Loading...
Public Works Construction Contract with J2 Construction for Idaho Avenue Sidewalk ImprovementsCONTRACT FOR PUBLIC WORKS CONSTRUCTION IDAHO AVENUE SIDEWALK IMPROVEMENTS PROJECT # 6003.57 THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this 11 th day of August, 2015, and entered into by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho, hereinafter referred to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and J2 Construction, hereinafter referred to as "CONTRACTOR", whose business address is 3742 W. Park Creek Dr., Meridian, ID 83642 and whose Public Works Contractor License # is C- 021829 -C-2-3. INTRODUCTION Whereas, the City has a need for services involving IDAHO AVENUE SIDEWALK IMPROVEMENTS; and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS 1. Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Contract and receipt of the City's written notice to proceed, all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Exhibit "A" and incorporated herein by this reference, together with any amendments that may be agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. If any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrighted by the Contractor, the City reserves a royalty -free, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, Idaho Avenue Sidewalk Improvements Project 6003.57 page t of 13 state and city laws, ordinances, regulations and resolutions. The Contractor represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part of the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in a timely manner in accordance with a Schedule of Work, which the parties hereto shall agree to. The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall be compensated on a Not -To -Exceed basis as provided in Exhibit B "Payment Schedule" attached hereto and by reference made a part hereof for the Not -To -Exceed amount of $59,281.00. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, of fees earned and costs incurred for services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Per the requirements of the CDBG Grant weekly certified payroll reports shall be submitted to the City of Meridian. 2.4 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a) completion of the agreed upon work, (b) or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time of termination is listed in Exhibit A. Idaho Avenue sidewalk Improvements page 2 of 13 Project 6003.57 3.2 Should Contractor default in the performance of this Agreement or materially breach any of its provisions, City, at City's option, may terminate this Agreement by giving written notification to Contractor. 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's option, may terminate this Agreement if the failure is not remedied by the City within thirty (30) days from the date payment is due. 4. Liquidated Damages: Substantial Completion shall be accomplished within 75 (seventy five) calendar days from Notice to Proceed. This project shall be considered Substantially Complete when the Owner has full and unrestricted use and benefit of the facilities, both from an operational and safety standpoint, and only minor incidental work, corrections or repairs remain for the physical completion of the total contract. Contractor shall be liable to the City for any delay beyond this time period in the amount of $300.00 (three hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. Upon receipt of a Notice to Proceed, the Contractor shall have 90 (ninety days) calendar days to complete the work as described herein. Contractor shall be liable to the City for any delay beyond this time period in the amount of $300.00 (three hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. See Milestones listed in the Payment Schedule for Substantial Completion. 5. Termination: 5.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails to fulfill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen (15) days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty (60) days notice to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be Idaho Avenue Sidewalk Improvements page 3 of 13 Project 6003.57 entitled to receive just and equitable compensation for any work satisfactorily complete hereunder. 