Irminger Construction for Well 30 ConstructionCONTRACT FOR PUBLIC WORKS CONSTRUCTION
WELL 30 PUMPING FACILITY
PROJECT # 10012.H
THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this
day of June , 2017, and entered into by and between the City of Meridian, a municipal
corporation organized under the laws of the State of Idaho, hereinafter referred to as
"CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and Irminger Construction, Inc.,
hereinafter referred to as "CONTRACTOR", whose business address is 25094 Homedale
Rd. Wilder ID 83676 and whose Public Works Contractor License # is C -026529 -AA -1-3.
INTRODUCTION
Whereas, the City has a need for services involving Well 30 Pumping facility
Construction; and
WHEREAS, the Contractor is specially trained, experienced and competent
to perform and has agreed to provide such services;
NOW, THEREFORE, in consideration of the mutual promises, covenants,
terms and conditions hereinafter contained, the parties agree as follows:
TERMS AND CONDITIONS
1. Scope of Work.
1.1 CONTRACTOR shall perform and furnish to the City upon execution of this
Contract and receipt of the City's written notice to proceed, all services and work,
and comply in all respects, as specified in the document titled "Scope of Work" a
copy of which is attached hereto as Exhibit "A" and incorporated herein by this
reference, together with any amendments that may be agreed to in writing by the
parties.
1.2 All documents, drawings and written work product prepared or produced by
the Contractor under this Agreement, including without limitation electronic data
files, are the property of the Contractor; provided, however, the City shall have the
right to reproduce, publish and use all such work, or any part thereof, in any
manner and for any purposes whatsoever and to authorize others to do so. If any
such work is copyrightable, the Contractor may copyright the same, except that, as
to any work which is copyrighted by the Contractor, the City reserves a royalty -free,
non-exclusive, and irrevocable license to reproduce, publish and use such work, or
any part thereof, and to authorize others to do so.
1.3 The Contractor shall provide services and work under this Agreement
consistent with the requirements and standards established by applicable federal,
state and city laws, ordinances, regulations and resolutions. The Contractor
WELL 30 PUMPING FACILITY page 1 of 14
Project 10012,H
represents and warrants that it will perform its work in accordance with generally
accepted industry standards and practices for the profession or professions that
are used in performance of this Agreement and that are in effect at the time of
performance of this Agreement. Except for that representation and any
representations made or contained in any proposal submitted by the Contractor
and any reports or opinions prepared or issued as part of the work performed by
the Contractor under this Agreement, Contractor makes no other wananties, either
express or implied, as part of this Agreement.
1 .4 Services and work provided by the Contractor at the City's request under this
Agreement will be performed in a timely manner in accordance with a Schedule of
Work, which the parties hereto shall agree to. The Schedule of Work may be
revised from time to time upon mutual written consent of the parties.
2. Consideration
2.1 The Contractor shall be compensated on a Not-To-Exceed basis as provided
in Exhibit B "Payment Schedule" attached hereto and by reference made a part
hereof for the Not-To-Exceed amount of $583,075.
3. Term:
WELL 30 PUMPING FACILITY
Project 10012.H
3.1 This agreement shall become effective upon execution by both parties, and
shall. expire upon (a) compretion of the agreed upon work, (bi or uniess sooner
terminated as provided in sections 3.2, 3.3, and Section 4 below or unless some
other method or time of termination is listed in Exhibit A.
3.2 Should contractor default in the performance of this Agreement or materiallybreach any of its provisions, city, at city's option, may termiriate this Agreementu},giving written notification to Contractoi.
2.2 The Contractor shall provide the City with a monthly statement and
supporting invoices, as the work warrants, of fees earned and costs incurred for
services provided during the billing period, which the City will pay within 30 days of
receipt of a correct invoice and approval by the City. The City will not withhold any
Federal or State income taxes or Social Security Tax from any payment made by
City to Contractor under the terms and conditions of this Agreement. Payment of
all taxes and other assessments on such sums is the sole responsibility of
Contractor.
2.3 Except as expressly provided in this Agreement, Contractor shall not be
entitled to receive from the City any additional consideration, compensation, salary,
wages, or other type of remuneration for services rendered under this Agreement
including, but not limited to, meals, lodging, transportation, drawings, renderings or
mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement
to consideration in the form of overtime, health insurance benefits, retirement
benefits, paid holidays or other paid leaves of absence of any type or kind
whatsoever.
page 2 ol '14
3.3 Should City fail to pay Contractor all or any part of the compensation set forth
in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's
option, may terminate this Agreement if the failure is not remedied by the City
within thirty (30) days from the date payment is due.
