
0.01500
635.67
Liability insurance
0.00550
236.58
Builders risk insurance
0.00350
151.38
Total
843,401.78
9:39 AM 1/20/2014
Page 1 Sheet3Change Order Request 19 - SS tubes
77
11
U
m
m
m
E
E
w
a
m
c
D
6
m
0
Nm
R
m
CL
�i
c
9
7
V
N
m
m
to
CL
>I
u
E
46cc
O
9
7
O
T
W
W
2
o
a
m
N
F
W
U
�
0
co
IL
F
N
z
AR
m
W
F
w
W
m
`m
0
H
�
�
H
O
Q
cel
J
O
200
0.,L.g
3!i
Z0
V-
o
X
w
>
en
cO
i
C O
N N
ch
c_
O
F
.o ,SN, O
Z. C?
o
E 9 cu
U
F
o `� m
y
`
O t. v
m OLU L c
O
_k
w�c�mc
m
Q N N m>,
0 m
7
N
C m m
Nc E0.
2
=
z
O
J
U
m
m
m
E
E
w
a
m
c
D
6
m
0
Nm
R
m
CL
�i
c
9
7
V
N
m
m
to
CL
>I
u
E
46cc
O
9
7
O
T
W
I Contractor. CONTRACTORS NORTHWEST, INC.
Project: Meridian W WTP Fermentation & Odor control - project # 424845
Reference:
Scope of change:
Additional odorous air ductwork, per COD #2,
Note: includes aluminum ductwork
Change Order Request No: 20
1/20/2014
2:30 PM1/20/2014 Page 1 Sheet3Change Order Request 2D
Item #
Description
quantity
Price
Unit
Cost
1
YMC Mechanical
1.00
24300.00
Is
24300.00
2
Titanium Excavation -excavate & backfill pads
1.00
2307.00
Is
2307.00
3
(6) Tx 5'6"x 1' deep concrete pads - conc material ( short load)
6.00
125.00
ry
750.00
4
(6) Tx 5'6"x 1' deep concrete pads - rebar material
768.00
0.62
lbs
476.16
5
( 8) Tx 5'6'x 1' deep concrete pads - form material 2x12
144.00
1 1.20
If
172.80
6
( 8) 3' x 6'6"x 1' deep concrete pads - e, bolts & grout material
8.00
12.00
hr
96.00
7
6) 3' x 5'6" x 1' deep concrete pads - form & pour labor
24.00
35.00
hr
840.00.
8
A -Core - core drill 10" diameter holes In wall
1.00
505.00
Is
505.00
9
Automated Dairy Systems- rubber mat material
1.00
3991.40
Is
3991.40
10
KB Welding -aluminum checkered plate & gat bar- materials
1.00
1850.00
Is
1850.00
11
Install rubber mat ( 780 sf )
16.00
45.00
hr
720.00
12
Install checkered & aluminum plate
64.00
45.00
hr
2880.00
fasteners, tools, equipment & consumables
1.00
280.00
Is
280.00
0.00
0.00
Sales tax @ 60/a
0.06
7520.36
451.22
Project Manager
3.00
85.00
HR
255.00
Superintendent
12.00
80.00
HR
960.00
Clerical -office
3-00 1
40.00
HR
120.00
Labor - clean-up
0.00
32.00
HR
0.00
0.00
Sub -total
40954.58
Overhead & Profit: CNI provided @ 10%
1.00
40954.58
0.10
4095.46
Bond rate
1.00
45050.04
0.01500
675.75
Liability insurance
1.00
45725.79
0.00550
251.49
Builders risk insurance
1.00
45977.28
0.00350
160.92
Total
$48,138
2:30 PM1/20/2014 Page 1 Sheet3Change Order Request 2D
WORK CHANGE DIRECTIVE
No. 002 — Rev. 001
PROJECT: WWTP FERMENTATION AND ODOR CONTROL
DATE OF ISSUANCE: October 31, 2013 EFFECTIVE DATE: TBD
DATE OF REVISION: January 3, 2014
OWNER: City of Meridian
Project No,
CONTRACTOR: Contractors Northwest, Inc.
ENGINEER: CI -12M HILL
You are directed to provide a price quotation for the following change(s);
Extend the odorous air ductwork from the 12 -inch wye to the Secondary Pump Station as shown on the attached
exhibits
Purpose of Work Change Directive:
Allows for the capture and filtration of the odorous air associated with the Secondary Pump Station.
If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change
order based thereon will involve one or more of the following methods of determining the effect of the change(s).
Method of determining change in Contract Price: Method of determining change in Contract Times:
❑ Unit Prices ❑ Contractor's records
® Lump Sum ❑ Engineer's records
❑ Other ❑ Other
Estimated increase (decrease) in Contract Price: Estimated increase (decrease) in Contract Times:
$ Substantial Completion: 0 days; Ready
If the change involves an increase, the estimated amount for final payment: 0 days. If the change
is not to be exceeded withdut further authorization. involves an increase, the estimated times are not to
be exceeded without further authorization.
RECOMMEND by ENGINEER: AUTHORIZED by OWNER:
By! Perrin Robinson, CH2M HILL By:
(Authorized Signature)
(Authorized Signature)
XN0
ONTRACTORS
, INC.
2-12-14
City of Meridian
Wastewater Division
3401 N. Ten Mile Road
Meridian, ID. 83646
Project: Meridian Fermentation & Odor #424845
RE: Request for Change Orders
ATT: Tracy Crane; Clint'Dolsby
Contractors Northwest, [nc is pleased to provide a quotation for additional work for the
following:
COR # 23 -A -REVISED Supply and install 6'x 6'x 6' Stor-Mor insulated shed for
storage of Bio Tower 55 drum liquids. Note: electrical excludes division 1, class 2 non-
combustible code compliance and consists of conductors, light & switch, and receptacle
outlet for use connecting heater or heat blanket by others. Includes heat trace of ( 2 ) I
%x" diameter pipes from shed to bio -tower. Add: $ 7,876.00
Please see attached scope of change for details on pricing for each of the above Change
Order Requests. We appreciate the opportunity to provide proposals for this work.
submitted,
Duncan Goundry
Project Manager
Coeur d'Alene P.O. Box 6300, Coeur d'Alene, ID 83816-1938 // Phone: (208) 667-2456 // Fax: (208) 667.6388
Boise P.O. Box 190689, Boise, ID 83719-0689 // Phone: (208) 362.9656 // Fax: (208) 362-9701
contractorenorthwent.cam
Idaho Contractors Regstration 4 RCE -1919
Contractor, CONTRACTORS NORTHWEST, INC.
Project Meridian W WTP Fermentation & Odor control - project # 424845
Reference:
Scope of change:
Supply & install G x 6 x 6' insulated Stor-Mor shed
for storage of Bio Tower 55 gallon drum
No heat or class r Div 2 compliance
Change Order Request No; 23-A
Revised 2.12-14
10 12 AM2I12J2014 Page 1 Sheet3Change Order Request 23A
Item #
Description
Quantity
Price
Unit
Cost
1
Sior-MorOwd
1.00
1452.20
Is
1452,20
2
CNI-install shed - labor
6.00
45.00
hr
-270.00
3
CNI - concrete pad - labor
12.00
45.00
ht
540.00
4
CNI - sawculting & removal of exislin concrete I asphalt paving
1.00
125.00
Is
125.00
5
CNI - concrete pad materials - concrete & rebar
1.00 t
150.60
Is 1
150.00
6
CNI - excavate & compact pad base
6.00
45.00
hr
270.00
7
Equipment - forldift
3.00
105.00
hr
315.0(1
8
Misc. materials & fasteners
1.00
'.100,00
IS
100.00
9
AME Electric- light, switch, recepl&conductors
1.00
.2980.00.
Is
2980.00
10
AME Electric- heat trace (2) 1 1W x 20' pipes
1.0D
Ind.
IS
included
11
Gale Industries - Insulate (2) 1 112"x 20' pipes
1.00
504.00
Is
504.OD
12
..000
0.00
0.00
0.00
Sales tax @ 6%
250.00
0.00.