5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to the CITY for damages sustained by the CITY by virtue of any breach of this Agreement by CONTRACTOR, and the CITY may withhold any payments to CONTRACTOR for the purposes of set-off until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR of its liability to the CITY for damages. G. CDBG Grant Requirements: This project is being funded by a Community Development Block Grant. The Davis - Bacon Act applies to this project and it is the responsibility of the Contractor to comply in all aspects of the law. This contract, will be subject to HUD -4010 Federal Labor Standards Provisions attached hereto as "Attachment C" and made a part hereof. Paragraph 2 on page 2 of 5 of HUD -4010 states that the City may withhold payment to Contractor for failure to pay wages when due. Davis -Bacon requires wages to be paid not less often than once a week. All subcontractors and any lower tier subcontractors are subject to the same Davis -Bacon Wage requirements as the general contractor. 7. Independent Contractor: 7.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided in Exhibit A, Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 7.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 7.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of Contractor in fulfillment of this Agreement. If in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. Idaho Avenue Sidewalk Improvements page 4 of 13 Project 6003.57 8. Sub -Contractors: Contractor shall require that all of its sub -contractors be licensed per State of Idaho Statute # 54-1901 9. Removal of Unsatisfactory Employees: The Contractor shall only furnish employees who are competent and skilled for work under this contract. If, in the opinion of the City, an employee of the Contractor is incompetent or disorderly, refuses to perform in accordance with the terms and conditions of the contract, threatens or uses abusive language while on City property, or is otherwise unsatisfactory, that employee shall be removed from all work under this contract. 10. Indemnification and Insurance: 10.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's elected officials, officers, employees, agents, and volunteers from and for any and all losses, claims, actions, judgments for damages, or injury to persons or property and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall maintain, and specificallu agrees that it will maintain, throughout the term of this Agreement, liability insurance, in which the CITY shall be named an additional insured in the minimum amounts as follow: General Liability One Million Dollars ($1,000,000) per incident or occurrence, Automobile Liability Insurance One Million Dollars ($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or judgments for damages or injury to persons or property and other costs, including litigation costs and attorneys` fees, arising out of, resulting from , or in connection with the performance of this Agreement by the Contractor or Contractor's officers, employs, agents, representatives or subcontractors and resulting in or attributable to personal injury, death, or damage or destruction to tangible or intangible property, including use of. CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (10) days prior to the date Contractor begins performance of it's obligations under this Agreement. In the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. Idaho Avenue Sidewalk Improvements page 5 of 13 Project 6003.57 10.2 Insurance is to be placed with an Idaho admitted insurer with a Best's rating of no less than A-. 10.3 Any deductibles, self-insured retention, or named insureds must be declared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 10.4 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City or the City's elected officers, officials, employees and volunteers shall be excess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 10.5 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 10.6 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 10.7 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 11. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. 12. Bonds: Payment and Performance Bonds are required on all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. Contractor is required to furnish faithful performance and payment bonds in the amount of 100% of the contract price issued by surety licensed to do business in the State of Idaho. In the event that the contract is subsequently terminated for failure to perform, the contractor and/or surety will be liable and assessed for any and all costs for the re -procurement of the contract services. Idaho Avenue Sidewalk Improvements page 6 of 13 Project 6003.57 13. Warranty: All construction and equipment provided under this agreement shall be warranted for 2 years from the date of the City of Meridian acceptance per the ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items found to be defective during a warranty inspection and subsequently corrected will require an additional two (2) year warranty from the date of City's acceptance of the corrected work. 14. Changes: The CITY may, from time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the same formalities as this Agreement. 