Stevens & Sons Well Drilling - Storey Park Well Page 1
Memo
To: C. Jay Coles, City Clerk
From: Keith Watts, Purchasing Manager
CC: Mike Barton/PM
Date: 08/09/2017
Re: August 15th City Council Meeting Agenda Item
The Purchasing Department respectfully requests that the following item be placed on the
August 15th City Council Consent Agenda for Council’s consideration.
Approval of Award of Bid and Agreement to STEVENS & SONS WELL DRILLING,
INC. for the STOREY PARK WELL project for a Not-To-Exceed amount of $59,550.
Recommended Council Action: Award of Bid and Approval of Agreement to
STEVENS & SONS WELL DRILLING, INC. for the Not-To-Exceed amount of
$59,550 and authorize Purchasing Manager to sign Purchase Order for Not-to-
Exceed amount of $59,550.
Thank you for your consideration.
City of Meridian Purchasing Dept.
CONTRACT CHECKLIST
Date: REQUESTING DEPARTMENT
Project Name:
Project Manager: Contract Amount:
Contractor/Consultant/Design Engineer:
Is this a change order? Yes No Change Order No.
Fund: Budget Available ( Purchasing attach report ):
Department Yes No Construction
GL Account FY Budget: Task Order
Project Number: Enhancement: Yes No Professional Service
Equipment
Will the project cross fiscal years? Yes No Grant
Grant #: Wage Determination Received Wage Verification 10 Days prior to bid due date Debarment Status (Federal Funded)
Print and Attach the determination Print, attach and amend bid by addendum (if changed) www.sam.gov Print and attach
Master Agreement Category
(Bid Results Attached) Yes No (Ratings Attached) Yes No Date MSA Roster Approved:
Typical Award Yes No
If no please state circumstances and conclusion:
Date Award Posted: 7 day protest period ends:
PW License Expiration Date: Corporation Status
Insurance Certificates Received (Date): Expiration Date: Rating: A
Payment and Performance Bonds Received (Date): Rating: A+
Builders Risk Ins. Req'd: Yes No
(Only applicabale for projects above $1,000,000)
Reason Consultant Selected 1 Performance on past projects
Check all that apply Quality of work On Budget
On Time Accuracy of Construction Est
2 Qualified Personnel
3 Availability of personnel
4 Local of personnel
Description of negotiation process and fee evaluation:
Date Submitted to Clerk for Agenda: By:
Purchase Order No.: Date Issued: WH5 submitted
(Only for PW Construction Projects)
NTP Date:
Contract Request Checklist.5.24.2016.Final
N/A N/A N/A N/A
Goodstanding C-12526 10/31/2017
I. PROJECT INFORMATION
8/7/2017 6/1/2018
FY17
8/2/2017 Parks
Storey Park Well
V. BASIS OF AWARD
7/28/2017 August 4, 2017
IV. GRANT INFORMATION - to be completed only on Grant funded projects
VI. CONTRACTOR / CONSULTANT REQUIRED INFORMATION
August 9, 2017
VIII. AWARD INFORMATION
Approval Date
Enter Supervisor Name Date Approved
VII. TASK ORDER SELECTION (Project Manager to Complete)
8/7/2017
Award based on Low Bid Highest Ranked Vendor Selected
$59,550 Mike Barton
If yes, has policy been purchased?
Construction Contractor - Stevens & Sons Drilling/Consultant - SPF Water
III. Contract Type II. BUDGET INFORMATION (Project Manager to Complete)
1
5200
93405
10768
TASK ORDER RFP / RFQ BID
CONTRACT FOR PUBLIC WORKS CONSTRUCTION
STOREY PARK WELL
PROJECT # 10768
THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this
day of August 2017, and entered into by and between the City of Meridian, a Municipal
corporation organized under the laws of the State of Idaho, hereinafter referred to as
"CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and STEVENS & SONS
WELL DRILLING, INC., hereinafter referred to as "CONTRACTOR", whose business
address is 3709 N Hawthorne Dr. Boise, ID 83703 and whose Public Works Contractor
License # is C- 12526-B-4.
I
Whereas, the City has a need for services involving STOREY PARK WELL;
T M14
WHEREAS, the Contractor is specially trained, experienced and competent
to perform and has agreed to provide Such services;
NOW, THEREFORE, in consideration of the mutual promises, covenants,
terms and conditions hereinafter contained, the parties agree as follows:
TERMS AND CONDITIONS
1. Scope of Work:
1.1 CONTRACTOR shall perform and furnish to the City upon execution of this
Contract and receipt of the City's written notice to proceed, all services and work,
and comply in all respects, as specified in the document titled "Scope of Work" a
copy of which is attached hereto as Exhibit "A" and incorporated herein by this
reference, together with any amendments that may be agreed to in writing by the
parties.
1.2 All documents, drawings and written work product prepared or produced by
the Contractor under this Agreement, including without limitation electronic data
files, are the property of the Contractor; provided, however, the City shall have the
right to reproduce, publish and use all such work, or any part thereof, in any
manner and for any purposes whatsoever and to authorize others to do so. If any
such work is copyrightable, the Contractor may copyright the same, except that, as
to any work which is copyrighted by the Contractor, the City reserves a royalty -free,
non-exclusive, and irrevocable license to reproduce, publish and use such work, or
any part thereof, and to authorize others to do so.
1.3 The Contractor shall provide services and work under this Agreement
consistent with the requirements and standards established by applicable federal,
STOREY PARK WELL page 1 of 13
Project 10768
state and city laws, ordinances, regulations and resolutions. The Contractor
represents and warrants that it will perform its work in accordance with generally
accepted industry standards and practices for the profession or professions that
are used in performance of this Agreement and that are in effect at the time of
performance of this Agreement. Except for that representation and any
representations made or contained in any proposal submitted by the Contractor
and any reports or opinions prepared or issued as part of the work performed by
the Contractor under this Agreement, Contractor makes no other warranties, either
express or implied, as part of this Agreement.
1 .4 Services and work provided by the Contractor at the City's request under this
Agreement will be performed in a timely manner in accordance with a Schedule of
Work, which the parties hereto shall agree to. The Schedule of Work may be
revised from time to time upon mutual written consent of the parties.
2. Consideration
2.1 The Contractor shall be compensated on a Not-To-Exceed basis as provided
in Exhibit B "Payment Schedule" attached hereto and by reference made a part
hereof for the Not-To-Exceed amount of $59.550.
2.2 The Contractor shall provide the City with a monthly statement and
supporting invoices, as the work warrants, of fees earned and costs incurred for
services provided during the billing period, which the City will pay within 30 days of
receipt of a correct invoice and approval by the City. The City will not withhold any
Federal or State income taxes or Social Security Tax from any payment made by
City to Contractor under the terms and conditions of this Agreement. Payment of
all taxes and other assessments on such sums is the sole responsibility of
Contractor.
2.3 Except as expressly provided in this Agreement, Contractor shall not be
entitled to receive from the City any additional consideration, compensation, salary,
wages, or other type of remuneration for services rendered under this Agreement
including, but not limited to, meals, lodging, transportation, drawings, renderings or
mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement
to consideration in the form of overtime, health insurance benefits, retirement
benefits, paid holidays or other paid leaves of absence of any type or kind
whatsoever.
3. Term:
3.1 This agreement shall become effective upon execution by both parties, and
shall expire upon (a) completion of the agreed upon work, (b) or unless sooner
terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some
other method or time of termination is listed in Exhibit A.
STOREY PARK WELL
Protect 10768
page 2 of 13
3.2 Should Contractor default in the performance of this Agreement or materially
breach any of its provisions, City, at City's option, may terminate this Agreement by
giving written notification to Contractor.
3.3 Should City fail to pay Contractor all or any part of the compensation set forth
in Exhibit B of this Agreement on the date due, Contractor, at the Contractois
option, may terminate this Agreement if the failure is not remedied by the City
within thirty (30) days from the date payment is due.
4. Liquidated Damages:
Upon receipt of a Notice to Proceed, the Contractor shall have 90 (ninety) calendar
days to complete the work as described herein. See Milestones listed in the
Payment Schedule for Substantial Completion.
5. Termination:
5.1 lf, through any cause, CONTRACTOR, its officers, employees, or agents fails
to fulfill in a timely and proper manner its obligations under this Agreement, violates
any of the covenants, agreements, or stipulations of this Agreement, falsifies any
record or document required to be prepared under this agreement, engages in
fraud, dishonesty, or any other act of misconduct in the performance of this
contract, or if the City Council determines that termination of this Agreement is in
the best interest of CITY, the CITY shall thereupon have the right to terminate this
Agreement by giving written notice to CONTRACTOR of such termination and
specifying the effective date thereof at least fifteen (15) days before the effective
date of such termination. CONTRACTOR may terminate this agreement at any
time by giving at least sixty (60) days notice to CITY.
ln the event of any termination of this Agreement, all finished or unfinished
documents, data, and reports prepared by CONTRACTOR under this Agreement
shall, at the option of the CITY, become its property, and CONTRACTOR shall be
entitled to receive just and equitable compensation for any work satisfactorily
complete hereunder.
5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to
the CITY for damages sustained by the CITY by virtue of any breach of this
Agreement by CONTRACTOR, and the CITY may withhold any payments to
CONTRACTOR for the purposes of seloff until such time as the exact amount of
damages due the CITY from CONTRACTOR is determined. This provision shall
survive the termination of this agreement and shall not relieve CONTRACTOR of
its liability to the CITY for damages.
6. lndependentContractor:
6.1 ln all matters pertaining to this agreement, CONTRACTOR shall be acting as
an independent contractor, and neither CONTRACTOR nor any officer, employee
or agent of CONTRACTOR will be deemed an employee of CITY. Except as
STOREY PARK WELL
Project '10768
page 3 of 13
expressly provided in Exhibit A, Contractor has no authority or responsibility to
exercise any rights or power vested in the City and therefore has no authority to
bind or incur any obligation on behalf of the City. The selection and designation of
the personnel of the CITY in the performance of this agreemenl shall be made by
the CITY.
6.2 Contractor, its agents, officers, and employees are and at alltimes during the
term of this Agreement shall represent and conduct themselves as independent
contractors and not as employees of the City.
6.3 Contractor shall determine the method, details and means of performing the
work and services to be provided by Contractor under this Agreement. Contractor
shall be responsible to City only for the requirements and results specified in this
Agreement and, except as expressly provided in this Agreement, shall not be
subjected to City's control with respect to the physical action or activities of
Contractor in fulfillment of this Agreement. lf in the performance of this Agreement
any third persons are employed by Contractor, such persons shall be entirely and
exclusively under the direction and supervision and control of the Contractor.
Contractor shall require that all of its sub-contractors be licensed per State of ldaho
Statute # 54-1901
8. Removal of Unsatisfactory Employees:
The Contractor shall only furnish employees who are competent and skilled for work
under this contract. lf, in the opinion of the City, an employee of the Contractor is
incompetent or disorderly, refuses to perform in accordance with the terms and
conditions of the contract, threatens or uses abusive language while on City
property, or is otherwise unsatisfactory, that employee shall be removed from all
work under this contract.
9. lndemnification and lnsurance:
9.1 CONTRACTOR shall indemnify and save and hold harmless ClTy and it,s
elected officials, officers, employees, agenls, and volunteers from and for any and
all losses, claims, actions, judgments for damages, or injury to persons or property
and losses and expenses and other costs including litigation costs and attorney's
fees, arising out of, resulting from, or in connection with the performance of this
Agreement by the CONTRACTOR, its servants, agents, officers, employees,
guests, and business invitees, and not caused by or arising out of the tortious
conduct of CITY or its employee s. CONTRACT OR shall maintain.and soecificallv
rees that it will main tn u hout the term IS reement liab il
rnsu rance.in which the CITY shall be na med an additional insured in the minimum
amounts as follow: General Liabili ty One ltlillion Dollars ($1,000,000) per incident
or occurrence, Automobile Liability lnsurance One Million Dollars (91,000,000) per
incident or occurrence and Workers' Compensation lnsurance, in the statutory
STOREY PARK WELL
Project 10768
page 4 of 13
7. Sub-Gontractors:
limits as required by law.. The limits of insurance shall not be deemed a limitation
of the covenants to indemnify and save and hold harmless CITY; and if CITY
becomes liable for an amounl in excess of the insurance limits, herein provided,
CONTRACTOR covenants and agrees to indemnify and save and hold harmless
CITY from and for all such losses, claims, actions, or judgments for damages or
injury to persons or property and other costs, including litigation costs and
attorneys' fees, arising out of, resulting from , or in connection with the
performance of this Agreement by the Contractor or Contractor's officers, employs,
agents, representatives or subcontractors and resulting in or attributable to
personal injury, death, or damage or destruction to tangible or intangible property,
including use of. CONTRACTOR shall provide CITY with a Certificate of
lnsurance, or other proof of insurance evidencing CONTRACTOR'S compliance
with the requirements of this paragraph and file such proof of insurance with the
CITY at least ten (10) days prior to the date Contractor begins performance of it's
obligations under this Agreement. ln the event the insurance minimums are
changed, CONTRACTOR shall immediately submit proof of compliance with the
changed limits. Evidence of all insurance shall be submitted to the City Purchasing
Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue,
Meridian, ldaho 83642.
