Loading...
2015-06-23ILS CITY COUNCIL REGULAR MEETING AGENDA City Council Chambers 33 East Broadway Avenue Meridian, Idaho Tuesday, June 23, 2015 at 6:00 PM Roll -Call Attendance X David Zaremba X_ Joe Borton _X Charlie Rountree X Keith Bird X_ Genesis Milam X Luke Cavener X Mayor Tammy de Weerd 2. Pledge of Allegiance Community Invocation by Steve Moore with Ten Mile Christian Church 4. Adoption of the Agenda Adopted 5. Consent Agenda Approved A. FP 15-020 Paramount Square Subdivision by Brighton Investments, LLC Located Northwest Corner of N. Meridian Road and W. McMillan Road Request: Final Plat Approval Consisting of Twenty (20) Commercial Buildable Lots and One (1) Multi -Family Residential Lot on Approximately 31.95 Acres in the C -G and R-40 Zoning Districts B. Findings of Fact, Conclusions of Law: RZ 15-006 Three Corners by Sweet Land Development, Inc. Located Southeast Corner of N. Locust Grove Road and Chinden Boulevard Request: Rezone of Approximately 12.65 Acres of Land from the C -C (Community Business), R-8 (Medium Density Residential) and R-4 (Medium -Low Density Residential) Zoning District to the C -C (9.38 Acres), R-8 (2.76 acres) and R-4 (0.51 Acres) Zoning Districts C. Findings of Fact, Conclusions of Law: CPAM 15-001 Hill Properties/Century Farm School by Martin Hill, Hill & Hill Properties and Brighton Investments Located East Side of S. Eagle Road and South Side of E. Amity Road Request: Amendment to the Comprehensive Plan Future Land Use Map to Change the Future Land Use Designation on 87.01 Acres of Land from Low Density Residential to Mixed -Use Neighborhood Meridian City Council Meeting Agenda — Tuesday, June 23, 2015 Page 1 of 4 All materials presented at public meetings shall become property of the City of Meridian. Anyone desiring accommodation for disabilities related to documents and/or hearing, please contact the City Clerk's Office at 888-4433 at least 48 hours prior to the public meeting. D. Findings of Fact, Conclusions of Law: AZ 15-004 Hill Properties by Martin Hill and Hill & Hill Properties Located East Side of S. Eagle Road and the South Side of E. Amity Road Request: Annexation of 78.62 Acres of Land with the R-8 (39.83 Acres) and C -N (38.79 Acres) Zoning Districts E. Findings of Fact, Conclusions of Law: RZ 15-007 Century Farm School by Brighton Investments Located 114 Mile South of E. Amity Road and 1l2 Mile East of S. Eagle Road Request: Rezone of 8.39 Acres of Land From the R-8 to the C -N Zoning District F. Final Order for Approval: FP 15-019 Oak Leaf Subdivision No. 2 by Oak Leaf Development Company, Inc. Located North of Chinden Boulevard and West of N. Jayker Way Request: Final Plat Approval Consisting of Eleven (11) Single Family Residential Lots on Approximately 7.99 Acres in the R-2 Zoning District G. Addendum B to September 23, 2013 Professional Services Agreement for Animal Control Services and Dog Licensing Between the City of Meridian and the Idaho Humane Society H. Approval of Award of Bid and Agreement to C & A Paving Company for the "CITY HALL WEST SIDE PARKING LOT" Project for a Not -To -Exceed amount of $239,540.75 I. West Ada School District Water Easement J. Release of Water Easement Instrument # 103007924 for Meridian Joint School District No. 2 K. Acknowledgement of Terms of Idaho Power Surplus Property Bill of Sale to City of Meridian of Wooden Distribution Pole L. Professional Services Agreement with DesignWorks Creative Inc. for Website Management Services for the Meridian Anti -Drug Coalition for a Not -to -Exceed Amount of $4,812.00 Annually for Four Years M. Professional Services Agreement with Monte Stiles for Policy and Advocacy Consultant Services for the Meridian Anti -Drug Coalition for the Not -to -Exceed Amount of $15,000.00 Annually for Four Years 6. Items Moved From Consent Agenda None 7. Action Items A. FP 15-022 Caven Ridge Subdivision No. 1 by New Cavanaugh, LLC Located East Side of S. Meridian Road and South of the Ridenbaugh Canal Request: Meridian City Council Meeting Agenda —Tuesday, June 23, 2015 Page 2 of 4 All materials presented at public meetings shall become property of the City of Meridian. Anyone desiring accommodation for disabilities related to documents and/or hearing, please contact the City Clerk's Office at 888-4433 at least 48 hours prior to the public meeting. Final Plat Approval Consisting of Thirty -Seven (37) Building Lots and Nine (9) Common Area Lots on 14.06 Acres of Land in the R-8 Zoning District Continued to July 7, 2015 B. FP 15-021 Fall Creek Subdivision No. 2 by Coleman Homes, LLC Located South of W. Overland Road and East of S. Linder Road Request: Final Plat Approval Consisting of Thirty -Nine (39) Building Lots and Four (4) Common Lots on 12.51 Acres of Land in the R-8 Zoning District Approved C. Public Hearing: PP 15-008 Normandy Subdivision by Schultz Development Located at 4145 S. Locust Grove Road Request: Preliminary Plat Approval Consisting of 110 Building Lots and 9 Common Lots on 26.93 Acres of Land in an R-8 Zoning District Approved D. Public Hearing: AZ 15-003 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request: Annexation and Zoning of 30.21 Acres of Land with an R-4 Zoning District Approved E. Public Hearing: PP 15-005 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request: Preliminary Plat Approval Consisting of Seventy -Eight (78) Building Lots and Fifteen (15) Common Lots on 30.2 Acres of Land Approved F. Public Hearing: VAC 15-006 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request Approved 8. Department Reports A. Continued from June 16, 2015: Legal and Fire Departments: Memorandum of Understanding and Agreement between the City of Meridian and the Meridian Rural Fire Protection District Continued to July 7, 2015 B. Legal Department Report: Updates to Meridian City Code to comply with updates to Idaho Code and to reclassify penalties C. Ordinance No. 15-1647: Updates To Meridian City Code To Comply With 2015 Updates To Idaho Code And To Reclassify Violation Penalties Approved D. Public Works: Budget Amendment for FY2015 in the Amount of $175,000.00 for Well 27 Water Treatment Facility Equipment Procurement Approved Meridian City Council Meeting Agenda—Tuesday, June 23, 2015 Page 3 of All materials presented at public meetings shall become property of the City of Meridian. Anyone desiring accommodation for disabilities related to documents and/or hearing, please contact the City Clerk's Office at 888-4433 at least 48 hours prior to the public meeting. E. Public Works: Budget Amendment for FY2015 in the Amount of $444,699.00 for the Design of the Wastewater Resource Recovery Facility Capacity Expansion Project Approved 9. Ordinances A. Ordinance No. 15-1648: An Ordinance (RZ 15-006 Three Corners Subdivision) for the Re -zone of a parcel of land located in the NW '/4 of the NW'/4 of Section 29, Township 4 North, Range 1 East, Boise Meridian, City of Meridian, Ada County, Idaho Establishing and Determining the Land Use Zoning Classification of Said Lands from C -C (Community Business) zoning district, R-8 (Medium Density Residential) zoning district and R-4 (Medium -Low Density Residential) zoning district to C -C (Community Business) zoning district (9.38 acres), R-8 (Medium Density Residential) zoning district (2.76 acres) and R-4 (Medium -Low Density Residential) zoning district (0.51 acres. Approved 10. Future Meeting Topics Adjourned at 7:42 p.m. Meridian City Council Meeting Agenda —Tuesday, June 23, 2015 Page 4 of 4 All materials presented at public meetings shall become property of the City of Meridian. Anyone desiring accommodation for disabilities related to documents and/or hearing, please contact the City Clerk's Office at 888-4433 at least 48 hours prior to the public meeting. Meridian City Council June 23, 2015 A meeting of the Meridian City Council was called to order at 6:00 p.m., Tuesday, June 23, 2015, by Mayor Tammy de Weerd. Members Present: Mayor Tammy de Weerd, Charlie Rountree, Keith Bird, David Zaremba, Joe Borton, Genesis Milam and Luke Cavener. Others Present: Bill Nary, Jaycee Holman, Bruce Chatterton, Sonya Watters, Kyle Radek, Scott Colianni, Chris Amenn, David Allison, Mike Barton, and Dean Willis. Item 1: Roll -call Attendance: CR.71M X David Zaremba X Joe Borton X Charlie Rountree X Keith Bird X Genesis Milam _X Lucas Cavener X Mayor Tammy de Weerd De Weerd: I will go ahead and get tonight's meeting started. I'd like to welcome you all to our City Council meeting. It's always nice seeing members of the public here joining us. For the record it is Tuesday, June 23rd. It's 6:00 p.m. We will start with roll call attendance, Madam Clerk. Item 2: Pledge of Allegiance De Weerd: Item No. 2 is the Pledge of Allegiance. If you will all rise and join us in the pledge to our flag. (Pledge of Allegiance recited.) Item 3: Community Invocation by Steve Moore with Ten Mile Christian Church De Weerd: Item No. 3 is our community invocation. Tonight we will be led by Pastor Steve Moore with the Ten Mile Christian Church. If you will all join us in the community invocation or take this as an opportunity for a moment or reflection. Thank you for joining us, pastor. Moore: It's an honor to be here. Our Father who is in Heaven, I was just thinking as I was driving here and thank you for that thought, that people that are in this room have a lot of authority and they make decisions that affect so many lives, but, God, I know the history of a lot of these folks and they were are all servants before they were elected to office. They have been servants in this city and I pray, God, that you would honor that heritage. I pray, God, that the decisions that they make will be made continually through a heart of the servant. I pray for us as citizens of this city and this community that we would be involved. I pray that this community will only improve because of factors like that. Meridian City Council June 23, 2015 Page 2 of 40 Especially tonight, God, specifically I pray for this meeting, the decisions that are made, that they would be for the prosperity of this community in all ways. God, we -- we want your help to be a harmonious community, one in which people contribute. I pray that we would -- we not forget those who have less than us and that we would operate as Jesus himself would on a daily basis, in the name