4. Liquidated Damages:
Substantial Completion shall be accomplished within 150 (one hundred fifty)
calendar days from Notice to Proceed. This project shall be considered
Substantially Complete when the Owner has full and unrestricted use and benefit
of the facilities, both from an operational and safety standpoint, and only minor
incidental work, corrections or repairs remain for the physical completion of the
total contract. Contractor shall be liable to the City for any delay beyond this time
period in the amount of $500.00 (five hundred dollars) per calendar day. Such
payment shall be construed to be liquidated damages by the Contractor in lieu of
any claim or damage because of such delay and not be construed as a penalty.
Upon receipt of a Notice to Proceed, the Contractor shall have 180 (one hundred
eighty) calendar days to complete the work as described herein. Contractor shall
be liable to the City for any delay beyond this time period in the amount of $500.00
(five hundred dollars) per calendar day. Such payment shall be construed to be
liquidated damages by the Contractor in lieu of any claim or damage because of
such delay and not be construed as a penalty. See Milestones listed in the
Payment Schedule for Substantial Completion.
5. Termination:
5.1 lf, through any cause, CONTRACTOR, its officers, employees, or agents fails
to fulfill in a timely and proper manner its obligations under this Agreement, violates
any of the covenants, agreements, or stipulations of this Agreement, falsifies any
record or document required to be prepared under this agreement, engages in
fraud, dishonesty, or any other act of misconduct in the performance of this
contract, or if the City Council determines that termination of this Agreement is in
the best interest of CITY, the CITY shall thereupon have the right to terminate this
Agreement by giving written notice to CONTRACTOR of such termination and
specifying the effective date thereof at least fifteen (15) days before the effective
date of such termination. CONTRACTOR may terminate this agreement at any
time by giving at least sixty (60) days notice to ClTy.
ln the event of any termination of this Agreement, all finished or unfinished
documents, data, and reports prepared by CONTRACTOR under this Agreement
shall, at the option of the crrY, become its property, and coNTRACToF shall beentitled to receive just and equitable compensation for any work satisfactorily
complete hereunder.
5.2
^
Notwithstanding the above, coNTRACToR shall not be relieved of liability tothe clrY for damages sustained by the crry by virtue of any breach of ihis
WELL 30 PUMPING FACILITY
Project'100'12.H page 3 of 14
Agreement by CONTRACTOR, and the CITY may withhold any payments to
CONTRACTOR for the purposes of seloff until such time as the exact amount of
damages due the CITY from CONTRACTOR is determined. This provision shall
survive the termination of this agreement and shall not relieve CONTRACTOR of
its liability to the CITY for damages.
6. lndependent Contractor:
6.1 ln all matters pertaining to this agreement, CONTRACTOR shall be acting as
an independent contractor, and neither CONTRACTOR nor any officer, employee
or agent of CONTRACTOR will be deemed an employee of CITY. Except as
expressly provided in Exhibit A, Contractor has no authority or responsibility to
exercise any rights or power vested in the City and therefore has no authority to
bind or incur any obligation on behalf of the City. The selection and designation of
the personnel of the CITY in the performance of this agreement shall be made by
the CITY.
6.2 Contractor, its agents, officers, and employees are and at all times during the
term of this Agreement shall represent and conduct themselves as independent
contractors and not as employees of the City.
6.3 Contractor shall determine the method, details and means of performing the
work and services to be provided by Contractor under this Agreement. Contractor
shall be responsible to City only for the requirements and results specified in this
Agreement and, except as expressly provided in this Agreement, shall not be
subjected to City's control with respect to the physical action or activities of
Contractor in fulfillment of this Agreement. lf in the performance of this Agreement
any third persons are employed by Contractor, such persons shall be entirely and
exclusively under the direction and supervision and control of the Contractor.
