Independent Contractor Agreement with McMaster for NW 8th Sewer TrunkCITY ®F NiEI®IAN
CONTRACT/AGN®A REQUEST CHECKLIST
Date: 1/22/2014 REQUESTING DEPARTMENT ~/ - E~ IN RlIV
Fund: 60 Department: 3590 GL Account: 95000 Project # 10329A
Construction: X PSA: Task Order:
Project Name: NW 8TH STREET SEWER TRUNK MAIN -PHASE 2 BROADWAY TO CHERRY LANE
Project Manager: John Boyd Department Representative: n/a
Contractor/Consultant/Design Engineer: McMaster COnStrUCtlOn 8c Development - MUrray Smlth & ASSOCIateS
Budget Available (Attach Report): Yes Contract Amount: $803,370.80
Will the project cross fiscal years? Yes No X
Budget Information: FY Budget: 14 Enhancement #: 7 Grant #:
Other: Type of Grant:
CONTRACT CHECKLIST
BASIS OF AWARD
Low Bidder X Highest Rated Master Agreement
(Bid Results Attached) Yes (Ratings Attached) (Category)
Typical Award Yes X No
If no please state circumstances and conclusion:
10 Day Waiting Period Complete
PW License # 4466
Yes
Date Award Posted: January 10, 2014
Current? (attach print out) Yes
Goodstanding
Corporation Status (Attach Print Out):
Insurance Certificates Received (Date): January 17, 2014 Rating:
Payment and Performance Bonds Received (Date): January 17, 2014 Rating:
Builders Risk Ins. Req'd: Yes No X If yes, has policy been purchased?
Correct Category? Yes
A
A
n/a
Date Submitted to Clerk for Agenda: January 22, 2014 Approved by Council January 28, 2014
Issue Purchase Order No, Date Issued: WH5 submitted
Issue Notice of Award: Date: NTP Date:
f calf '
~y~/
®: Jaycee L. Holman, City Clerk,
r®nn: Keith Watts, Purchasing Manager
Jacy Jones, Clint Dolsby
ate: 01 /22/14
e: January 28~' City Council Meeting Agenda Item
The Purchasing Department respectfully requests that the following item be placed on the
January 28 City Council Consent Agenda for Council's consideration.
Approval of Award of Bid and Agreement to McMaster Construction and
Development, Inc. for the "NW 8~' Street Sewer Trunk Main -Phase 2 Broadway to
Cherry Lane -Construction" project for aNot-To-Exceed amount of $803,370.80.
Recommended Council Action: Award of Bid and Approval of Agreement to
McMaster Construction ~ ®evelopment, Inc. for the Not-To-Exceed amount of
$803,370.80.
Thank you for your consideration.
Page 1
Mayor Tammy de Woerd
City Counefl Ment6erfe
Keith Bird
Brad Hoaglun
Charles Rountree
David Zaremba
rkS @a~'tl'ri@11
TO: PURCHASING
FROM: John Boyd
Engineering Technician II
DATE: December 18, 2013
SUBJECT: AUTHORIZE CONSTRUCTION OF THE NW 8TH STREET SEWER TRUNK
MAIN -PHASE 2 (PROJECT #10329A) FOR ANOT-TO-EXCEED AMOUNT OF
$970,000.00.
PLEASE PLACE ON NEXT AVAILABLE CONSENT AGENDA
I. DEPARTMENT CONTACT PERSONS
John Boyd, Engineering Technician II ...............................................................................489-0364
Clint Dolsby, Asst. City Engineer ......................................................................................489-0341
Warren Stewart, PW Engineering Manager .......................................................................489-0350
John McCormick, Deputy Director of Public Works .........................................................489-0378
Tom Barry, Director of Public Works ................................................................................489-0372
II. DESCRIPTION
A. Baclc rg ound
In early 2011, the Public Works Department (PW) undertook a design project to
rehabilitate the existing 18" sewer trunkline between W. 7th Street and W. 8th Street
from W. Broadway Avenue to W. Cherry Lane. The preliminary engineering revealed
the existing sewer trunkline was located in backyards and an alley which provided
limited access for cleaning and maintenance. Additionally, a portion of the existing sewer
trunkline has no access or maintenance easement. Due to these factors, Murray Smith &
Associates (MSA) was contracted and completed a design to relocate the line within the