Project Manager
1.00
85.00
HR
85.00
Superintendent
2.00
80.00
HR
160.00
Clerical - office
100
40,00
HR
40.00
Labor -dean -up
0.00
32.00
HR
0.00
0.0D
Sub -total
6891.20
Overhead & Profit: CNI provided 10%
1.00
6991.20
0.10
699.12
Bond rate
1.00
769032
0.01500
115.35
Liability insurance
1 1.00 1
7805.67
0.00550
42.93
Builders risk insurance
1.00
7848.61
0.00350
27.47
Total
$7,876
10 12 AM2I12J2014 Page 1 Sheet3Change Order Request 23A
JAMIEI WINTERS � lJ4eCtx1L', .l..rAC. MIKES. TENI11)IZEN
iomi�j(antelecv¢enm INDUSTRIAL •MUNICIPAL miLciGam.elnlricaam
COMMEflCIAL •RESIDENTIAL
MOTOR CONTROL
3621 ARTHUR STREET
CALDWELL, IDAHO
PHONE: (208) 459-8959
FAX: (208) 459-2243
February 6, 2014
PUBLIC WORKS LICENSER 11544 -AA -4 (16000) IDAHO CONTRACTOR LICENSER C 2854
UL 508A INDUSTRIAL CONTROL PANEL LICENSE H E 312625
Web Site; www.ameelectric.com
To: CONTRACTORS NORTHWEST
Reference: MERIDIAN W WTP FERMENTATION DRUM SHED WIRING AND HEAT
TRACE
Proposal: A.M E. PROPOSAL #2014-132
A.M.E. Electric, Inc. is pleased to present this proposal for your review and consideration. Our
proposal is to provide and install electrical and heat trace for the new 55 gallon drum shed,and piping
to be located in an unclassified area
INCLUDED IN THIS PROPOSAL:
1. Provide and install one (1) 4' 24amp T-8 fluorescent strip light
2. Provide and install one (I) toggle switch to operate the light
3. Provide and install one (1) 20A, 120V, GFCI convenience receptacle
4. Provide and install heat trace for two (2) 1 %;' pipes from the shed to the bio tower
(approximately 20' runs)
5. Provide and install conduit, circuit, and wiring to feed the light, convenience receptacle, and heat
trace
COST AS DETAILED....................................................................... $2,980.00
LABOR.................................................................................................... $1,950A0
MATERIALS............................................................................................ $1,030.00
A.M.E. Electric, Inc. appreciates this opportunity and we strive to earn your future business. Should
you have any questions, or require any additional information please feel free to contact us.
Sincerely,
Jamie J. Winters
Urner; Eitlmaror
N�
CONTRACTORS
NORTHWEST, INC.
fin,
1-23-14
City of IVIeridian
Wastewater Division
3401 N. Ten Mile Road
tMeridian, ID. 83646
Project: Meridian Fermentation & Odor 0424845
RE: Request for Change Orders
ATT: Tracy Crane; Clint Dolsby
Contractors Northwest, Inc is pleased to provide a quotation for additional work for the
following:
COR # 25 Install ( l ) owner supplied 8" valve, and supply & install drain valve
assembly & additional flange adapters for valve at mechanical room. Add: $ 1,576.00
Please see attached scope of change for details on pricing for each of the above Change
' Order Requests. We appreciate the opportunity to provide proposals for this work.
submitted,
Duncan Goundry
Project Manager
Coeur d'Alene P.O. Bax 6300, Coeur d'Alene, to 83816.1938 // Phone: (208) 667-2456 // Fax. (208) 667-6388
Boise P.O. Box 190689, Boise, to 63719.0689 // Phone: (208) 362-9656 // Fax: (208) 362-9701
contractorsnorthwest.com 1 `
Idaho Contractors Regstrabon i RCE 1919 •• :
I Contractor. CONTRACTORS NORTHWEST, INC.
Project Meridien W WTP Fermentation & Odor control - project # 424845
Reference:
Scope of change: Change Order Request No. 25
Install (1 ) owner supplied valve and new drain valve on W diameter pipe 1/23/2014
9'40AM112312014
Page 1 Sheet3Change Order Request 25
Item #
Description
Quantity
Price
Unit
Coat
1
Fowler-(2)vldsullcedeptemll,draln-maledal
1.00
524.12
to
524.12
2
CNI-inatell valve, couplers 8 drain assembly -labor
8.00
45.00
HR
360.00
3
CNI- ilmovedInstall piping -labor
3.00
45.00
HR
135.00
4
lEolulpmerril,smalltools, gaakels.olherconeumablea
1.00
60.00
Is
60.00
5
0.00
6
0.00
7
0.00
8
0.00
9
0.00
10
0.00
11
0.00
12
0.00
0,00
0.00
0.00
Sales tax 6%
0.06
584.12
35.05
Project Manager
1.00
135.00
HR
86.00
Superintendent
2.00
80.00
HR
160.00
Clerical - office
1.00
40.00
HR
40.00
Labor -dean -up
0.00
32.00
HR
0.00
0.00
Sulkotal
1399.17
Overhead &Profit: CNI provlded ®10%
1.00
1399.17
0.10
139.92
Bond rate
1.00
1539.08
0.01500
23.09
UabAitylnsurance
1.00
1582.17
0.00550
8.59
Builders dsk insurance
1.00
1570.76
0.00350
5.50
Total
$1,676
9'40AM112312014
Page 1 Sheet3Change Order Request 25
Bid No: Q239208 Page 1 of 1
H.D. FOWLER
COMPANY
Customer: BIDDING CONTRACTORS Quote #: Q239208
Estimator: EMILEE DUNCAN Bid Date: 1/23/2014
Job Name: MERIDIAN WWTP DRAIN ASSY
Location: MERIDIAN ID
Line Qty UoM Description Unit Price Extended Price
1
2
EA
B" FUG CI SIZE VIC x341, M GASK, GROOVED
149.67
299.34
2
1
EA
9.05 X 1-1/2"113 SADDLE ROMAC 202 BODY ONLY
30.59
30.59
3
2
EA
9.80 5 S STRAP WITH NUTS FOR ROMAC SADDLE
29.35
58.70
4
1
EA
11/2" X 6" GALV NIPPLE,STO WT,A53 ERW
3.60
3.60
5
1
EA
1.1/2" BRASS BALLVALVE THREADED NO LEAD
30.88
30.88
6
1
EA
1-1/2" MALE CAMLOCK X MIPT ALUMINUM 15F
11.73
11.73
7
1
EA
1-1/2' CAMLOCK DUST CAP 20V ALUMINUM
19.28
19.28
Approximate Total
454.12
eS h irW
10.6a
4 524..tz
WORK CHANGE DIRECTIVE
No. 007
PROJECT: W WTP FERMENTATION AND ODOR CONTROL
DATE OF ISSUANCE: January6, 2014 EFFECTIVE DATE: January 6, 2014
OWNER: City of Meridian
Project No. 472317
CONTRACTOR: Contractors Northwest, Inc.
ENGINEER: CH2M HILL
You are directed to provide a price quotation for the following change(,):
Relocate 8" valve SMCB I-VAL-4001 and flow meter arrangement, including 8" x4" eccentric reducers, 4" spool
pieces, and flow meter PMT -003 on the VFA-Enriched pump discharge line. Install line drain valve and install 8"
V405 (provided by the W WTP) on the VFA-Enriched pump discharge line as shown on the attached plan redlines.
Purpose of Work Change Directive:
Provide for isolation of flowmeter for future maintenance.
' If a claim is made that the above change(s) have affected Contract Price or Contract Times any claim for a Change
- order based thereon will involve one or more of the following methods of determining the effect of the change(s).
Method of determining change in Contract Price:
Unit Prices
Lump Sum
Other
Estimated increase (decrease) in Contract Price:
If the change involves an increase, the estimated amount
is not to be exceeded without further authorization.
RECOMMEND by ENGNEER:
Method of determining change in Contract Times:
❑ Contractor's records
❑ Engineer's records
❑ Other
Estimated increase (decrease) in Contract Times:
Substantial Completion: 0 days; Ready
for final payment: 0 days. If the change
involves an increase, the estimated times are not to
be exceeded without further authorization.
By: By:
(Authorized Signature)
AUTHORIZED by OWNER:
(Authorized Signature)
cni�
g9XAC
GRTNWEHT ING.
1-23-14
City of Meridian
Wastewater Division
3401 N. Ten Mile Road
Meridian, ID. 83646
Project: Meridian Fermentation & Odor #424845
PL: Request for Change Orders
ATT: Tracy Crane; Clint Dolsby
Contractors Northwest, Inc is pleased to provide a quotation for additional work for the
following:
COR# 26 Insulate ( t ) exterior fermentation draft tube. Add: $ 1,679.00
Please see attached scope of change for details on pricing for each of the above Change
Order Requests, We appreciate the opportunity to provide proposals for this work.