7. Sub-Contractors:
Contractor shall require that all of its sub-contractors be licensed per State of ldaho
Statute # 54-1901
8. Removal of Unsatisfactory Employees:
WELL 30 PUMPING FACILITY
Project 10012.H
9
The contractor shall only furnish employees who are competent and skilled for work
under this contract. lf, in the opinion of the city, an employee of the contractor is
incompetent or disorderly, refuses to perform in accordance with the terms and
conditions of the contract, threatens or uses abusive language while on cityproperty, or is othenivise unsatisfactory, that employee shall be iemoved from ail
work under this contract.
lndemnifi cation and lnsurance:
9.1 coNTRAcroR shail indemnify and save and hord harmress crry and it,selected officiars, officers, emproyees, agents, and vorunteers from ano ror rny anJ
page 4 ot 14
all losses, claims, actions, judgments for damages, or injury to persons or property
and losses and expenses and other costs including litigation costs and attorney's
fees, arising out of, resulting from, or in connection with the performance of this
Agreement by the CONTRACTOR, its servants, agents, officers, employees,
guests, and business invitees, and not caused by or arising out of the tortious
conduct of CITY or its employe es. CONTRACTOR shall maintain, and specificallv
aqrees that it will maintain, throuqhout the term of this Aqreement, liabilitv
insurance, in which the CITY shall be named an additional insured in the mtnrmum
amounts as follow: General Liability One Million Dollars ($1,000,000) per incident
or occurrence, Automobile Liability lnsurance One Million Dollars ($1 ,000,000) per
incident or occurrence and Workers' Compensation lnsurance, in the statutory
limits as required by law.. The limits of insurance shall not be deemed a limitation
of the covenants to indemnify and save and hold harmless CITY; and if CITY
becomes liable for an amount in excess of the insurance limits, herein provided,
CONTRACTOR covenants and agrees to indemnify and save and hold harmless
CITY from and for all such losses, claims, actions, or judgments for damages or
injury to persons or property and other costs, including litigation costs and
attorneys' fees, arising out of, resulting from , or in connection with the
performance of this Agreement by the Contractor or Contractor's officers, employs,
agents, representatives or subcontractors and resulting in or attributable to
personal injury, death, or damage or destruction to tangible or intangible property,
including use of. CONTRACTOR shall provide CITY with a Certificate of
lnsurance, or other proof of insurance evidencing CONTRACTOR'S compliance
with the requirements of this paragraph and file such proof of insurance with the
CITY at least ten (10) days prior to the date Contractor begins performance of it's
obligations under this Agreement. ln the event the insurance minimums are
changed, CONTRACTOR shall immediately submit proof of compliance with the
changed limits. Evidence of all insurance shall be submitted to the City Purchasing
Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue,
Meridian, ldaho 83642.
9.2 lnsurance is to be placed with an ldaho admitted insurer with a Best's rating
of no less than A-.
9.3 Any deductibles, self-insured retention, or named insureds must be declared
in writing and approved by the City. At the option of the City, either: the insurer
shall reduce or eliminate such deductibles, self-insured retentions or named
insureds; or the Contractor shall provide a bond, cash or letter of credit
guaranteeing payment of losses and related investigations, claim administration
and defense expenses.
9.4 To the extent of the indemnity in this contract, contractor's lnsurance
cove.rage shall be primary insurance regarding the city's elected officers, officials,employees and volunteers. Any insurance or self-insurance maintained by the cityor the city's elected officers, officials, employees and volunteers shall be excess oithe contractor's insurance and shall not contribute with contractors insuianceexcept as to the extent of City's negligence.
WELL 30 PUMPING FACILITY
Prqect 10012.H page 5 of 14
9.5 The Contractor's insurance shall apply separately to each insured against
whom claim is made or suit is brought, except with respect to the limits of the
insure/s liability.
9.6 All insurance coverages for subcontractors shall be subject to all of the
insurance and indemnity requirements stated herein.
9.7 The limits of insurance described herein shall not limit the liability of the
Contractor and Contracto/s agents, representatives, employees or subcontractors.
10. Time is of the Essence:
The parties hereto acknowledge and agree that time is strictly of the essence with
respect to each and every term, condition and provision hereof, and that the failure
to timely perform any of the obligations hereunder shall constitute a breach of, and
a default under, this Agreement by the party so failing to perform.
11. Bonds:
Payment and Performance Bonds are required on all Public Works lmprovement
Projects per the ISPWC and the City of Meridian Supplemental Specifications &
Drawings to the ISPWC, which by this reference are made a part hereof .