15. Taxes: The City of Meridian is exempt from Federal and State taxes and will execute the required exemption certificates for items purchased and used by the City. Items purchased by the City and used by a contractor are subject to Use Tax. All other taxes are the responsibility of the Contractor and are to be included in the Contractor's Bid pricing. 16. Meridian Stormwater Specifications: All construction projects require either a Storm Water Pollution Prevention Plan (SWPPP) or an erosion sediment control plan (SSCP) as specified in the City of Meridian Construction Stormwater Management Program (CSWMP) manual. The CSWMP manual containing the procedures and guidelines can be found at this address: http://www.meridiancity,org/environmental.aspx?id=13618. 17. ACRD: Contractor shall be responsible for coordinating with the City to obtain appropriate ACRD permit(s) and will reimburse the City for fees, fines, or penalties City incurs due to Contractor's violation of any ACHD policy. City shall certify to ACHD that Contractor is authorized to obtain a Temporary Highway and Right -of -Way Use Permit from ACHD on City's behalf. The parties acknowledge and agree that the scope of the agency granted by such certification is limited to, and conterminous with, the term and scope of this Agreement. Idaho Avenue Sidewalk Improvements page 7 of 13 Project 6003.57 18. Reports and Information: 18.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 18.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement for a minimum of four (4) years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographic and every other means of recording upon any tangible thing, any form of communication or representation including letters, words, pictures, sounds or symbols or any combination thereof. 19. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. 20. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 21. Equal Employment Opportunity: In performing the work herein, Contractor agrees to comply with the provisions of Title VI and VII of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code Section 2176. Specifically, the Contractor agrees not to discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. Contractor will take affirmative action during employment or training to insure that employees are treated without regard to race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. In performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. Idaho Avenue Sidewalk Improvements page 8 of 13 Project 6803.57 22. Employment of Bona Fide Idaho Residents: Contractor must comply with Idaho State Statute 44-1002 which states that the Contractor employ ninety-five percent (95%) bona fide Idaho residents. 23. Advice of Attorney: Each party warrants and represents that in executing this Agreement. It has received independent legal advice from its attorney's or the opportunity to seek such advice. 24. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. 25. Construction and Severability: It any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 26. Waiver of Default: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. 27. Entire Agreement: This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. 28. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent of CITY. Idaho Avenue Sidewalk Improvements page 9 of 13 Project 6003.57 29. Payment Request: Payment requests shall be submitted to City of Meridian through the City's project management software, if requested by the Project Manager. The Project Manager will compare the invoice against the Payment Schedule in the Agreement for compliance. Upon approval that the work has been done and is in compliance with the Agreement, the Project Manager will approve the pay request for processing. City of Meridian payment terms are Net 30 from the date City receives a correct invoice. Final payment will not be released until the City has received a tax release from the Tax Commission. 30. Cleanup: Contractor shall keep the worksite clean and free from debris. At completion of work and prior to requesting final inspection, the Contractor shall remove all traces of waste materials and debris resulting from the work. Final payment will not be made if cleanup has not been performed. 31. Order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted bid document. 32. Compliance with Daws: In performing the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 33. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 34. Notices: Any and all notices required to be given by either of the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY CONTRACTOR City of Meridian J2 Construction Purchasing Manager Attn: Duane Spooner 33 E Broadway Ave 3742 W. Park Creek Dr Meridian, ID 83642 Meridian, ID 83642 208-489-0417 Phone: 208-401-4731 Email: i2construction1218 c1maii.corn Idaho Public Works License #C -021829-C-2-3 Idaho Avenue Sidewalk Improvements page 10 of 13 Project 6003.57 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 35. Approval Required: This Agreement shall not become effective or binding until approved by the City of Meridian. CITY M€ URIAN TAMMY de ry ` D, MAYOR Dated: g7a /. Approved by Council: J2 CONSTR CTION BY: DUAN POONER Dated:_ _-7-3/-?®/,- C4p�TTiT3 it UCAS City of (YTCL m -�- DAN& ��++����771UAN 0- �Q SEAL V Purchasing Approval ""ITH BY: Zz,�,/�''f KEIT ATS, OAKas'inj Manager Dated:: Project Manager Jay Gibbons Idaho Avenue Sidewalk Improvements Project 6003.57 ISQ� Departure Approval BY: 0 STEVE SIDDOWAY, Parks & Rec Director Dated:122xr page 11 of 13 : _IFS] SCOPE OF WORK REFER TO INVITATION TO BID PKS-15-6003.57 ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation to Bid Package # PKS-15-6003.57, are by this reference made a part hereof. SPECIFICATIONS I SCOPE OF WORK All construction work shall be done in accordance with the 2012 version of the Idaho Standards for Public Works Construction (ISPWC), the 2013 City of Meridian Supplemental Specifications to the ISPWC (and any Addendums). See separate attached documents: • PLANS NAME BY Civil Survey Consultants dated April 14, 2015 (6 pages) • SPECIAL PROVISIONS by Civil Survey Consultants dated March 10, 2015 (is pages) Idaho Avenue Sidewalk Improvements page 12 of 13 Project 6303.57 Exhibit B MILESTONE 1 PAYMENT SCHEDULE A. Total and complete compensation for this Agreement shall not exceed $59,261.00. CONTRACT TOTAL ....................... 61, I CONTRACT IS A NOT TO EXCEED AMOUNT. LINE ITEM PRICING BELOW WILL BE USED FOR INVOICE VERIFICATION AND ANY ADDITIONAL INCREASES OR DECREASES IN WORK REQUESTED BY CITY. Contract Pricing Schedule Item No. Description Quantity Unit Unit Price 201.4.1.C,1 Removal of obstructions 1 LS $4,500.00 307.4.1.E.1 Type c surface restoration 67 SY $17.50 307.4.1.G.1 Type p surface restoration 110 SY $31.50 706.4.1.A.1 Standard 3" rolled curb and gutter 24 LF $40.00 706.4.1.E.1 Concrete sidewalk, 5" thickness 779 SY $44,00 706.4.1.G.1 Concrete repair 33 SY $55.00 706.4.1.1-1.1 Ada pedestrian ramp with Detectable warning domes 1 EA $1,400.00 1001.4.2.A.1 Staging area 1 EA $500.00 1006.4.1.C.1 Inlet protection 15 EA $50.00 1103.4.1.A.1 Traffic control 1 LS $2,500.00 2010.4.1.A.1 Mobilization 1 LS $5,000.00 513-1 Lawn sod restoration 1918 SF $1.25 SP -2 Adjust water meter to grade 3 EA $75.00 SP -3 Replace water meter lid 2 EA $150.00 Idaho Avenue Sidewalk Improvements page 13 of 13 Project 6003.57 u LLJ LU w w 17, z D 0 sqns # Oil PUOQ Pie POUBIS w 0 a z uj IINI�:�� 0o�wun mo�m�n �aae� nn IDSOS Viewing Business Entity Page 1 of 1 )! YLiq IDAHO SECRETARY OF STATE Viewing Business Entity zm- Lawerence Denney, Secretary of State ry New Search ] [Back to Summa ] ,5,....�._.�. [ Monitor 32 CONSTRUCTION business filings ] 32 CONSTRUCTION 3742 W PARK CREEK DR MERIDIAN, ID 83642 Type of Business: ASSUMED BUSINESS NAME Status: CURRENT State of Origin: IDAHO Date of 18 Dec 2014 Origination/Authorization: File Number: D175579 wd ; e:::: [ Help Me Print/View TIFF ] Filed 18 Dec 2014 ORIGINAL. View Image (PDF format) View FILING Image (TIFF format) Idaho_ Secretary of State's Main Page State of Idaho Home Page Comments, questions or suggestions can be emailed to: sos1nfoC5)sos.idaho.gov bttp://www.accessidatio.org/public/sos/corp/D 175579.html 7/27/2015 AIA Document A312 TM .2010 Performance Bond CONTRACTOR: {Name, legal status and address) Duane Spooner dba J2 Construction 3742 W Park Creek Drive Meridian, Idaho 83642 OWNER: (Name, legal status and address) City of Meridian 33 E Broadway Ave Meridian, Idaho 83642 CONSTRUCTION CONTRACT Date: August 11, 2415 Amount: $59,261.00 SURETY: (Name, legal status and principal place of business) Developers Surety and Indemnity Company Five Cante€pointe, Suite 530 Lake Osweqo, Oregon 97035 Description: (Name and location) Idaho Ave Sidewalk Improvements Project 6003.57 BOND Date: August 11, 2015 (Not earlier than Construction Contract Date) Amount: $59,261.00 Modifications to this Bond: ® None ❑ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Am r Bond No. 757244P This document has Important legal consequences. Consultation Kith an attorney Is encouraged with respect to Its comptatlon or modification. Arty singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2810 combines two separate bonds, a Performance Bond and a Payment Bond, Into ane ions. This is not a single combined Performance and Payment Bond, Duane Spooner d a J2 