W. 8th Street and W. 7th Street rights-of--way (ROW).
B. Proposed Project
This project is Phase 2 of 3 and consists of constructing an 18" sewer trunkline in NW 8`h
Street from W. Carlton Avenue to W. Broadway Avenue with several individual services
and side sewers.
The remainder of the design for the 3`d Phase will be completed this hscal year with
construction planned for FY15.
Page 1 of 2
C. Contractor Selection
Bids will be opened for this project on January 10, 2014.
III. IMPACT
A. Service/Delivery Impact:
The construction of this sewer line will complete the second phase of the trunkline
relocation and with this approval will enable the construction to commence this fiscal
year.
B. Strate ig c Impact:
This project meets our mission requirements to identify and prioritize work to
anticipate, plan and provide public services and facilities that support the needs of
our growing community and ensure modern reliable facilities while maintaining
financial stewardship.
C. FiscalImpact:
Available Project Funding
The project will be funded with existing City funds from the following account.
Sewer Line Replacements (60-3590-95000) ................................................... $970,000.00
Total Phase 2 Funding ..................................................................................... $970,000.00
IV. LIST OF ATTACHMENTS
A. Engineering Estimate
APPROV FOR BID /AWARD PROCESS
amen Stewart, PE -Engineering Manager
/ 2 1 / .3
Date
Page 2 of 2
a
r K
~°
1
~.
~~
~ ~
fi
r ~ ~
ii y ~
4 ~`
>igned
ddendum 1
ddendum #2
id Bond
is #
ubs
ertification
W
a
O
C
z
C
W
m
70
a
C
flt
--I
.~
t
~,,.
,t z ~
~ # ~
P
~~
~ ~
.+ r
f
~1
~~
~r
~~J
AGREEMENT F®R INDEPENDENT C®NTRACT®R SERVICES
NW 3T" STREET SEWER TRUNK MAIN -PHASE 2 C®NSTRUCTI®N
BR®ADWAY AVE. T® CHERRY LANE
PR®JECT 10329A
THIS AGREM NT F®R INDEPENDENT C®NTRACT®R SERVICES is made this
28T" day of January, 2014, and entered into by and between the City of Meridian, a
municipal corporation organized under the laws of the State of Idaho, hereinafter referred
to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and McMaster
Construction & Development, Inc., hereinafter referred to as "CONTRACTOR", whose
business address is 16166 N. 20 , Nampa, ID 83687 and whose Public Works Contractor
License # is 004466.
INTR®DUCTI®N
Whereas, the City has a need for services involving NW 8t" Street Sewer
Trunk Main -Phase 2 Broadway Ave to Cherry Lane -Construction; and
WHEREAS, the Contractor is specially trained, experienced and competent
to perform and has agreed to provide such services;
NOW, THEREFORE, in consideration of the mutual promises, covenants,
terms and conditions hereinafter contained, the parties agree as follows:
TERMS AND C®NDITI®NS
Sc®pe ®f W®rk:
1.1 CONTRACTOR shall perform and furnish to the City upon execution of this
Agreement and receipt of the City's written notice to proceed, all services and work,
and comply in all respects, as specified in the document titled "Scope of Work" a
copy of which is attached hereto as Attachment "A" and incorporated herein by this
reference, together with any amendments that may be agreed to in writing by the
parties.