Contractor is required to furnish faithful performance and payment bonds in the
amount of 100% of the contract price issued by surety licensed to do business in
the State of ldaho with a Best's rating of no less than A-. ln the event that the
contract is subsequently terminated for failure to perform, the contractor and/or
surety will be liable and assessed for any and all costs for the re-procurement of the
contract services.
All construction and equipment provided under this agreement shall be warranted
for 2 years from the date of the City of Meridian acceptance per the ISPWC and the
Meridian Supplemental Specifications & Drawings to the ISPWC and any
modifications, which by this reference are made a part hereof.
All items found to be defective during a warranty inspection and subsequenfly
corrected will require an additional two (2) year warranty from the date of City,s
acceptance of the corrected work.
WELL 30 PUMPING FACILIry
Project 10012.H
13. Changes:
The clrY may, from time to time, request changes in the scope of work to beperformed hereunder. such changes, including iny increase or decrease in the
amount of coNTRACToR's compensation, which are mutuaily agreed upon by andbetween the crry and CONTRACTOR, shalr be incorpJrated 'in writtenamendments which shall be executed with the same formalities as this Agreement.
page 6 of 14
12. Warrantlr:
14. Taxes:
The City of Meridian is exempt from Federal and State taxes and will execute the
required exemption certificates for items purchased and used by the City. ltems
purchased by the City and used by a contractor are subject to Use Tax. All other
taxes are the responsibility of the Contractor and are to be included in the
Contractor's Bid pricing.
15. MeridianStormwaterSpecifications:
All construction projects require either a Storm Water Pollution Prevention Plan
(SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of
Meridian Construction Stormwater Management Program (CSWMP) manual. The
CSWMP manual containing the procedures and guidelines can be found at this
address: http://www.meridiancity-oro/environmental.aspx?id=1 361 B.
Contractor shall retain all stormwater and erosion control documentation generated
on site during construction including the SWPPP manual, field inspections and
amendments. Prior to final acceptance of the job by the City the contractor shall
return the field SWPPP manual and field inspection documents to the City for
review. A completed Contractor Request to File Project N.O.T. with the EPA form
shall be provided to the City with the documents. These documents shall be
retained, reviewed and approved by the City prior to final acceptance of the project.
16. ACHD:
Contractor shall be responsible for coordinating with the City to obtain appropriate
ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs
due to Contractor's violation of any ACHD policy. City shall certify to ACHD that
Contractor is authorized to obtain a Temporary Highway and Right-of-Way Use
Permit from ACHD on City's behalf. The parties acknowledge and agree that the
scope of the agency granted by such certification is limited to, and conterminous
with, the term and scope of this Agreement.
WELL 30 PUMPING FACILITY
Project 10012.H
17. Reports and lnformation:
17.1 At such times and in such forms as the clry may require, there shall be
furnished to the clrY such statements, records, reports, data and information as
the CITY may request pertaining to matters covered by this Agreement.
17.2 contractor shall maintain all writings, documents and records prepared orcompiled in connection with the performance of this Agreement for a minimum offour (4) years from.the termination or compretion oithis or Rgreement. ftisincludes any handwriilng, typewriting, printing, photo static, prrotogiapnic and "r"ryother means of recording upon any tangibre thing, any form of c-ommunication orrepresentation incruding retters, words, pictures, sounds or symbors or anycombination thereof.
page 7 ol 14
18. Audits and lnspections:
At any time during normal business hours and as often as the CITY may deem
necessary, there shall be made available to the CITY for examination all of
CONTRACTOR'S records with respect to all matters covered by this Agreement.
CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or
transcripts from such records, and to make audits of all contracts, invoices,
materials, payrolls, records of personnel, conditions of employment and other data
relating to all matters covered by this Agreement.
19. Publication, Reproduction and Use of Material:
No material produced in whole or in part under this Agreement shall be subject to
copyright in the United States or in any other country. The CITY shall have
unrestricted authority to publish, disclose and otherwise use, in whole or in part, any
reports, data or other materials prepared under this Agreement.
20. Equal Employment Opportunity:
ln performing the work herein, Contractor agrees to comply with the provisions of
Title Vl and Vll of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code
Section 2176. Specifically, the Contractor agrees not to discriminate against any
employee or applicant for employment because of race, color, religion, sex, national
origin, age, political affiliation, marital status, or handicap. Contractor will take
affirmative action during employment or training to insure that employees are
treated without regard to race, color, religion, sex, national origin, age, political
affiliation, marital status, or handicap. ln performing the Work required herein,
CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or
local law, rule or regulation against any person on the basis of race, color, religion,
sex, national origin or ancestry, age or disability.