9.2 lnsurance is to be placed with an ldaho admitted insurer with a Best's rating
of no less than A-.
9.3 Any deductibles, self-insured retention, or named insureds must be declared
in writing and approved by the City. At the option of the City, either: the insurer
shall reduce or eliminate such deductibles, self-insured retentions or named
insureds; or the Contractor shall provide a bond, cash or letter of credit
guaranteeing payment of losses and related investigations, claim administration
and defense expenses.
9.4 To the exlent of the indemnity in this contract, Contractor's lnsurance
coverage shall be primary insurance regarding the City's elected officers, officials,
employees and volunteers. Any insurance or self-insurance maintained by the City
or the City's elected officers, officials, employees and volunteers shall be excess of
the Contractor's insurance and shall not contribute with Contractor's insurance
except as to the extent of City's negligence.
9.5 The Contractor's insurance shall apply separately to each insured against
whom claim is made or suit is brought, except with respect to the limits of the
insurer's liability.
9.6 All insurance coverages for subcontractors shall be subject to all of the
insurance and indemnity requirements stated herein.
9.7 The limits of insurance described herein shall not limit the liability of the
Contractor and Contractor's agents, representatives, employees orsubcontractors.
STOREY PARK WELL
Project 10768
page 5 of 13
10. Time is of the Essence:
The parties hereto acknowledge and agree that time is strictly of the essence with
respect to each and every term, condition and provision hereof, and that the failure
to timely perform any of the obligations hereunder shall constitute a breach of, and
a default under, this Agreement by the party so failing to perform.
11. Bonds:
Payment and Performance Bonds are required on all Public Works lmprovement
Projects per the ISPWC and the City of Meridian Supplemental Specifications &
Drawings to the ISPWC, which by this reference are made a part hereof.
Contractor is required to furnish faithful performance and payment bonds in the
amount of 100% of the contract price issued by surety licensed to do business in
the State of ldaho with a Best's rating of no less than A-. ln the event that the
contract is subsequently terminated for failure to perform, the contractor and/or
surety will be liable and assessed for any and all costs for the re-procurement of the
contracl services.
12. Warranty:
All construction and equipment provided under this agreement shall be warranted
for 2 years from the date of the City of Meridian acceptance perthe ISPWC and the
Meridian Supplemental Specifications & Drawings to the ISPWC and any
modifications, which by this reference are made a part hereof.
All items found to be defective during a warranty inspection and subsequently
corrected will require an additional two (2) year warranty from the date of City's
acceptance of the corrected work.
13. Changes:
The CITY may, from time to time, request changes in the Scope of Work to be
performed hereunder. Such changes, including any increase or decrease in the
amount of CONTRACTOR'S compensation, which are mutually agreed upon by and
between the CITY and CONTRACTOR, shall be incorporated in written
amendments which shall be executed with the same formalities as this Agreement.
14. Taxes:
The City of Meridian is exempt from Federal and State taxes and will execule the
required exemption certificates for items purchased and used by the City. ltems
purchased by the City and used by a contractor are subject to Use Tax. All other
taxes are the responsibility of the Contractor and are to be included in the
Contractor's Bid pricing.
STOREY PARK WELL
Project 10768
page 6 of 13
15. Meridian StormwaterSpecifications:
All construction projects require either a Storm Water Pollution Prevention Plan
(SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of
Meridian Construction Stormwater Management Program (CSWMP) manual_ The
CSWMP manual containing the procedures and guidelines can be found at this
address: http.//www. merid ia ncitv. orq/environ mental. as px?id=1 3618
Contractor shall retain all stormwater and erosion control documentation generated
on site during construction including the SWPPP manual, field inspections and
amendments. Prior to final acceptance of the job by the City the contractor shall
return the field SWPPP manual and field inspection documents to the City for
review. A completed Contractor Request to File Project N.O.T. with the EpA form
shall be provided to the City with the documents. These documents shall be
retained, reviewed and approved by the City prior to final acceptance of the project.
16. ACHD:
Contractor shall be responsible for coordinating with the City to obtain appropriate
ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs
due to Contractols violation of any ACHD policy. City shall certify to ACHD that
Contractor is authorized to obtain a Temporary Highway and Right-of-Way Use
Permit from ACHD on Cily's behalf. The parties acknowledge and agree that the
scope of the agency granted by such certification is limited to, and conterminous
with, the term and scope of this Agreement.
17. Reports and lnformation:
17.1 Al such times and in such forms as the CITY may require, there shall be
furnished to the CITY such statements, records, reports, data and information as
the CITY may request pertaining to matters covered by this Agreement.
17.2 Contractor shall maintain all writings, documents and records prepared or
compiled in connection with the performance of this Agreement for a minimum of
four (4) years from the termination or completion of this or Agreement. This
includes any handwriting, typewriting, printing, photo static, photographic and every
other means of recordlng upon any tangible thing, any form of communication or
representation including letters, words, pictures, sounds or symbols or any
combination thereof.
18. Audits and lnspections:
At any time during normal business hours and as oflen as the CITY may deem
necessary, there shall be made available to the CITY for examination all of
CONTRACTOR'S records with respect to all matters covered by this Agreement.
CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or
transcripts from such records, and to make audits of all contracts, invoices,
materials, payrolls, records of personnel, conditions of employment and other data
STOREY PARK WELL page 7 of 13
Project 10768
relating to all matters covered by this Agreement.
19. Publication, Reproduction and Use of Material:
No material produced in whole or in part under this Agreement shall be subject to
copyright in the United States or in any other country. The CITY shall have
unrestricted authority to publish, disclose and otherwise use, in whole or in part, any
reports, data or other materials prepared under this Agreement.
20. Equal Employment Opportunity:
ln performing the work herein, Contractor agrees to comply with the provisions of
Title Vl and Vll of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code
Section 2176. Specifically, the Contractor agrees not to discriminate against any
employee or applicant for employment because of race, color, religion, sex. national
origin, age, political affiliation, marital status, or handicap. Conlractor witl take
affirmative action during employment or training to insure that employees are
treated without regard to race, color, religion, sex, national origin, age, political
affiliation, marital status, or handicap. ln performing the Work required herein,
CONTRACTOR shall not unlaMully discriminate in violation of any federal, state or
local law, rule or regulation against any person on the basis of race, color, religion,
sex, national origin or ancestry, age or disability.
21. Employment of Bona Fide ldaho Residents:
Contractor must comply with ldaho State Statute 44-1002 which states that the
Contractor employ ninety-five percent (95%) bona fide ldaho residents.
22. Advice of Attorney:
Each party warrants and represents that in executing this Agreement. lt has
received independent legal advice from its attorney's or the opportunity to seek such
advice,
23. Attorney Fees:
Should any litigation be commenced between the parties hereto concerning this
Agreement, the prevailing party shall be entitled, in addition to any other relief as
may be granted, to court costs and reasonable attorneys'fees as determined by a
Court of competent jurisdiction. This provision shall be deemed to be a separate
contract between the parties and shall survive any default, termination or forfeiture
of this Agreement.
24. ConstructionandSeverability:
lf any part of this Agreement is held to be invalid or unenforceable, such holding will
not affect the validity or enforceability of any other part of this Agreement so long as
the remainder of the Agreement is reasonably capable of completion.
STOREY PARK WELL Page I of 13
Project 10768
25. Waiver of Default:
Waiver of default by either party to this Agreement shall not be deemed to be waiver
of any subsequent default. Waiver or breach of any provision of this Agreement
shall not be deemed to be a waiver of any other or subsequent breach, and shall
not be construed to be a modification of the terms of this Agreement unless this
Agreement is modified as provided above.
26. Entire Agreement:
This Agreement contains the entire agreement of the parties and supersedes any
and all other agreements or understandings, oral of written, whether previous to the
execution hereof or contemporaneous herewith.
27. Assignment:
It is expressly agreed and understood by the parties hereto, that CONTRACTOR
shall not have the right to assign, transfer, hypothecate or sell any of its rights under
this Agreement except upon the prior express written consent of CITY.
28. Payment Request:
Payment requests shall be submitted to City of Meridian through the City's project
management soft\rare. The Project Manager will compare the invoice against the
Payment Schedule in the Agreement for compliance. Upon approvalthat the work
has been done and is in compliance with the Agreement, the Project Manager will
approve the pay request for processing. City of Meridian payment terms are Net 30
from the date City receives a correct invoice. Final payment will not be released
until the City has received a tax release from the Tax Commission.
29. Cleanup:
Contractor shall keep the worksite clean and free from debris. At completion of
work and prior to requesting final inspection, the Contractor shall remove all traces
of waste materials and debris resulting from the work. Final payment will not be
made if cleanup has not been performed.
30. Order of Precedence:
The order or precedence shall be the contract agreement, the lnvitation for Bid
document, then the winning bidders submitted bid document.
31. Compliance with Laws:
ln performing the scope of work required hereunder, CONTRACTOR shall comply
with all applicable laws, ordinances, and codes of Federal, State, and local
governments.
STOREY PARK WELL
Project 10768
page I of 13
32. Applicable Law:
This Agreement shall be governed by and construed and enforced in accordance
with the laws of the State of Idaho, and the ordinances of the City of Meridian.
33. Notices:
Any and all notices required to be given by either of the parties hereto, unless
otherwise stated in this agreement, shall be in writing and be deemed
communicated when mailed in the United States mail, certified, return receipt
requested, addressed as follows:
CITY
CONTRACTOR
City of Meridian
STEVENS & SONS WELL DRILLING, INC,
Purchasing Manager
Attn: Ron Stevens
33 E Broadway Ave
3709 N Hawthorne Dr.
Meridian, ID 83642
Boise, ID 83703
208-489-0417
Phone: 208-344-0726
Ernail: ron
Stevensdrilling@g mail, corn
Idaho Public Works License # C -'12526-B-4
Either party may change their address for the purpose of this paragraph by giving
written notice of such change to the other in the manner herein provided.
34. Approval Required:
This Agreement shall not become effective or binding until approved by the City of
Meridian.
CITY OF_ 1AN---- STEVENS & S fI LING, INC.
B
BY: Y:
TAMMY de RD, MAYOR
Dated: -/1/7 Dated:
Approved by Council: AV Ifl A/7
b9 -
Attest:
c'hy of
C.JAY tOLES UIT'CLERK ERMAN&,—
\ ! �"o
SEAL
STOREY PARK WELL page 10 of 13
Project 10708
Purchasing Approval
BY:
KEITH ATTS, Purchasing Manager
Dated B ./O- t 1
Project Manager
Mike Barton
STOREY PARK WELL
Project 10768
Depa nt p
BY:
IVIIKE N, PA s Superintendent
Dated::-1-t1
page11of13
lt )
")4t
EXHIBIT A
SCOPE OF WORK
REFER TO INVITATION TO BID PKS-1746.10768
ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS inctuded in the
lnvitation to Bid Package # PKS-I746-10768, are by this reference
made a part hereof.
SPECIFICATIONS / SCOPE OF WORK
All construction work shall be done in accordance with the current version
of the ldaho Sfandards for Public Works Construction (ISPWC), the 2013
City of Meridian Supplemental Specifications to the ISPWC (and any
Addendums).