1.2 All documents, drawings and written work product prepared or produced by
the Contractor under this Agreement, including without limitation electronic data
files, are the property of the Contractor; provided, however, the City shall have the
right to reproduce, publish and use all such work, or any part thereof, in any
manner and for any purposes whatsoever and to authorize others to do so. If any
such work is copyrightable, the Contractor may copyright the same, except that, as
to any work which is copyrighted by the Contractor, the City reserves aroyalty-free,
non-exclusive, and irrevocable license to reproduce, publish and use such work, or
any part thereof, and to authorize others to do so.
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 1 of 13
Project 10239A
1.3 The Contractor shall provide services and work under this Agreement
consistent with the requirements and standards established by applicable federal,
state and city laws, ordinances, regulations and resolutions. The Contractor
represents and warrants that it will perform its work in accordance with generally
accepted industry standards and practices for the profession or professions that
are used in performance of this Agreement and that are in effect at the time of
performance of this Agreement. Except for that representation and any
representations made or contained in any proposal submitted by the Contractor
and any reports or opinions prepared or issued as part of the work performed by
the Contractor under this Agreement, Contractor makes no other warranties, either
express or implied, as part of this Agreement.
1.4 Services and work provided by the Contractor at the City's request under this
Agreement will be performed in a timely manner in accordance with a Schedule of
Work, which the parties hereto shall agree to. The Schedule of Work may be
revised from time to time upon mutual written consent of the parties.
2. C®n~iderati®n
2.1 The Contractor shall be compensated on aNot-To-Exceed basis as provided
in Attachment B "Payment Schedule" attached hereto and by reference made a
part hereof for the Not-To-Exceed amount of $303,370.0.
2.2 The Contractor shall provide the City with a monthly statement and
supporting invoices, as the work warrants, of fees earned and costs incurred for
services provided during the billing period, which the City will pay within 30 days of
receipt of a correct invoice and approval by the City. The City will not withhold any
Federal or State income taxes or Social Security Tax from any payment made by
City to Contractor under the terms and conditions of this Agreement. Payment of
all taxes and other assessments on such sums is the sole responsibility of
Contractor.
2.3 Except as expressly provided in this Agreement, Contractor shall not be
entitled to receive from the City any additional consideration, compensation, salary,
wages, or other type of remuneration for services rendered under this Agreement
including, but not limited to, meals, lodging, transportation, drawings, renderings or
mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement
to consideration in the form of overtime, health insurance benefits, retirement
benefits, paid holidays or other paid leaves of absence of any type or kind
whatsoever.
3. Tenn:
3.1 This agreement shall become effective upon execution by both parties, and
shall expire upon (a) completion of the agreed upon work, or (b) unless sooner
terminated as provided below or unless some other method or time of termination
is listed in Attachment A.
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 2 of 13
Project 10239A
3.2 Should Contractor default in the performance of this Agreement or materially
breach any of its provisions, City, at City's option, may terminate this Agreement by
giving written notification to Contractor.
3.3 Should City fail to pay Contractor all or any part of the compensation set forth
in Attachment B of this Agreement on the date due, Contractor, at the Contractor's
option, may terminate this Agreement if the failure is not remedied by the City
within thirty (30) days from the date payment is due.
3.4 TIME FOR EXECUTING CONTRACT AND LIQUIDATED DAMAGES
Upon receipt of a Notice to Proceed, the Contractor shall have 954 (one hundred
fifty four) calendar days to complete the work as described herein. Contractor
shall be liable to the City for any delay beyond this time period in the amount of
$500 (five hundred dollars) per calendar day. Such payment shall be construed to
be liquidated damages by the Contractor in lieu of any claim or damage because of
such delay and not be construed as a penalty.
All Irrigation Crossings shall be completed by March 15, 2014. Contractor
shall be liable to the City for any delay beyond this time period in the amount
of $250.00 (two hundred fifty dollars per calendar day. Such payment shall
be construed to be liquidated damages by the Contractor in lieu of any claim
or damage because of such delay and not be construed as a penalty.
Substantial Completion shall be accomplished within 139 (one hundred thirty
nine) calendar days from Notice to Proceed. Substantial completion for this
project shall be described as completion of all work within the Right of Way.