2'i.. Employment of Bona Fide ldaho Residents:
Contractor must comply with ldaho State Statute 44-1002 which states that the
Contractor employ ninety-five percent (95%) bona fide ldaho residents.
WELL 30 PUMPING FACILITY
Project 10012.H
22. Advice of Attorney:
Each pafi warrants and represents that in executing this Agreement. rt hasreceived independent legal advice from its attomey's or thl opport-unity to seek suchadvice.
23. Attorney Fees:
should any litigation be commenced between the parties hereto concernino thisAgreement, the prevalling party shall be entited, in'aOOiton io an;;t# ;;ii"i;;may be granted, to court costs and reasonabre
"itorr"ys,re"s as iei"rmi.;;ly "court of competent jurisdiction. This provisio.
"n"ii o; deemed to oe a sep#tl
page 8 of 14
contract between the parties and shall survive any default, termination or forfeiture
of this Agreement.
24. ConstructionandSeverability:
lf any part of this Agreement is held to be invalid or unenforceable, such holding will
not affect the validity or enforceability of any other part of this Agreement so long as
the remainder of the Agreement is reasonably capable of completion.
25. Waiver of Default:
Waiver of default by either party to this Agreement shall not be deemed to be waiver
of any subsequent default. Waiver or breach of any provision of this Agreement
shall not be deemed to be a waiver of any other or subsequent breach, and shall
not be construed to be a modification of the terms of this Agreement unless this
Agreement is modified as provided above.
26. Entire Agreement:
This Agreement contains the entire agreement of the parties and supersedes any
and all other agreements or understandings, oral of written, whether previous to the
execution hereof or contemporaneous herewith.
27. Assignment:
It is expressly agreed and understood by the parties hereto, that CONTRACTOR
shall not have the right to assign, transfer, hypothecate or sell any of its rights under
this Agreement except upon the prior express written consent of CITY.
28. Payment Request:
Payment requests shall be submitted to City of Meridian through the City's project
management software. The Project Manager will compare the invoice against the
Payment Schedule in the Agreement for compliance. Upon approval that the work
has been done and is in compliance with the Agreement, the Project Managerwill
approve the pay request for processing. City of Meridian payment terms are Net 30
from the date City receives a correct invoice. Final payment will not be released
until the City has received a tax release from the Tax Commission.
29. Cleanup:
contractor shall keep the worksite clean and free from debris. At completion of
work and prior to requesting final inspection, the contractor shall remove all tracesof waste materials and debris resulting from the work. Final payment will not bemade if cleanup has not been performed.
WELL 30 PUMPING FACILITY
Prolect 10012.H page 9 of 14
30. Order of Precedence:
The order or precedence shall be the contract agreement, the Invitation for Bid
document, then the winning bidders submitted bid document.
31. Compliance with Laws:
In performing the scope of work required hereunder, CONTRACTOR shall comply
with all applicable laws, ordinances, and codes of Federal, State, and local
governments.
32. Applicable Law:
This Agreement shall be governed by and construed and enforced in accordance
with the laws of the State of Idaho, and the ordinances of the City of Meridian.
33. Notices:
Any and all notices required to be given by either of the parties hereto, unless
otherwise stated in this agreement, shall be in writing and be deemed
communicated when mailed in the United States mail, certified, return receipt
requested, addressed as follows:
CITY
CONTRACTOR
City of Meridian
Irminger Construction, Inc.
Purchasing Manager
Attn: Travis Longer
33 E Broadway Ave
25094 Homedale Rd
Meridian, ID 83642
Wilder, ID 83676
208-489-0417
Phone: 208800-9616
Email: iceitravis@gmail.com
Idaho Public Works License #026529 -AA -1-3
Either party may change their address for the purpose of this paragraph by giving
written notice of such change to the other in the manner herein provided.
34. Approval Required:
This Agreement shall not become effective or binding until approved by the City of
Meridian.
CITY OF MERIDIAN IRMINGER CONSTRUCTION, INC.