Duncan Goundry
Project Manager
tied,
Coeur d'Alene P.O. Box 6300, Coeur d'Alene, ID 83816-1938 // Phone: (208) 667-2456 // Fax: (208) 667.6388
Boise P.O. Box 190689, Boise, ID 83719.0689 // Phone: (208) 362-9656 // Fax: (208) 362-9701
cantractoranorthwest.com 1aae
�
Idaho Contractors Regstragon 9 R& 1919 _
I Contractor CONTRACTORS NORTHWEST, INC.
Project Meridian WWTP Fermentation & Odor control - project #424845
Reference.
Scope of change:
Insulate (1) exterior fermentation draft tube
Change Order Request No. 26
1123/2014
9'57 A141112312014
Page 1
Sheet3Chengs Order Request 25
Item #
Description
Quantity
Price
Unit
Cost
1
Sub - Gala ContractorServloes
1,00
1205,00
Is
1205.00
2
0,00
3
0.00
4
0.00
5
0.00
6
0.00
7
0.00
8
0.00
9
0.00
10
0.00
11
0.00
12
0.00
0.00
0.00
0.00
Sales tax ® 6%
0.08
0.00
Project Manager
1.00
85.00
HR
85.00
Superintendent
2.00
80.00
HR
ISOM
Clerical - office
1.00
40.00
HR
40.00
Labor - clear-up
0.00
32.00
HR
0.00
0.00
Sub -total
1490.00
Overhead & Profit CNI provided @ 10%
1.00
1490.00
0.10
149.00
Bond rate
1.00
1639.00
0.01500
24.59
,Usbility Insurance
1.00
1663.59
0,00550
9.15
Builders nsk Insurance
1.00
1672.73
0.00350
5.85
Total
$1,679
9'57 A141112312014
Page 1
Sheet3Chengs Order Request 25
a
ibis agnamany Company is willing to famish to Customer all medal and labor required for
art not
within Company's Work unless specifically listed below,
OSE NOTICE. If cellulose is to be applied with a wat spray application, you must allow adequate done for it to cure and dry
italling drywall or other materials. The adequate lime required varies depending upon climate, aldlude and weather. Do not
pat barriers, vapor words, dry wall, or other interior finish until dw material has dried W less than 20% m0lstale content Time
Ill very based on climate and weather. Be pure to schedule your trade accordingly.
codes may require a thermal barrier or ignition bonier be applied to the spray applied foam insulation. A thermal barrier or
ender is not incl Wed within the stupe of this pgteemenr of work unlet sperl really listed below.
Work Arm Product Nato
DRAFTTUBE 2'PIPE&TANK WRAP W/AS749'X 29
.016 ALUMINIUM JACKETING 36'X 100' SMOOTH
____;>___---_____.._... ..
Use Price: S1105.00 _ - - Additional Information:
options
TANKSEAL R-11. 3.5 NOMINAL INCHES CLOSED CELL FOAM
NOW: SPRAY FOAM INSTALLEDAROUND
TOP PERIMETER CHANNEL OF TANK
t]J
. TO SEAL THE ATTACHED LID
-------- 7 ------
-----------
NOTE: This agreemenr consists of multiple pages. If you do not receive the number of pages noted below, please contact Company
directly at the telephone number sated above.
PRICING! The
CLSTDMER:
9y
SIGNATURE 'TITLE
eninwm¢sadlwofmyprym la Voorna you hart mmdot
aw IhSavrtemenl 11 CampmY deer nd I[Ria raianmN ieueume
I who mM- Quuon4,har,q mon, huh„ Pores U, Mn.
neat undo. A., ryrzimwl
COMPANY
8v
SIGNATURE TITLE
Can,, %arae Dare
THE INFORMATION CONTAINED IN THIS AGREEMENT IS CONFIDENTIAL. NEITHER THIS ,ACREEMENTNOR ITS
TERMS NAY BE DISCLOSED TO THIRD PARTIES.
230
1.
Gale Contractor Services -
P
Lle 8: RCE -906 (Ideho)l CCB -113363 (Oregon)
5
2908 Brandt Ave Nampa, ID 83687-6856
i� II �p
Tel: (708) 465-5201, Fu: (208) 465-0773
•g.�9
WORK AGREEMENT
TO: CONTRACTORTN0RTUWnST
Rg:MERIDL4YwWIFTANUIINS11LATION
Addreu: I0940,v EXEMIVE DRIVE
Job Addrea: 3401 N 10 MILE ROAD nerwEEN OsncK A MnCREL
110ISE,m0A13
MERIDIAN. ID
Ana:
oam 0ly^J30W
Espinhlas Dale ON+J++-0W
70,11011363-9036
Fu:
Eaivaar. vmlcata LuryD
Ouaa1_095101 Vaalea lOT1
ibis agnamany Company is willing to famish to Customer all medal and labor required for
art not
within Company's Work unless specifically listed below,
OSE NOTICE. If cellulose is to be applied with a wat spray application, you must allow adequate done for it to cure and dry
italling drywall or other materials. The adequate lime required varies depending upon climate, aldlude and weather. Do not
pat barriers, vapor words, dry wall, or other interior finish until dw material has dried W less than 20% m0lstale content Time
Ill very based on climate and weather. Be pure to schedule your trade accordingly.
codes may require a thermal barrier or ignition bonier be applied to the spray applied foam insulation. A thermal barrier or
ender is not incl Wed within the stupe of this pgteemenr of work unlet sperl really listed below.
Work Arm Product Nato
DRAFTTUBE 2'PIPE&TANK WRAP W/AS749'X 29
.016 ALUMINIUM JACKETING 36'X 100' SMOOTH
____;>___---_____.._... ..
Use Price: S1105.00 _ - - Additional Information:
options
TANKSEAL R-11. 3.5 NOMINAL INCHES CLOSED CELL FOAM
NOW: SPRAY FOAM INSTALLEDAROUND
TOP PERIMETER CHANNEL OF TANK
t]J
. TO SEAL THE ATTACHED LID
-------- 7 ------
-----------
NOTE: This agreemenr consists of multiple pages. If you do not receive the number of pages noted below, please contact Company
directly at the telephone number sated above.
PRICING! The
CLSTDMER:
9y
SIGNATURE 'TITLE
eninwm¢sadlwofmyprym la Voorna you hart mmdot
aw IhSavrtemenl 11 CampmY deer nd I[Ria raianmN ieueume
I who mM- Quuon4,har,q mon, huh„ Pores U, Mn.
neat undo. A., ryrzimwl
COMPANY
8v
SIGNATURE TITLE
Can,, %arae Dare
THE INFORMATION CONTAINED IN THIS AGREEMENT IS CONFIDENTIAL. NEITHER THIS ,ACREEMENTNOR ITS
TERMS NAY BE DISCLOSED TO THIRD PARTIES.
230
1.
Bid Summary
Quote d Plan Trade Total
2095101 Version I Of I INSULATION $1,205.00
Pricer Good For Work Perfarmed Tbmagh: April 22, 2014 Taut Bid: 51,205.00
Bid ealc Jammy 22, 2014
Gale Conlcoclor Servicer
t�
LIc P: RCE•90d (Idaho); CCB -113362 (Oregon)
56
8346740/13
Tel: 209)46 Ave01.I=:
Se)
2
Tel: (208) 465-520 1. Fax: (2119) 9fi5A773
WORK AGREEMENT
M. Coirm%cm"3011THWFSF
Rg WRIDIAN WW(P*ANKS I D(5ULA21ON
Ja4 Addmn 3401 N ID SULE ROAD BEIWEEH USf1OLG 64ITCM
Mdmn 10140 • EXECUTIVE DRIVg
11FJUDIAN.no
0015141D0371)
Aum
D.W 01/»11014 BapINUo)DHn ON12/]019
Td: (NO)362-905b
gpimamn Vwhkk WyO
Fu:
Bid Summary
Quote d Plan Trade Total
2095101 Version I Of I INSULATION $1,205.00
Pricer Good For Work Perfarmed Tbmagh: April 22, 2014 Taut Bid: 51,205.00
Bid ealc Jammy 22, 2014
ACCEPTANCE.
2.