Construction Developers Surety and Indemj(ni Company Signature: Signature:go . NamepulsvcSPao+,r are Jit K Holth us, Attorney -in -Fact and Title: ar:d Title: (Arty additional signan( appear on the last page ofthis Performance Bond) (FOR INF0AWTION ONLY-- Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Allied Bonding (Architect, Engineer or other parry:) 5605 Overland Rd. Boise, ID 83705 Phone (208) 345-4177 Fax (208) 384-1677 Ink AtA Dooumnn! A312'"-2010. The American Inetltute of Archtp . omelo § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 Ifthere is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner fust provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surely may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § S When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 6.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 6.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surely perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. tnit. AM Document A312TM — 2010. The Amedeen lnaftrbe of Arehftwu. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract, Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § B If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 8 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § it Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default, Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Intl AIA Doaument A3127% -2olo. The Amerkan lnaMute of Awhitects. § 16 Modifications to this bond are as follows: None (Space is provided below for additional signatures of added parties, other than those appearing on the cover page) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title; Address Signature, Name and Title: Address CAUTION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not be obscured. Inst AIA Document A312Tm -2010. The American Inaftte dArchimabe. RECEIVED JUL 3 4 2015 AIA Document A312 TM -.201 61NANCE °Epy Payment Bond Bond No. 757244P CONTRACTOR: (Name, legal status and address) Duane Spooner dba J2 Construction 3742 W Park Creek Drive Meridian, Idaho 83642 OWNER: (Name, legal status and address) City of Meridian 33 E Broadway Ave Meridian, Idaho 83642 CONSTRUCTION CONTRACT Date: August 11, 2015 Amount: $59,261.00 SURETY: (Name, legal status and principal place of business) Developers Surety and Indemnity Company Five Centerpointe, Suite 530 Lake Oswego, Oregon 97035 Description: (Name and location) Idaho Ave Sidewalk Improvements Project 6003.57 BOND Date: August 11, 2015 Not earlier than Construction Contract Date) Amount: $59,261.00 Modifications to tins Bond: ® None ❑ See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seat) Company: (Corporate Seal) Duane Spooner db J2 Construction Developers.§qrety and Indem ity Compan Signature: twe: atL Name lbrei4�t"AO�r r Name et K Holthaus, Attorney -In -t=act and Title: 7 I -FOtS` and Title: (Any additional signatures appear on the last page of this Payment Bond) (FOR INFOMM TION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Allied Bonding (Architect, Engineer or other party:) 5605 Overland Rd. Boise, ID 83705 Phone (208) 345-4177 Fax (208) 384-1677 This document has important legal consequences. Consultation with an attorney Is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AtA DocumentA312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, Info one form. This Is not a single combined Performance and Payment Bond. Inge Ali► D0GWr#snt A712'■ -2010. The Amedcan lratkuts of Arennects. WHO 5 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terns. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless tate Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. 14 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § S If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections S.I or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § S The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. Init. AJA ti MMIM AMTM -2010. The Amedcan insftft of Amhhecte. I 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations, § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5. 1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (l) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 16 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Qeflnitlone § 16.1 Claim. A written statement by the Claimant including at a minimum., .