of Christ I pray, amen. De Weerd: Thank you, Pastor Steve. Moore: Thank you. Item 4: Adoption of the Agenda De Weerd: We appreciate you joining us. Item No. 4 is adoption of the agenda. Rountree: Madam Mayor? De Weerd: Mr. Rountree. Rountree: On the agenda Item No. 7-A has been requested to continue to July 7th. On Item 8-A, that has been requested to continue again until July 7th. On Item 8-C the ordinance number is 15-1647 and Item 9-A the ordinance number is 15-1648 and with those additions, Madam Mayor, I move that we approve the agenda. Bird: Second. De Weerd: I have a motion and a second to approve the agenda as read. All those in favor say aye. All ayes. Motion carried. MOTION CARRIED: ALL AYES. Item 5: Consent Agenda A. FP 15-020 Paramount Square Subdivision by Brighton Investments, LLC Located Northwest Corner of N. Meridian Road and W. McMillan Road Request: Final Plat Approval Consisting of Twenty (20) Commercial Buildable Lots and One (1) Multi - Family Residential Lot on Approximately 31.95 Acres in the C -G and R-40 Zoning Districts B. Findings of Fact, Conclusions of Law: RZ 15-006 Three Corners by Sweet Land Development, Inc. Located Southeast Corner of N. Locust Grove Road and Chinden Boulevard Request: Rezone of Approximately 12.65 Acres of Land from the C -C (Community Business), R-8 (Medium Density Residential) and R-4 (Medium - Low Density Residential) Zoning District to the C -C (9.38 Acres), R-8 (2.76 acres) and R-4 (0.51 Acres) Zoning Districts Meridian City Council June 23, 2015 Page 3 of 40 C. Findings of Fact, Conclusions of Law: CPAM 15-001 Hill Properties/Century Farm School by Martin Hill, Hill & Hill Properties and Brighton Investments Located East Side of S. Eagle Road and South Side of E. Amity Road Request: Amendment to the Comprehensive Plan Future Land Use Map to Change the Future Land Use Designation on 87.01 Acres of Land from Low Density Residential to Mixed -Use Neighborhood D. Findings of Fact, Conclusions of Law: AZ 15-004 Hill Properties by Martin Hill and Hill & Hill Properties Located East Side of S. Eagle Road and the South Side of E. Amity Road Request: Annexation of 78.62 Acres of Land with the R-8 (39.83 Acres) and C -N (38.79 Acres) Zoning Districts E. Findings of Fact, Conclusions of Law: RZ 15-007 Century Farm School by Brighton Investments Located 114 Mile South of E. Amity Road and 112 Mile East of S. Eagle Road Request: Rezone of 8.39 Acres of Land From the R-8 to the C -N Zoning District F. Final Order for Approval: FP 15-019 Oak Leaf Subdivision No. 2 by Oak Leaf Development Company, Inc. Located North of Chinden Boulevard and West of N. Jayker Way Request: Final Plat Approval Consisting of Eleven (11) Single Family Residential Lots on Approximately 7.99 Acres in the R-2 Zoning District G. Addendum B to September 23, 2013 Professional Services Agreement for Animal Control Services and Dog Licensing Between the City of Meridian and the Idaho Humane Society H. Approval of Award of Bid and Agreement to C & A Paving Company for the "CITY HALL WEST SIDE PARKING LOT" Project for a Not -To -Exceed amount of $239,540.75 West Ada School District Water Easement J. Release of Water Easement Instrument # 103007924 for Meridian Joint School District No. 2 K. Acknowledgement of Terms of Idaho Power Surplus Property Bill of Sale to City of Meridian of Wooden Distribution Pole L. Professional Services Agreement with DesignWorks Creative Inc. for Website Management Services for the Meridian Anti -Drug Coalition for a Not -to -Exceed Amount of $4,812.00 Annually for Four Years Meridian City Council June 23, 2015 Page 4 of 40 M. Professional Services Agreement with Monte Stiles for Policy and Advocacy Consultant Services for the Meridian Anti -Drug Coalition for the Not -to -Exceed Amount of $15,000.00 Annually for Four Years De Weerd: Item 5 is our Consent Agenda. Rountree: Madam Mayor? De Weerd: Mr. Rountree. Rountree: I move that we approve the Consent Agenda as published, authorize the Clerk to attest and the Mayor to sign. Bird: Second. De Weerd: I have a motion and a second to approve the Consent Agenda. Is there any discussion? Madam Clerk, will you call roll. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. Item 6: Items Moved From Consent Agenda De Weerd: There were no items moved from the Consent Agenda. Item 7: Action Items A. FP 15-022 Caven Ridge Subdivision No. 1 by New Cavanaugh, LLC Located East Side of S. Meridian Road and South of the Ridenbaugh Canal Request: De Weerd: Item 7-A has been requested to continue to July 7th. Do I have a motion? Rountree: Madam Mayor? De Weerd: Mr. Rountree. Rountree: I move that we continue Item 7-A until July 7th, 2015. Bird: Second. Meridian City Council June 23, 2015 Page 5 of 40 De Weerd: I have a motion and a second to continue this item to July 7th. All those in favor say aye. All ayes. Motion carried. MOTION CARRIED: ALL AYES. B. FP 15-021 Fall Creek Subdivision No. 2 by Coleman Homes, LLC Located South of W. Overland Road and East of S. Linder Road Request: Final Plat Approval Consisting of Thirty -Nine (39) Building Lots and Four (4) Common Lots on 12.51 Acres of Land in the R-8 Zoning District De Weerd: Item 7-B is FP 15-012. 1 will turn this over to staff. Watters: Thank you, Madam Mayor, Members of the Council. The application before you now is for a final plat. This site consists of 12.51 acres of land. It's currently zone R-8 and is located south of West Overland Road and east of South Linder Road. The proposed final plat depicts 39 building lots and four common lots on 12.51 acres of land in an R-4 zone -- or, excuse me, R-8 zoning district. The proposed plat complies with the preliminary plat and the dimensional standards of the R-8 district. The proposed plat does not include the street buffer and sidewalk along South Linder Road. Staff is recommending as a condition of approval that this area is included within the boundaries of this final plat and constructed with this phase. Written testimony has been submitted from Becky McKay, the applicant's representative. She requests Condition No. 4-B and 5-B, which requires the street buffer along the new road to be included in this phase is removed and they will be allowed to construct the entire buffer along Linder at one time with the entrance at Kodiak Drive. Staff will stand for any questions Council may have. De Weerd: Thank you. Council, any questions? Rountree: I have none. Bird: I have none. De Weerd: Okay. Would the applicant like to make comment? Good evening. If you will, please, state your name and address for the record. McKay: Becky McKay. Engineering Solutions. Business address 1029 North Rosario. Thank you, Madam Mayor, Members of the Council. De Weerd: Thank you. McKay: We are in agreement with all the conditions of approval as set forth by the staff. The only one that -- that I had hoped to have removed would be 4-B and 5-B. We did not include the arterial buffer adjacent to Linder Road, because I have 16 -- about 1,643 linear feet of buffer and so my reasoning was it made more sense that we install it all in one fatal swoop and there is only 573 feet of buffer adjacent on the west side of these lots and it's Meridian City Council June 23, 2015 Page 6 of 40 kind of in the middle of our Linder frontage and so it just seemed to kind of make sense to me not to install just this little portion in the middle. When we come down and we get our Kodiak collector entrance, then, we are going to -- I'm going to have an entire landscape buffer all along Linder. So, staff had indicated that the -- the ordinance requires the buffer. I'm not asking to get out of the buffer, I'm just kicking that buffer down the road and I guess it's up to the Council to determine if that is appropriate or not at this juncture. So, we just ask you to please consider it. Thank you. De Weerd: Becky, as part of that -- sidewalks. Are the sidewalks already in? McKay: Madam Mayor, no. The sidewalks are not in. The sidewalk is within our landscape buffer. We have detached walks outside the right of way. De Weerd: But you would be asking to postpone the extension of the sidewalks as well. McKay: Yes. We would install the sidewalk along with the buffer. We will do that whole Linder stretch and we had the outparcel that was the existing house. Mr. Coleman has purchased that, so that is now under his ownership. We will be removing the home and the buffer will continue. We are trying to save the mature trees that were in the front yard of that home. De Weerd: So, what kind of time frame are you looking at in terms of this buffer and the sidewalk? McKay: I think probably it will be next year, because we are going to have to open up that second entrance for fire. We are going to be looping the water with this phase to Linder. have to build water in Linder for a redundant source. De Weerd: I won't share my opinion unless it's not said by any of the Council Members, so -- any questions from Council? Okay. Well, then, I will share my thoughts. We need connectivity for pedestrians, in particular kids to have safe routes, and if I had anything to say to it I would ask you to finish that whole buffer along Linder, so you would have sidewalks put in. Connectivity is huge and in particular along Linder where plenty of kids walk up and down those roads. So, my two cents. McKay: Thank you. De Weerd: Okay. Council, any information needed from the applicant or staff? Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: You brought up a point and Becky can answer this or maybe somebody. I can't remember driving out there. On the south end of your buffer sidewalk, is there -- coming north from Victory is there a sidewalk to that location yet? Meridian City Council June 23, 2015 Page 7 of 40 McKay: The only existing sidewalk I believe is on the west side at -- what Southridge has built of Linder. Bird: Okay. McKay: But there are -- to my knowledge there is no other sidewalk adjacent to our site. We do have detached walks. Bird: Okay. McKay: We do have detached walks internally through -- and your multi -use pathway to the school will go down our collector. That's the ten foot multi -use pathway. Bird: Thank you. Borton: Madam Mayor? De Weerd: Yes, Mr. Borton. Borton: So, Becky, your answer to the earlier question is the -- the idea that the buffer along Linder for the enter length of the project is next year? McKay: Yes. We are going to include it as one entire -- so we could do the whole frontage. So, the sidewalk -- everything would connect to Kodiak. Borton: And -- Madam Mayor? De Weerd: Yes. Borton: Is the -- McKay: This phase will be built this year. Borton: Okay. Is the trigger for that appropriately described as a date that it would occur by or a phase that it would occur by or -- installation of the entire buffer. How would you characterize that? McKay: I guess it would be up to the Council. I mean to -- to put a phase on it. With phase three, phase four. We started on the east side of this project and we have been working our way westward. Borton: Is a date more appropriate? It seems clearer to have a date certain that it would be installed by and so what date would you pick? Meridian City Council June 23, 2015 Page 8 of 40 McKay: Specific dates are harder than phases, because you don't know what the market is going to do and I'd hate to agree to a specific date and, then, just have to build the landscape and the sidewalk without a phase. That would be my fear. I guess, you know, you could say with the third phase -- the fourth phase. This phase will be built and paved before November 15th. That is our target. Borton: Just phase two? McKay: This phase two. Yes, sir. And so, then, we will roll to -- in fact, we already are working on design of the third phase at this time. Borton: Okay. De Weerd: So, Becky, isn't it disruptive to any of the lots that build up against that that you would be putting that in after the fact? McKay: It could be. Yes. I guess that's what you have to balance. De Weerd: When was this subdivision approved? Apparently it was before Council has been pretty consistent about trying to get infrastructure along roads in prior to than on each phase. McKay: Two years? Watters: 2012. The preliminary plat Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: I would say that it was approved before I was aware there was going to be a school in the neighborhood and to repeat the same question everybody else is asking, the objective is to have a sidewalk in before the school is there. Immediate would be nice, but to me the point is to have it be there before the school. Do we know when the school is going to be opened? De Weerd: Well, the school that's being built currently is on Stoddard. So, it's a half mile over. Zaremba: Okay. It's not on Linder? McKay: No. De Weerd: Not this one. Not the one being built. Zaremba: Okay. Never mind. Meridian City Council June 23, 2015 Page 9 of 40 McKay: Madam Mayor, to answer your question, Councilman Zaremba, when it was approved the school bond had not passed. The school was planned, but there was no exact date. It's under construction now. Zaremba: Okay. De Weerd: Is it -- is it the one -- McKay: On Stoddard. De Weerd: On Stoddard. It's on Stoddard and Kodiak right across from Bear Creek Park Zaremba: So, my question doesn't relate. So, thank you. Milam: Madam Mayor? I mean is there -- and maybe you said it in the very beginning when you started -- the reason you don't put in the entire buffer now with -- for all phases and, then, it's already there and all the sidewalks are in there and the landscaping is there. Can you not do that on the other -- because -- on the other phases that you haven't started yet, as opposed to putting the whole thing off, do the whole thing ahead of time. McKay: We have done that before, but when we have a site like this that we have to do a significant amount of grading because of changes in elevation, then, we end up tearing into it. So, we usually -- it's -- normally we will go ahead and with each phase put in that arterial buffer. Typically that is what we do. This -- this particular project it's odd that we are in the middle of that arterial buffer frontage with this phase. So, that's why I thought I would ask. If, obviously, the Council deems it that they would prefer the buffer in, then, that's what we will do. Milam: Thank you. De Weerd: Okay. Any other questions? Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: I guess I would ask staff. I think it's our regular request and maybe part of the ordinance, that perimeter landscaping goes in with phase one. Just looking for an opinion on whether we could or should -- De Weerd: Mr. Zaremba, can you move closer to your mike. Zaremba: Sorry. Question of whether we would be starting a bad precedent if we allow this or are there circumstances that would make it okay this time? Meridian City Council June 23, 2015 Page 10 of 40 Watters; Madam Mayor, Councilman Zaremba, Councilmen, at a minimum, Councilman Zaremba, it would be installed with each phase that abuts the arterial. Sometimes with the preliminary plat, if there is a -- especially in this instance where there is a school nearby, we would probably require the whole sidewalk at the very least to be constructed up front. Zaremba: Okay. Thank you. Borton: Madam Mayor? De Weerd: Mr. Borton. Borton: To that point, wouldn't it -- why wouldn't it be required to be constructed with phase one with this project? Watters: Madam Mayor -- De Weerd: Probably because you didn't ask for it to be. Watters: This project came in before the school property did. De Weerd: Not to you you, but you Council. Watters: It's not always a requirement. It just kind of depends on the individual site and what's going on around it. Borton: Madam Mayor? De Weerd: Mr. Borton. Borton: It appears that if this is installed adjacent to this phase is that not a -- I don't understand the connectivity that creates if it's not attached to anything on either side. What does that help? Watters: It's -- Madam Mayor, Councilman, it's not necessarily going to help anything at this point until Kodiak is extended to Linder Road. At least for the school. But it is a -- like you said, it is adjacent to this phase, so we typically include the buffer with the adjacent phase. Especially when that -- the Kodiak section gets installed, then, they will have a pathway connection -- follow my arrow here -- Borton: Right. Watters: -- up north and, then, along Kodiak down to the school site. Borton: Is that phase three to the north? Meridian City Council June 23, 2015 Page 11 of 40 Watters: I'm not positive. De Weerd: Becky, do you want to come and talk about what is currently in. That might be helpful. McKay: Okay. Watters: Does this show better, Becky, or would you like the other view? McKay: So, this -- this is the school property right here. We have extended Kodiak to this point right there, which is a collector roadway, and you can see this is phase one. So, none of the Linder Road buffering was completed with phase one, because it -- none of the Linder Road frontage was included. We did complete our Stoddard frontage and sidewalk. We also have a micropath right here, right here through our mid block, and, then, we installed a ten foot multi -use pathway for bikes and for pedestrians along the south side of the collector Kodiak. So, what Sonya indicated is we do have a micropath right there, so the only existing sidewalk on Linder is right there at Southridge on that west side. I think they have got it to that point. So, in theory, if we extend sidewalk we could get -- pick up some pedestrian traffic that could go to the school that direction. I'm kind of leaving it up to the Council. We thought we would ask. If the Council thinks that because the school is going in it's imperative that we get that in, you know, with this phase, then, so be it. Borton: Okay. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: Becky, what if -- what if it was a phase plus a date certain? McKay: It will open in the fall of '16. Bird: That's the middle school? McKay: Yes. I think they are on the fast track -- Bird: I knew that Hills -- I knew Hillsdale was, but I -- I didn't know the middle school was. McKay: I guess it would probably be easier, to be honest with you, just to go ahead and put it in with this phase, that stretch, if it makes things simpler, instead of trying to come up with a date. Bird: Thank you, Beck. McKay: You know, we want -- we want to make safe routes to school. Meridian City Council June 23, 2015 Page 12 of 40 Bird: Thank you. McKay: We don't want to cause any hardship. We just thought we would ask. De Weerd: Thank you. McKay: Thank you. Bird: Want it done by the time school starts. McKay: Yeah. De Weerd: Okay. Council, do I have a motion? Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: I move we approval FP 15-021 and to include staff, applicant comments, and that would include leaving in Item 4-B and 5-B. Zaremba: Second. De Weerd: I have a motion and a second. Any discussion? Madam Clerk, will you call roll. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. C. Public Hearing: PP 15-008 Normandy Subdivision by Schultz Development Located at 4145 S. Locust Grove Road Request: Preliminary Plat Approval Consisting of 110 Building Lots and 9 Common Lots on 26.93 Acres of Land in an R-8 Zoning District De Weerd: Item 7-C is a public hearing on PP 16-008. 