NI
a
1 nes
OF
anal. wail to yen uee.pr
fir one year firm the dam
United wrramy does Rt over statuettes o oft m (O uCidM% inqume .1 R`SIM or nmmn wear and Iter. (b) /whim m um or mmwn em ptv¢u r In
awotdaneewith nrenof eves imduetlolii aM (a)dmadun repilrw tt4sisped repair by myaR ober dim Caepmy err ire amhorimlrePreseamdye, Youshalbe
solely responsible for the canermem M the plum and m aeutmeamm and sw Blase and hold hamlet Campmy Rom any dehugn Inultfg'Rmn Improper,
Imdapae m ague Inrmtnaift aupDllhd by you. Cwnpmy dent eke on my dllgul-n m impn orevd •^••Ian wash afousee peones In my mama m open
ThisNSUR rsaml. Conrad,
1. INSURANCE. eimP�nr shat murrain aorlms' eompwaefion (anpfym Iiab1110'I, u tequimed by Iso. dad 51.000.000 m ge^a^I.IIeGEay Imutma while
pcRotmiog the umY. CatW^Y raervn dee fight m be uifinmued m Ian amu alowcd by vPPltnble law. CaopanY ureses Pw age m onnm mY odta peteannor
4. LIMITATION
arid OF
R
a. LIMITATION OF REMEDIES. Yaa wlh and aelbyC remedy t co Company for my ye rt eluw'fir nod,
she boat Dfm case w such
adwt w[ be Wank wilt 6e IMited m die tepiirmlepkumem by Cafpat6'. a Capponyl opfivA eranYRmdfoimfg wak or m du lsvuceors creat far such
nonwnfomiing woh f uwNence with dwu amdt and ewdldom powded CompenY k giro a toulmble wPmadiry m ftpect the wok and onRmu rich
n-ncwfoemlty. Thk
nanwnfarmi¢ work add�I. my Co nRteMr bs emadmam m OebHvllery IWfnkdtearrdamme nsdilpl be olimited
W.I. coCWmnpteonwy i[s aid.B Cooper, fmm rths,Worris tendo the
under shat
agramenL This Lindell or Retalles shun "I apply to Em psrein an We agteanea u well as m One ounal ulnad
sumewa sod anigne, If you sues...Wm for dumge, by my owrar srising m -for dleged an mvestfapt out ofde I
Ca mom of the eWm and provide Company an Opportunity impem rho dlagdd damsga within 10 do ager Cmpmys n
MOM sad. aWm fall an alba Com uay m uppameiry x impns de. iii., damsga with. 10 days, yes lardy wail
Rc
codwofwadtq"Cmpmy.This LimiiagweorR edianmybep1aW useomrylsbhammy xdo to viakdonl
S. LIMITATIONS ON ACTIONS AND LIABILITY. All chime andur kawlm alluding but we lmdledat
BE LIABLE
FOR GNYLOS,DAodes thisu INJURY
Ruebemade FROM
II monde Rom Endue DELIVERY
THE ofsh
BE LLARM FOR ANY LOSS, DAMAGE OR IN CES BEYOND IT FROM RELAY IN COMPANY
DI OF THE PRO
PERFORM THAT IS IGH TO CIRCUMSTANCES BEYOND ITS CONTROL COMPANY IC TO DISCLAIMS AL1
DAMAGE WHICH MIGHT RE SRSTABiED BY ANY PERSON WHO MAY BE ALLERGIC i0 OR AFF!
LT' FOR ANY AND ALL
BY THE EMANATION OF
PIIIIPOSL
6, PRICES, TERMS AND SHIPMENT. No ash&sevam,psd clwgeu ha offs irsvlmmmkims ate dlawed wlasspsified by Campmy. in addivw
m to prim spelfisd. you W.I. Fetzer fid", trae or kcd aurae. ume, aWpdonal, msnda m mw In forte or mbe cueud io Ian 0mve, aseud agaWa
ConNmY myau byrman a[thm aenmalon No reTnfiwhpe+mhad wlmsCRlpanY+gtenoAawim in wrifing. AnYyeedn RYmmEuillhe.uCmnpenYs
opdom subject aiarmilat5%pn mom(11%pmsmuml mtbeumapeamimudby law, You at= mte¢!ve(mpmnll Company kaceivhl mm dm wa lm
You
E. CONFIDENTIALITY. Ifyou visitcwrpmya pmnkeocyou odoawiu tredve my peopinay ermnftdmdd infomudw bars Campnr.yawWll natio
wash (allowed can u co attended and tet uses or drachm, It an my did Perry aithsd CampmYm art= assume.
9. CREDIT APPROVAL. SNpmw[ and ddivay of Bawds aM p:doRena of wary mol u W ebrms be mbdm m the rpptvvd err Compmys sredim
d:pu-umhind CampsnY mY u anYEan deelMe m maim mY tF•ptmmardellw0• m � tet my avhanptupoa taeipt afpeYmmlor upon vans mdmditlom
10. CANCELLATION.
TION. Thi B eraloo t. my plus you m y u,d CompmY mebad clurpony, mwsama
IB. CANCEL(ATeraC This agtwnmh m my pre of M1 may wait' I. esmdmd waters [ompuyt when approval. to 0e mot of <undiadao of suis
agmanmLmmY PuldnmLyvu shill pY:U)dm onimtpNceofml mmplercd lmlde:@I Uwl pomanafEo olwatpda lhetkquJmdu hgrm nfeom euro.
or tet R wmB In protta. ... w tU dem CompOr- taatm mda.gudies-",re (d the on of W. m es; ad and my. la which EmtIPNy I hove
IWa:WdWmd m d loam and ahtdt atm o 1, oftY mild ha un o far a0a m Orr0re RRaer, (d) a h. h pat a fa: and (el my apnwt Iaurmd by Campmy
1lmludlttg legdf mdJWgmmtlaaradaardm Mnllado ofsubLonmuamRtsOaa rela�mthk aDeanem
IL DEFAULT, Ywmryav Wmmhisgrwnotfor Compmy'sdefult.whORymmya byglvingcm"ywdnenmda.rlm Mena6n.w. Yau
may give a mina =on or temtimdw only If eaRmY bee radved a areas mon hors you spoelf ing surh ddadc do dehde Is at nmuble unEer my
doomed a tleRdt fir purposes of tertttwnan. In the event of Immmdao fm defads fa than bes rtllewd of da obligarmn to pat, for weds at pedomted by
Compay pries m Em eRecfiva darn of fmh termtmdw. A ddbdt a Company's pan slWl not mbJm Company to liability. duou th pymmsby Company. sn oRar
athwAmrarmyothadstmgeuwhMerdlrcgcomqumualarmcldeoW,Wwhedeisoughtwdadoarinofaa immm
12, ASSIGNMENT. Yo may nor anlp lhk agteanm or my dam apse Company rckhng r -this agrtmtmn
Il. GOVERNMGLAW. Two yrtmRrit shill be summed. ammdand im nights of the penia dmamud In noNaue with the kw of the Savor
Campmymedthasnmiii dmdmhmiarthlsaBreanent
Id. DISPUTES AND MANDATORY MEDIATION. f ole amt dm a dhpue arises ova the teamnablenm of a enddwma m fm charged by
cempnY. Ito CMIng pang mll he mmlN m roaombla mnmeys fas and mus [nil olhesdbplRs ofmY tenors, exh prey Ibdl pay to aw rm and cam
Ealeptm(glt mpmmn onRamrW mfatmAdw andmdmf puhtuauy tnjunceve rtbefm Prevmtlmpa+bla Aum, you andthe Campmy agtm lha pnnm
Im Initiation of my begil actiondw penia all casesin fcAnatsve owdfatmafmy ad At disputer loony way related to lhuafirealm, Ifthepudamnotsgra
upon a fullltuive mvdim er with. 10 days of ohm the dispute one, as will be alatd pram, m the Camtemkl Mutilation Rules of dm Amednn ArfRuan
Alsodatlan. FYh parry tell IM1w gmlly tlm fm afthe fxlloanve mdiamrmd test ofdmmediadw.
13. INSULATION DOES NOT PREVENT FROZEN PIPES. Imukang mated ester Iola in m annul dmwd Or semi conditioned are. will me
Items pulpa from Rearing or neon mlmttg modavaium To demmm dm pumbthry of M1mm pipes, loam any won pipet whhln s omgdomd ares Web u
mtemd walls miter thenewnnal walls tryout do not tome the pip" mlhm m Internet wall. you how Claps" mrmlems ad Neve Canpmy gam my dorsa
16. SEVERABILITY. SEVERABILITY. Ifmy pmcutnwdus sgteemmtsOut mfartmple. thus pmwmn shill be ettadve,nlY'a tan m:ea pwkedNlew wJ dl other
prunwas or.ho,. dullraven,
17, ENTIREAGREEMENT
Thur l Ily by. eamm.a rte omus, pang mt o the paten ommo m the abject mem mmir+al my aniv be calved.
