Loading...
Independent Contractor Agreement with Bricon for WWTP Sampling StationsAGREEMENT FOR INDEPENDENT CONTRACTOR SERVICES (WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION) PROJECT # 10381.b THIS AGREEMENT FOR INDEPENDENT CONTRACTOR SERVICES is made this 18t" da of Februa , 2014, and entered into by and between the City of Meridian, a ._._. Y rY . munici al cor oration or anized under the laws of the State of Idaho, hereinafter referred p p 9 to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and BriCon, Ind, hereinafter referred to as "CONTRACTOR", whose business address is 2345 E. White Hawk Meridian Id 83646 and whose Public Works Contractor License # is C-11823-AA- 3-4 INTRODUCTION Whereas, the City has a need for services involving WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION; and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS 1. Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Agreement and receipt of the City's written notice to proceed, all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Attachment "A"and incorporated herein by this reference, together with any amendments that maybe agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. If any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrigh#ed by the Contractor, the City reserves aroyalty-free, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION page 1 of 11 Project 10381.b and ci laws ordinances, regulations and resolutions. The Contractor state ty nts and warrants that it will perform its work in accordance with generally represe ted Indust standards and practices for the profession or professions that accep ry f are used in erformance of this Agreement and that are In effect at the time o p . erformance of this A reement. Except for that representation and any p g . re resentations made or contained In any proposal submitted by the Contractor p rf rmed b and an re orts or opinions prepared or issued as part of the work pe o y Y p • the Contractor under this A reement, Contractor makes no other warranties, either g express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this A reement will be performed in a timely manner in accordance with a Schedule of g Work, which the parties hereto shall agree to, The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall becompensated on aNot-To•Exceed basis as provided in Attachment B "Payment Schedule attached hereto and by reference made a part hereof for the Not-To-Exceed amount of 54 00o Qo. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, of fees earned and costs incurred #or services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of al! taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a} completion of the agreed upon work, (b} or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time of termination is listed in Attachment A. WWTP SAMPLING STATION IMPPOVEMENTS -CONSTRUCTION page 2 of 11 Project 10381.b ntractor default in the erformance of this Agreement or materially 3.2 Should Co p n of its rovisions Cit , at City's option, may terminate this Agreement by breach a y p ~ Y giving written notification to Contractor. h uld Cit. fail to a Contractor all or any part of the compensation set forth 3.3 So y py , in Attachment 6 of this A reement on the date due, Contractor, at the Contractor s g . tion ma terminate this A reement if the failure is not remedied by the City op ~ Y g within thirty (30) days from the date payment Is due. .4 TIME FOR EXECUTING CONTRACT AND LIQUIDATED DAMAGES 3 U on recei t of a Notice to Proceed, the Contractor shall have 45 fort -five p p calendar da s to complete the work as related to the Installation of the bridge Y footin s as described herein. Contractor shall be liable to the City for any g . delay beyond this time period in the amount of X200 two hundred dol~ per calendar da .Contractor has ten (10} calendar days from Notice To Proceed Y .. to notif City of any delays due to product availability. Such payment shall be Y . construed to be liquidated damages by the Contractor In Ileu of any claim or damage because of such delay and not be construed as a penalty. *NOTE: The project completion date is contingent upon the local irrigation season. Contract times may only be extended with Project Manager approval and a written contract change order. Without exception, all contract construction, installation, inspection, invoicing shall be completed no later than November 25, 2014. Under no circumstances will the project be extended beyond this date due to permit expiration. 