1 will open this public hearing with staff comments. Watters: Thank you, Madam Mayor, Council. Next application before you is a request for a preliminary plat. This site consists of 26.93 acres of land. It zoned R-8 and is located at 4145 South Locust Grove Road on the west side of Locust Grove south of East Victory Road. This property was annexed and zoned and preliminary platted in 2007 for the development of single family residential homes. A development agreement was not Meridian City Council June 23, 2015 Page 13 of 40 required as a provision of annexation. A couple of time extensions were approved for the preliminary plat, but the plat later expired. So, this is a new preliminary plat. The proposed plat consists of 110 building lots and nine common lots on 26.93 acres of land in an R-8 zoning district. The plat is proposed to develop in three phases as shown on the phasing plan on the right. Although the second and third phases are not labeled, the applicant states the second phase will probably be the one south of phase one along Locust Grove. The first phase will incorporate both access points. So, that will be this top one. The gross density for the subdivision is 4.1 dwelling units per acre and the net density is 6.8 dwelling units per acre, with an average lot size 6,398 square feet, with homes ranging from 1,300 to 2,800 square feet in size. One access via South Locust Grove Road is proposed along with the extension of the stub street, South Picasso Avenue, at the north boundary, which will provide a secondary access via Chatsworth Subdivision to the north. The master street map depicts a future roundabout at the northeast corner of this site. However, ACHD is requesting it be removed from the master street map. A 25 foot wide street buffer is required along South Locust Grove Road, an arterial street, as proposed. A minimum of ten percent qualified open space is required to be provided for this development, along with one site amenity. Based on the area of the preliminary plat, a minimum of two six -- 2.69 acres of qualified open space is required to be provided. The applicant is proposing a total of 2.73 acres or 10.13 percent as qualified open space. The application proposes playground equipment for the tot lot as a site amenity. The applicant has submitted four pictures of typical sample building elevations for future homes within this development as shown. Building materials appear to consist of a mix of horizontal and vertical siding, with stone and brick accents. Staff recommends that the rear and/or size of homes on lots that face South Locust Grove Road incorporate articulation through changes in materials, colors, modulation, and architectural elements to break up monotonous wall plains and roof lines. The Commission recommended approval of the proposed preliminary plat. Matt Schultz testified in favor. No one testified in opposition or commented and written testimony was received from the applicant's representative Matt Schultz. Key issues of discussion by the Commission. There were none. There are no outstanding issues for Council. Written testimony since the Commission hearing was submitted from Matt Schultz in agreement with the staff report and Brian and Judy White. You should have a copy of their letter in your packet. Staff will stand for any questions Council may have. De Weerd: Thank you, Sonya. Council, any questions? Bird: I have none, Mayor. De Weerd: Okay. Would the applicant like to make comment? Schultz: Good evening, Mayor and Council. Matt Schultz. 8421 South Ten Mile in Meridian. De Weerd: Thank you. Meridian City Council June 23, 2015 Page 14 of 40 Schultz: I'm here for the Normandy Subdivision. This is a project that I have been familiar with for a long time now. I originally brought it through back in -- started working on it in 2006 and it was approved in 2007 in a very similar format as this and the same number of lots and it was annexed and zoned back then an R-8. Even though you're voting on it tonight -- on the annexation again, I believe that I would bring the same project forward again at an R-8, given the fact that we have R-8 to the north, R-8 to the south it fits. We meet all the requirements of the R-8 zone. You have a very ample landscape ordinance, that ten percent, and as you can see it takes up a good -- a good percentage of our site, a nice centrally located park, and I think Meridian has a very good open space ordinance that sets it apart from all other cities, so it makes it nice -- one of the things that makes it nice. We have good interconnectivity. Utilities are all at the site. There is not ground water or rock. It's one of those sites that every once in a while, not very often, you get them to -- everything seems to kind of fall in place and this is one of those where it makes sense and it's a good mix of -- of the two and three car garage product. Two of the lot sizes -- we didn't go down to the absolute minimums, but we went down to something that was efficient and a lot of good mix of housing products and housing sizes. With that we concur with staff's recommendation for approval and hope to get going on the first phase probably over winter and get this time with next homes going up. And our first phase, like Sonya said, excuse me, does bring in both accesses. The one to the north is the existing subdivision, as well as Locust Grove to make sure we have got our -- get emergency access, as well as water looping with that first phase. So, that's what dictated how that first phase looks. We probably wouldn't have done that had it not been for that, but it meets code that way, so -- I will stand for any questions. Thanks. De Weerd: Thank you, Matt. Any questions from Council? Bird: I have none. Rountree: None. De Weerd: Thank you. This is a public hearing. Is there anyone who would like to offer testimony on this item? Okay. Borton: Madam Mayor? De Weerd: Mr. Borton. Borton: Seeing no testimony, I'd move that we close the public hearing on Item 7-C, PP 15-008. Rountree: Second. De Weerd: I have a motion and a second to close the public hearing on Item 7-C. All those in favor say aye. All ayes. MOTION CARRIED: ALL AYES. Meridian City Council June 23, 2015 Page 15 of 40 Borton: Madam Mayor? De Weerd: Mr. Borton. Borton: I move that we approve Item 7-C, PP 15-008, Normandy Subdivision, to include all staff and applicant comments. Rountree: Second. De Weerd: I have a motion and a second to approve Item 7-C. Any discussion from Council? Bird: I have none. De Weerd: Madam Clerk. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. D. Public Hearing: AZ 15-003 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request: Annexation and Zoning of 30.21 Acres of Land with an R-4 Zoning District E. Public Hearing: PP 15-005 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request: Preliminary Plat Approval Consisting of Seventy -Eight (78) Building Lots and Fifteen (15) Common Lots on 30.2 Acres of Land F. Public Hearing: VAC 15-006 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request De Weerd: Item 7-D, E and F are public hearings on AZ 15-003, PP 15-005, and VAC 15- 006. 1 will open this with staff comments. Watters: Thank you, Madam Mayor, Council. The next applications before you are a request for annexation and zoning, preliminary plat, and a vacation of easements. This site consists of 30.21 acres of land. It's currently zoned RUT in Ada County and is located at 3405, 3497, and 3801 East Zaldia Lane. The applicant has applied for annexation and zoning of 30.21 acres of land with an R-4 zoning district, with a request for a step down in Meridian City Council June 23, 2015 Page 16 of 40 density shown on the future land use map for this property from medium density residential to low density residential, the Comprehensive Plan allows requests for other residential densities in residential areas to be considered without the requirement of an amendment to the future land use map, provided that the change is only one step. For example, from medium density to low density. This is a view of the existing site conditions, the existing homes on the property. As you can see here there is -- see this little green dot? There is one home here, one home here, and one home here. The preliminary plat depicts 78 building lots and 13 common lots on 30.21 acres of land. The property is proposed to develop in two phases as shown on the phasing plan. The gross density for the subdivision is 2.58 dwelling unit per acre, with a net density of 4.33 dwelling units per acre. The average lot size is 10,090 square feet. Access is proposed for this development via access at the northwest corner from East Zaldia Street via South Eagle Road. A secondary emergency access will be provided prior to development of phase two. Direct lot access to the proposed collector street is prohibited. The collector street are this street right here, Zaldia, that turns into Elliana and comes out to Howry Lane. This is also a collector that runs north -south. The existing home proposed to remain on Lot 5, Block 6, is proposed -- is proposing an access via East Elliana Drive, a collector street, due to the existing topography of the land in this area. Council approval of the access is required and that is the existing home here on this parcel. A roundabout is depicted on the master street map at the northeast corner of this site. ACHD is recommending a modification to the master street map to remove the roundabout from the map. Block 6 where the pond and large common area is located exceeds the maximum block length allowed of 750 feet. That is this block length right here. The applicant is requesting Council approval of a block length up to 1,200 feet, as allowed by the Unified Development Code due to the block design being constrained by the pond and topography in that area. A minimum of ten percent or 3.02 acres of qualified open space is required to be provided for this development. A total of 4.3 acres or 14.5 percent is proposed. A minimum of one qualified site amenity is required. The applicant proposes a gazebo on the island in the pond and some picnic tables on the north side of the pond as amenities. The little island they are talking about is right here. The pond is required to have recirculated water and be maintained such that it does not become a mosquito breeding ground. As a water amenity, the pond is also required to have banks no steeper than one foot vertical for every four feet horizontally, with a depth and velocity in accord with UDC standards. There are existing homes and associated accessory structures on the site that are proposed to remain on the building lots within the subdivision. There is an accessory structure on the existing Shoemaker property that is proposed to be located on the adjacent Lot 4 while their home is proposed to remain on Lot 5, Block 2. This home right here is the Shoemaker property and their accessory structure will be located on this lot right here where they plan to build a new home and retain the accessory structure. City code does not allow an accessory structure to be located on a property without a primary structure. Therefore, staff is recommending the common lot lines between Lots 4 and 5 is reconfigured to include the accessory structure on Lot 5, which would allow the Shoemakers to construct a new home and later apply for a property boundary adjustment to shift the lot line between the two properties to include the accessory structure on their new property. The applicant has submitted seven photos of sample building