I:utasd.ismotevL enendN errnd zoreTNnt ortbyawrung ugnell Syrhe putt'eYamtwhom 4-'a moms or my musM1 waiver. aharya mudidmtion. ntenaona
I S. I'N Esmghe The term{and;mua fa"gragreementapndemysdtemmui whlrhdiswaded
13.INDEMNITY, F sh o(qe penin ta:fugrmam+gras:o defend and tmlemntfyane nloAardom mV and dl:!eims xfims mdrr Wwluiu;msed by the
pdlgemxturumtvuum.Thu,ndemntrychuu d$euhtgmua:m redicrcmthdlcunmlmJrdrcpdad uvermYaroma idmni ogknem
manmed cdomm pour tmiupamenu F•snhewltre. Nlvindmwlry.Ivum mJ ole obllgenum mrN neteln shall wood eM the ydaria avermymnmryindemmty
hyrtummt enured anti muhsgtwm m:hw aytevn<m unlal Ihe;ubsryums eyeement Ipemgeally refnc .o Ihuindemnlry:Suu roil Jce';ern i1 null wJ vmd
11=
I Contractor: CONTRACTORS NORTHWEST, INC.
Project: Meridian W WTP Fermentation & Odor control - project # 424845
Reference:
Scope of change:
Foam spray new roof on fermentation lank.
Change Order Request No: 27
21612014
11:29 AM21612014 Page 1 Sheet3Change Order Request 27
Item #
Desorption
quantity
Price
Unit
Cost
1
Sub- Gale Contractor Services - foam new roof
1.00
6878.00
Is
6878.00
2
Sub- Gale Contractor Services- foam in trough at perimeter
1.00
406.00
Is
406.00
3
scaffolding
1.00
124.00
Is
124.00
4
equipment - forklift
2.00
105.00
day
210.00
5
CNI - clean trough prior to spray
4.00
1 45.00
HR
180.00
6
0.00
7
0.00
8
0.00
9
0.00
10
0.00
11
1
0.00
12
0.00
O.00
0.00
O.oO
Sales tax Q 6%
0.06
530.00
31.80
Project Manager
1.00
1 85.00
HR
1 85.00
Superintendent
4.00
80.00
HR
320.00
Clerical - office
1.00
40.00
HR
40.00
Labor - clean-up
0.00
32.00
HR
0.00
0.00
Sub -total
8274.80
Overhead & Profit: CNI provided Q 10%
1.00
8274.60
0.10
827.48
Bond rate
1.00
9102.28
0.01500
136.53
Liability Insurance
1.00
9238.81
0.00550
50.81
Builders risk insurance
1.00
9289.63
0.00350
32.51
Total
$9,322
11:29 AM21612014 Page 1 Sheet3Change Order Request 27
Subject to the leans and conditions stated in this agreement, Company is willing to furnish to Customer all material and labor required for
the Seem of Work described below:
or
(LOSE NOTICE. If cellulase Ism be applied With A wet spray application, you must allow adequate time for life cure and dry
installing drywall or other materials. The adequate time required varies depending upon climate, altitude and weather. Do not
,spar barriers, vapor retards, dry wall, or other interior finish until the material has dried to less than 201/6 moisture content. Time
will vary based on climate and weather. He sure to schedule your trades accordingly.
ig codes may require a thermal harrier or ignition barrier be applied to the spray applied ream insulation. A Ihennal barrier or
t bamicr I$ not included within the scope of this agreement of work unless specifically listed below.
Trade: INSULATION
Work Area Praduel Note$
ORAFTTUBE 2"PIPE& TANK WRAP Wl ASJ 43-x26'
.016 ALUMNUMJACKETINO Jfi'X 100'.SMOOTH __ -
Base Price: $1,205.00 ' — � � � � - _ _ Addltlonel lnformalion: . .
ANK SEAL R-172.5 NOMINAL INCHES CLOSED CELL FOAM
Notes: SPRAY FOAM INSTALLED AROUND
TOP PERIMETER CHANNEL OF TANK
TO SEAL THE ATTACHED LID
BAYBLOCK 700 ACRYLIC COATING
+5406,00
'IPING . - . , ... ` t,5 %P FIBERGLASS PIPE INSULATION' _
.016 ALUMINUM IACKETING CUT & ROLLED 1.5 K 2
NOTE: This agreement consists ofmultiple pages. If you donor receive rhe number ofpages noted below, please contact Company
directly az the telephone number stated above.
TERMS OF PAYMENT P,Ym.mm
ACCEPTANCE1 Company may oho
PRICING: mePst.�Y Jamlln:hn A;
sans m Par C,ntwnya nen.vn a
ask IDmmw�ninJ �m1aJe mY+ndA dl n
C_5TO31EA. CUMIANY
3, ...�_
SIGNATURE TILE-� SIGNATURE TITLE
^.xnpvy X u:x
bens.
THE INFORMATION CONTAINED IN THIS AGREEMENT iS CONFIDENTIAL. NEITHER THIS AGREEMENTNOK ITS
TERNIS MAY BE DISCLOSED TO THIRD PARTIES
?YJ
Gale Contractor Services
Llc N: RCE -906 (Idaho); CC" 13362 (Oregon)
2908 Brandt Ave Nampa, ID 87687.6856
{N11,0
Cunlaxwr
(V=)�"
Tel: (208)465-5201, Fax: (208) 465-0777
Services
WORKAGREEMENT
TO: CONTR\CTORSYORTHWEST
RE: MERIDIAN WWTP TANKS M. SUlAT10N
Job Addreut 34DI N 10 MILE ROAD BETWEEN CSTICK & MITCIIEL
Addle: 10340 w. EXECUTIVE DRIVE
MEMDIAN.ID
9mSE, ID317D
Alm,
Dme:01r'rr201J Espinton Oel¢Oaa?9201J
Td, 12031362.9056
Estimator. Vamiekle. Larry D Quote 0 209510 Vaaaton IOf 1
Pae
Subject to the leans and conditions stated in this agreement, Company is willing to furnish to Customer all material and labor required for
the Seem of Work described below:
or
(LOSE NOTICE. If cellulase Ism be applied With A wet spray application, you must allow adequate time for life cure and dry
installing drywall or other materials. The adequate time required varies depending upon climate, altitude and weather. Do not
,spar barriers, vapor retards, dry wall, or other interior finish until the material has dried to less than 201/6 moisture content. Time
will vary based on climate and weather. He sure to schedule your trades accordingly.
ig codes may require a thermal harrier or ignition barrier be applied to the spray applied ream insulation. A Ihennal barrier or
t bamicr I$ not included within the scope of this agreement of work unless specifically listed below.
Trade: INSULATION
Work Area Praduel Note$
ORAFTTUBE 2"PIPE& TANK WRAP Wl ASJ 43-x26'
.016 ALUMNUMJACKETINO Jfi'X 100'.SMOOTH __ -
Base Price: $1,205.00 ' — � � � � - _ _ Addltlonel lnformalion: . .
ANK SEAL R-172.5 NOMINAL INCHES CLOSED CELL FOAM
Notes: SPRAY FOAM INSTALLED AROUND
TOP PERIMETER CHANNEL OF TANK
TO SEAL THE ATTACHED LID
BAYBLOCK 700 ACRYLIC COATING
+5406,00
'IPING . - . , ... ` t,5 %P FIBERGLASS PIPE INSULATION' _
.016 ALUMINUM IACKETING CUT & ROLLED 1.5 K 2
NOTE: This agreement consists ofmultiple pages. If you donor receive rhe number ofpages noted below, please contact Company
directly az the telephone number stated above.
TERMS OF PAYMENT P,Ym.mm
ACCEPTANCE1 Company may oho
PRICING: mePst.�Y Jamlln:hn A;
sans m Par C,ntwnya nen.vn a
ask IDmmw�ninJ �m1aJe mY+ndA dl n
C_5TO31EA. CUMIANY
3, ...�_
SIGNATURE TILE-� SIGNATURE TITLE
^.xnpvy X u:x
bens.
THE INFORMATION CONTAINED IN THIS AGREEMENT iS CONFIDENTIAL. NEITHER THIS AGREEMENTNOK ITS
TERNIS MAY BE DISCLOSED TO THIRD PARTIES
?YJ
Subject to the terms and conditions stated in this agreement, Company is willing to furnish to Customer all material and labor required for
the Scope of Work described below:
Until: scop, ilia block, tiro stop (unC 7116.2.1 01 seq., lonnerly 2516(q, of locally- 'g0yl equivalent), and fire rated caulking are not
included within Company's Work unless specifically listed below, - 'S
CELLULOSE NOTICE. Ifccllulose is 10 be applied with a wet spray appli o _ must allow adequmc time for it to cure and dry
before installing drywall or other materials. The adequate time required 'd N
limate, attitude and weather. Do not
install veporhorricrs, vapor retards, dry wall, ar other interior finish anti t atcrlolcss Ihon 20°/. moistarc content Timc
la cure will vary based on climate and wemher. Besureloschcdulc d d ccordBuilding codes may require a thermal baffler or ignition barri applied to the sp11 [[qqem insulalian. A Ihcrmal bonier ar
ignition barrier is not Included within abc scope of this agree fwork unless speciJI- W.