BY - BY:_ -
TAMMY de E�2D, MAYOR
.m_1
WELL 30 PUMPING FACILITY page 10 of 14
Project 10012.1-1
Dated: & / a 7 / �1�
Approved by Council: � ( a� Z r
Attest:
C.JAY OLE , CI CLERK
Purchasing Approval
BY;
KEITH W TS, urch/asing Manager
Dated:: 6/z- �-% r
Project Manager
Brent Blake
Dated:
eQ` Kn v,U AUCUs>l
GGA i�o�
City of
t111A
sgc
BY:
WARR N STE ART, City Engineer
Dated;;
WELL 30 PUMPING FACILITY page 11 of 14
Project 10012.1-1
EXHIBIT A
SCOPE OF WORK
SPECIFICATIONS / SCOPE OF WORK
All construction work shall be done in accordance with the current version
of the ldaho Standards for Public Works Construction (ISPWC), the 2013
City of Meridian Supplemental Specifications to the ISPWC (and any
Addendums).
See separate attached documents:
Plans - WELL NO. 30 PUMPING FACILITY by Civil Survey
Consultants, lnc. dated December 2016 1le pagesl
Special Provisions and/or Technical Specifications by Civil
Survey Consultants, lnc. dated 4-17-2017 (66 pases)
WELL 30 PUMPING FACILIry
Pro.iect 10012.H page 12 ol 14
REFER TO INVITATION TO BID PW.l736.10012.h
ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the
lnvitation to Bid Package # PW-1736-10012.H, are by this reference
made a part hereof.
Exhibit B
MILESTONE / PAYMENT SCHEDULE
A. Total and complete compensation for this Agreement shall not exceed $583,075.
WELL 30 PUMPING FACILITY
Project 10012.H
MILESTONE DATES/SCHEDULE
Milestone 1 Substantial Completion 150 Days from Notice to Proceed
Milestone 2 Final Completion 180 Days from Notice to Proceed
PRICING SCHEDULE
Contract includes furnishing all labor, materials, equipment, and incidentals as required per IFB
PW-1736-10012.H
NOT TO EXCEED CONTRACT TOTAL $593J25,00
Contract is a not to excoed amount. Line item pricing below will be used for invoice verification and any
additional increases or decreases in work requested by city. The City will pay the contractor based on actual
quantities of each item of work in accordance with th€ contract documents.
Contract Pricing Schedule
Item No.Description Quantity Unit Unit Price
201.4.1.8.1.Clearing and Grubbing 1 LS $ 5,885.00
202.4.1.4.1.Excavation (Plan Unit Quantity)800 CY $ 13,600.00
401.4.1.4.1.12" PVC, AWWA C900, DR18
Water Main 126 LF $ 14,868.00
402.4.1.A.1.12" Gate Valve J EA $ 6,660.00
404.4.1 .A.1 .
1-112"4 Standard Water Service
Connection 1 EA
706.4.1.A.3 Standard 6" Vertical Curb
(No Gutter)155 LF $ 5,425.00
706.4.1.F.1 Concrete Driveway 74 SY $ 5,106.00
802.4.1.A.1 3/4" Minus Crushed Aggregate Base 175 CY
810.4.1.A.3.3" Thick Hot Plant Mix Pavement 698 SY $ 16,0s4.00
Staging Area 1 EA $ 7,0s6.00
1001 .4.2.8.1 .1 EA $ 572.00
1 006.4.1 .C. 1 .4 EA $ 288.00
2010.4.1 .A.1 .Mobilization 1 LS $ 7,1s8.00
2040.4.1 .A.1 .
6' Ornamental Steel Fence with Gates
as Noted 290 LF $ 31,320.00
Submersible Pump and Motor 1 LS $ 44,385.00
SP-2 1 LS $ 24,243.00
page 13 of 14
$ s,898 00
$ 15,050.00
1001 .4.2.A.1 .