Contractor shall be liable to the City for any delay beyond this time period in
the amount of $500.00 (five hundred dollars per calendar day. Such payment
shall be construed to be liquidated damages by the Contractor in lieu of any
claim or damage because of such delay and not be construed as a penalty.
4. Termination:
4.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails
to fulfill in a timely and proper manner its obligations under this Agreement, violates
any of the covenants, agreements, or stipulations of this Agreement, falsifies any
record or document required to be prepared under this agreement, engages in
fraud, dishonesty, or any other act of misconduct in the performance of this
contract, or if the City Council determines that termination of this Agreement is in
the best interest of CITY, the CITY shall thereupon have the right to terminate this
Agreement by giving written notice to CONTRACTOR of such termination and
specifying the effective date thereof at least fifteen (15) days before the effective
date of such termination. CONTRACTOR may terminate this agreement at any
time by giving at least sixty (60) days notice to CITY.
In the event of any termination of this Agreement, all finished or unfinished
documents, data, and reports prepared by CONTRACTOR under this Agreement
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 3 of 13
Project 10239A
shall, at the option of the CITY, become its property, and CONTRACTOR shall be
entitled to receive just and equitable compensation for any work satisfactorily
complete hereunder.
4.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to
the CITY for damages sustained by the CITY by virtue of any breach of this
Agreement by CONTRACTOR, and the CITY may withhold any payments to
CONTRACTOR for the purposes of set-off until such time as the exact amount of
damages due the CITY from CONTRACTOR is determined. This provision shall
survive the termination of this agreement and shall not relieve CONTRACTOR of
its liability to the CITY for damages.
5. Independent C®ntract®r:
5.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as
an independent contractor, and neither CONTRACTOR nor any officer, employee
or agent of CONTRACTOR will be deemed an employee of CITY. Except as
expressly provided in Attachment A, Contractor has no authority or responsibility to
exercise any rights or power vested in the City and therefore has no authority to
bind or incur any obligation on behalf of the City. The selection and designation of
the personnel of the CITY in the performance of this agreement shall be made by
the CITY.
5.2 Contractor, its agents, officers, and employees are and at all times during the
term of this Agreement shall represent and conduct themselves as independent
contractors and not as employees of the City.
5.3 Contractor shall determine the method, details and means of performing the
work and services to be provided by Contractor under this Agreement. Contractor
shall be responsible to City only for the requirements and results specified in this
Agreement and, except as expressly provided in this Agreement, shall not be
subjected to City's control with respect to the physical action or activities of
Contractor in fulfillment of this Agreement. If in the performance of this Agreement
any third persons are employed by Contractor, such persons shall be entirely and
exclusively under the direction and supervision and control of the Contractor.
6. Indemnificati®n and Insurance:
6.1 CONTRACTOR shall indemnify and save and hold harmless CITY from and
for any and all losses, claims, actions, judgments for damages, or injury to persons
or property and losses and expenses and other costs including litigation costs and
attorney's fees, arising out of, resulting from, or in connection with the performance
of this Agreement by the CONTRACTOR, its servants, agents, officers,
employees, guests, and business invitees, and not caused by or arising out of the
tortious conduct of CITY or its employees. CONTRACTOR shall maintain, and
specifically agrees that it will maintain, throughout the term of this Agreement,
liability insurance, in which the CITY shall be named an additional insured in the
minimum amounts as follow: General Liability One Million Dollars 01,000,000) per
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 4 of 13
Project 10239A
incident or occurrence, Automobile Liability Insurance One Million Dollars
($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in
the statutory limits as required bylaw.. The limits of insurance shall not be deemed
a limitation of the covenants to indemnify and save and hold harmless CITY; and if
CITY becomes liable for an amount in excess of the insurance limits, herein
provided, CONTRACTOR covenants and agrees to indemnify and save and hold
harmless CITY from and for all such losses, claims, actions, or judgments for
damages or injury to persons or property and other costs, including litigation costs
and attorneys' fees, arising out of, resulting from or in connection with the
performance of this Agreement by the Contractor or Contractor's officers, employs,
agents, representatives or subcontractors and resulting in or attributable to
personal injury, death, or damage or destruction to tangible or intangible property,
including use of. CONTRACTOR shall provide CITY with a Certificate of
Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance
with the requirements of this paragraph and file such proof of insurance with the
CITY at least ten (10) days prior to the date Contractor begins performance of it's
obligations under this Agreement. In the event the insurance minimums are
changed, CONTRACTOR shall immediately submit proof of compliance with the
changed limits. Evidence of all insurance shall be submitted to the City Purchasing
Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue,
Meridian, Idaho 83642.