See separate attached documents:
SPECIAL PROVISIONS/TECHNICAL SPECIFICATIONS by
SPF Water Engineering dated February 2017 (27 of pases)
a
STOREY PARK WELL
Proiect 10768
page 12 ol 13
Exhibit B
MILESTONE / PAYMENT SCHEDULE
Total Bid Schedule A $59,5s0.00
NOT TO EXCEED CONTRACT TOTAL $59.500J0
MILESTONE DATES/SCHEDULE
Mrlestone 1 Final Completion 90 Days from Notice to Proceed
PRICING SCHEDULE
Contract includes furnishing all labor, materials, equipment, and incidentals as required for the
STOREY PARK WELL per IFB PKS-1746-'10768
Con
add i
tract is a not to exceed amount. Line item pricing below will be used for invoice verification and any
tional increases or decreases in work requested by city. The city will pay the contractor based on
actual quantities of each item of work in accordance with the contract documents
Contract Prici Schedule
Description Quantity Unit Unit Price
1 Mobilization and demobilization 1 LS 4,000.00
25Q LF
3 tnGehical I
Drill borehole
1
22.500.00
2,500.00
4 Furnish and install S" steel well casinq 22 LF 660.00
5 Furnish and insta ll 8' PVC well casing 190 LF 5,700.00
6 Furnish and install 8" well screen 6,400.00
7 Furnish and install sand filter ack 60 LF
8 Furnish and install annular well seal LF
2,280.00
6.650.00
o Well develo ent 16 PH 4,480.00
10 1 2,500.00
11 8 PH 1,320.00
Ri time 2 PH 560.00
STOREY PARK WELL
Project 10768
page 13 of 13
A. Total and complete compensation for this Agreement shall not exceed $59,550.
I
2
190
Item No.
40 lLFl
FuJnish, install, and remove test pump
Test pumpinq
E IDIAN
IDAH()
BID NAME: Sto Park Well DUE DATE & TIME: Jul 27,2017 2:3O
BID NUMBER: PKS-1746-10768
Opened
Attest:
VEN DOR
E
!@
dt =
BID AMOUNT
5(Vlet-h < lon r'r'5a,550
Oo5 AZIWIF.E't/,/t/r'(IIIIIIIIIIIIIIIITITIIIIIIIIIIIIIIIIIIIII
TSII
BID RESULTS
L]
Cj.ty Of Melidr.arr
Statement of Revenues and Expenditures - Rev and Exp Report - Sandra - Unposted Transactions Tncluded Io Report
01 - cenelal E\rnd
5200-Palks-Admin
Frotr, 10/1/2A16 Through 9/30/2017
Budget with
Actual
Budgel
Remaining
Capital outlay
Ir.prov-ments G Storey P.r k
Totaf Capita L Outlay
13 0, 131 . 13
13 0, 131 . 13
0. 00
0.00
130-131.13
130-131. 13
1Q0.003
100.00*
Percent of
Budget
Renaining
93405
DEPT EXPENDITURES
TOTAL EXPENDITURES
130,131.13
I30, 131 . 13
0. 00
0. 0(l
13 0, 131 . 13
130,131.13
100.00r
t (
s9100
(
CITY OF MERIDIAN
STOREY PARK WELL
BID ABSTRACT
BID OPENING 7/27/2017
Item
No.Description Qty Unit Unit
Price
Bid Item
Total
Unit
Price
Bid Item
Total
1 Mobilization and demobilization 1 LS 15,000.00$ 15,000.00$ 4,000.00$ 4,000.00$
2 Drill borehole 250 LF 200.00$ 50,000.00$ 90.00$ 22,500.00$
3 Geophysical logging 1 LS 3,500.00$ 3,500.00$ 2,500.00$ 2,500.00$
4 Furnish and install 8” steel well casing 22 LF 22.00$ 484.00$ 30.00$ 660.00$
5 Furnish and install 8” PVC well casing 190 LF 25.00$ 4,750.00$ 30.00$ 5,700.00$
6 Furnish and install 8” well screen 40 LF 120.00$ 4,800.00$ 160.00$ 6,400.00$
7 Furnish and install sand filter pack 60 LF 50.00$ 3,000.00$ 38.00$ 2,280.00$
8 Furnish and install annular well seal 190 LF 35.00$ 6,650.00$ 35.00$ 6,650.00$
9 Well development 16 PH 350.00$ 5,600.00$ 280.00$ 4,480.00$
10 Furnish, install, and remove test pump 1 LS 3,500.00$ 3,500.00$ 2,500.00$ 2,500.00$
11 Test pumping 8 PH 225.00$ 1,800.00$ 165.00$ 1,320.00$
12 Rig time 2 PH 350.00$ 700.00$ 280.00$ 560.00$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
-$ -$ -$ -$
TOTAL BASE BID 99,784.00$ 59,550.00$
POST DRILLING INC STEVENS & SONS
@ Swiss Re
Corporate Solutions
KNOW ALL BY THESE PRESENTS, thAt WC,Stevens & Sons Well Drillino, lnc
North Americsn Specialty lnsurance Company
Washington International In6uran€e Compaly
Westpo lDsurance Corporation
1450 America[ I"ane, Suite 1100
SchaumbErS, lL 50173
Bond#
2259018
as Principal, and
as Surety, are held and firmly bound untoNorth American S oe oa Itv ln surance Com anD
City of Meridian
Fifty Nine Thousand Five Hundred Fifty Dollars and 00/100 Dollars ($59.550.00
whereof said Principal and Surety bind themselves, jointly and severalln as provided herein.
- as obli gee, in the penal sum of
) for the p alment
WHEREAS, Principal has entered into a contract with Obligee dated
Storey Park Well
Auq ust 15, 2017 for
("Contract"), which is incorporated herein by reference for the
limited purpose ofdefining the scope ofthe Construction Work.
NOW, THEREFORE, the condition of this obligation is such that if Principal promptly and faithfully performs the
Construction Work, then this obligation shall be null and void; ot]erwise to remain in fulI force and effect.
IT IS FURTHER PROVIDED, that:
1. The obligation of Surety under this bond ("Bond") shall arise only when all the following conditions have been met:
(A) The Obligee has fi:lfilled its obligations under the Conhacq and
@) Principal is, and Obligee has declared Principal to be, in material default under the Contract for failing to
perform the Construction Work ("Principal's Default'); and
(C) Obligee has terminated the Contract and notified the Surety in writing of Principal's Default
and such termination.
2. When a[[ the conditions in Section I are met, Surety shall have a reasonable period of time to investigate and elect at
its sole discretion one ofthe following remedies:
(A) Notiff Obligee that Surety elects to complete lhe performance ofthe Construction Work through conhactor(s)
retained by Surety and then commence such performance with reasonable promptness. h this event, that
portion ofthe Contract Balance as may be required !o complete the Construction Work or remedy Principal's
Default and to reimburse Surety for its expenditures shall be paid to Surety at the times and in the manner as
said sums would have been payable under the Contract to Principal had there been no Principal's Default; or
(B) Notiry Obligee that it elects to arrange for a contract between Obligee and a replacement contractor acceptable
to Obligee, such acceptance not to be unreasonably withheld, guaranteed by both contract payment and
performance bonds provided by the replacement contractor in the amount ofthe replacement contract. kl this
event, Surety shall pay Obligee that portion of the cost of the replacement contractor that is in excess of the
Contract Balance. Such payment(s) may be made to Obligee in a lump sum (in the event of a lump sum
contract) or periodically as incurred by Obligee; or
(C) Request Obligee to complete the Construction Work. In this event, Surety shall pay Obligee that portion of
the reasonable cost to complete the Construction Wort incurred by Obligee that is in excess of the Contract
Balance; or
KRcv.04/17 Pagc I of3
PrnronvuNcE BoND
(D) A"rrange to give assistanee, financial or otherwise, !o the Principal to assist the Principal with completing the
Conshuction Work. This remedy shall be zubject to Obligee's agreement, which shall not be unreasonably
withheld. The Obligee shall pay the Conhact Balance as directed by Surety. In the event Surety provides
financial assistance, Swety, in its sole discretion, may upon written notice to Obligee cease providing such
financial assistance at any time, in which event Surety shall immediately make a further election under this
Section 2; or
(E) Noti$, the Obligee that Suety denies liability. Surety shall cite its reasons for the denial ofliability; or
(F) After investigation, determine the amount for which Surety may be liable to the Obligee and as soon as'
reasonably possible aller the amount is determined, make paymeni to the Obligee.
3. After Obligee has provided Surety with written notice of Principal's Default, and before the commencement of
work under Section 2, subparagraphs (A) or (B), Obligee may, pursuant to its Contract dghts, mitigate the damages
caused by the Principal's Default. If Obligee performs obligations under the Conhact during this period, Obligee
shall be entitled to deduct the Mitigation Costs from the Conhact Balance. If the Contract Balance is exhausted,
and Surety elects to proceed under Section 2, subparagraphs (A), (B), (C) or @), Surety shall reimburse Obtigee
for the difference between the Contract Balance and the Mitigation Costs incurred and paid by Obligee.
4. If Surety proceeds under Section 2, zubparagraphs (A), (B), (C), @) or (F), Surety may also advise in the notice of
its remedy election to Obligee that the Obligee's claim is disputed as to liability aDd/or amount and Surety is
proceeding under and asserting a reservation of all rights, remedies, claims, and defenses. In the event Surery
prevails, in whole or in part, with respect to the dispute regarding liability and/or amount of Obligee's claim and
Surety paid monies in excess of the funds paid by Obligee to Suety, then Surety shall be entitled to recover the
excess from Obligee.
Surety's aggregate liabilityunder this Bond is limited to the penal sum ofthis Bond, regardless ofwhether the liability
arises from the actions or inactions of Principal or Surety. The penal sum of this Bond shall be reduced by and to the
extent of any and all monies paid by Surety under this Bond in excess of funds paid by Obligee to Surety. If Surety
paid monies in excess ofthe penal sum ofthis Bond, then Surety shall be entitled to recover the excess monies liom
Obligee. The Surety waives notice ofany change to the Contract.
5
6. Definitions:
(A) The phrase "Contract Balance," means the total amount payable by Obligee to Principal under the Contract
and any amendments thereto, less the amounts properly paid by Obligee under the Cootract.
(B) The phrase "Mitigation Costs" means the cost actually incurred by Obtigee in proper performance of the
Construction Work. Such costs shall be at hours and rates not higher than those Customarily incurred at the
place ofthe Construction Work rmless Suety provides its prior written consent
(C) The phrase "Conshuction Work" means all labor and materials necessary to complete Principal's scope
ofwork under the Contract
7. Any suit or action by Obligee under this Bond must be instituted within one (l) year from the earliest of the following
dates: (A) the date of substantial completion of the Constnrction Work; (B) the date Principal ceased performing thi
Construction Work; or (C) the date of Principal's Default. If the limitation period set forth in this Bond is void or
prohibited by law, then the minimum limitation period available to sureties as a defense in the jurisdiction ofthe suit
or action shall apply and shall be deemed to have accrued and commenced. to run on thi earliest of the dates
referenced in this Section 7 (A), (B) and (C). It shall be understood that in no event shall punch list, waranty, or
maintenance work constitute Construction Work for the purpose of determining the limitation period for filing a suit
or action under this Bond.
Rcv, 04/l7
Page 2 of3
8. No prejudgment or pre-award interest may be recovered under this Bond. Post judgnrent interest shall be calculated
from the date of the entry of the judgment, at a rate equal to the weekly average l -year constant maturity Treasury
yield, as published by the Board ofGovernors ofthe Federal Reserve System, for the calendar week preceding the date
of the judgment.
9. The Obligee is the sole beneficiary under this Bond. No right ofaction shall accrue on this Bond to or for the use
ofany person other than the Obligee. This Bond is not transferable without the express written consent of Surety, and
no successor or assignee ofobligee shall have any rights under this Bond. Any suit or action under this Bond shall be
instituted in a State orFederal court ofcompetentjurisdiction in the location in which the Construction Work is situated.
10. Notwithstanding any'thing in this Bond or the Contract to the conhary, Surety shall have no liability to Obligee for:
legal fees or costs; any form ofconsequential, indirect, punitive, or exemplary damages; or any liability ofPrincipal for
tortious acts, whether or not said liability is direct or imposed by the Subcontract or otherwise. Nor shall this Bond
serve as or be a substitute for or supplemental to any insuance coverage required under the Subcontract.
I l. Notice or demand given to Surcty pursuaDt to this Bond shall be in writing and delivered to the following mailing
address or email address:
Swiss Re Corporate Solutions - Surety Claims
1450 American Lane, Suite I100
Schaumburg, IL 60173
SuretyClaimsNA_CorporateSolutions@swissre.com
Signed this-lllL day of August , 2017
WelStevens & Son Dri
--/
by
ame:5t<Je,>rdc-.CTitlc: 1,,.:
North American S
by lL
Brenda J. Smit
al lnsurance Com
Surety
Atton
STAL
i!73
Page 3 of3
Y;fciyirrt
l<,
Rev.04/17
@ Swiss Re
Corporate Solutions
LABORAND MATERIAL PaymnNT BoND
KNOW ALL BY THESE PRESENTS, thAt WC,Stevens & Sons Well Drillino, lnc
North American So ecial lnsu rance ComDanv Surety are
North American Specialty Insuialce CoDpany
Washington Intemational lNura[ce CoDpany
Iy€stport Insuratrce Corporatlon
1450 Ameri(an lane, Suite ll00
Schaumburg, IL 60173
Bond#
2259018
,as hincipal, and
as held and firmly bound unto
CitV of Merldian as Obligee, in the penal sum of
Fiftv Nine Thousand Five Hundred Fiftv Dollars and 0 100 Dollars
$ 59,550.00
WHEREAS, Principal has eDtered iDto a contract with Obligee dated
Storey Park Well
) for the p&ymenl whereof said Prircipal and Surety bind themselves, jointly and severally, as provided herein.