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .T the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents, Int. ""R aooumen%w.71W- -2010. TM Amerfcan InstHute atAmhitacts, POWER OF ATTORNEY FOR DEVELOPERS SURETY AND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box 19725, IRVINE, CA 92623 (949) 283-3304 KNOWALL BY THESE PRESENTS that except as expressly limited, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, do each hereby make, constitute and appoint: ***Karyl A. Richter, Janet K. Hoithaus, jointly or severally*** as their he and lawful Attomey(s)4n•FaGk to make, execute, deliver and acknowledge, for and an behalf of said corporations, as sureties, bonds, undertaWngs and contracts of suretyship giving and granting unto said Attomey(s)-in•Fact full power and authority to do and to perform every act necessary, requisite or proper to be done In connection therewith as each of said corporations could do, but reserving to each of sold oorporatens full power of substitution and revocation, and all of the acts of said Attomay(s)-in•Fact, pursuant to these presents, are hereby ratified and confirmed. This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolutions adopted by the respective Boards of Directors of DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, effective as of January 1st, 2448, RESOLVED, that a combination of any Iwo of the Chairman of the Board, time President, Executive Vice•Prosident, Se€uor Vice-Presldant or any Vice President of the corporations be, and that each of them hereby is, authorized to execute this Power of Attorney, qualifying the aftomey(s) named In the Power of Attorney to execute, on behalf of the corporations, bonds, undertakings and contracts of suretyship, and that the Secretary or any Assistant Secretary of either of the corporations be, and each of them hereby Is, authorized to attest the execution of any such Power of Attorney, RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attomey or to any certificate relating thereto by facsimile, and any such Power ofAftomey or eerfificate bearing such Iacsimife signatures shalt be valid and binding upon the corporations when so affixed and In the futurewith respect to any bond, undertaking or contract of suretyship to which It is attached. IN WITNESS WHEREOF, DEVELOPERS SURETYAND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA have severally caused these presents to be signed by their respective officers and attested by their respective Secretary or Assistant Secretary this January 29, 2015. f , r.r, 1.001 �i ANI) P AN Y 8y. Daniel Young, Senior Vice -President O 'os`��vpN p R j �>y's Al POR �'cn ems.ui:: r]CT =mac£ = OCT. 5 �� 'sm By: s C 193 6 .- 1967 Z Mark Landon, Vice -President �'•,j�7 roW P ` A notary public or other officer completing this certificate verifies only the identity of the Individual who signed the document to which this certificate Is attached, and not the truthfulness, accuracy, or validity of that document State of California County of Orange On — _..___ January 29, 2015 before me, Ludlle Raymond, Notary Public Date Itara Insed N&m aM'riflaatWeoffa*r personally appeared appeared -- ------.....---.... _ . Daniel Youg and Mark Lansdon N—(s)ef*—(&) --------- „- LUCILLE RAYMOND 7 Commission 0 2081945 -� Notary Public - California Orange Conty -* M Comm. Wires Oct 13 2010 Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) Islare subscribed to the within Instrument and acknowledged to me that helshelthey executed the same in his/ref/their authorized capacity(ies), and that by hWherltheir signature(s) on the instrument the parson(s), or the entity upon behalf of which the person(s) acted, executed the instrument, I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my Land and official seal. Signature _ Lucia Dori, Notary Pnblio R�� CERTIFICATE The undersigned, as Secretary orAsslstant Secretaryof DEVELOPERS SURETYAND INDEMNITY COMPANY or INDEMNITY COMPANY OF CALIFORNIA, does hereby certify that the foregoing Power of Attomey remains in fuli farce and has not been revoked and, hrrthermore, that the provisions of the fesolutions of the respactiva Boards of Dlrectors of said corporations set fo€th in the Power of Attorney are in force as of the date of this Certificate. %� This Certificate Is executed in the City of Irvine, California, this day of By: &.-At� ,j Cassie J. rrisford, Assistant Secplary r Iia-138D(Rev.O tf15) J2CON-2 OP ID: TH CERTIFICATE OF LIABILITY INSURANCE CUVtrcAGES CERTIFICATE NUMBER: REVISION NUMBER• THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. DATE 07{33010/ 15 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 208-322-5525 RICKETTS AND ASSOCIATES INC 13177 W PERSIMMON LANE 208-377-0203 CON NAMEACT Tracy Higgs AI1c° No ext;208-322-5525 tile, Not: 208-377-0203 BOISE, ID 83713 Tracy Ann Higgs E-MAIL ADDRESS: traCy@rickettsinsurance.corn INSURER(S) AFFORDING COVERAGE NAIC q . _ INSURERA:AUTO OWNERS INSURANCE INSURED J2 CONSTRUCTION Duane Spooner dba INSURER B INSURER C: 3742 W Park Creek Dr Meridian, ID 83642 INSURER D, INSURER E: INSURER F: GEN'L AGGREGATE LIMIT