elevations for future homes within this development included on the Meridian City Council June 23, 2015 Page 17 of 40 screen before you. Building materials appear to consist of a mix of stucco, board and batten, lap siding, and cultured stone wainscot with architectural shingles. These are photos of the existing home that is on Block 6 that it is the -- the block here that contains the pond and this just -- the photos kind of demonstrate the topography in this area, how it slopes up behind this house. The applicant has also submitted a request to vacate the existing public utilities drainage and irrigation easements on the portion of the site that was previously applied with Zaldien Zerua Subdivision as shown here like a grid. All of the easement holders have granted consent for vacation of these easements. The Commission recommended approval of the annexation and zoning and preliminary plat request. Bradford Deadman and Randy Clarno testified in favor and Lonnie Stiles, John -- Sean Oldman commented on the application. And written testimony was received from Janie Peters, Cindy Pixley, and Lonnie and Bonnie Stiles. Key issues of discussion by the Commission. They were supportive of the step down in density from medium density residential to low density residential and transition to existing residences. They did not change anything in the staff recommendation. Outstanding issues for City Council tonight is the Block 6 where the pond and large common area are located that exceeds the maximum block length of 750 feet. The applicant is requesting Council approval of a block length up to 1,200 feet as allowed by the UDC due to the block design being constrained by the pond and topography of the land. The applicant requests a step down in density from medium density residential to low density residential as allowed by the comp plan without an amendment to the future land use map. Third, the applicant requests approval for the accessory structure that exists on the proposed Lot 4, Block 2, on the Shoemaker property to remain until the primary structure can be built. That, again, is this property right here. The applicant lastly requests approval of one access via East Elliana Drive for the existing home proposed to remain on Lot 5, Block 6, right here. This access requires Council approval of a waiver to UDC 11 -3C -3A for direct lot access via a collector street. Written testimony since the Commission hearing has been received from Cindy Pixley. You should have a letter in your packets from her stating her concerns and a letter from the Kirsti Allphin, the applicant's representative, in response to the staff report. You should also have a copy of her letter. Just a couple other items. From her letter that staff is agreement with is she requests the qualified open space requirement not include the storm drainage area, which results in 13.2 percent qualified open space. Staff is agreeable with this change to condition number 1.1.1 D and second removal of condition number 1.12C and 1.13G, which requires a separate common lot to be provided for a landscape strip adjacent to lots not taking access via the common driveway. Staff is agreeable with this change, as the landscape strip can be included in the common lot for the driveway. Staff will stand for any questions Mayor and Council may have. De Weerd: Thank you. Council, any questions for staff at this time? Bird: I have none, Mayor. Rountree: Madam Mayor? De Weerd: Mr. Rountree. Meridian City Council June 23, 2015 Page 18 of 40 Rountree: There appears to be an access coming out of the north of this proposed subdivision to some homes to the north. Is that by easement? Is that going to be a private drive? What's the situation with -- with that approach out of this subdivision? Watters: Madam Mayor, Councilman Rountree, this is a public stub street that is provided with this subdivision. It is a private drive. I believe it's in an access easement for those lots to the north. You can see them a little better on here. Rountree: Thank you. De Weerd: Any other questions? Bird: I have none. De Weerd: Okay. Would the applicant like to make comment? Thank you for joining us. If you will, please, state your name and address for the record. Clarno: Good evening, Mayor and Members of the Council. My name is Randy Clarno. I'm the managing partner for Shelburne Properties, LLC. Address P.O. Box 8265, Boise. 83707. Just to give you a little background on this. We -- we have had a number of issues to work through, mainly the collector roadway of Zaldia and what we are calling Elliana Drive. ACHD's plan -- the city's plan originally called for it to be north of the pond or, actually, encroaching into part of the pond and run along that existing private easement that serves those four or five acre tracts. When we met with the neighborhood they didn't like that and they didn't think it was a good -- good location and after we studied it some more we didn't think it was a good location either, because it would have impacted the pond probably so much that we would have had to have filled it, removed it, plus there are a number of trees -- very large mature trees on the north side of that pond that we wanted to preserve. So, we moved the road as you can see south into the site. That -- that created some other issues that I think through meeting with the neighborhood and reaching out to the neighborhood and working with staff that we have addressed that we think are adequate. But I just want to point out that we have reached out to -- to all the neighbors. We have a couple of individual meetings outside of the neighborhood meeting that we are required to have to address concerns. Sandy Pixley is somebody that we have met with, although I wasn't aware of a letter that she's written for this meeting. I have seen a letter that she wrote for P&Z. Was that the letter you were referring to? Okay. So, I don't know what she said in that letter, but I know that they -- the residents of Napoli -- the Napoli development, which is to the west, were concerned about several things, mainly about drainage, what we were going to do with the grading on the site, how the homes next to them would appear relative to their homes, and so we met with them one evening, went through all that, discussed it, have agreed to do some things there to help alleviate some of their concerns. So, I believe we have addressed that. The nature and character of the project is going to be a little more upper end project. I developed the Kingsbridge -- the original Kingsbridge project to the north. Boise Hunter Homes finished it years later after we held onto the land for four years during the crash and suffered through that, but we want to see something of a similar character and quality on this Meridian City Council June 23, 2015 Page 19 of 40 project and we have already been discussing that with a number of builders in the area that are very excited about -- about this project. The pond is -- if you haven't seen the pond, if you haven't been out there, it's gorgeous. The one photo in that lower right-hand corner of the color plan that you have kind of shows that. That was taken by a friendly drone and it's a great -- great photo. It kind of represents -- it shows what's there and we are going to put a gazebo on that island, something nice, and, then, on the north side of the pond we are going to put in some -- probably some benches and some picnic tables so that the residents there can enjoy that -- that water feature. We are pretty much in agreement with everything in the staff report and what Sonya has described. We -- we do want to just reiterate that the - the home that is the Shoemaker home -- the Shoemakers are one of the sellers of this -- of this property and their plan is to build a big beautiful home on -- on that larger lot there. If Council is able to, we would just -- we would prefer not to have to go through the lot line adjustment process later. I will be acquiring that house and I would -- I want to -- to resell the house as soon as possible. A lot line adjustment would delay that process a number of months. I would prefer not to do that. Plus I don't know -- there is -- the barn on the property right now is nice, it meets setback requirements for accessory structures, I don't know that there is any need to -- to make us go through an extra process unnecessarily. So, I would request that. The block length, as Sonya has described, you know, we are constrained by several things there. Obviously, the -- the linear fashion of the pond -- shape of the pond. The -- just to the east of the pond we did look at one time at putting a road up just to the east side of the pond, but discovered that the topography of the design of the road would have to wipe out many very nice trees and would stub a road right into that property to the north of us where you can see is a nice house. So, we didn't think that was appropriate. And in the middle of that is where the house is, the existing home, and, then, of course, to the east is the best location, because of how it lines up with Howry and ACHD agreed with that. So, we are asking for your approval to make the block length longer than normal. The access to Elliana to the one home there to the east, similar circumstances. You saw the photos, the photography, to force a driveway down into that home from up above and, then, turn it sharply and try to make it look appropriate for the front of the house facing south is just a great, difficult challenge and it didn't make any sense and it would not -- the home just wouldn't look right and we don't know that there is any -- anything really compromised by allowing one driveway access on this 1,300 foot stretch of roadway, plus we can use the access or we can have a joint access for maintenance to the common area and the pond -- use the same access. One last thing that we -- that we request is that -- I don't know that it was stated clearly in the staff report, but we are asking that the sidewalk on the north side of Elliana in front of the pond, that we be allowed to make that sidewalk adjacent to the curb, as opposed to separating and the reason for that is there is some really nice trees along the south side of that pond right now and if we were to separate the sidewalk we would have to take all