6.2 Any deductibles, self-insured retention, or named insureds must be declared
in writing and approved by the City. At the option of the City, either: the insurer
shall reduce or eliminate such deductibles, self-insured retentions or named
insureds; or the Contractor shall provide a bond, cash or letter of credit
guaranteeing payment of losses and related investigations, claim administration
and defense expenses.
6.3 To the extent of the indemnity in this contract, Contractor's Insurance
coverage shall be primary insurance regarding the City's elected officers, officials,
employees and volunteers. Any insurance orself-insurance maintained by the City
or the City's elected officers, officials, employees and volunteers shall be excess of
the Contractor's insurance and shall not contribute with Contractor's insurance
except as to the extent of City's negligence.
6.4 The Contractor's insurance shall apply separately to each insured against
whom claim is made or suit is brought, except with respect to the limits of the
insurer's liability.
6.5 All insurance coverages for subcontractors shall be subject to all of the
insurance and indemnity requirements stated herein.
6.6 The limits of insurance described herein shall not limit the liability of the
Contractor and Contractor's agents, representatives, employees or subcontractors.
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 5 of 13
Project 10239A
7. fonds: Payment and Performance Bonds are required on all Public Works
Improvement Projects per the ISPWC and the City of Meridian Supplemental
Specifications & Drawings to the ISPWC, which by this reference are made a part
hereof.
8. Warranty: All construction and equipment provided under this agreement shall be
warranted for 2 years from the date of the City of Meridian acceptance per the
ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC
and any modifications, which by this reference are made a part hereof.
All items found to be defective during a warranty inspection and subsequently
corrected will require an additional two (2) year warranty from the date of City's
acceptance of the corrected work.
9. Notices: Any and all notices required to be given by either of the parties hereto,
unless otherwise stated in this agreement, shall be in writing and be deemed
communicated when mailed in the United States mail, certified, return receipt
requested, addressed as follows:
CITY COtdTRACT®R
City of Meridian McMaster Construction & Development, Inc.
Purchasing Manager Attn: Eric Bird
33 E Broadway Ave 16166 N. 20th
Meridian, ID 83642 Nampa, ID 83687
208-489-0417 Phone: 208-461-1234
Email: ericQa mcmasterconst.com
Idaho Public Works License # 004466
Either party may change their address for the purpose of this paragraph by giving
written notice of such change to the other in the manner herein provided.
10. Attorney Fees: Should any litigation be commenced between the parties hereto
concerning this Agreement, the prevailing party shall be entitled, in addition to any
other relief as may be granted, to court costs and reasonable attorneys' fees as
determined by a Court of competent jurisdiction. This provision shall be deemed to
be a separate contract between the parties and shall survive any default,
termination or forfeiture of this Agreement.
11. Time is of the Essence: The parties hereto acknowledge and agree that time is
strictly of the essence with respect to each and every term, condition and provision
hereof, and that the failure to timely perform any of the obligations hereunder shall
constitute a breach of, and a default under, this Agreement by the party so failing to
perform.
12. Assignnnent: It is expressly agreed and understood by the parties hereto, that
CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any
of its rights under this Agreement except upon the prior express written consent of
CITY.