APPLIES PER: POLICY FX]PRO JEC LOC CUVtrcAGES CERTIFICATE NUMBER: REVISION NUMBER• THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ILTR TYPE OF INSURANCE D UBR POLICY NUMBER 1NM10lDNYYY MMID�IIYYYY LIMITS A GENERAL LIABILITY X COMMERCIALGENFFtALLIABILITY CLAIMS -MADE 1x:1 J OCCUR X 57301032 03/19/15 03119116 ACH OCCURRENCE $ 1,000,000 =1.0 PREMISES Maccurrence $ 300,000 MED EXP (Anyone person) 10,000 _$ PERSONAL & ADV INJURY $ 1,000,000 GENERALAGGRFGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: POLICY FX]PRO JEC LOC PRODUCTS - COMPIOP AGG $ 2,000,000 $ A AUTOMOBILE LIABILITY ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS HIRED AUTOS X NON -OWNED AUTOS 57301032 03119/15 03/19/16 COMBINED SINGLE LIMIT Fa accident 1,000,000 X BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE Peraccident $ $ A X UMBRELLALIAB EXCESS LIAR X OCCUR CLAIMS -MADE 5030103200 03/25115 03119/16 EACH OCCURRENCE $ 1,000,000 AGGREGATE $ 1,000,000 DED RETENTION$ $ WORKERS COMPENSATIONWC AND EMPLOYERS' LIAB€LITY YIN ANY PROPRIETORIPARTNERfEXECUTIVE OFFICERIMEMBER EXCLUDED? (Mandatory In NH) If yes, describe under DESCRIPTION OF OPERATIONS below N I A STATU- OTH- TORY LIMITS ER E.L. EACH ACCIDENT $ E.L-DISEASE - EA EMPLOYE $ E.L- DISEASE - POLICY LIMIT $ DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES {Attach ACORD 161, Additional Remarks Schedule, if more space is required) CERTIFICATE HOLDER rrANrP1 l ATtnnl CITYM-2 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN CITY OF MERIDIAN ACCORDANCE WITH THE POLICY PROVISIONS. Attn: Purchasing Manager AUTHORIZED REPRESENTATIVE Tracy Ann Higgs 33 E BROADWAY AVE, STE 106 MERIDIAN, ID 83642 ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD Search Results I System for Award Management View assistance for Search Results Search Results Current Search Terms: 32 construction* Notice; This printed document represents only the first page of your SAM search results. More results may be available. To Print Your complete search results ou can download the PDF and print it, io records found for current search. SAN i System for Award Management 1,0 Note to all Users: This is a Federal Government computer system. Use of this system constitutes consent to moni6Ddng at all times. Glossary Search Results Entity Exclusion Search Fitters By Record Status By Functional Area - Entity Management By Functional Area - Performance Information IBM v1.P.34.2 1 10-1415 �USA,gpv Errs Page 1 of 1 https://www.sam.gov/portal/SAM/?navigationalstate=JBPNS rOOABXdcACJgYXZheC5m... 8/3/2015 eTRAKiT Home I Selup an Account I Login COnUaCfOf V Username Passyiorc! LOGIN © REMEMBER ME Forgot Password Page 1 of 1 Permits Apply Public Works Search f-' Search Again Bownload ReSUILS PriNable View Search Pay Fees LicensesJ2 Construction 021829 00002 ppp03 2, 3 C ACTIVE J2 Construction Search Trade Licenses Search Pubic Works Inspections Firsk Prey Page: 1 of 1 g Nez 'Last) Schedule Can Caoce/ -� ;Details - License Number: 021828 -- ' Elevators - Info Fees $175.00 Search Elevators - Violations Registration #: 021829 Search StiO In Cart pp Issue: 1/29/2015 Pay Ali Fees Expire: 1/31/2016 Contact Type: PUBLIC WORKS Contact us Sub -Type: C Status: ACTIVE Company: J2 Construction Phone: (208)376-7168 Celt: (208) 401-4731 Pager: Pax: Owner Name: The Division of Building Safety, stakes every effort to produce and publish the most current and accurate information possible. No warranties, expressed or implied, are provided for the data herein, its use, or its interpretation. Utilization of this vmbsite indicates undesslanding and acceptance of this statement. 1-890-955-3044, 1690 E Walartavw Si, Suite 150 Meridian ID 83642 FUME I CONTACT https://web.dbs,idaho.gov/eTRAKiT3/Custom/ldaha PublieWorksSearchRslts.aspx 7/27/2015 7fl r dl O r -I N O M M M M M M M O O 4 CD 0 O N O O H N O W W 44 bi O o M €- o m 0 o m m V• 4 O Ln co 61 4 CO CO ri ri U � � Ui W' 4L O O O O 4- d O r c- o O O O 4 O O 4 O iTl ) 'rf 47 N OO M ri r A 4 A) F. (n m coaD 4 01 M o r -I r -I ul It `d ro ri N >` -:I t9 O M M rl r -I Y{ Lf) O O fA N rl dl W xN 4 4 4 4 M 4 O M M }A O Cl O O U% O O m m ¢ 0 0 4 >i ri ri o o O Sf1 i- O ri O O N H l0 k0 �{ ri N dl d' U O O 0 0 0 0 4 4 4 O O 0 0 O O O O O 4-J 4-J '3 r- IT f0 0 o o M O 0 o O o o o 'A N ri N 44 W r O O O O H H rI uF M M r CO o Ol a b1 NNy rI M N r -i Ln dl v W M N 14 14 RI PE W w 1 U) 4 U) 1� k rd 11 r -i .'T'zs 4r -I E f� 5-) Y ill -1 b) >, H .j 47 � m O •rl N 4q. Ww N El.01 A U O t r-[ Ct'i 4) � E ,t V) P, H z�AIs° roro vr60 �'�� fd P, t -i [1 ai Pt Fi Com+ F t U +)W Z f-. 4-J W H W P4 w O R 7fl r dl O r -I N O M M M M M M M O O 4 CD 0 4 4 0 0 0 0 0 0 0 0 a W w l0 lO kD k➢ l0 co do r m OD r O ti H 3 M O W M Jl r O l0 d' O si N ri m Q H d