those out and replant trees and we don't think that's really appropriate. We'd like to just use the trees that are there. I have addressed all the concerns I have. Do you have any questions for me? De Weerd: Thank you. Council, any questions? Bird: I have none, Mayor. Meridian City Council June 23, 2015 Page 20 of 40 De Weerd: I don't see any. Thank you. I did have a couple of people sign up to -- when I read your name if you would like to provide testimony at that time I would invite you forward. John or Beth Freeman signed up as neutral or did indicate. Do you have anything you would like to add? Okay. Bradford Deadman. Deadman. Thank you. signed up as for. So, is there anyone who would like to provide testimony on this item? It is somewhat rare to see someone ask for less density, which we always appreciate. So, Council, any questions for staff or applicant? Milam: Madam Mayor? De Weerd: Mrs. Milam. Milam: We did have some -- some written testimony and it would be nice to see those issues addressed. I don't know if we need to read the -- or -- De Weerd: Yeah. I'm afraid I'm not really understanding it myself, so -- Sonya -- would the applicant like to come forward and maybe, Sonya, you can summarize what -- what was brought up in the -- the letter. I could read it verbatim, but -- Milam: There is three of them, Madam Mayor. De Weerd: Yes. If you could just summarize what the -- Watters: Yes, Madam Mayor. I did include a slide that shows the Pixley residents here at the west boundary of the site. Bear with me here. One concern they have is that the land immediately behind their backyard is currently a hay field and irrigated with the runoff collection -- collecting in a ditch behind their fence and running into drains. Their land is actually higher, because of fill in the irrigated land. I will just read this portion of it. For example, my fence lawn to the top is only four and a half feet tall. After looking the situation over Mr. Clarno stated that the top soil on the land behind this will need to be moved to the east side of the development where it's needed and the gradation of the land will, then, slope towards the main road that will run into the subdivision for those homes and drain to the street and into the main drainage. The houses behind us could end up much lower than we are. That's their first concern. Second concern was the structure of the houses placed directly behind them. Some of these homes will be north and south, where all of their homes are west and east. We request that single family -- excuse me -- single level homes be placed behind us to alleviate the loss of the view that we now have. Mr. Clarno did not directly say that this could be done, but proposed to the builders that the city wanted this. Their other concern was the irrigation water used by the new subdivision and if it would affect the Napoli Subdivision. Mr. Clarno stated it would not affect the source for irrigation water. He stated that possibly in the future we could be connected to the irrigation system of the new subdivision, instead of receiving water from Kingsbridge. These are some of the concerns we shared and I have encouraged the other homeowners affected to communicate their concerns also. Meridian City Council June 23, 2015 Page 21 of 40 Clarno: Was that the only letter? Watters: No. This is the one to Council. There was one previously to the Commission. Clarno: Yeah. Okay. Could you put the color plan back up there and I can address those. We did talk about all three of those items at that meeting. As we have talked about the fill first, the grading. Those are five lots -- we are proposing five lots against five lots and those -- those -- you know, our lots would be more east -west. If that house wasn't in the way, we would have run our road more north -south, but because of the position of that house the most efficient layout is the one that we have there. Otherwise, it would be east -west against east -west. I made those lots that have -- that are north - south wider than normal for that reason. But in terms of the grading, they -- she's right, a lot of that land is higher than our land, probably two to three and a half feet or so and there is a ditch that runs down there, it's an irrigation ditch. We are going to bury that or relocate it, so it won't be an issue and if it's determined that water drains off of their lots into that ditch we will accommodate water as we are required to. So, the drainage issue is not an issue to me. The grading -- we are going to try to grade the site from west to east, so that our land, which is already three feet lower than their land, would be -- our high point and our low point would go further east. That would help with some of their concerns on height. I think it's been known that this land would be developed at some point in time. I have done everything I can to try to lessen the impact. They do have some view. They don't all have views. I told them that I would put building envelopes on those lots and meet with them again and talk about those building envelopes to see if -- you know, the views are going to get cut up a little bit, but I will try to, you know, preserve a view from a particular room in their house or something. I have done that before in Eagle successfully. I can -- I think I can do it here. But just not going to be able to make them completely satisfied I'm sure a hundred percent. The other thing is is on the irrigation, since I did Kingsbridge I'm aware of the agreement that Kingsbridge has with Napoli. They had no water. Kingsbridge barely had enough water. We shared some of that with them. It's kind of a problem for them. But this site has plenty of water. Probably more than it needs. So, I told them that I would -- you know, as soon as I know exactly what I have to -- excess I have to share, we will sit down and talk about it and see if we can't help their situation a little bit. Did that answer your -- Milam: I think so. Yeah. Clarno: Okay. Milam: Thank you. Clarno: Is that good? All right. Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Meridian City Council June 23, 2015 Page 22 of 40 Zaremba: While you're still here, a couple of the other depictions -- not the one we are looking at the moment, appear to show that ACHD is contemplating a roundabout on the northeast end of your property and would be taking up one of your building lots I'm sure and connecting to what is now a private lane -- since you moved where Zaldia is going to connect with that street have they discussed moving that roundabout? Clarno: They have decided not to do the roundabout. Zaremba: Okay. Clarno: They still want a road to go east as a collector. It could happen up there at that point or it could happen -- Zaremba: Thank you, De Weerd: Okay. Thank you. Okay. Council, any further information needed from staff or the applicant? Or any of the neighbors out there? If not I would entertain a motion to close. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: I move we close the public hearings on AZ 15-003, PP 15-005 and VAC 15-006. Rountree: Second. De Weerd: I have a motion and a second to close the public hearings on Items 7-D, E and F. All those in favor say aye. All ayes. MOTION CARRIED: ALL AYES. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: I move we approve AZ 15-003 and to include all staff, applicant, and public comments. Milam: Second. De Weerd: I have a motion and a second to approve Item D. Any discussion from Council? And is this -- would the consideration from the applicant be under AZ? Bird: You mean the streets? Meridian City Council June 23, 2015 Page 23 of 40 De Weerd: Are we doing a DA? Watters: We are. De Weerd: To require the house -- the -- Watters: I would recommend that's included as a provision in the development agreement. For the accessory structure to remain -- primary structure? Bird: Oh, the existing structure -- that would be in the zoning. Watters: Yeah. A particular provision of the development agreement. Bird: Then I would include that in -- in my motion -- Watters: Please. Yes. Bird: -- that the structure be included in the DA. Milam: Second agrees. De Weerd: Okay. If there is nothing further, Madam Clerk, will you call roll. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. De Weerd: Item 7-E. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: I move we approve PP 15-005 and that also in my motion includes leaving -- having no detached sidewalk at the south side of the pond -- existing pond, so that the trees can remain and the sidewalk will be part of the curb and gutter. Milam: Second. De Weerd: I have a motion and a second. It's hard to approve the plat before approving the variance when you extend the block length; right? Meridian City Council June 23, 2015 Page 24 of 40 Watters: It actually is not a variance, Madam Mayor, it's included as a waiver as part of the plat, yeah, if you would, please, speak to the block length and also the existing collector. If you're approving that or not, please. Bird: I am approving that. Watters: Thank you. Bird: That was part of it. Watters: Thank you. De Weerd: Okay. Anything further from Council? Okay, Madam Clerk. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. De Weerd: Okay. That is VAC, not VAR. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: I move we approve VAC 15-006, include staff, applicant, and public testimony. Milam: Second. De Weerd: I have a motion and a second to approve Item 7-F. Any discussion? Madam Clerk. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. Item 8 Department Reports A. Continued from June 16, 2015: Legal and Fire Departments: Memorandum of Understanding and Agreement between the City of Meridian and the Meridian Rural Fire Protection District Meridian City Council June 23, 2015 Page 25 of 40 De Weerd: Okay. We will move to Department Reports. Item 8-A is continued from June 16th that has been requested to move to July 7th. Do I have a motion? Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: I move we continue the Legal and Fire Department Memorandum -- MOU between the City of Meridian and Meridian Rural Fire Protection District to July 7th, 2016. Milam: 2015. De Weerd: 2015. Bird: 2015. Milam: Second. De Weerd: We don't want to move it that far away. Okay. I have a motion to continue this to July 7th of this year. All those in favor say aye. All ayes. MOTION CARRIED: ALL AYES. B. Legal Department Report: Updates to Meridian City Code to comply with updates to Idaho Code and to reclassify penalties De Weerd: Item 8-B is a report from our Legal Department. Nary: Thank you, Madam Mayor, Members of the Council. Just a brief update on what the -- Item C is an amendment to the City Code. It's to meet some requirements that were passed by the legislature that go into effect July 1st, so we wanted to make sure our code references were changed prior to that date. There is a couple of them that have some impact on how we do things. First there is a new section of the Idaho Code now called the Transparent and Ethical Government Act. What they did is they combined a bunch of different sections of the Public Records Act, Open Meeting Law, Executive Sessions provisions, Ethics in Government provisions, all into a new code section. They didn't change the text of those sections, they just changed the numbers. So, we have provided you a little card to help with the executive session, since the numbers are different and we have all gotten used to the other -- the other numbers. It also had two provisions that will probably never have an impact on us at all. One is there are increased fines for violation of the open meeting law and there is also the labor negotiations are now mostly held in public. There are sections that allow for certain provisions of the labor negotiations with a collective bargaining agreement like our fire department that can still be done in executive session, but the general sessions of negotiations are now in public. There are other updates to move certain criminal offenses from misdemeanors to infractions. Part of that is a movement by the state to eliminate as many misdemeanors that are of lesser impact Meridian City Council June 23, 2015 Page 26 of 40 or lesser offense types of cases. These ones are curfew violations, fireworks violations, and minor tobacco. There are also some updates to the city code. They have also requested city to evaluate certain types of violations. We had three more that we found that could be infractionalized and those were regarding barking dogs and dogs at large, and public urination offenses. There were also some areas that have been codified in the state code now that we have now removed from the city code, since they are now in state code and preempted by -- by those, so those are regarding cruelty to animals, adoption of the state criminal code, there is a specific provision in the city code, malicious injury to property, trespassing, illegal smoking products, including Spice. Minors in possession of alcohol. Encouraging delinquency of a minor. Runaways. Adoption of state vehicle laws and speeding in a school zone. Those are all now in the state code and so we would simple go with those. And, finally, we removed one section that dealt with minors being in pool halls and we didn't find that to be as serious of an offense as it may have been back a hundred years ago or so. Well, we know that trouble begins with capital T and it rhymes with P and stands for pool. We didn't think it was really necessary to keep that in the code book. So, all of these are really cleanups. They are, again, effective -- will be effective before July 1st, which the state code requires, and I would stand for any questions. De Weerd: Council, do you have any questions? Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: Just for clarity on the open negotiations with -- with unions. That doesn't necessarily mean they have to happen at a city council meeting, I'm guessing it means that the committee that normally meets to discuss that has to now post your meetings and youragenda. Nary: Madam Mayor and Members of the Council, Council Member Zaremba, yes, and the --the long lawyery answer is that there is a lot of lack of clarity and there is a five year sunset clause in this code, so I think there is going to be some changes to the law over time. In fact, some of the language in the law basically says do your best to do what it asks as correctly as you can, but it's not very clear. But it does -- it is clear to me that a committee which we will now instead of doing it informally, we will formally have the Council at some point adopt and recognize that committee, will then operate like any other committee or commission or the Council, with the meeting requirements, noticing of the meeting minutes, recording the meetings, those kinds of things. Most of that we already do, we just don't really don't have them in public. So, that's really the change which won't impact us greatly, but it's a little bit different from a logistical standpoint to make sure the noticing and all that's done the same as other committees are. Zaremba: Thank you. Meridian City Council June 23, 2015 Page 27 of 40 C. Ordinance No. 15-1647: Updates To Meridian City Code To Comply With 2015 Updates To Idaho Code And To Reclassify Violation Penalties De Weerd: Anything further? Item 7-C is Ordinance 15-1647. Madam Clerk, will you, please, read this by title. Holman: Thank you, Madam Mayor. City of Meridian Ordinance No. 15-1647, an ordinance of the City of Meridian in Ada County, Idaho, amending or repealing the following provisions of Meridian City Code: Section 1-7-5C regarding City Council meetings. Section 1-14-7 regarding statutory standards. Section 6-4-11) regarding juvenile curfew. Section 6-4-2 regarding minors in possession of cigarettes or tobacco. Section 5-4-12A regarding penalties for fireworks code violations. Section 6-2-8A regarding barking dogs. Section 6-2-813 regarding cruelty to animals. Section 6-2-8D regarding dog at large in public place. Section 6-3-1 regarding adoption of Title 18 Idaho Code. Section 6-3-4 regarding malicious injury to property. Section 6-3-5 regarding trespassing. Section 6-3-9A regarding public urination. Section 6-3-11 regarding unlawful sale and possession of illegal smoking products. Section 6-4-3 regarding minor in possession of alcoholic beverage. Section 6-4-4 regarding minors in pool halls. Section 6-4-5 regarding encouraging delinquency. Section 6-4-6 regarding runaways and delinquents. Section 7-1-1 regarding adoption of state vehicle laws. Section 7-1-6C regarding speed restrictions in school zones. Adopting a savings clause and providing an effective date. De Weerd: I think we needed to add a few more of those. Is there anyone who would like to hear this read in its entirety? Seeing none. Milam: Madam Mayor? Zaremba: Madam Mayor? De Weerd: Mrs. Milam. Milam: I move that we approve Ordinance No. 15-1647 with suspension of rules. Bird: Second. De Weerd: I have a motion and a second to approve this ordinance under 8-C. Madam Clerk, will you call roll. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. Meridian City Council June 23, 2015 Page 28 of 40 D. Public Works: Budget Amendment for FY2015 in the Amount of $175,000.00 for Well 27 Water Treatment Facility Equipment Procurement De Weerd: Item 8-D is under our Public Works Department. Radek: Madam Mayor, Council Members, we are bringing forward a budget amendment of 175,000 dollars for filter equipment procurement for Well 27 water treatment facility. This is year one of the KIA project, which includes bio testing equipment specification development and equipment procurement. The bio testing and the specification development have been completed, so the equipment needed -- and the equipment proposals have been evaluated. Cost of the equipment for the winning proposal is more than the FY -15 project budget, so the 175,000 dollars was needed in order to award a contract for the equipment. The reasons this -- this is our third water treatment facility that we have procured equipment for. So far we have scheduled 600,000 dollars for the first year, which is the design, product testing, and equipment procurement and it has worked out fairly well for the first two. This third one, Well 27, turned out a little different. It had a larger capacity, so you have to treat more water and it has a smaller sewer capacity near the -- near the facility, so the back flush, even though it will treat more water, the back flush from the filter is less, so what that means is the filter has to end up with more cells, so you have a more expensive filter. We also have a difference supplier for this third filter, which the equipment procurement is not necessarily a low bid. In fact, it's not a low bid, it's a -- it's a qualification bid for equipment procurement. So, this different supplier was a little more expensive than the other supplier. We were able to negotiate down the price after we chose the equipment. But they were -- they were awarded largely based on the -- the customer service that they provided at United Water in the past and their ability to provide training and customer service to us and our first two equipment procurements with the different supplier we have been a little less than satisfied with their ability to provide us customer service when we needed it. So, those are the reasons and, again, we are asking for 175,000 dollars so we can procure this equipment and we will build this facility starting next spring and finish it next summer and it will be our third facility. And I will stand for any questions. De Weerd: Thank you, Kyle. Any questions from Council? So, I guess I -- I have a question. If you need the money now, but it won't be done until next budget year, why doesn't it need to be in the next budget year's -- Radek: Madam Mayor, this is a two year project. During the first year we do the design and pilot testing to procure the equipment and, then, we put out a qualification based selection to get the equipment, say, hey, we need a -- we need a filter that will treat the water with this chemistry to this degree and we have manufactures that bid on that or submit a qualifications based selection submittal on that and we need to contract for that equipment and, then, when we -- when we get a contract for the equipment, then, our designer can design the building around that equipment. Some of the steps we are going through on this kind of a project. So, we won't be able to complete the design until we get this contract, which is, you know, in the next few weeks, provided