Stabilized Construction Entrance
lnlet Protection
SP-1
Discharge Piping
SP-3 Pump House 1 LS $ 162,684.00
SP-4 Chlorination Equipment 1 LS $ 14,401.00
SP.5 Electrical 1 LS $ 'r 23,053.00
Heating, Ventilation and Air
Conditioning 1 LS $ 12,872.00
SP-7 18" Wide Concrete Strip 333 LF $ 10,989.00
SP_8 Permeable Pavers 1,567 SF $ 26,639.00
SP-9 Landscaping 1 LS $ 11,581.00
SP.1O Landscaping lrrigation 1 LS $ 10,358.00
SP-11 Structural Fill 90 CY $ 6,930.00
WELL 30 PUMPING FACILITY
Project l0012.H page 14 of 14
SP.6
City Of t4eridian
Statement of Revenues and Expenditures - Rev and Exp Report - sandra Ilnposted Transactions Included In Report
60 - Eaterpriaa Eund
3490 - Water Constnrction Plojects
Erom la/l/2416 Th,ronq]n 9/30/2077
Blrdget sith Current Year
Actual
Budget
Remaining
Percent of
Budget
Remaining
Capital Outlay
well#30
Total Capita.I Outlay
844, 369 .21
844,369 .21
rl9, r21 .31
1t9, 721 .31
85.89'!
85.899
DEPT EXPENDITURES
TOTAL EXPENDITURES
u44,369.21
844, 369 .21
719,121 .3',7
719,72'7 .31
T25,247 84
125,247.84
85.89t
DaLa: 6/22/ t1 03:41:51 ,.1,i
125 ,24r.8 4
125,24r.84
CITY OF MERIDIAN
Well 30 Pumping Facility
BID ABSTRACT
BID OPENING 2-Jun-17
Item
No.Description Qty Unit Unit
Price
Bid Item
Total
Unit
Price
Bid Item
Total
Unit
Price
Bid Item
Total
Unit
Price
Bid Item
Total
Unit
Price
Bid Item
Total
201.4.1.B.1 Clearing and Grubbing 1 LS 16,200.00$ 16,200.00$ 3,355.00$ 3,355.00$ 3,390.00$ 3,390.00$ 5,885.00$ 5,885.00$ -$ 13,440.00$
202.4.1.A.1.Excavation (Plan Unit Quantity)800 CY 27.85$ 22,280.00$ 22.35$ 17,880.00$ 22.50$ 18,000.00$ 17.00$ 13,600.00$ -$ 33,040.00$
401.4.1.A.1.12” PVC, AWWA C900, DR18 Water Main 126 LF 95.00$ 11,970.00$ 111.84$ 14,091.84$ 113.00$ 14,238.00$ 118.00$ 14,868.00$ -$ 6,384.00$
402.4.1.A.1.12” Gate Valve 3 EA 2,847.00$ 8,541.00$ 2,796.00$ 8,388.00$ 2,825.00$ 8,475.00$ 2,220.00$ 6,660.00$ -$ 9,576.00$
404.4.1.A.1.1-1/2ӯ Standard Water Service Connection 1 EA 7,015.00$ 7,015.00$ 5,623.00$ 5,623.00$ 5,763.00$ 5,763.00$ 5,898.00$ 5,898.00$ -$ 5,432.00$
706.4.1.A.3.Standard 6” Vertical Curb (No Gutter)155 LF 24.00$ 3,720.00$ 40.83$ 6,328.65$ 41.24$ 6,392.20$ 35.00$ 5,425.00$ -$ 868.00$
706.4.1.F.1.Concrete Driveway 74 SY 92.00$ 6,808.00$ 89.50$ 6,623.00$ 90.41$ 6,690.34$ 69.00$ 5,106.00$ -$ 1,960.00$
802.4.1.A.1.3/4” Minus Crushed Aggregate Base 175 CY 54.00$ 9,450.00$ 67.00$ 11,725.00$ 67.80$ 11,865.00$ 86.00$ 15,050.00$ -$ 7,840.00$
810.4.1.A.3.3” Thick Hot Plant Mix Pavement 698 SY 22.00$ 15,356.00$ 47.00$ 32,806.00$ 47.46$ 33,127.08$ 23.00$ 16,054.00$ -$ 23,296.00$
1001.4.2.A.1.Staging Area 1 EA 500.00$ 500.00$ 2,800.00$ 2,800.00$ 1,695.00$ 1,695.00$ 7,056.00$ 7,056.00$ -$ 2,016.00$