Auoust 15, 2017 for
("Contract"), which is
incorporat€d herein by reference for the limited purpose oldefining the scope ofthe Construction Work
NOw, THEREFORE, the condition of this obligation is such ftat if Principal promptly makes payment of all sums due to Claimants fo!
labor, materials or rental equipmeot actually used, consumed or incorporated in the performance of the Conskuction Work, then Surety and
Principal shall have no obligatiofl under tiis Bond ("Bond").
lT IS FURTHER PROVIDED, thatr
l. The obligation of Surety unde! this Bond shall arise only when all the following conditio$ have been met;
(A) Claimant has, within ninety (90) days of Claimant's last fumishiog of taboq materials, or rental equipment in the perfonnance of
the Constructiol Work, provided wdtleD notice of nol-payment lo Principal, Surety (at the addrcss identified or this Bond) and
Obligee stating with substantial accuracy the amount claimed and tho name of the party to whom the labor, materials, or rcntal
equipment was fumished; and
(B) Claimast has fumished a Prcof of Claim to Surcty along with th€ following:
(i) A written statement including the name ofClaimant, the amount ofthe claim, the name ofthc party to whom the labor, materials,
or rental equipment was fumished, a bdef dessriptioo of the labor, materials, or rEntal equipBent fumished, and the date on
\a,hich Claimant last fumished such labor, rnaterials, or rcntal equipmeot for use in the perfomarce ofthe Construction Work;
and
(ii) A copy ofthe agreemen! coDtiact orpuchase order pursuant to which Claimant ftmished labor, materials, or rental equipment
for usc ill the performance of the Conskuction Work; and
(iii) A statement ofaccouot showing the total amount eamed by Claimant, the amount of previous paynents received by Claimant,
and the total amount due aod unpaid to Claimanq and
(iv) Copies ofall unpaid invoices for which Claimant is making the claim.
2. No suit or action shall be commenced by Claimant under this Bond after the expiration ofone (l) year from the date on which Claimant
last fumished labor, materiols, or rcDtal equipmert foruse in the performonce ofthe Conskuction Work, Ifthe limitatiotr period set forth
in this Bond is void or prohibited by law, then the minimum limitation pedod available to sueties as a defense in thejurisdiction of the
suit or actiorl shall apply and shall be deemed to have accrued and commenced to run on the date on which Claimant last furnished the
labor, matcrial, or rcntal equipment for which Claimant is making the claim. For purposes of dctermining the limitation pcriod,
performance ofthe CoNtruction Work shall not include punch list, warranty, or maintenance work.
Notwithstanding anrthing in this Bond or the Contract to the contrary, SuEty shali have no liability to Claimant for legal fees or costs or
any form ofconscqucntial, indirect, punitivc, or exemplary damages. No prcjudgmcut or pre-award interest may be recovered undcr tbis
Bond. Postjudgment itrtercst shall be calculated from the datc of the entry of thc judgme[! at a rate equal to thc weekly avcrage l -ycar
constant maturity Trersury leld, as published by the Board ofGovemors ofthe Federal Reserve System, for the caleDdar week preceding
the date of the judgncnt.
3
Rev.04/17 Page I of2
4. The aggregate tiability of Surety under this Bond shall not exceed the penal sum ofthis Bond; aod the penal sum of this Bond shall be
rcduced by and to the extent ofall pa).menls made by Surety under this Bond.
5. Any suit or action under this Bond shallbe instituted in a State or Federal Court of competent jurisdiction in the location in which the
CorNtructiol Work is sih]ated. No dght of action shall accrue on this Bond to or for the use of any individual or entity othcr thatr a
Claimant. This Bond is not raDsferable.
6. Notice or demand giver to Surety pursuant to this Bord shall be in writing and delivered to the following mailing address or email
address:
Sx.iss Re Corporate Solutions - Sulety Claims
1450 Americar Lane, Suite I100
Schaumburg, IL 60173
SuretyClaimsNA_Corporatesolutions@swissr€.com
Delinitions
(A) The words "claimant" and "claimants" mean one or more individuals or entities having a dircct contract with Principal or with 8
subcontractor ofPri[cipal for labor, material, or rental equipment actually used, consumed or incorporated in the performance ofde
Construction Work.
(B) The. phrase-"Construction Work'r means all labor, materials, and rental equipment necassary to complete Principal's scope of work
under the Contract.
Signed and sealed this 15th day of Au USt A.D., 2017
IN THE PRESENCE OF:
Stevens & Sons Well Drillino, lnc,
by
Zun S/av q,s
p -es, J--C
Name:
Title:
North American S lnsurance
Surety
by
Bre J. Smith Attome;.
Rev.04/17 PaEc2olZ
/-lnncip* .
)Z ,/)
)1973
S}VISS Rf, CORPORATE SOLUTIONS
NORTH AMERICAN SPECIALTY INSURANCE COMPA}IY
WASHINGTON INTERNATIONAL INSURANCE COMPAI.IY
GENERAL POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS, THAT North American Specialty Iruurancc Company, 8 corporatior duly organized and existing under
la\rs ofthe State ofNew Hampshire, and hsving its principal office in the City ofoverland Parlq Kansas, and Washington Intemational Insurance
Company, a corporatioo organized and existing under the laws of thc Slste ofNew Hampshire and haviog its principal ollice in the City ofoverland
Par*, Kansas. each does hercby make, conslitute and appoinr Brenda J. Smith
Principal: Stevens & Sons Well Drilling, Inc. Bond Number:2259018
Obligee: City of Meridian Bond Amount: See Bord Form
Bond Description! Storey Park Well
Its tue and lawful Attomey-in.Fact, to make, execute, seat and deliver, for and orl its behalfand as its act and deed, bonds or other writings
obligatory in the nature ofa bond on behalf of each ofsaid Companies, as surety, on coltracts ofsuretysbip as are or may be required or permitted by
law, r€gulation, cont'act or otherwise, provided that no bond or undedaking or contract or suetyship executed under this authority shall e\ceed the
amount of: FIFTv MILLIoN ($50,000,000.00) DoLLARS
This Power ofAnomey is gmnted and is signed by facsimile under and by the authority ofthe following Resolutions adopted by the Boards of
Directors ofboth North American Specialty Insurance Company and Washington Intemational Insurance Company at meetings duly called and held
on the 96 ofMay,20l2:
"RESOLVED that any two ofthe Presidents, any Maraging Dircctot ary Senior Vica Pre8ident, any Vice President, any Assistant Vice Prcsident,
the Secretary or any Assistant Secrelary be, and each or any ofthem hereby is authorized to execute a Power ofAttomey qualiling the attomey named
in the given Power ofAttorney to execute on behalfofthe Company bonds, undertakings and all contracts ofsurety, and that each or any of them
hereby is authorized to attest to the execution ofany such Power ofAttomey and to attach therein lhe seel ofthe Compaay; and it is
FURTHER RESOLVED, that thc signaturr ofsuch officers and the seal ofthe Company may be allixed to any such Powcr of Attomcy or to any
cenificate relating thereto by facsimile, and any such Power of Attomey or certificate bearing such facsimile signalures or facsimile seal shall be
binding upon the Company when so alfixed and in the future witi r€gard to any bond, undedaking or contract ofsurety to which it is attached,"
By
SEAL Sl.r., P. And.fun, Sdhr Vk fr.dd.nl of \Yinlnetor IntE.!.I@.| l!!unn.! CoDp.ny
& 9rior vl.. ?Gld. or,lodh Am.ner Spfti.lty ltuuon.. Cohprn,
By
& S.rhrvlc. PFdd.nr.rN.nn Amr|.ln Spsl.lty l unroCMp.n,
IN WITNESS WHEREOF, North American Specialty Insurance Company and \Yashington Intemational Insurance Company have caused their
official seals to be hereunto affixed, ard these presents to be signed by their authorized omcers this ]![day of November 20t6.
North American Specialtv Insurance Comprn!'
Washington International Insurance Company
State oflllinois
County of Cook ss
On this !![ day of November 2O-!!- before me, a Notary Public personally appeared Steven P. Anderson , Senior Vice President of
Washington Intemational ltrsuraocr Company and Senior Vice Prcsident ofNorth AmericaD Specialty Insuranc! Company and Michael A. ho .
Senior Vice President ofWashington Intemational Insurance Company and Senior Vice President ofNorth American Specialty Insurance
Company, personally known to me, who being by me duly swom, acknowledged that th€y signed the above Power ofAltomey as oflic€rs ofand
acknowledged said instrument to be the volunhry act and deed oftheir respective companies.
M. Kenny, Notary Public
I, Jeffr€v Goldberg . the duly clcctcd AssistantSccretary of No.th American Specialty Imurance Company and Washingtot
Intemational Insurancc Company, do hcrcby ccrtify that thc above and foregoing is a true aod corrcct q{py ofa Power of Attomcy givcn by said No.th
American Specialty Insu.anc€ Company and Washington Intemational Insurance Company, which is still in ftll force and cffect.
IN WITNESS WHEREOF, I have set my hand and aflixed the seals ofthe Companies this 15th day of August ,2ol'l
SEAL
*
MY @lillrlssloN OGIHES 1
OFFIOAI. SEIL
lil I(EIINY
NOTABY H.EJC, SIAIE OF IINOS
,cftGy Coldb.tE Vk. Pcltat & A$hknr S.ctl.ry or
W6hingI@ Lrcmii@l IBul.G Chpsy & Nafi Ar6im Sfct.lry lNuac! CnFry
"4f**-
STEV&SO41
CERTIFICATE OF LIABILITY INSURANCE
R
DATE {MM/OO'iYYY)
08t02t2017
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER, THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, ANO THE CERTIFICATE HOLDER.
IMPORTANT: lf the certiticate holdor is an ADDITIONAL INSURED, the polioy(ios) must havo AOOITIONAL INSURED provisions or bo 6ndorsed.
It SUBROGATION lS WAIVED, subjoct to the lormsand conditions ofthopolicy, certain policios may roquiro an ondoBomont. Astatemonton
this Gortificate doos not confer rights to tho certiticato holdor in lieu ot such ondorsomoht(s).
fil, *.r,(zoa) lz+-zsss
INSURERIS) Af FOROIIiG COVERAGE
]NSUREO
N
PHONE (208l. 424-29OO
INSIJRER C
Boise Oftico
Paynowost lnsuranco, lnc.
960 Broadway Avonue Suite 100
Boise, lD 83706
rNsuRER a rContinental Western lnsurance Company
tNsuRER I :ldaho state lnsurance Fund
Stevon6 & Sons Wirll Diilling, lnc.
3709 Hawthorne Drive
Boiso, lO 83703
INSURER D
INSURER E
ITISURER F
VERA RTIF tst ER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTEO BELOW HAVE EEEN ISSU EO TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWTHSTANOING ANY REQUIREMENT, TERIVI OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO VV}IICH THIS
CERTIFICATE IVAY BE ISSUEO OR MAY PERTAIN, THE INSURANCE AFFOROED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL TH E TERMS.