NW Sr" STREET SEWER TRUNK MAIN -PHASE 2 page 6 of 13
Project 10239A
13. ®iscrirr~inati®n Pr®hibited: In performing the Work required herein,
CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or
local law, rule or regulation against any person on the basis of race, color, religion,
sex, national origin or ancestry, age or disability.
14. Rep®rts and Inf®rrr~ati®n:
14.1 At such times and in such forms as the CITY may require, there shall be
furnished to the CITY such statements, records, reports, data and information as
the CITY may request pertaining to matters covered by this Agreement.
14.2 Contractor shall maintain all writings, documents and records prepared or
compiled in connection with the performance of this Agreement for a minimum of
four (4) years from the termination or completion of this or Agreement. This
includes any handwriting, typewriting, printing, photo static, photographic and every
other means of recording upon any tangible thing, any form of communication or
representation including letters, words, pictures, sounds or symbols or any
combination thereof.
15. Audits and Inspecti®ns: At any time during normal business hours and as often
as the CITY may deem necessary, there shall be made available to the CITY for
examination all of CONTRACTOR'S records with respect to all matters covered by
this Agreement. CONTRACTOR shall permit the CITYto audit, examine, and make
excerpts or transcripts from such records, and to make audits of all contracts,
invoices, materials, payrolls, records of personnel, conditions of employment and
other data relating to all matters covered by this Agreement.
16. Publicati®n, Repr®ducti®n and lJse ®f Material: No material produced in whole
or in part under this Agreement shall be subject to copyright in the United States or
in any other country. The CITY shall have unrestricted authority to publish, disclose
and otherwise use, in whole or in part, any reports, data or other materials prepared
under this Agreement.
17. C®rnpliance with Laves: In performing the scope of work required hereunder,
CONTRACTOR shall comply with all applicable laws, ordinances, and codes of
Federal, State, and local governments.
18. Changes: The CITY may, from time to time, request changes in the Scope of Work
to be performed hereunder. Such changes, including any increase or decrease in
the amount of CONTRACTOR'S compensation, which are mutually agreed upon by
and between the CITY and CONTRACTOR, shall be incorporated in written
amendments which shall be executed with the same formalities as this Agreement.
19. C®nstructi®n and Severability: If any part of this Agreement is held to be invalid or
unenforceable, such holding will not affect the validity or enforceability of any other
part of this Agreement so long as the remainder of the Agreement is reasonably
capable of completion.
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 7 of 13
Project 10239A
20. Waiver ®f ®efault: Waiver of default by either party to this Agreement shall not be
deemed to be waiver of any subsequent default. Waiver or breach of any provision
of this Agreement shall not be deemed to be a waiver of any other or subsequent
breach, and shall not be construed to be a modification of the terms of this
Agreement unless this Agreement is modified as provided above.
21. Advice ®f Att®rney: Each party warrants and represents that in executing this
Agreement. It has received independent legal advice from its attorney's or the
opportunity to seek such advice.
22. Entire Agreement: This Agreement contains the entire agreement of the parties
and supersedes any and all other agreements or understandings, oral of written,
whether previous to the execution hereof or contemporaneous herewith.
23. ®rder ®f Precedence: The order or precedence shall be the contract agreement,
the Invitation for Bid document, then the winning bidders submitted bid document.
24. Public Rec®rda Act: Pursuant to Idaho Code Section 9-335, et seq., information
or documents received from the Contractor may be open to public inspection and
copying unless exempt from disclosure. The Contractor shall clearly designate
individual documents as "exempt" on each page of such documents and shall
indicate the basis for such exemption. The CITY will not accept the marking of an
entire document as exempt. In addition, the CITY will not accept a legend or
statement on one (1) page that all, or substantially all, of the document is exempt
from disclosure. The Contractor shall indemnify and defend the CITY against all
liability, claims, damages, losses, expenses, actions, attorney fees and suits
whatsoever for honoring such a designation or for the Contractor's failure to
designate individual documents as exempt. The Contractor's failure to designate as
exempt any document or portion of a document that is released by the CITY shall
constitute a complete waiver of any and all claims for damages caused by any such
release.