1001.4.2.B.1.Stabalized Construction Entrance 1 EA 2,535.00$ 2,535.00$ 2,078.00$ 2,078.00$ 2,090.00$ 2,090.00$ 572.00$ 572.00$ -$ 1,064.00$
1006.4.1.C.1.Inlet Protection 4 EA 113.00$ 452.00$ 84.00$ 336.00$ 84.75$ 339.00$ 72.00$ 288.00$ -$ 1,792.00$
2010.4.1.A.1.Mobilization 1 LS 31,200.00$ 31,200.00$ 74,909.00$ 74,909.00$ 13,500.00$ 13,500.00$ 7,158.00$ 7,158.00$ -$ 39,200.00$
2040.4.1.A.1.6’ Ornamental Steel Fence with Gates as Noted 290 LF 125.00$ 36,250.00$ 104.00$ 30,160.00$ 105.01$ 30,452.90$ 108.00$ 31,320.00$ -$ 38,640.00$
SP-1 Submersible Pump and Motor 1 LS 43,344.00$ 43,344.00$ 44,420.00$ 44,420.00$ 44,070.00$ 44,070.00$ 44,385.00$ 44,385.00$ -$ 46,816.00$
SP-2 Discharge Piping 1 LS 46,632.00$ 46,632.00$ 35,964.00$ 35,964.00$ 9,944.00$ 9,944.00$ 24,243.00$ 24,243.00$ -$ 37,520.00$
SP-3 Pump House 1 LS 122,055.00$ 122,055.00$ 210,056.00$ 210,056.00$ 326,543.00$ 326,543.00$ 162,684.00$ 162,684.00$ -$ 164,171.00$
SP-4 Chlorination Equipment 1 LS 16,867.00$ 16,867.00$ 20,952.00$ 20,952.00$ 20,340.00$ 20,340.00$ 14,401.00$ 14,401.00$ -$ 17,920.00$
SP-5 Electrical 1 LS 135,000.00$ 135,000.00$ 147,000.00$ 147,000.00$ 28,481.00$ 28,481.00$ 123,053.00$ 123,053.00$ -$ 127,456.00$
SP-6 Heating, Ventilation and Air Conditioning 1 LS 20,306.00$ 20,306.00$ 13,562.00$ 13,562.00$ 12,770.00$ 12,770.00$ 12,872.00$ 12,872.00$ -$ 13,522.00$
SP-7 18” Wide Concrete Strip 333 LF 25.00$ 8,325.00$ 41.00$ 13,653.00$ 39.55$ 13,170.15$ 33.00$ 10,989.00$ -$ 2,464.00$
SP-8 Permeable Pavers 1,567 SF 19.00$ 29,773.00$ 28.50$ 44,659.50$ 28.25$ 44,267.75$ 17.00$ 26,639.00$ -$ 20,832.00$
SP-9 Landscaping 1 LS 8,623.00$ 8,623.00$ 23,287.00$ 23,287.00$ 10,283.00$ 10,283.00$ 11,581.00$ 11,581.00$ -$ 18,592.00$
SP-10 Landscaping Irrigation 1 LS 10,800.00$ 10,800.00$ 11,283.00$ 11,283.00$ 7,910.00$ 7,910.00$ 10,358.00$ 10,358.00$ -$ 10,752.00$
SP-11 Structural Fill 90 CY 30.00$ 2,700.00$ 70.00$ 6,300.00$ 67.80$ 6,102.00$ 77.00$ 6,930.00$ -$ 3,360.00$
-$ -$ -$ -$ -$ -$ -$ -$ -$ -$
-$ -$ -$ -$ -$ -$ -$ -$ -$ -$
TOTAL BASE BID 616,702.00$ 788,239.99$ 679,898.42$ 583,075.00$ 647,953.00$
CASCADE ENTERPRISES, INCSTAR CONSTRUCTION CHALLENGER COMPANIES EXCELSIOR CONSTRUCTION IRMINGER CONSTRUCTION
E IDIAN
BID RESULTS
B I D NAM E w I I 30 P FacilityemuInp DUE DATE & TIME: June2,2017 2t3O
BID NUMB ER: PW-1736-10012.h
(
(*-b
VENDOR
E
!
!,
E
tt
d)
a0 :BIO AMOUNT
5T4P- cetu=--t/r'r'V.
I
t.,/t/t/r'lr/,l<./t/,..>
L
z,/),./,/'<<5-a /s-
E
,/,/r',/,/y't
IIIII
tli,HffiA
-
rI
nffiffiffi
,&Gflre'
IDAHO
openedby: S^nJfr- .Arr/r-
Aftest: 4 5d
F><z:z /<:;i-ZA--