EXCLUSIONS ANO CONDITIONS OF SUCH POLICIES, LIirlITS SHOWN MAY HAVE BEEN REDUCEO BY PAID CLAIMS,
'lS wpE oF rNsrrRlxcE i.?"o.t ""V,"S poLrcy NUTBER ,ISHBLffi, ,!9H9",'i€, ,*,r"
, EACH OCCURRENCE , S
DAMAGE TO RENTED
iE8lMlsES (Ea (rlfcloeL s
LUED ExP (any one peMn) , S
PE&SoNAL & ADrr' !!!!L . $
. GEN€RAL AGQ8qQ!]E , 5
PROOUCTS COMP/OP AGG $
1,000,000
300,000
ao,ooo
1,000,000
2,000,000
2,000,000
cPA2691959-31 06t01t2017 06t01t2018x
S
A X couueacnl cENERAL LrABrLrry
cLArMs MAoE X occuR
GEN'L AGGREGATE LIMIT APPLIES PER
I "o,"" ix- 5$9 [ ] .o"
I orxen
OWNED
AUTOS ONLY
HIRED
AUTOS ONLY
] COMBINEO SINGLE LIMII
!E! lcqdrot]
060112018 BoDtLy TNJURv iperpsm)
l
,,000,000
c PA269't 959-3 t
s
x s
$
s
5
o6t01t2017
BOD LY N.]URY
A ourocoE,...,o.,.'tt
(Pera@,denl)
X occua
I "*,rr-r^0,
LE
l$
$
'1,000,000
1p00,ooocPA2691959-31 06101t2017 06101t2014
lo.oTl*.r.^.,L*i
A UMARELLA LIAB
X ExcEss LraB
EACH OCCURRENCE
AGGREGA'TE
519761
B
o4to1t20't7 04t01nua
E L D]SEASE POL]CY LIMIT
STATLJTE
OTH.
]ER
llEAC c DE NI 1,000,000
EL DSEASE.EAEIiPLOYEE, S
x
1,000,000
't,000,
ANY PROPRIETOR/PARTNER/EXECUTIVE
OFFICER/MEMBER EXCLUOEO'(M.nd.lory In NH)
OF OPERATIONS below
WORKERS COMPENSATION
ANO EMPLOYERS' LIAAILIIY
DESCRmO OF OPERATIONS / LOCATIOI|S / VEHICLES (ACORD 101, A.L!t ond Rl !r.rb S.fi.dul., m.y b..tbcrrld il moE.p.o is Eq!tuld)
Prorcot . Storey Park Wcll
c TION
O 1988-2015 ACORD CORPORATION. All rights reserveq. v
Tho ACORD name and logo are registared marks ot ACORO m\
SHOULO ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVEREO IN
ACCORDANCE WTH THE POLICY PROVISIONS-City ol Moridian
Purchasing Manager
33 E Broadway Ave.
Moridian, lD 83&{2
lvL
AUTHORIZEO REPRESENIAIIVE
ACORD 25 (2016/03)
,-l,ACORD
10804
3512s
SCIEDULED
AUTOS
NON,OWNED
AUTOS ONLY
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
GENERAL LIABILITY ULTRA PLUS ENDORSEMENT
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SUMMARY OF COVERAGE EXTENSIONS
The above is a summary only. Please consult the specific provisions that follow for complete information on the
extensions provided.
The provisions of the Commercial General Liability
Coverage Part apply except as olherwise provided in
this endorsement. This endorsement applies only if
such Coverage Part is included in this policy.
A, MISCELLANEOUSADDITIONALINSUREDS
1. Section ll - Who ls An lnsured is amended
to include as an insured any person or
organization (referred to as an additional
insured below) described in Paragraphs
A.1.c.(1) through A.1.c.(8) below when you
and such person or organization have agreed
in writing in a contract or agreement that
such person or organization be added as an
lncludes copyrighted material of lnsurance Services Office, lnc.,
with its permission
COMMERCIAL GENERAL LIABILITY
cL cG 04 92 09 16
additional insured on your policy, provided
that:
a. The written contract or wrilten agreement
is:
(1) Currently in effect or becoming
effective during the term of this
policy; and
(2) Fully executed by you and the
additional insured prior to the "bodily
injury", "property damage" or "per-
sonal and advertising injury".
Provision Name Of Coverage Extension lncluded or Limit of
lnsurance
A Miscellaneous Additional lnsureds lncluded
B Expected Or Intended lnjury Or Damage lncluded
c Knowledge Of Occurrence lncluded
D Legal Liability - Damage To Premises Rented To You (Fire, Lightning,
Explosion, Smoke, Or Leakage From Automatic Fire Protective Systems)
$300,000
Medical Payments $ 1 0,000
F Mobile Equipment Redefined lncluded
G Newly Formed Or Acquired Organization, Partnership Or Limited Liability
Company And Extended Period Of Coverage
lncluded
H Who ls An lnsured - Amendment lncluded
t.Non-Owned Watercraft (lncreased to maximum length of less than 51
feet)
lncluded
J Supplementary Payments - lncreased Limits
1. Bail Bonds
2. Loss Of Earnings
$ 3,000
$ I ,000
K Unintentional Omission Or Unintentional Error ln Dasclosure lncluded
L Waiver Of Transfer Of Rights Of Recovery Against Others lncluded
M Liberalization Clause lncluded
N lncidental Medical Malpractice lncluded
cL cG 04 92 09 16 Page 1 of 7
E,
b. The insurance afforded by this provision
does not apply to any person or
organization included as an additional
insured by a separate endorsement
issued by us and made a part of this
policy or coverage part.
c. Only the following persons or organi-
zations are additional insureds under this
provision, with coverage for such
additional insureds limrted as provided
herein:
(1) Managers Or Lessors Of Premises
A manager or lessor of premises but
only with respect to liability arising
out of the ownership, maintenance or
use of that part of the premises
leased to you and subject to the
following additional exclusions:
This insurance does not apply to:
(a) Any "occurrence" which takes
place after you cease to be a
tenant in that premises.
(b) Structural alterations, new con-
struction or demolition operations
performed by or on behalf of
such additional insured.
(2) Mortgagee, Assignee Or Receiver
A mortgagee. assignee, or receiver
but only with respect to their liability
as mortgagee, assignee, or receiver
and arising out of the ownership,
maintenance, or use of a covered
premises by you.
This insurance does not apply to
structural alterations, new con-
struction or demolition operations
performed by or on behalf of such
additional insured.
(3) Owners Or Other lnterests From
Whom Land Has Been Leaaed
An owner or other interest from
whom land has been leased to you
but only with reEpect to liability
arising out of the ownership, mainte-
nance or use of that part of the land
leased to you and subject to the
following additional exciusions:
This insurance does not apply to:
(a) Any "occunence" which takes
place after you cease to lease
that land.
(b) Structural alterations, new con-
struction or demolition opeaations
lncludes copyrighted material of lnsurance Services Office, lnc.,
with its permission
performed by or on behalf of
such additional insured.
(4) Lessor Of Leased Equipment
Any person(s) or organization(s)
from whom you lease equipment but
only with respect to liability for "bodily
injury", "property damage" or "per-
sonal and advertising injury" caused,in whole or ln part, by your
maintenance, operation or use of
equipment leased to you by such
person(s) or organization(s).
A person's or organization's status
as an additional insured under this
endorsement ends when their written
contract or written agreement wth
you for such leased equipment ends.
This insurance does not apply to any
"occurrence" which takes place after
the equipment Iease expires.
(5) State, Municipality, Govemmental
Agency Or Subdivision Or Other
Political Subdivision - Permits Or
Authorizations Relating To
Premises
Any state, municipality, govern-
mental agency or subdivision or
other political subdivision subject to
the following additional provisions:
(a) This insurance applies only with
respect to:
(i) The following hazards for
which the state, municipality,
governmental agency or
subdivision or other political
subdivision has issued a
permit or authorization in
connection with premises
you owr, rent or control andto which this insurance
applies:
(1.1) The existence,
maintenance, repair,
construction, erection
or removal of adver-
tising signs, awnings,canopies, cellar
entrances, coal holes.
driveways, manholes,
marquees, hoist away
openings, sidewalk
vaults, slreet bannersor decorations and
similar exposures; or
cL cG 04 92 09 15 Page 2 ol 7
(1.2) The construction, erec-
tion or removal of
elevators; or
(1.3) The ownership. main-
tenance or use of any
elevators covered by
this insurance
(ii) Operations performed by you
or on your behalf for whichthe state, municipality,
governmental agency or
subdivision or other political
subdivision has issued a
permit or authorization.
(b) This insurance does not apply to
"bodily injury", "property dam-
age" or "personal and advertising
injury" arising out of operations
performed for the state, munici-
pality, governmental agency or
subdivision or other political
subdivision.
(8) Controlling lnterest
Any person(s) or organization(s) with
a controlling interest in the Named
lnsured but only with respect to their
liability arising out of:
(a) Their financial control of youi or
(b) Premises they own, maintain or
control while you lease or occupy
these premises.
This insurance does not apply to
structural alterations. new con-
struction or demolition operations
performed by or for such person(s)
or organization(s).
(7) Co-Owner Of lnsured Premises
A co-owner of a premises ccowned
by you and covered under this
insurance but only with respect to the
co-owner's liability as co-owner of
such premises.
(8) Vendors
(a) Any person(s) or organization{s)
(referred to as vendor), but only
with respect to "bodily injury" or
"property damage" arising out of"your products" which are
distributed or sold in the regular
course of the vendor's business.
lncludes copyrighted material of lnsurance Services Of{ice, lnc.,
with its permission
The insurance afforded the
vendor does not apply to:
(i) "Bodily injury" or "property
damage" for which the
vendor is obligated to pay
damages by reason of the
assumption of liability in a
written contract or written
agreement. This exclusion
does not apply to liability for
damages that the vendor
would have in the absence of
the written contract or written
agreement;
(ii) Any express warranty unau-
thorized by you;
(iii) Any physical or chemical
change in the product made
intentionally by the
vendor;
(iv) Repackaging, except when
unpacked solely for the
purpose of inspection,
demonstration, testing, or the
substitution of parts under
instructions from the manu-facturer, and then
repackaged in the original
container;
(v) Any failure to make such
inspections, adjustments,
tesls or servicing as the
vendor has agreed to make
or normally undertakes to
make in the usual course of
business, in connection with
the distribution or sale of the
products;
(vi) Demonstration, installation,
servicing or repair opera-
tions, except such operations
performed at the vendor's
premises in connection with
the sale of the producq
(vii) Products which. after distri-
bution or sale by you, have
been labeled or relabeled or
used as a container, part or
ingredient of any other thing
or substance by or for the
vendor: or
cL cG 04 92 09 16 Page 3 of 7
(viii) "Bodily injury" or "property
damage" arising out of the
sole negligence of the
vendor for its own acts or
omissions or those of its
employees or anyone else
acting on its behalf. How-
ever, this exclusion does not
apply to:
(1.1) The exceptions
contained in Sub-
paragraphs (iv) or (vi);
or
{1.2) Such inspections, ad-
justments, tests or
servicing as the
vendor has agreed to
make or normally
undertakes to make in
the usual course of
business, in con-
nection with the
distribution or sale of
the products.
(b) This insurance does not apply to
any insured person or organi-
zation, from whom you have
acquired products, or any
ingredient, part or container,
entering into. accompanying or
containing such products.
2. With respect to coverage proyided by this
Provision A. Miscellaneous Additional
lnsureds, the following additional provisions
applv:
a. Any insurance provided to an additional
insured designated under Paragraphs
A.1.c.(1) through A.1.c.(8) above does
not apply:
(1) To "bodily iniury" or "property
damage" included within the
"products-completed operations
hazard"; or
(2) To "bodily injury", "property damage"
or "personal and adve(ising injury"
arising out of the sole negligence of
such additional insured.
b. The insurance afforded to such additional
insured only applies to the extent
permitted by law.
c, The insurance afforded to such additional
insured will not be broader than that
which you are required to provide by the
written contract or written agreement.
3. With respect to the insurance afforded to the
additional insureds within this Provision A.
Miscellaneous Additional lnsureds, the
following is added to Section lll - Limits Of
lnsurance:
The most we will pay on behalf of the
additional insured is the amount of insurance:
a. Required by the written contract or
written agreement; or
b. Available under the applicable Limits Of
lnsurance shown in the Declarationsi
whichever is less.
This endorsement shall not incr€aae the
applicable Limits Of lnsurance shown in the
Declarations.
B. EXPECTED OR IIITENDED INJURY OR
DA]tl|AGE
Exclusion 2.a. Expected Or lntended lnjury of
Section I - Coverage A - Bodily lnjury And
Property Damage Liability is deleted and
replaced by the following:
a. Expected Or lntended lnjury Or Damage
"Bodily inlury" or "property damage" expected
or intended from the standpoint of the
insured. This exclusion does not apply to
"bodily injury" or "property damage" resulting
from the use of reasonable force to protect
persons or property.
C. XNOWLEDGE OF OCCURRENCE
Paragraph 2.a. Duties ln The Event Of
Occurrence, Offense, Claim Or Suit of Section
lV - Commercial General Liability Conditions
is deleted and replaced by the following:
a. You must see to it that we are notified as
soon as practicable of an "occurrence" or an
offense which may result in a claim only
when the "occurrence" or offense is known
to:
(1) You, if you are an individual;
(2) A partner, if you are a partnership;
(3) A manager, if you are a limited liability
company; or
(4) An "executive officef' or the "employee"
designated by you to give such notice, if
you are an organization other than a
partnership or a limited liability company.