4. Termination: 4.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails to fulfill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud., dishonesty, or any other act of misconduct in the performance of this contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen X15} days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty X60} days notice to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation for any work satisfactorily complete hereunder. WWTP SAMPLING STATION IMPROVEMENTS - CONSTRUCTIQN page 3 of 11 Project i 0381.b twithstandin the above, CONTRACTOR shall not be relieved of liability to 4.2 No g h ITY for dama es sustained by the CITY by virtue of any breach of this teC g , A reement b CONTRACTOR, and the CITY may withhold any payments to g y ~ ~ f CONTRACTOR for the urposes of set-off until such time as the exact amount o p .. ma es due the CITY from CONTRACTOR is determined. This provision shall da g , rvive the termination of this agreement and shall not relieve CONTRACTOR of su its liability to the CITY for damages. 5, Independent Contractor: 5.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as an inde endent contractor, and neither CONTRACTOR nor any officer, employee p , or a ent of CONTRACTOR well be deemed an employee of CITY. Except as 9 ... ex ressl rovided in Attachment A, Contractor has no authority or responsibility to p Yp exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 5.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 5.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of Contractor in fulfillment of this Agreement. If in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. 6. Indemnification and Insurance: fi.1 CONTRACTOR shall indemnify and save and hold harmless CITY from and for any and all losses, claims, actions, judgments for damages, or injury to persons or property and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall_maintain, and s ecificall a rees that it will maintain throu hout the term of this A reement liabiiit insurance in which the CITY shall be named an additional insured in the minimum amounts as follow: General Liability One Million Dollars ($1,000,000} per incident or occurrence, Automobile Liability Insurance One Million Dollars x$1,000,000}per incident or occurrence and Workers' Compensation insurance, in the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION page 4 of 11 Project 10381.b CITY becomes liable for an amount in excess of the insurance limits, herein rovided CONTRACTOR covenants and agrees to indemnify and save and hold p harmless CITY from and for all such losses, claims, actions, or judgments for dama es or injury to persons or property and other costs, including litigation costs g and attorne s' fees, arising out of, resulting from , or in connection with the Y erformance of this Agreement by the Contractor or Contractor s officers, employs, p . a ants, representatives or subcontractors and resulting in or attributable to g . ersonal injury, death, or damage or destruction to tangible or intangible property, p . . includin use of. CONTRACTOR shall provide CITY with a Certificate of g Insurance, or other proof of insurance evidencing CONTRACTOR S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten X10) days prior to the date Contractor begins performance of it's obligations under this Agreement. In the event the insurance minimums are changed, CaNTRACTC~R shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. 