NG-,_--._._-_
Price: 56.878.1
NOTE: This ngmementeonsists of multiple pages. If you do not receive the number of pages noted below, please contact Company
directly at die telephone number stated above.
TERMS OF PAYMENT: P,, In full due us smlN nn Intake wraNlus ofenyymnMamnymwnuyuu M1aw rvi,h IhiN panics.
ACCEPTANCE: Company mey uhangc roxYx i,hdmw ad,asn:nmw RCnwpany Joe, net make yvurdp,W=Mana on or sroe do Eapfmdwr Dow saalN AMre.
PRICING+TM1.p,nv nand ln,hk Aan•nwnr o'lllrcmsin 0nn for9a Jan aarr,AA Oat awwl abort. Ifwrf � re of,hi3hamememmrcnd.MwnJ dti, Jn.l�. ue6W r
rills ryn m •Anna stand.• any Awt All Adewdwna. amahmmu, UbdUks ar aMbiu atlad,N lees, "Bw Pfk vnrduJr any And Oil wmw+nd mnJillan, nmdptuly sknd
eosin imluJlna,vult., IlmOalen. any Abli'd.. bYCAnwAnY In mmu you umA,dkA ,.A.Adiaond io,umd un in, tnfuranac sulky: wpmviduperpmjm aygrryuw
mripr fm ae• lYork:,opankllwk to any Arvvu:anwllN. crap, orfbnibrimumucpmamnAra inJomnify w deYrnJ ymnr any IM1iNpmY awnany daMn.
wlnm an,h�u laoxulunfmry tlnJ ur nuwewhaso waren...... rhe Ilmind a,dnnmle in AAOrMn axn06k iy mnrnl. AnY remsur eunPubuna nyuhN br5nu by snuxl ur
.nhamlm In 1k iann w ry Iwvnsluenr .hit rh,t2 uTrlsely slaved Imhb Ay.n., alit nauh In adaidmnl ah'aryes a„ "r hasher Pring. Any sddiltual it pno.s l Is
sublee, m C"l.Ys @.'Arrant Viking lunhv, Cnmpmy mEmoim agn+•s in rditl Ou m Ihls rylremenl.
CUSTOMER: COMPAM
By: ....... ..... _---"-. B,r.-- "—"
SIGNATURE TITLE. SIGNATURE TITLE
CJA1p., yNorm Bali:
THE INFORMATION CONTAINED IN THIS AGREEMENT IS CONFIDENTIAL. NEITHER THIS AGREEMENT NOR ITS
TERMS MAY BE DISCLOSED TO THIRD PARTIES.
2af3
Gale Contractor Services
Lle#: RCE -906 (Idaho); CCB -113362 (Oregon)
Awa
2908 Brandt Ave Nampa, ID 83687-6856
Conlydr1ar
Tel: (208)465-5201, Fax: (2081465-0773
Services
WORK AGREEMENT
TO: CONTRACTORSNORTUIVEST
RE:NER101ANW `r TANK ROOF? INSULATION
Addrnu 10940w. EKECU7IVE DRIVE
Job Address: 3401 N TENMILE RD MERIDIAN, ID
BOISE. ID 83713
Alto:
Dere:mi3113014
Rfpinllan Dle:05A)In9I4
Tel-In")361-9056
Quote 9:2107072 version l of
Fal
Esmrul.r: Wnskklk Lowy D
Subject to the terms and conditions stated in this agreement, Company is willing to furnish to Customer all material and labor required for
the Scope of Work described below:
Until: scop, ilia block, tiro stop (unC 7116.2.1 01 seq., lonnerly 2516(q, of locally- 'g0yl equivalent), and fire rated caulking are not
included within Company's Work unless specifically listed below, - 'S
CELLULOSE NOTICE. Ifccllulose is 10 be applied with a wet spray appli o _ must allow adequmc time for it to cure and dry
before installing drywall or other materials. The adequate time required 'd N
limate, attitude and weather. Do not
install veporhorricrs, vapor retards, dry wall, ar other interior finish anti t atcrlolcss Ihon 20°/. moistarc content Timc
la cure will vary based on climate and wemher. Besureloschcdulc d d ccordBuilding codes may require a thermal baffler or ignition barri applied to the sp11 [[qqem insulalian. A Ihcrmal bonier ar
ignition barrier is not Included within abc scope of this agree fwork unless speciJI- W.
NG-,_--._._-_
Price: 56.878.1
NOTE: This ngmementeonsists of multiple pages. If you do not receive the number of pages noted below, please contact Company
directly at die telephone number stated above.
TERMS OF PAYMENT: P,, In full due us smlN nn Intake wraNlus ofenyymnMamnymwnuyuu M1aw rvi,h IhiN panics.
ACCEPTANCE: Company mey uhangc roxYx i,hdmw ad,asn:nmw RCnwpany Joe, net make yvurdp,W=Mana on or sroe do Eapfmdwr Dow saalN AMre.
PRICING+TM1.p,nv nand ln,hk Aan•nwnr o'lllrcmsin 0nn for9a Jan aarr,AA Oat awwl abort. Ifwrf � re of,hi3hamememmrcnd.MwnJ dti, Jn.l�. ue6W r
rills ryn m •Anna stand.• any Awt All Adewdwna. amahmmu, UbdUks ar aMbiu atlad,N lees, "Bw Pfk vnrduJr any And Oil wmw+nd mnJillan, nmdptuly sknd
eosin imluJlna,vult., IlmOalen. any Abli'd.. bYCAnwAnY In mmu you umA,dkA ,.A.Adiaond io,umd un in, tnfuranac sulky: wpmviduperpmjm aygrryuw
mripr fm ae• lYork:,opankllwk to any Arvvu:anwllN. crap, orfbnibrimumucpmamnAra inJomnify w deYrnJ ymnr any IM1iNpmY awnany daMn.
wlnm an,h�u laoxulunfmry tlnJ ur nuwewhaso waren...... rhe Ilmind a,dnnmle in AAOrMn axn06k iy mnrnl. AnY remsur eunPubuna nyuhN br5nu by snuxl ur
.nhamlm In 1k iann w ry Iwvnsluenr .hit rh,t2 uTrlsely slaved Imhb Ay.n., alit nauh In adaidmnl ah'aryes a„ "r hasher Pring. Any sddiltual it pno.s l Is
sublee, m C"l.Ys @.'Arrant Viking lunhv, Cnmpmy mEmoim agn+•s in rditl Ou m Ihls rylremenl.
CUSTOMER: COMPAM
By: ....... ..... _---"-. B,r.-- "—"
SIGNATURE TITLE. SIGNATURE TITLE
CJA1p., yNorm Bali:
THE INFORMATION CONTAINED IN THIS AGREEMENT IS CONFIDENTIAL. NEITHER THIS AGREEMENT NOR ITS
TERMS MAY BE DISCLOSED TO THIRD PARTIES.
2af3
Bid Summary
Plan
2107072 Version I Of I INSULATION 56,878.00
Prices Goad For Work Performed Through: May 01, 2014 Total Bid: $6,878.00
Bid Dale: January 31,2014 AK
700
Gale Contractor Servicer
Lie N: RCE -906 (Idaho); CCB -111362 (Oregon)
34ECU
2908 Brandt Ave Nampo, ID 81687-6856
�� ia,
Tel:(208)465-5201, Fax: (208) 465-0771
WORK AGREEMENT
TO: CONTRACTORS NORTHWEST
RE: MERIDIAN WWTP TANK ROOFI INSULATION
Add,.,: 10840w. EXECUTIVE DRIVE
Jab Addna: 7401 N TEN MILE RD MERIDIAN. ID
OOISE, ID 81713
Allo:
0a1r. O1,31014 E,Irulaa Daly. OSMIPA14
Ld;l (101)362.9056
Far.