To the extent possible, notice should include:
(i) How, when and where the "occurrence"
or offense took placej
lncludes copyrighted material of lnsurance Services Omce, lnc.,
with its permission
cL cG 04 92 09 16 Page 4 ol 7
(ii) The names and addresses of any injured
persons and witnesses; and
(iii) The nature and location of any injury or
damage arising out of the "occurrence"
or offense.
D. LEGAL LIABILITY - OAMAGE TO PREMISES
RENTED TO YOU (Fire, Lightning, Explosion,
Smoke, Or Leakage From Automatic Fire
Protective Systems)
lf damage to premises rented to you is not
otheMise excluded from this policy or coverage
part, then the following provisions apply:
1. Under S€cthn l- Coverage A - Bodily
hjury And Property 'Damage Liability, the
last paragraph (after the exclusions) is
deleted and replaced by the following:
Exclusions c. through n. do not apply to dam-
age by fire, lightning, explosion, "smoke", or
leakage from automatic fire protective
systems to premises while rented to you or
temporarily occupied by you with the
permission of the owner. A separate limit of
insurance applies to this coverage as
described in Section lll - Limits Of
lnsurance.
2. The paragraph immediately after Sub-
paragraph j.(6) of Paragraph 2. Exclusions
of Section | - Coverage A - Bodily lnjury
And Property Damage Llablllty is deleted
and replaced by the following:
Paragraphs (1), (3) and (4) oi this exclusion
do not apply to "property damage" (other
than damage by fire, lightning, explosion,
"smoke", or leakage from automatic fire
protective systems) to premises, including
the contents of such premises, rented to you
for a period of seven or fewer consecutive
days. A separate limit of insurance applies to
Damage To Premises Rented To You as
described in Section lll - Limits Of
lnsurance.
3. Paragraph 6. of Section lll - Limits Of
ln3urance is deleted and replaced by the
following:
6. Subject to Paragraph 5. aboye. the
greater of:
a, $300,000; or
b. The Damage To Premises RentedTo You Limit shown in the
Declarations,
is the most we will pay under CoverageA for damages because of ,,property
damage" to premises while rented to
you, or in the case of damage by fire,
lightning, explosion, "smoke", or leakage
from automatic flre protective systems,
while rented to you or temporarily
occupied by you with permission of the
owner.
This lirnit will apply to all damage
proximately caused by the same event,
whether such damage results from flre,
lightning, explosion, "smoke", leakage
from automatic fire protective systems, or
other covered causes of loss or any
combination thereof.
4. Subparagraph b.{lxaxii) of Paragraph 4.
Other lnsurance of Section IV
Commercial General Liability Conditions
is deleted and replaced by the following:
(ii) That is flre, lightning, explosion, "smoke"
or leakage from automatic fire protectrve
systems insurance for premises rented to
you or temporarily occupied by you with
permission of the owner;
5. Subparagraph a. of Definition 9. "lnsured
contract" of Section V - Definitions is
deleted and replaced by the following:
a. A contract for a lease of premises.
However, that portion of the contract for
a lease of premises that indemnifies any
person or organization for damage by
fire, lightning, explosion, "smoke" or
leakage from automatic flre protective
systems to premises wlrile rented to you
or temporarily occupied by you with
permission of the owner is not an
"insured contract".
6. As used in this Provision D. Legal Liability -
Damage To Premises Rented To You:
"Smoke" does not include smoke from
agricultural smudging, industrial operations
or "hostile flre".
E. MEDICAL PAYMENTS
lf Corerage C - Uedical Payments is ftot
otherwise excluded from this policy or coverage
part, the lvledical Expense Limit is changed,
subject to lhe terms of Section lll - Limits Of
lnsurance, to the greater of:
a. $10,000; or
b. The lredical
Declarations.
Expense Limit shown in the
F. MOBILE EQUIPMENT REDEFINED
Subparagraph f.(1) of Definition 12. ,,Mobile
equipment" of Section V - Definitions is deleted
and replaced by the following:
lncludes copyrighted material of lnsurance Services Office, lnc.,
with its permission
cL cG 04 92 09 16 Page 5 of 7
(1) Equipment with a gross vehicle weight of
1 ,000 pounds or more and designed primarily
for:
(a) Snow removal;
(b) Road maintenance, but not construction
or resurfacing; or
(c) Street cleaning;
G. NEWLY FORMED OR ACQUIRED ORGANIZA-
TION, PARTNERSHIP OR LIMITED LIABILITY
COMPANY AND EXTENDED PERIOD OF
COVERAGE
Paragraph 3, of Section ll - Who ls An lnsured
is deleted and reptaced by the following:
3. Any organization you newly acquire or form,
other than a joint venture, and over which
you maintain ownership or:
a. Majority interest of more than 50% if you
are a corporationi
b, Majority interest of more than 50o/o as a
general partner of a newly acquired or
formed partnership; and/or
c. Majority interest of more than 50% as an
owner of a newly acquired or formed
limited liability company;
will qualify as a Named lnsured if there is no
other similar insurance available to that
organization. However, for these organiza-
tions:
(i) Coverage under this provision is afforded
only until the next anniversary date of
this policy's effective date after you
acquire or form the organization,
partnership or limited liability company,
or the end of the policy period, whichever
is earlie(
(ii) Section I - Coverage A - Bodily lniury
And Property Damage Liability does
not apply to "bodily injury" or "property
damage" that occurred before you
acquired or formed the organization,
partnership or limited fiability company;
(iii) Section l- Coverage B - Personal
And Advertising lniury Liabitity does
not apply to "personal and adve(ising
injury" arising out of an offense
committed before you acquired or formed
the organization, partnership or limited
liability company;
(iv) Coverage applies only when operationsof the newly acquired organization,
partnership or limited liability company
are the same or similar to the operations
of insureds already covered under this
insurance;
(v) Coverage only applies for those limited
liability companies who have established
a date of formation as recorded within
the filed state articles of organization,
certificates of formation or ce(ificates of
organization; and
(vi) Coverage only applies for those part-
nerships who have established a date of
formation as recorded within a written
partnership agreement or partnership
certmcate.
H, WHO IS AN INSURED. AMENDMENT
The last paragraph of Section ll - Who ls An
lnsured is deleted and replaced by the following:
No person or organization is an insured with
respect to the conduct of any:
a. Current partnership or limited liability
company, unless otherwise provided for
under Paragraph 3. of Section ll - Who ls
An lnsured;
b. Current joint venture; or
c. Past partnership, Joint venture or limited
liability company;
that is not shown as a Named lnsured in the
Declarations.
I. NON-OWNEDWATERCRAFT
Subparagraph (2) of Exclusion 2.9. Aircraft,
Auto Or Watercraft of Section I - Coverage A
- Bodily lnjury And Property Damage Liability
is deleted and replaced by the following:
(2) A watercraft you do not own that is:
(a) Less than 51 feet long; and
(b) Not being used to carry persons or
property for a charge.
J, SUPPLEMEilTARY PAYMENTS - INCREASED
LIiIITS
Section I - Supplementary Payments -
Coverages A And B is changed as follows:
1. The limit shown in Paragraph 1.b. for the
cost of bail bonds is changed from $250 to
$3,000; and
2. The limit shown in Paragraph 1.d. for loss of
earnings because of time off from work is
changed from $250 a day to 91,000 a day.
lncludes copyrighted material of lnsurance Services Of{ice, lnc.,
with its permission
cL cG 04 92 09 16 Page 6 of 7
M. LIBERALIZATION CLAUSE
The following is added to Section lV -
Commercial General Liability Conditions:
lf we adopt a mandatory attachment form change
which broadens coverage under this edition of
the Commercial General Liability CG000'l for no
additional charge, and those changes are
intended to apply to all insureds under this edition
of CG000'l, that change will automatically apply
to your insurance as of the date we implement
the change in your state. This liberalization
clause does not apply to changes implemented
through introduction of a subsequent edition of
the Commercial General Liability form CG0001.
N. INCIDENTAL MEDICAL MALPRACTICE
1. Paragraph 2.a.(1xd) of Section ll - Who ls
An lnsured does not apply to a physician,
nurse practitioner, physician assistant, nurse,
emergency medical technician or paramedic
employed by you if you are not in the
business or occupation of providing medical,
paramedical, surgical, dental, x-ray or
nursing services.
2. This provision is excess over any other valid
and collectible insurance whether such
insurance is primary, excess, contingent or
on any other basis. Any payments by us will
follow Paragraph 4.b. of Section lV -
Commercial General Liability Conditions.
cL cG 04 92 09 16 lncludes copyrighted material of lnsurance Services Office, lnc.,
with its permission
Page 7 of 7
K. UNINTENTIONAL OMISSION OR UNINTEN.
TIONAL ERROR IN DISCLOSURE
The following provision is added to Paragraph 6.
Representations of Section lV - Commercial
General Liability Conditions:
However, the unintentlonal omission of. or
unintentional error in, any information given or
provided by you shall not prejudice your rights
under this insurance.
This provision does not affect our right to collect
additional premium or to exercise our right of
cancellation or non-renewal.
L. WAIVER OF TRANSFER OF RIGHTS OF
RECOVERY AGAINST OTI{ERS
The following is added to Paragraph 8. Transfer
Of Rights Of Recovery Against Others To Us
of Section lV - Commercial General Liability
Conditions:
We waive any right of recovery we may have
against any person or organization because of
payments we make for injury or damage arising
out of your ongoing operations or "your work" and
included in the "products-completed operations
hazard" when you have agreed in a written
contract or written agreement that any right of
recovery is waived for such person or
organization. This waiver applies only to the
person(s) or organization(s) agreed to in the
written contract or written agreement and is
subject to those provisions.
This waiver does not apply unless the written
contract or written agreement has been executed
prior to the "bodily injury" or "property damage".
However, if any person or organization is
separately scheduled on a separate waiver of
transfer of rights of recovery which is attached to
this policy, then this waiver does not apply.
This endorsement modifies insurance provided under the folloWng
COMMERCIAL GENERAL LIABILITY COVERAGE FORM
A, The following coverage is added:
ADDITIONAL INSURED . OWNERS, LESSEES
OR CONTRACTORS - AUTOMATIC STATUS
INCLUDING PRIMARY NON-CONTRIBUTORY
1. Section ll - Who is An lnsured is amended to
include as an additional insured any person(s)
or organization(S) for whom you are required
by virlue of a written contract or agreement
that such person(s) or organization(s) be
added as an additional insured on your policy.
2. The insurance provided to the additional
insured is limited as follows:
a. Such person or organization is an
additional insured only with respect to
liability for "bodily injury", "property
damage" or "personal and advertising
injury" caused in whole or in part by:
(1) Acts or omissions of the Named
lnsured: or
(2) The acts or omissions of those acting
on behalf of the Named lnsured;
in the performance of the Named lnsureds
work for the additional insured(s) speciriedin the written contract provided the
contract or agreement requires you to
provide the additional insured such
coverage and is:
i. Cunently in effect or becomes
effective during the term of this
policy; and
ii. Was executed prior to the "bodily
injury", "property damage,, or
"personal and advertising injury".
b. lf the written contract specifically requires
you to provide additional insured coverage
via the '10/01 edition of CG2010 (aka CG
20 10 10 01) or via the 11185 edition of
CG2010 (aka CG 20 10 11 85), then in
COMMERCIAL GENERAL LIABILITY
cL cG 05 29 09 16
paragraph 2.a. above, the words caused in
whole or in pad by are replaced by the
words arising out of.
c. The insurance afforded to such additional
insured only applies to the extent
permitted by law, and
d, lf coverage provided to the additional
insured is required by a contract or
agreement, the insurance afforded to such
additional insured will not be broader than
that which you are required by the contractor agreement to provide for such
additional insured.
e. This insurance ends at the earliest of the
following times;
(1) When any Named lnsured(s) work
called for in the written contract has
been completed
(2) When all of any Named lnsured(s)
work done at a job site has been
completed if the written contract calls
for work at more than one job site
(3) When that part of any Named
lnsured(s) work done at a Job site has
been put to its intended use by any
person or organization other than the
Named lnsured or those acttng on the
Named lnsured(s) behalf.
Work that may need service, maintenance,
correction, repair or replacement, but is
otheNise complete, will be treated as
completed
f. This insurance does not apply to any
additional insured scheduled on your
policy by separate endorsement.
g. For purposes of paragraph A. of this
endorsement, the terms "you" and "your,,
refer to the Named lnsured shown in the
Declarations.