25. Applicable Lave: This Agreement shall be governed by and construed and enforced
in accordance with the laws of the State of Idaho, and the ordinances of the City of
Meridian.
26. Appr®val Required: This Agreement shall not become effective or binding until
approved by the City of Meridian.
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 8 of 13
Project 10239A
CITY OF MERIDIAN
BY: /''~''~~
TAMMY de RD, MAYOR
Dated: ~ ~ ZS'- ~~
MCMASTER CONSTRUCTION & DEV.
INC.
BY:
ERIC BIRD, VIC RESIIIE
Dated: ~ ~ ~, ~ ~ `{
Approved by Council: ~ o~ o~~ /~
``~
Att st: ~ -,~.
,.
CE . HOLMAN, CITY CLERK, • , ~ ,~. r-,; ~-.--
lye n. 1. +
~~a~.
Purchasing Approval ~ Department Approval
,~
BY: ~ :/
KEITH T S, Purchasing Manager RREN STEWART, Engineering Manager
Dated:: I/ 2 ~ f I y Dated:: Z~f ~~
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 9 of 13
Project 10239A
Attachment A
SC®PE ®F W®RK
E T INUIT TI N 1° I ~!®14®1032 0
ALL N lJM TT' H NT , N XFII IT included in the
Invitatin t® i ackae W®1®1032 vA, are y this reference rna e
a part rfa
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 10 of 13
Project 10239A
Attachment B
MILE~T®NE /PAYMENT SCH®IJL
A. Total and complete compensation for this Agreement shall not exceed
$803,370.80.
~ MII=~STO~~ ~A`~~~/~~6-i.~~t~l~
Milestone 1 All Irrigation Crossings March 15, 2014
Milestone 2 Substantial Completion 139 (one hundred thirty-nine)
da s
Milestone 3 Final Acceptance 154 (one hundred fifty four)
da s
~~~~I~Ifi~~~ ~~F~~f~Rl_,
Contract includes furnishing all labor, materials, equipment, and incidentals as required for the
NAME OF PROJECT per IFB PW-14-10417.0
C®NTRACT T®TAL ....................... $303,370.30
CONTRACT IS A NOT TO EXCEED AMOUNT. LINE ITEM PRICING BELOW WILL BE UBED FOR INVOICE
VERIFICATION AND ANY ADDITIONAL INCREASES OR DECREASES IN WORK REQUESTED BY CITY.
~~i~~ ~~;~`~~~~~al
Item
No. Description Quantit Unit Unit Price
201.4.1.F.1 ABANDONMENT OF SANITARY SEWER AND 16 EA
$1,680,00
IRRIGATION MANHOLE
205.4,1,8.1 DEWATERING 1 LS $1.20
8" MINUS UNCRUSHED AGGREGATE -For
306.4.1.D.1 subgrade repair
(only if requested by ACHD and approved by 4,591 CY
$6.60
the City of Meridian in writing)
TYPE P SURFACE RESTORATION FOR SEWER
307.4.1.G.1. MAIN (ROW ONLY) - 3" CLASS III AC 6,886 SY $21.10
PAVEMENT (includes road base and pit run)
RESTRAINED WATER MAIN PIPE -SIZE 10" PVC $65.20
(includes pipe, connections, excavation,
401.4.1.A.1 bedding, restraints, thrust blocking, backfill, 447 LF
cleaning, disinfection and testing, and all
appurtenances not itemizing in the Bid
Schedule)
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 11 of 13
Project 10239A
WATER MAIN FITTING -SIZE 10" -TYPE 22,5 or $307.00