EIIImwoD VansIckh%Lwry D
Bid Summary
Plan
2107072 Version I Of I INSULATION 56,878.00
Prices Goad For Work Performed Through: May 01, 2014 Total Bid: $6,878.00
Bid Dale: January 31,2014 AK
700
2-6-14
City of Meridian
Wastewater Division
3401 N. Ten Mile Road
Meridian, ID. 83646
Project: Meridian Fermentation & Odor #424845
RE: Request for Change Orders
ATT: Clint Dolsby
CNS
CONTRACTORS
NORTHWEST INC.
Contractors Northwest, Inc is pleased to provide a quotation for additional work for the
following:
COR # 28 Extension of project schedule from original date of 5-5-14 to new
completion date of 6-9-14. No Charge : $ 0.00
Please see attached scope of change for details on pricing for each of the above Change
Order Requests. We appreciate the opportunity to provide proposals for this work.
Respectfully submitted,
Duncan Goundry
Project Manager
Coeur d'Alene P.O. Box 6300, Coeur d'Alene, ID 83816-1936 // Phone: (208) 667-2456 // Fax: (208) 667-6388
Bolsa P.O. Box 190689, Boise, ID 83719-0689 // Phone: (208) 362-9656 // Fax: (208) 362-9701 ��� �`�
contractorenorthwest. cam
Idaho Contractors Registratlan M RCE 1919
Contractor; CONTRACTORS NORTHWEST, INC.
Project: Meridian W WTP Fermentation & Odor control - project # 424845
Reference:
Scope of change: Change Order Request No: 28
Project time extension from original completion date of 5-5-14 to 216/2014
new completion date of 6-9-14.
11 23 AM2/612014
Page 1 Sheet3Change Order Request 28
Item #
Description
Quantity
Price
Unit
Cast
1
Time extension of completion date
1.00
0.00
Is
0.00
2
0.00
3
0.00
4
0.00
5
0.00
6
0.00
7
0.00
8
0.00
9
0.00
10
0.00
1
11
0.00
12
0.00
0.00
0.00
0.00
Sales tax @ 6%
0.06
0.00
0.00
Project Manager
0.00
1 85.00
HR
0.00
Superintendent
0.00
80.00
HR
0.00
Clerical - office
_ 0.00
40.00
HR
0.00
Labor - clean-up
0.00
32.00
HR
0.00
0.00
Sub -total
0.00
Overhead & Profit CNI provided @ 10%
1.00
0.00
0.10
0.00
Bond rate
1.00
0.00
0.01500
0.00
Liability Insurance
1.00
0.00
0.00550
0.00
Builders risk insurance
1.00
0.00
0.00350
0.00
Total
$0
11 23 AM2/612014
Page 1 Sheet3Change Order Request 28
Bid Summary
Quote 8 Plan Trade Total
2095101 Version I Of I INSULATION $1,205.00
Priced Good For Work Performed Through: April 22, 2014
Did Date: January 22, 2014
I If
Total Bid. 51,205,00
Gate Contractor Services
Lie 0: RCE -906 (Idaho); CCR -1!3362 (Oregon)
2908 Brandt Ave Nampa, ID 83687-6856
NMI)
Conlraclor
Tel: (208) 4655201, Fax: (208) 465-0773
�I�
WORK AGREEMENT
TO: CONTR%CfORS NORTBWEST
BE: MERIDIAN WIMP TANKS I INSULATION
Address 10840 w. EXECUTIVE DRIVE
Jab Address: 3401 N 10 MILE ROAD BETWEEN USTICK & MITCNBL
BOISE, ID 83713
MERIDIAN, m
Ana:
Date: OIPM014 ExpInIka Date: 04PJ-014
Te6 (208)361-9056
Estisoxbr: Vanskkla, Levy D
Rax:
Bid Summary
Quote 8 Plan Trade Total
2095101 Version I Of I INSULATION $1,205.00
Priced Good For Work Performed Through: April 22, 2014
Did Date: January 22, 2014
I If
Total Bid. 51,205,00
aThis in., diffam. fressdie.cdmanu made
addition ro or diRertm from thou mnmincd herein
uunnd to all terms and conditions contained M1emin irony pan ofthe product arwone described noon are pmwdm or
h: Limited Wmmry. Limimtian ofRcmediu end Limitatlom on Actions and Uabiliry provisions setfoNr below. You
c based on the enfa¢mbiliry oftheu terms and canditions. and on On Limited Wamrnry. Limitation of Remedies and Limimnm
claw. goodie price would be Wmar ully higher ilCompury could not limit its liability as herein provided, and that you accept
2, LIMITED WARRANTY. All work performed by Company is w nWd to be ace from dance¢ in mated.] and workmanship far one year ft. the dem of
completion of the installation subject to die terms below. Company makes no warranties regarding mandate; sold bur assigns to you any mmufaztur¢ wamndes
relating on the product, THIS EXPRESS WARRANTY IS IN LIEU OF AND EXCLUDES ALL OTHER WARRANTIES, WHETHER EXPRESSED,
IMPLIED OR STATUTORY, INCLUDING IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FORA PARTICULAR PURPOSE. This
limited waremry does not cover dmanges minting . (al azeidmt. mise. ehme, region. or ramal wear and tar. Hd failure a. uta m maintain die produW in
azcmdmce witheto, thnr. inswuwu: ands and
it
repairby myope WarrthenCompany or its my damages
rendndve,Youshell be
mlely responsible for the coememess of the plans and spenlm na[s .nth shall mi lig and hold ct oro Company ham any damage resulting bora improper,
in i, mato or vague In tirmabon supplied by you. Company does not wkc on any abliguion oo impea ormalmu rhe work ¢father pmies in any manner or aspect.
This wamnry is tat mnumble.
3. INSURANCE. Company shall maintain workers compensation (emplimer liability], W required by Was. and S1.000,000 in general Ianiny Imuran¢ while
performing the work Company reserves the right m be self insured m the .mm allowed by applicable law. Company dues Rod agree to mare my other persons or
mid, ostddili...I insureds.
A. LIMITATION OF REMEDIES, Your sole and .elusive remedy attains, Company for my and .11 claims for damages arising on, of ey alleged to have
arisen our the Work will W limited .,he repair or mphcemcm by Company, at Company's optimn, of my nommnkmming work or to the Issuance of. credit for such
nanconfoming work in simulative with these turns and conditions provided Company is given a reammble oppommiry to impar the .,it and mnfims such
mnconfomiry.
nil .clusi a rcmdy shall not be deemed to have haled mf m csamami pmpow, an long as Company is willing and able to repair or m,1.. the
nonconforming work and. in any evens Company's randru m liability far my damages shall be limited an the Tend amount paid to Company for the Work miler this
agreement. This Limitation or Remedies clause shall apply to the parties to this agreement as well as to the mrzeno owmQsl of the project and i W their respective
succnw¢ and assiSm. If you receive a claim for damages by my owner arising out of in alleged to have arisen out or the Work, you agree in give write notice to
Company ofthe claim and psevO, Company An oppmardY m Inspect the alleged damages within 30 days Wile, Company's notip, of the retire. Ifyou fail to give rhe
requital ..He. No, fail to allow Company m eup... try to inspect rhe allege damages within 30 days, you hereby waive my and all rights for damages anNm
correction of work against Company. This Limindons of Remedies maybe plead ss s mmpkm bars. any aztim in vhhtion erthiz deme
5. LIMITATIONS ON ACTIONS AND LIABILITY. All deims md/ar lawsuit including bra not limited m.hims or lawsuit fm Indemnity mdfor
contrbution against Company arising under this agreement must ba made within 13 months Fmm the Jett ohompledon of roc iumllmion. COMPANY WILL NOT
BE LIABLE FOR ANY LOSS, DAM,%GE OR INJURY RESULTING FROM DELAY IN DELIVERY OF THE PRODUCTS OR FOR ANY FAILURE TO
PERFORM THAT IS DUE TO CIRCUMSTANCES BEYOND ITS CONTROL COMPANY DISCLAIMS ALL LIABILITY FOR ANY AND ALL
DAMAGE WHICH MIGHT BE SUSTAINED BY ANY PERSON WHO MAY BE ALLERGIC TO OR AFFECTED BY TILE EMNATION OF
PARTICLES FROM CERTAIN TYPES OF INSULATION. THE MAXIMUM LIABILITY, IF ANY, OF COMPANY FOR ALL DAMAGES, INCLUDING
WITHOUT LIMITATION CONTRACT DAMAGES AND DAMAGES FOR INJURIES TO PERSONS OR PROPERTY, WHETHER ARISING FROM
COMPANY'S BREACH OF THIS AGREEMENT', BREACH OF WARRANTY, NEGLIGENCE, 9MLT LIABILITY OR OTHER TORT WITH
RESPECT TO THE PRODUCTS, OR ANY SERVICES IN CONNECTION WITH THE PRODUCTS, IS LIMITED TO AN AMOUNT NOT TO EXCEED
THE CONTRACT PRICE. IN NO EVENT SHALL COMPANY BE LEABLE FOR ANY INCIDENTAL, CONSEQUENTIAL, LIQUIDATED, OR
SPECIAL DAMAGES, INCLUDING WITHOUT LIMITATION, LOST REVENUES AND PROFITS, ATTORNEYS FEES ANDIOR COSTS EVEN IF IT
HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE RIGHT TO RECOVER DAMAGES WITHIN THE LIMITATIONS
SPECIFIED 15 YOUR EXCLUSIVE REMEDY IN THE EVENT TIAT ANY OTHER CONTRACTUAL REMEDY FATS OF ITS ESSENTIAL
PURPOSE.