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
GENERAL LIABILITY ULTRA PLATINUM
ENHANCEMENT COVERAGES
lncludes copyrighted material of lnsurance Services
Office. lnc., with its permission
cL cG 05 29 09 16 Page 1 of 3
3. Exclusions
With respect to the insurance afforded to these
additional insureds, the following additional
exclusions apply to "bodily injury", "property
damage" or "personal and advertising injury"
arising out of:
a. The rendering of or failure to render any
professional services by you or on your
behalf, but only with respect to either or
both of the following operations:
(1) Providing engineering, architectural or
surveying services to others in your
capacity as an engineer, architect or
surveyor; and
(2) Providing, or hiring independent
professionals to provide, engineering,
architectural or surveying services in
connection with construction work you
perform.
b. Subject to Paragraph c, below,
professional services include:
(1) Preparing, approving, or failing to
prepare or approve, maps, shop
drawings, opinions, reports, surveys,
field orders, change orders, or
drawings and specifications; and
(2) Supervisory or inspection activities
performed as part of any related
architectural or engineering activities.
c. Professional services do not include
services within construcilon means,
methods, techniques, sequences and
procedures employed by you or performed
by or for the construction manager, its
employees or its subcontractors in
connection with your ongoing operations.
This exclusion applies even if the claims
against any insured allege negligence or other
wrongdoing in the Supervision, hiring,
employment, training or monitoring of others
by that insured, if the "occurrence" which
caused the "bodily iniury" or "property
damage", or the offense which caused the
"personal and advertising injury", involved the
rendenng of, or the failure to render, any
professional architectural. engineering or
surveying services.
4, Limits of lnsurance
With respect to the insurance afforded to these
additional insureds, the following is added to
Section lll - Limits Of lnsurance:
lf coverage provided to the additional insured
is required by a contract or agreement, the
most we will pay on behalf of the additional
insured is the amount of insurance:
a. Required by the contract or agreementi or
b. Available under the applicable Limits of
lnsurance shown in the Declarations:
whichever is less.
This endorsement shall not increase the
applicable Limits of lnsurance shown in the
Declarations.
5. Other lnsurance
For purposes of this endorsement, the
following is added to the Section lV -
Commercial General Liability Conditions, 4.
Other
Inauranee condition and supersedes any
provision to the contrary:
This insurance is excess of all other
insurance available to an additional
insured whether on a primary, excess.
contingent or any other basis. But, if
required by a Mitten contract or written
agreement to be primary and
noncontributory, this insurance will be
primary to and will not seek contribution
from any insurance on which the additional
insured is a Named lnsured.
No other coverage or limit in the policy
applies to loss or damage insured by this
coverage.
B. The following coverage is added:
CONTRACTUAL LIABILITY - RAILROADS
1. With respect to operations performed for a
Railroad within 50 feet of railroad property, the
definition of "insured contract" in Section V -
Definitions is replaced by the following:
9. "lnsured Contract" means:
a. A contract for a lease of premises.
However, that portion of the contractfor a lease of premises that
indemnifies any person or
organization for damage by fire to
premises while rented to you or
temporarily occupied by you with
permission of the owner is not an
"insured contract";
b. A sidetrack agreement;
c. Any easement or license agreement;
d. An obligation, as required by
ordinance, to indemnify a municipality,
except in connection with work for a
municipality;
e. An elevator maintenance agreement;
f. That part of any other contract or
agreement pertaining to your business
(including an indemnification of a
municipality in connection with work
performed for a municipality) under
lncludes copyrighted material of lnsurance Services
Office. lnc., with its permission
Page 2 of 3 cL cG 05 29 09 16
which you assume the tort liability of
another party to pay for "bodily injury"
or property damage" to a third person
or organization. Tort liability means a
liability that would be imposed by law
in the absence of any contract or
agreement.
Paragraph f. does not include that part
of any contract or agreement:
(1) That indemnifies an architect,
engineer or surveyor for injury or
damage arising out of:
(a) Preparing, approving or failing
to prepare or approve maps,
shop drawings, opinions,
reports, surveys, field orders,
change orders or drawings
and specafications; or
(b) Giving directions or
instructions, or failing to give
them, if that is the primary
cause of the injury or damage;
(2) Under which the insured, if an
architect. engineer or surveyor.
assumes liability for an injury or
damage arising out of the
insured's rendering or failure to
render professional services,
including those listed in Paragraph(1) above and supervisory,
inspection, architectural or
engineering activities.
2. Other lnsurance
For purposes of this endorsement, the
following is added to the Section lV -Commercial General Liability
Conditions, 4, Other lnsurance condition
and supersedes any provision to the
contrary:
This insurance is excess of all other
insurance that is Railroad Protecttve
Liability or similar coverage for "your work"
performed for a Railroad. But, if required
by a written contract or written agreement
to be primary and noncontributory, this
insurance will be primary to and will not
seek contribution from any insurance on
which the Railroad is a Named lnsured.
No other coverage or limit in the policy
applies to loss or damage insured by this
coverage.
C. The following coverage is added:
NON.EMPLOYMENT DISCRIMINATION
LIABILITY
This coverage contains a DEFENSE WITHIN
LIMIT provision: The limit of liabitity for "Non-
employment discrimination" coverage available to
pay settlements or judgments will be reduced, and
may be exhausted, by defense expenses.
The following is added to paragraph 14. "Personal
and advertising injury" SECTION V -
DEFINITIONS OF COMMERCIAL GENERAL
LIABILITY COVERAGE FORM:
h. "Non-employment discrimination" means
violation of a person's civil rights with
respect to such person's race, color,
national origin, religion, gender, marital
status, age, sexual orientation or
preference, physical or mental condition,or any other protected class or
characteristic established by any federal,
state or local slalutes, rules or regulalions.
"Non-employment discrimination" does not
include violation of civil rights ansing out of
past, present or prospective employment.
Any obligation to the insured to pay "non-
employment discrimination" liability damages
on your behalf applies only to the amount of
damages in excess of $5,000 deductible as
the result of any one offense regardless of the
number of persons or organizations who
sustain damages because of the offense.
The most we will pay for all damages for "non-
employment discrimination" is $15,000 annual
aggregate. No other liability to pay sums or
perform acts or services is covered.
Supplementary Payments - Coverage A andB do not apply to non-employment
discrimination.
D. AGGREGATE LIMITS OF INSURANCE
The General Aggregate Limit under SECTION lll -
LIMITS OF INSURANCE applies separately to
each of your:
1. Projects away from premises owned by or
rented to you.
2. "Locations" owned by or rented to you.
"Location" means premises involving the sameor connecting lots, or premises whose
connection is interrupted only by a street,
roadway, waterway or right-of-way of a
@ilroad.
When paragraph B. Construction Project
General Aggregate Limit on form CL CG 00 20 is
a part of this policy, then this endorsemenl
CL CG 05 29 paragraph O. Aggregate Limits Of
lnsurance does not apply.
lncludes copyrighted material of lnsurance Services
Office, lnc., with its permission
cL GG 05 29 09 16 Page 3 of 3
COMMERCIAL GENERAL LIABILITY
cL cc 20 71 09 16
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED . OWNERS, LESSEES,
CONTRACTORS OR OTHERS - COMPLETED OPERATIONS
- AUTOMATIC STATUS, INCLUDING PRIMARY
NONCONTRIBUTORY
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
A. SECTION ll - WHO lS AN INSURED is amended
to include as an additional insured any person(s)
or organization(s) when you are obligated by
virtue ofa wriften contract or agreement that
such person or organization(s) be added as an
additional insured to your policy.
Such person(s) or organization(s) is an additional
insured only with respect to liability for "bodily
iniury" or "property damage" or "personal and
advertising injury" caused, in whole or in part by:
(1) Acts or omissions of the Named Insured;
or
(2) The acts or omissions of those acting on
behalf of the Named lnsured;
and included in the "products-completed
operations hazard"
This insurance applies only when you are required
to add the additional insured by virtue of a written
contract or agreement, provided the contract or
agreement is:
1. Currently in effect or becomes effective during
the term of this policy; and
2. Was executed prior to the "bodily hjury" or
"property damage" or "personal and
advertising injury".
However:
a. The insurance afforded to such additional
insured only applies to the extent permitted by
lawl and
b. lf coverage provided to the additional insured
is required by a contract or agreement, the
insurance afforded to such additional insured
will not be broader than that which you are
required by the contract or agreement to
provide for such additional insured.
For purposes of this endorsement, throughout
the policy, the terms "you" and "you/' refer to
the Named lnsured shown In the Declarations.
B. Exclusions
With respect to the insurance afforded to these
additional insureds, the following additional
exclusions apply to "bodily injury" and "property
damage" arising out of:
1. The rendering of or failure to render any
professional services by you oron your behalf,
but only with respect to either or both of the
following operations:
a. Providing engineering, architectural or
surveying services to others in your
capacity as an engineer, architect or
surveyor; and
b. Providing, or hiring independent
professionals to provide, engineering,
architectural or surveying services in
connection with construction work you
perform.
This exclusion applies even if the claims againstaoy insured allege negligence or other
wrongdoing in the supervision, hiring,
employment, training or monitoring of others by
that insured, if the "occurrence" which caused the
"bodity injury" or "property damage", or lhe offense
which caused the "personal and advertising
jn.iury", involved the rendering of, or the failure to
render, any professional architectural, engineering
or surveying services.
2. Subject to Paragraph 3. below, professional
services include:
a, Preparing, approving, or failing to prepareor approve, maps, shop drawings,
opinions, reports, surveys, field orders,
change orders, or drawings and
specifications; and
lncludes copyrighted material of Insurance Services
Office. lnc.. wth its permission
cL cG 20 7,1 09 16 Page 1 of 2
b. Supervisory or inspection activities
performed as part of any related
architectural or engineering activities.
3. Professional services do not include services
within construction means, methods,
techniques, sequences and procedures
employed by you or performed by or for the
construction manager, its employees or its
subcontractors in connection with your
ongoing operations.
C. Limits of lnsurance
With respect to the insurance atforded to these
additional insureds, the following is added to
Section lll ' Limits O{ lnsurance:
lf coverage provided to the additional insured is
required by a contract or agreement, the most we
will pay on behalf of the additional insured is the
amount of insurance:
1. Required by the contract or agreement; or
2. Available under the applicable Limits of
lnsurance shown in the Declarationsi
whichever is less.
This endorsement shall not
applicable Limits of lnsurance
Declarations.
increase the
shown in the
lncludes copyrighted material of lnsurance Services
Office. lnc., with its permission
D. Other lnsurance
For purposes of this endorsement, the following is
added to the Section lV - Commercial General
Liability Conditions, 4. Other lnsurance
condition and supersedes any provision to the
contrary:
This insurance is excess of all other insurance
available to an additional insured whether on a
primary, excess, contingent or any other basis.
But, if required by a written contract or written
agreement to be primary and noncontributory, this
insurance will be primary to and will not seek
contribution from any insurance on which the
additional insured is a Named lnsured.
No other coverage or limit in the policy applies to
loss or damage insured by this coverage.
Page 2 ol 2 cL cc 20 71 09 16
$3fn17 Referencec onnecl
Berkley North Pacific Group I Forms I 01/01/12
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
CONTRACTOR GENERAL LIABILITY PLATINUM ENDORSEMENT
This endorsement modifies insurance provided under the following
COMMERCIAL GENERAL LIABILITY COVERAGE PART
A. PROPERTY DAMAGE TO BORROWED EQUIPMENT
1. Paragraph 2.j. of SECTION I - COVERAGES, COVERAGE A BODILY INJURY AND PROPERW DAMAGE
LIABILITY is amended as follows:
ParagraplB (3) and (4) of this oxclusion do not apply to tools or equiprnent loaned to you, provided they are not hing
used to perform operations at the time of loss.
2. SECTION lll - LIMITS OF INSURANCE is deleted and replaced by ttle following:
The most we will pay in any one "occurrence" for "property damage" to bono\,ved equipment is $15,000. This limit of
insurance is the most we will pay regBrdless of the number of:
a. lnsureds;
b. Claims made or "suits" brought; or
c. Persons or organizations making claims or bringing "suits".