401.4.1.8.1 4 EA
45 DEGREE ELBOW
$717.00
401.4.1.6,1 WATER MAIN FITTING -SIZE 10" -TYPE TEE 2 EA
$1,900.00
402.4.1.A.4 VALVE -SIZE 10" -TYPE GATE VALVE 1 EA
WATER SERVICE CONNECTION $1,143.00
(includes excavation, bedding, backfill, service
line, service tap and saddle, corporation stop,
404,4.1,A.1
all appurtenance not itemized in the Bid 4 EA
Schedule, and surface restoration not included
in other bid items)
GRAVITY SEWER PIPE SIZE 18" PVC $66.20
501.4.1.8.1 (includes excavation, bedding, backfill, etc.) 1,761 LF
GRAVITY SEWER PIPE SIZE 8" PVC $50.90
501.4,1.8.1 (includes excavation, bedding, backfill, etc.) 1,141 LF
$4,670.00
502.4.1.A.1 SANITARY SEWER MANHOLE - 48' DIAMETER 13 EA
$8, 210.00
502.4.1.A.1 SANITARY SEWER MANHOLE - 60' DIAMETER 2 EA
SEWER SERVICE LINE, SIZE 4" $15,00
(includes excavation, bedding, backfill,
504,4.1.A.1
cleanouts, surface restoration not included in 2,207 LF
other bid items, potable/non-potable crossing)
SEWER SERVICE LINE, SIZE 6" $17,00
(includes excavation, bedding, backfill,
504.4.1.A.1
cleanouts, surface restoration not included in 2,374 LF
other bid items, potable/non-potable crossing)
STORM DRAIN PIPE, Class 12" DIAMETER SOLID $112,60
601.4.1.A.5 241 LF
WALL PVC
$4,560.00
602.4.1.A.1 STORM DRAIN MANHOLE - 48" DIAMETER 2 EA
IRRIGATION PIPE, Class 12" DIAMETER SOLID $125.00
601.4.1.A.1 74 LF
WALL PVC
PRECAST CONCRETE IRRIGATION STRUCTURE - $4,290.00
602,4.1.N.1 1 EA
IRR-1.0
PRECAST CONCRETE IRRIGATION STRUCTURE - $3,170.00
602.4.1,N,1 2 EA
IRRIGATION BOX
MISCELLANEOUS PAVEMENT-TEMPORARY $26.30
ASPHALT PAVEMENT
810.4.2
(only if requested by ACHD and approved by 942 SY
the City of Meridian in writing)
$25,400.00
1001.4,1,A.1 STORMWATER POLLUTION PREVENTION PLAN 1 LS
$ 24,100.00
1103.4,1,A.1 CONSTRUCTION TRAFFIC CONTROL 1 LS
$33,000.00
2010.4.1.A.1 MOBILIZATION 1 LS
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 12 of 13
Project 10239A
SEWER SERVICE -EXCAVATION/PLUMBING $38.00
SP1-1A pERMIT (FIXED COST) 37 EA
SEWER SERVICE/WATER SERVICE - $50.00
SP1-16 EXCAVATION/PLUMBING PERMIT (FIXED COST) 9 EA
WATER SERVICE -EXCAVATION/PLIMBING $3,00
SP1-1C pERMIT (FIXED COST) 1 Ea.
SP1-2 6" SLEEVE FOR SEWER SERVICE - C900 PVC -
240
LF $14,90
POTABLE/NON POTABLE CASING
8" SLEEVE FOR SEWER SERVICE LINE - C900 $21.50
SP1-3 PVC -POTABLE/NON POTABLE CASING 180 LF
CONNECT TO EXISTING MANHOLE $2,850.00
(includes excavation, backfill and flexible
SP1-4
manhole connector, and necessary manhole 2 EA
invert work)
$7,180,00
SP1-5 WATER LINE LOWERING 9 EA
°fravel expenses, if applicable, vuill be paid at n® rn®re than the City ®f Meridian's
'Travel and Expense Reirnbursernent P®licy.
NW 8T" STREET SEWER TRUNK MAIN -PHASE 2 page 13 of 13
Project 10239A