6. PRICES, TERMS AND SHIPMENT. Norah Ottoman. lauskehouges, set aft mmmmmdums areallowdtalesspaVOedby Company. in addition
lathe prices spacifled. you agree to pay any fubml, sore .,?.,a] .nim, me, occupmi mad. or similar was new in fore or to be enanred in dm fume, us and against
Coenpmy or you by rm n althu ==coon. No mrcndon is pernlned talus Company alma other ;,e it writing. Any put due payment will be, u Company's
option,subjectmded to oIJVteamonm (MS You
agre 10 r rhe extortpsmim-0by law. Youaloesrod,rorl(arpema Campmyareceive) near theworksite,
my mmerials needed m sampler. the and You agree m promet sura meoeuils arta damage le loss and provide Company. Ree of charge, with ..able o use of
Cmispaeaeecives wer,nnrage1. Comfort,
.h., hl...eean and hors¢ ssmmani h.pb ailmeteriadyfares Water hisagrdo"mhallnatify. myov mall
Campmy receives payroem in full Company may ehmge yauafce mdit uncal.p.ns<s ifthejob rim is norrmdy hrwork on rhe due you specify.
7. FORCEMAJEURE. C¢mpenyshul not be liable for myd.ry, failurte, ordebutln Mureaanccolthie agrtmmtmmismone. In wade ormpaircaund
by it. tworr ma of my contingency beyead the mmol eirher.fCompany or of suppliers to the Company. Such contingencies include but am not limited to hi]ure
an delay in transportation. ants of my govemmrnt or my agency or subdivision mWorj.dicial actin, labor dispmu, Ire, accident. tats of moue, sevens wanner.
producr ulacedm m shomgu. labor shormga, hal sh.mga. nw memnal shoneg., machinery or saaucal lallurt, or work that mmol be eomplbmd bemuse of
morhec Campmyreveringtheeminentpardon it thebuilding.IfsWmmingmdy coeurs, Campmymayng,o. produedon, deliveries, and petfommtt of work
mrmg i¢ customers orsubadmm suhstmoally similar mmcriala In i¢ soln uurttion, without liability for doing so.
8. CONFIDENTIALITY. Ifyou visit Company's prtmiuz or you otherwise receive my propdehry orconftlmtiu infomatian ham Campmy. ymu soul ¢min
taco infoermden as confidmdu and mouse ordisclou it to my thW perry wilhom Campmy's writer mnsena
9. CREDIT APPROVAL. Shipment and delivery of goods and performance of work shall at all drums be subject to the appmvu of Compmy's credit
department and Company ..yet my time dedicate make my shipment ordclivey, or parfom my work except upon reaipt¢f payment or upon wars and conditions
ecuriry. sadsfazery m Campmy. By signing this agreement, you mthoeiae Company to check your credit and mfimerm s.
10. CANCELLATION. This agrtmenL or my Two of is, may only be ..celled with Company's W. a,,..L Ira the event of condition of this
agreemena nr my pm hereof. you shall pay: (al the comraet priev fall completed name: (b) twepotoroldw contromprieethat is equal mLhadegreeofmmpletlen
of products ar work in proms, irf.rive m the dem Company receives nate of cmeellm..: Codes cou of my materials and supplies which Company shell hove
purchased to perform and which cannot be readily mold or used for other or shNlar purposes: (d) a rest.,king fm: and (el my expense Incumd by Company
[including legal fees mdjudgmema) a a result ¢robe mncellnian ofsubcmoac¢ or pumhues related in this agrement
11. DEFAULT. You may tnminate this agaermen[ for Company's defauia wholly or in pan. by giving Campmy writer nmice eReminanon ss follows. You
may give . wdue. mitt of teminmi in only if Company has received a anion. mine. ft. you specifying such default, the default Is net ..able ender my
provision hereof, and doe default has not been mmedied within thins 1301 days (.,such ]anger Most as may be ...able order the cimumsunm) alter Company's
receipt eCtbe nodes of defaila Delivery of nonconfoming pedmt or work by Campmy soul give you oho right set fano in pmgaph i hereof but shall tar be
deemed is defauh Bir p..... of oamianon. In the event of u m mama, far dehulc you shall be rtdievcd of rhe obligation to pay for work nor perfumed by
Company prior m the off rive dem of such semination. A default on Company's pan shall not subjeco Company to liabdiry, through payment by Company. set off or
mherwiss. farany otherJarmge, whedandirect. consequential orincidmal, and whether sought under dead. ufmmmrt or tort.
12. ASSIGNMENT. You maynm usign chis agrtmem ao any claim aloins. Company relating res rM1is agrtemenc
13, GOVERNING LAW. This agrtemmo shall be mummies. interpreted and the rights arrhe Mies dclinumedin azcutdame with the laws ofthe Sum of
Compmy's addres rim Itso.dm rhe front of this agmcmenc
13. DISPUTES AND MANDATORY MEDIATION. In the even Wo a dupum vises ova rhe ressanableness of or mdtlemem m fs eM1arged by
Company, pe topg party will be emitled m tion die
ie anomepr fees and cast. in all other dtpumn ofmy name. mea nary shall pay it own fes and asst.
Erceposs unpavedm pmenconhdennallnfomanen and mobtain preliminary injunctive relief us prevent irtepamble hum,yen and the Company magree nrhesprior to
rhe Initiation ofany legal anon she penia svitl engage in faelim,ive mmhedun ofmy and all disputes in my way related oo tht alrtmenr. I(the panics cannot agmc
upon. ic..Each medhm, withiny't J.yscfees the dlepme.unse,00e,anduretarde magnuo oh.0mmmmialMdimlan Rules of rhe Americm Abimtian
Mseci.dan. Each pony will short equally the fees Fun, fazilimrv<mediam, and costs of oho medieoion.
15. INSULATION DOES NOT PREVENT FROZEN PIPES. Insulating around water lines in an unconditioned or s.mi-condinomd vea will not
prevent pipes Ram Seem, a, accumulating condemadun. To Jecrmm the possibility of banes pipes. lame my water pipes within a conditioned arca such u
imervl wills mohcnhan ramal walls IlYau da nm lumen the pipes within m mmmol walk you hold Company hamlets and rete.. Company Erma any nhMs
relating to ft.. or burst pipes.
16. SEVERABILITY. If my pownum an this'ralraem to not enfoneW,le. ohms pmvbmn ;hull be effective only m die event pemind by law and all other
point ... s ordas "neon, diAl mount
17, ENTIRE AGREEMENT. Tom msttummt cenmim;he inure agrecmmo of the pant. rchamg to the mbleer matter hemur snit may ..to be waivcd.
ehurgd, modified axmndcd m discharged urmly by a wtiting .,,cd Sy rhe parry ag.uml whom mfotmen, ofmy such waver, change. muduimnon. estenamn or
Jmnhmge is sough.. The tams sod:omlthurt of rhmagteemenrupende any ageeemrnt in which it is notched.
IS. INDEMNITY. Each of rhe pmre m:hu a,tw ent agtm:o defend and indemnity me another fmmmy and Al amens. suns mdse luwsmt mused ay the
parry: ale;ligmt act ur oro sWai. Tbt lndarron. clause and 'he obligations crmted hwm n,lull cental and rake pmnry over any contrary indemnity agreement
mmrallima rira rotht ageemenc Fmdtemme,Ori indwwrmyclauw and the obligaions-erawarercm shall wmrd and rakc;mmiyovenmmmaey;ndemntry
agrccmem emend taro uOwa,em m tht ay¢emmwnlas the remequem ay .anent sotnholly refer, m this mdmiroy clause and Jeclams ¢null and void.