3. Deductible
a. Our obligation to pay damages on behalf of the insured applies only to the amount of damages in excess of $250
as applicaue to "property damage' as the result of any one "@cunence', regardless of the number of persons or
organizations who sustain damages because of that "occurence".
b, The terms of this insurance, including those with respect to our right and duty to defend the insured against any
''suits" seeking tho6e damages; ard yoJr duties in the event of an "occsrence", claim, or "suit" apdy inespective
of the application of the deductible amount.
c. We may pay any part or all of the deductible amount to ef{ect settlement of any claim or suit aM, upon notification
of the action taken; you shall promptly reimburse us for such part of the deductible amount as we have paid.
B. GONSTRUCTION PROJECT GENERAL AGGREGATE LIMIT
1. For all sums which the insured becomes legally obligated to pay as damages caused by "occunences" under
COVERAGE A (SECTION l), and for all medical expenses caused by accidents under COVERAGE C (SECTION l),
which can be attributed only to ongoing operations at a single construction pro.lect away from premises owned by or
rented to the insured:
a. A Single Construction Project General Aggregate Limit applies to each construction proJect away from premises
o\,vned by or rented to the insured, and that limit is equd to the amount of the Gereral Aggregate Limit shovvn in
the Declarations.
b. The Single Construction Prolect General Aggregate Limit is the most we will pay for the sum of all damages under
COVERAGE A, except damages because of "bodily in1ury" or "property damage" included in the "products-
cornplded operaions hazard, ard for medicd expenses urder COVERAGE C regBrdless of the number of:
(1) lnsureds;
(2) Claims made or "suits" hangrht; or
(3) Persons or organizations making claims or bringing "suits".
c. Any payTents made under COVERAGE A for damages or under COVERAGE C fff medical expenses shall
reduce the Single Construction Projecl General Aggregate Limit for that construction project away from premises
gwned by or rented to the insured. Such payments shall not reduce the General Reig(€ate Limit shor;vn in the
Declarations nor shall they.reduce-any other Single Construction Project General Aggregate Limit for any other
separate construction project away from premises ou/ned by or rented to the insured. -
d' The limits sho,vn in the Declarations for Each Occunence, Fire Damage and Medical Expense continue to apply.
Ho\ /ever, instead of being subject to the General Aggregate Limit shdvn in the Declarations, such limits wiil'b'esub,ect to the appticable Single Construction project General Aggregate Limit.
2. For all sums which the insured becomes legally obligated to pay as damages caused by ,,qccunences,, undercovERAGE A (SEcTloN l), and for all medicd exlensei caused by accidents "unoer CoVeHlce C tsECrrot ll,
tttss/ vww.silverplume.corn/SPor{irdsPsage.aspx?cmd=doc&id=AK CL CG 0o 20-01_12 hfn&Gd=291ocrdgt&ssEmate&rd=102E692&tsig= Do yxE2B.1/4
4nfn17 RefererE€Corr€cl
which cannot be attributed only to ongoing opeErtions at a single designated construction project away from premises
owned by or rented to the insured:
a. Any payments made under COVERAGE A for damages or under COVERAGE C for medical expenses shall
reduce the amount availaue under the General Aggregate Limit or the Products-Completed Operations Aggregate
Limit, whichever is applicable; and
b. Such payments shall not reduce any Single Consttuction Poject General Aggregate Limit.
3. When coverage for liability arising out of the "products-completed operations hazard" is provided, any payments for
damages because of "bodily
'njury"
or "property damage" included in the "products-completed operations hazard" will
reduce the Products-Completed Operations Aggregate Limit, and not reduce the General Aggregate Limit or the Single
Construction Pro.iect General Aggregate Limit.
4. lf the applicable construction project away from premises owned by or rented to the insured has been abandoned,
delayed, or abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints,
designs, specifications or timetables, the project will still be deemed to be the same construction prciect.
5. The provisions of Limits Of lnsurance (SEGTION lll) not otheMise modified by this endorsement shall continue to
apply as stipulated.
C, LIMITED JOB SITE POLLUTION
1. Exclusion f. under Section I - Coverage A is replaced by the follo\,\,ing:
2. Exclusions
This insurance does not apply to:
f. Pollution
(1) "Bodily injury" or "property damage" arising out of the actual, alleged or threatened discharge, dispersal,
seepage, migration, release or escape of "pollutants":
(a) At or from any premises, site or location on which any insured or any contractors or subcontractors
working directly or indirectly on any insured's behalf are performing operations if the operations are to
test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or
assess the effects of, "pollutants"; or
(b) At or frorn a storage tank or other container, ducts or piping which rs below or partially below the
surface of the ground or water or which, at any time, has been buried under the surface of the ground
or water and then subsequently exposed by erosion, excavation or any olher means if the actual,
alleged or threatened discharg€, dispersal, seepage, migration, release or escape of "poliutants" arises
at or from any premises, site or location which any insured or any contractors or subcontractors
working directly or indirectly on any insured's behalf are performing operations if the "poilutants" are
brought on or to the premises, site or location in connection with such operations by such insured,
contractor or subcont€ctor.
Subparagraph (b) does not apply to "bodily injury" or "property damage' arlsing out of heat, smoke or
fumes from a "hostile fire".
(2) Any loss, cost or expense arising out of any:
(a) Request, demand, order or statutory or.regulatory requirement issued or made pursuant to any
environmental protection or environmental liability statutes or regulations that any insured test foi
monitor, clean up, remove, contain, treat, detoxify or neutralize, oi in any way respond to, or assess
the effects of, "pollutants"i or
(b) Claim or suit by or on behalf of a govemmental authority for damages because of testing for,
mo#todng,
. clear*ng up, removirg, cstair$rg, trcdir€, detoxiryirg. or retrtrdlzing or in any-way
responding to or assessing the effects ol "pollutants".
Ho/vever, this paragraph does- not apply to.liability for those sums the insured becomes legally obligated topay 6 darnages becanse of "poperty &mage" that tfp inswed wordd have in the albseree -of strhrequest, demand,. order or statutory or regulatory requirement, or such claim or "suit" by or on behalf of agovemmental authority.
2. With respect to "bodily inJury" or "property. damage" ansing out of the actual, alleged or threatened discharge, dispersal,
seepage, migration, release or escape of "pollutants,,:
a. The "Each Occunence Limit" shown in the Declarations does not apply.
b. Paragraph 7. of Limits Of lnsurance (Section lll) does not apply.
c. Paragraph 1. of Section lll - Limits Of lnsurance is replaced by the following:
The Limits Of lnsurance sholvn in this endorsement, or in the Declarations and the rules below fix the most we willpay regardless of the number of:
(1) lnsureds;
(2) Claims made or',suits,, brought; or
https:/A ww silverplume com/sPoriirdsPsage aspx?cind=doc&id=AK-cL-cG-oo_20_0'1-12.hkn&fed=29.1oodgt&seEmab&d=1078892&sis=DD3634XE2B 2l4
4Ym17 RefererE€onrEcl
(3) Persons or organizations making claims or bringing "suits".
d. The following are added to Section lll - Limits Of lnsurance:
8. Subject to 2. or 3. above, whichever applies, the most we will pay for the sum of:
a. Damages under Coverage A;and
b. Medical expenses under Coverage C
because of "bodily injury" or "property damage" arising out of the actual, alleged or threalened discharge,
dispersal, seepage, migration, release or escape of "pollutants" is 5100,000 aggregate.
9. Subject to 8. above, the Medical Expense Limit is the most we will pay under Coverage C for all medical
expenses because of "bodily injury" sustained by any one person arising out of the actual, alleged or
threatened discharge, dispersal, seepage, migration, release or escape of "pollutants".
D. VOLUNTARY PROPERTY DAMAGE
1. The following is added to Section 1 - COVERAGES:
We will pay, at your r€quest Jor "propcrty damage" to that part of any prop€rty:
a. Which you or any subcontractors working directly or indirectly on your behalf are performing operations; or
b. That must be restored, repaired or replaced because "your work" was inconectly performed on it.
This insurance applies only to "property damage" to property of others while in your care, custody, or control, and
arising out of operations away from your insured premises and incidental to your business.
Exclusions j.(3),(4),(5) and (6) do not apply to this coverage.
This insurance does not apply to "property damage' included within the "exdosion hazard", the "collapse hazard"
or the "underground property damage hazard".
2. For the purposes of the coverage provided by D. VOLUNTARY PROPERTY DAMAGE, SECTION lll - LIMITS OF
INSURANCE is replaced by the following:
A. Limits of lnsurance
1. Unless a higher limit is shown in the Declarations, the most we will pay in any one "occurrence" for "property
damage" under this endorsement is $15,000.
2. Unless a higfEr limit is slD\rn in the Declarations, the most we will pay for all covered "occunences" durng
any one policy period is $15,000 Aggregate Limit of lnsuEnce.
tttFsr/'l./ww silverdume.com/sPoriirdsPsage.aspx?cmd=docEid=AK cL cG oo 20-01_12.htm&fed=291oodgt&seEmate&d=1o7E892&lsig=DD3634xE2B.3t4
The Umits of lnsurance of this endorsement apply separately to each consecutive annual penod and to any
remaining period of less than 12 months, starting with the beginning of the policy penod shown in the DeclaEtions,
unless the policy period is extended after issuance for an additional period of less than 12 months. ln that case,
the additional period will be deemed part of the last preceding period for purposes of determining the Limits of
lnsurance.
3. Oeductible
a. Our obligation to pay damages on behalf of the insured applies only to the amount of damages in excess of
$250 as the result of any one "occunence", regardless of the number of persons or organizations who sustan
damages because of that "occurrence".
b. The terms of this insurance, including those with respect to our right and duty to defend the insured against
any "suits" seeking those damages; and your duties in the event of an ,'occunence,, claim, or',suit" apply
inespective of tfE @icdion of the dedtrctiue anc[mt.
c. .._Yve..may _pay any. part or all of the deductible amount to effect settlement of any claim or suit and, upon
notification of the action takeni you shall p.omptly reimbuBe us for such part of the deductible amount as we
have paid.
!.^ ioj tle purposes of the coverage provided by D. VoLUNTARY PRoPERTY DAMAGE, sEcTtoN tv -COMMERCIAL GENERAL LtABtLtTY CONDIT|OIIS is amended as fo ows:
a. The following is added to paragraph 2. Duties ln The Event Of Occurrence, Ofiense, Claim or Suit:
ln the event of loss covered.by lhis endorsement, the insured shall, if requested by us, replace the prope(y orfurnish the labor and materials necessary for repairs at actual cost to lhe insured, 'exciudihg prospebtirie piotit
or overhead charges of any nature. . Any property so paid for or replaced shall, at our o-piion,'becom6 ouiproperty. Any payment made by us shall not constitute an admission bf liability by an insured, or'by us.
b. Paragraph 4. Other lnsurance is amended as follors:
('t) Paragraph 4,a. p mary lnsurance is deleted.
nat2017 Referenc€C onnecl
(2) Subparagraphs (1) and (2) of paragraph 4,b. Excess lnsurance are deleted and replaced with the
follorving:
This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other
basis.
All other provisions that apply to paragraph 4. Other lnsurance contained in the Commercial General Liability
Coverage Form are applicable.
5, For the purposes of the coverage provided by D. VOLUNTARY PROPERTY DAMAGE, the following definitions
are added to SECTION V - DEFINITIONS:
a. "Collapse hazard" includes "structural property damage" and any resulting "property damage" to any other
property at any time.
b. "Explosion hazard" includes "property damage" arising out of blasting or explosion. The "explosion hazard"
does not include "property damage' arising out of the explosion of air or steam vessels, p{ping under pressure,
pfime movers, machinery or power transmitting equipment.
c. "Structural propedy damage" means the coll@se of or structural injury to any building or structure due to:
('l) Grading of land, excavating, bonowing, filling, back-filling, tunneling, pile driving, cofferdam work or
caisson work; or
(2) Moving, shoring, undepinning, raising or demolition of any building or structure or removal or rebuilding of
any structural support of that building or structure.
d. "Underground property damage hazard' includes "underground property damage" and any resulting "property
damage" to any other property at any time.
e. "Underground property damage" means "property damage" to wires, conduits, pipes, mains, selvers, tanks,
tunnels, any similar property, and any appaErtus used with them beneath the surface of the ground or water,
caused by and occuning during the use of mechanical equipment for the purpose of grading land, paving,
excavating, drilling, bonowing, filling, back-filling or pile driving.
@Berkley North Pacific Group
q20'17 Vertafore, lnc. All Rights Reserved.
https:/
^'ww'silvefd
ume com/sPoni irdsPsage 6px?. cm d= doc&id=AK-c L-cG-m_20_01_1 2 htn &ftd= 291ftIdsl&seEmab&d= 1078892&lsig= DD3634xE2B 4t4