6.2 Any deductibles, self-insured retention, or named insureds mustbe declared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 6.3 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance orself-insurance maintained by the City or the City's elected officers, officials, employees and volunteers shall be excess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 6.4 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. fi.5 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 6.6 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 7. Bonds: Payment and Performance Bonds are required on all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. WWTP SAMPLING STATiQN IMPROVEMENTS -CONSTRUCTION page 5 of 11 Project 10381.b n :All construction and a ui ment provided under this agreement shall be 8. Warra ty q p rr nted for 2 ears from the date of the City of Meridian acceptance per the wa a y , and the Meridian Su lemental Specifications & Drawings to the ISPWC ISPWC pp and an modifications, which by this reference are made a part hereof. Y All items found to be defective during a warranty inspection and subsequently corrected will re uire an additional two ~2) year warranty from the date of City's q acceptance of the corrected work. 9. Notices: An and all notices required to be given by either of the parties hereto, Y, . . unless otherwise stated in this agreement, shall be In writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY CONTRACTOR City of Meridian BriCon, (nc Purchasing Manager Attn: Mark Brice 33 E Broadway Ave 2345 E. White Hawk Meridian, ID 83642 Meridian, ID 83646 208-888-4433 Phone: 208-888-3746 Email: briconl msn~com Idaho Public Works License #C-11823-AA-3-4 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 10. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a se arate contract between the parties and shall survive any default, p termination or forfeiture of this Agreement. 11. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement bythe parley so failing to perform. 12. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent of CITY. 13. Discrimination Prohibited: In performing the Work required herein,. CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. WWTP SAMPLING STATION IMPROVEMENTS ,CONSTRUCTION page 6 of 11 Projec# 10381.b 14. Reports and Information; 14.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports; data and information as the CITY may request pertaining to matters covered by this Agreement. 14.2 Contractor shall maintain all writings, documents and records prepared or com lied in connection. with the performance of this Agreement for a minimum of p four 4 ears from the termination or completion of this or Agreement. This ~)Y . includes an handwriting, typewriting, printing, photo static, photographic and every y other means of recording upon any tangible thing, any form of communication or re resentation including letters, words, pictures, sounds or symbols or any p combination thereof. 15. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY fior examination all of CaNTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. 16. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 17. Compliance with Laws: In performing the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 1$. Changes: The CITY may, from time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the amount of C~?NTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the same formalities as this Agreement. 19. Construction and Severability: If any part of this Agreement is held to be 'invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 20. yllaiver of De#ault: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION page 7 of 11 Project 10381,b ' f Attorne : Each a warrants and represents that in executing this 21. Advice o y p ttY , m nt. It .has received Inds endent legal advice from Its attorney s or the Agree e p opportunity to seek such advice. mire A reement: This A reement contains the entire agreement of the parties 22. E g g , and su ersedes an and all other agreements or understandings, oral of written, p Y whether revious to the execution hereof or contemporaneous herewith. p 23. order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted bid document. 24. Public Records Act: Pursuant to Idaho Code Section 9-335, et seq., information or documents received from the Contractor may be open to public inspection and co in unless exempt from disclosure. The Contractor shall clearly designate py. g ,~ individual documents as exempt on each page of such documents and shall indicate the basis for such exemption. The CITY will not accept the marking of an entire document as exempt. In addition, the CITY will not accept a legend or statement on one (1) page that all, or substantially all, of the document is exempt from disclosure. The Contractor shall indemnify and defend the CITY against all liability, claims, damages, losses, expenses, actions, attorney fees and suits whatsoever for honoring such a designation or for the Contractor's failure to designate individual documents as exempt. The Contractor's failure to designate as exempt any document or portion of a document that is released by the CITY shall constitute a complete waiver of any and all claims for damages caused by any such release. 25. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 26. Approval Required: This Agreement shall not become effective ar binding until approved by the City of Meridian. END OF TEXT. SIGNATURES TO FOLLOW ON NEXT PAGE. WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION page 8 of 11 Project 10381.b SIGNATURE PAGE WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION Project 10381.b CITY OF MERIDIAN TAMMY de D, MAYOR Dated: ~- I ~ i ../". A roved b Council: ~~ pp Y ~.~..~ CE~~. HQLMAN, CITY CL .~.w ~~~~ ~ ~~ i~ ~€ t~ 4 ~': } ~• f i,y *' ~l, ~ 1 ~r ~~, Purchasing Appr val , ~ ~- ~ ~~~~~ e a nt oval ~~~~~~;~~~~~,~ p p BY: KEIT S, urchasing Manager Dated:: .2 j~ I BRIGON, INC ' C~ /~ BY• MARK BRICE, President Dated: t~ 1 1~ ~~~ 3 ,~~~t,; t~~~.'' ~~ ~ ,f ;~, . ~~ BY: VILA REN STE RT, Engineering Manager Dated:: ~- ~ WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION page 9 of 11 Project 10381.b Attachment A SCOPE OF WORK REFER TO INVITATION TO BID PW-14-10381.b ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation to Bid Package # PW-14-i0381.b, are by this reference made a part hereof. WWTP SAMPLING STATION IMPROVEMENTS -CONSTRUCTION page 10 of 11 Project 10381.b Attachment B MILESTONE 1 PAYMENT SCHEDULE T tal and com fete com ensation for this Agreement shall not exceed A. o p p $54,000.00. ^~-rt :,r e<e ~... '.',a ~;,; ~ c/"~. .,~ ' t~ l ". ~.~ r!, J _~.4 ~!~ l I I h "I,, f ~'~t D 4 i ..Y 1 t c,. y''f~ ~ ; t / t~ L'~ dYCyI.;):r.W ~~v N~Vf yt~~ t ~~- ,., .,. ,, t , r~r }Y"~n ~ { ~. ~ ;.~:1 to '~ 47 + 1 ~ ~ `ix 1. yf r~,i ~W ~~ V"L ~ { ~,~ yPl Fi Y ~rS ~v,~ ~`Y 11f k.` .yr. Il rp ''~ 1 P ~ ~1.. li:. 7 } Y ~ 1 r 1 1^'~ ~ (~ r ~ ,~ r I~„ N t -i ti4f ~+ (+V iy~ 1 !r fV!( ~" ~ ~ i , ~ r r In) V I } r h ,tf T (~ t Y ~~~_;'r ~ t..~/ 6 yW; r ~ ~ ~ ~~r p;'f `ter ~. ., y. 44 t s.~ 'i; ~ ~ ,g±, l~ 1 ' 1 ~',S~ ~. ~ ~ , ~ A"Y::~ 4 tl f 1 3 r~ r. ./ } 'r : ~ f~' {~~r` g+a 1 r>~~.i , } ,:x+1.5 , n ial Com letion ~~~ ~ : Milestone 1 Substa t p 45 forty-five} days ~ 'I ne 2 Final Completion November 15, 2014 MI esto }~ r :,Y ,~x r r i x t {., t~ f t,. ~ ~ ~ v, ~ h ~ ~ r o- ~~ ,~ rr i,i. ~ i ~~ vLd~ t' ~, ~~S ~ r " ~'. r~ r i~. w , .~ a ,~~ ~ J ~~y,c ~ ,. y ~' ~ '. ~~ ~ -n.r-~ n, ~ ~~~ i,~ V7 '",~a k 7 ~sl r {~ ~F ,I ~4r+ ~~ t~"('i u}~ 7 ); ~ t ~ { -" yrl 1 ~~, r s I r ~ 1 .~ ' Yf{d. t~Y1 , ° f~f f ,y ~: ~ f ~ ~~ ! 7`' h ti !' J y r p~Y 1 ~ r ~ ~ Ise' "~ I ~ t'y ('r r~ ~` ! rr "~! ~ ~ ~' N ' I des furnishin all labor, materials, equipment, and incidentals as required for the Contract Inc u g AMPLING STATION IMPROVEMENTS -CONSTRUCTION per IFB PW-~ 4-10381.b WWTP S Total Bid Schedule 1 ...................$54,000.00 CONTRACT TOTAL ....................... ~~ ~QQQ.~ CONTRACT IS A NOT TO EXCEED AMOUNT. LINE ITEM PRICING BELOW WILL BE USED FOR INVOICE BY CITY. IN WORK REQUESTED INCREASES OR DECREASES VERIFICATION AND ANY ADDITIONAL , 4. Yis ` n ` , -.7 r .Y' G '~ ; rv + ~}:~, ~t "'~ 'y i' r4. ,.A,"r, fi. k r.l, ~; r~" r r, i ` t;T ~~,1, a ~ ~ : k.y;, tr ~:f F .~A~Fi K:d~ U~ {~ t t (~.~ V ~ t t , . V. l r I ~ `` ,' 1. i,~ ' ,~ ' ~ / ,qtr p-: y}F,.. ~v~ ~^ "~,4:, > '`~ t ~' .„!~, _~ y/ ~L~ ~ 5 ,.I1 '~'StJA ,Y:. `m rY ' YF .:'! ~:'{r .f `~'~' h: "~ Uy y rt i ,.N ;29`. A ..t p.^•• %r ,t4 I,.. ti C;i{1 ~,. .:1~ xr N (~'?~ '~x, 1 ti ~~. ,~'~['~.~ 1 ~ i~ ~ ~ ~~ t F r A'. ~~ ,. . r t s Yr ' r ; r ~:~ r V 1 r J r -;T 'i ~' ` r ~ ~~ ~ ~ ~ - a t Ja} f ~ ~'e~ sx"1 rr+ ~`vt~}re ~. }l~ t rg F ~' LR i'~ ~ * N ~ ~~ J f1 ~ , - r ~. ro r ~x .~ ~ ~ ~ 3 ' . ~. N .. i ~. r r Item No. Descri tion Quantit Unit Unit Price 1 Mobilization/Demobilization 1 LS 3,800 2 Existing Bridge Removal 1 LS 1,500 3 Site Work 1 LS 1,800 4 Erosion and Sedimentation Control 1 LS 2,000 5 Seeding 1 LS 1,300 6 Concrete Foundation 1 LS 5,000 38,fi00 7 Badge and Handrail ~ ~ Travel ex enses, if applicable, will be paid at no more than the City of Meridian's p Travel and Expense Reimbursement Policy. WWTP SAMPLING STATION IMPROVEMENTS • CONSTRUCTION page 11 of 11 Project 10381.b