that this amendment is Meridian City Council June 23, 2015 Page 29 of 40 approved, then, our designer Keller Engineering can start designing the building around a piece of equipment and have that design done by -- by October and, then, we get our funding for the building. We start the building in -- well, we bid it out in October, start the building in late winter or early spring, and, then, get it done next summer. De Weerd: So, it's the second phase under next year's budget? Radek: That is correct, Madam Mayor. De Weerd: So, that was in front of Council last week. Radek: That is correct. De Weerd: Okay. And is there a time sensitivity that we need to do this right now and not do it all in one budget year? Radek: Madam Mayor, yes, if we wait until the next budget year we -- we won't have equipment -- it's about 130 days lead time on getting the equipment going and we can't start designing the building until we procure the equipment contract. So, rather than Keller starting on design in two weeks, Keller would have to start design in October or November. So, it would just push it all back. And I don't know if we would be able to -- actually, if we started design in October and November I'm not sure we would be able to complete the project in the next fiscal year. De Weerd: Okay. Thank you. Any questions from Council? Borton: Madam Mayor? De Weerd: Mr. Borton. Borton: In light of your questions -- you asked good ones that are, quite frankly, relevant to both of these that there is an ability to do them now. There isn't necessarily an urgency or lost opportunity, other than time, in doing them now. This one in particular and the next one anymore so we can talk about that, too, but I struggle with -- with this magnitude of a budget for these two items, you know, 90 days before the next budget cycle, if there is not a real immediacy to them. They are sizeable and I'm not sure of the need to do them right now. Bird: Madam Mayor? Radek: Councilmen -- Madam Mayor, Councilman Borton, I guess let me clarify. If we don't contract for the equipment purchase now, we won't be able to contract it until the next fiscal year. We won't have the money to contract for it. That will move our project back four or five months and we will be coming back to ask for that 175,000 dollars again and probably more than that when we -- or possibly more than that when we -- when we have to build the building and we will likely not be able to build that building in the next Meridian City Council June 23, 2015 Page 30 of 40 fiscal year if we do that. So, that's an option. Also I don't know if -- if our -- if our contract that's before us now would be honored if we said thanks for the submittal, vendor. We are going to think about it for four months and, then, come back to you, we might not get the same contract. In fact, I doubt we would get the same contract. They will have different prices. So -- so, not getting this budget amendment now does have some cascading effect on us. Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: I realize we are only discussing one project at the moment, but considering all of the things that are going to be coming at us in the Public Works Department capital improvements plan, there are a series of activities on this and other wells that are coming and something has to be first and something has to be later. Yes, this one could be put off, but, then, that either destroys the whole plan for the CIP or something else needs to be accelerated to take its place. So, if you only look at this one project the case could be made maybe timing is flexible, but this is part of a series of projects and my feeling is it doesn't just delay this project, it delays the whole CIP if we don't get something moving now. Bird: Madam Mayor? Zaremba: Am I correct in that? Radek: Madam Mayor, Councilman Zaremba, I would agree with that statement. We have -- we have a design -- we have our designers ready to do the building, stopping a project in -- at the end of year one will just, essentially, delay that project and it will probably delay -- you know, we will have to push back some other things as well. But we have, essentially -- this project is scheduled for 1.2 million dollars, including the -- the budget enhancement for next year. When you look at 1.2 million dollars and compare the 175,000 to it, maybe the percentage of money doesn't seem that significant. I guess my main concern is that we get this project -- we deliver this project when we told you, the Council, that we would deliver it and -- and the only feasible way I can see that happening is if we get our contract for the equipment during this fiscal year. If we wait until next fiscal year we will be behind the curve on the building. Bird: Madam Mayor? Milam: Madam Mayor? De Weerd: Mr. Bird. Bird: Kyle, a couple things. On your request for proposal or your bid or whatever you want to call it, what was -- what was the -- they give a time. How many months did they guarantee the price? Meridian City Council June 23, 2015 Page 31 of 40 Radek: Councilman Bird, I'm not quite sure on that. I believe it was 90 days. Bird: Which is three months. And when did you get the price? When did you get the bid? Radek: Oh. We got the bid -- I believe it was about three or four weeks ago. Bird: So -- and another thing, on this equipment does it -- does it have to be installed before you can build the building? Does it have to be installed when you build the building around it or do you build the building and, then, install the equipment? Radek: Yes. Bird: Yes and no? Radek: Yes and no. Madam Mayor, Councilman Bird, the way we did the first one Well 21 they actually built half of the building and, then, installed in the building before they put the roof on. I guess my main point here is that the building can't be designed until we select the equipment. Bird: Why can't it be designed if you -- if you have the specifications on the equipment? Radek: Well, the specifications on the equipment are -- are qualification based selections. One supplier might give us a tank that's ten foot by 40 feet. Another supplier might give us an answer that is 12 feet by 20 feet. So, we don't know how big that footprint is until we select a piece of equipment. Bird: Well, you have already told us you have selected this piece of equipment. Radek: Well -- Bird: And it's got -- it's got to have the specifications on what size and what size building you need. Radek: Councilman Bird, we have not selected -- we have selected -- we have not awarded that contract. Bird: You haven't awarded it, but you have selected it you just told us. Radek: We have selected -- Bird: You needed this 175 to get the contract going with this company; right? Radek: Correct. So, until we get that contract we don't know what piece of equipment we have. Meridian City Council June 23, 2015 Page 32 of 40 Milam: Madam Mayor? De Weerd: Mrs. Milam. Milam: Kyle, you mentioned that that was not the low cost bid. Can you tell us the price on the low cost bid? Radek: Originally the low cost bid was -- it was about 100,000 dollars less. But since we have negotiated with the -- the equipment vendor that -- that won, it's closer to 50,000 dollars difference. And we think we are getting a better product and better service. It's a qualification based selection. But to answer your question, Councilman Bird, we can't design the building until we get the contract, because we don't know what piece of equipment we are going to get. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: Kyle, it seems to me like you guys have already selected the product you're going buy. You need this 175,000 to do it. You have evidently got a confirmed bid and a contract ready; is that not right? Radek: That is correct Bird: Okay. And this -- this bid was good for 90 days. Radek: Councilman Bird, I think it was good for 90 days. I'm not sure of that. Bird: Most -- that's standard I think in any industry. I just -- and you say -- and you also stated that this was the same equipment that United Water is using or is this the same supplier United Water is using? Radek: Same supplier. Bird: Okay. Radek: It's a different piece of equipment for each site and each -- each different chemistry requirement at each site. Bird: But you have, evidently, selected a certain bunch of equipment to purchase under this contract to do it; right? Radek: That's correct. Bird: And this -- this supplier can't give you the physical sizes that that building needs to be? Meridian City Council June 23, 2015 Page 33 of 40 Radek: Councilman Bird, they could give us the size of the equipment, but we don't have a contract with them, so I'm not sure if we -- if we design a building to the specifications of a piece of equipment that we might obtain, and, then, don't obtain it and -- we have to design the building over again. If we ended up with a longer or a shorter piece of equipment -- I guess I'm not sure -- I guess I'm not sure what the -- what's going on with the questioning. We want to delay the -- De Weerd: Is your concern that if you don't get the piece of equipment now, but you do design the building to it, that the price of this equipment might go up and, then, you lose -- Radek: Madam Mayor, that's -- that's one of my concerns and this is the third contract that we have done in this manner. My main concern would be that we don't even get that same piece of equipment, because it's -- let's say as Councilman Bird suggested it's a 90 day guarantee. Well, that -- 30 of that 90 days has gone, so if we wait until we have money next year we are probably going to have to redo the qualifications based selection for that equipment and we will have maybe the same suppliers to bid on it, maybe not. Maybe this supplier might say, well, we don't want the old one, we want -- you know, they select suppliers and, then, they don't award contract, so maybe we won't even see them. So, it would seem to me not very prudent to base a design on something you don't know what you're going to get. De Weerd: Well -- and I don't mean to be disrespectful, but if we have put out an RFQ and we didn't have a budget for it, it just seems that we probably should have sought the budget spending authority first, at least to put it out. To say we might lose a supplier because we don't award this that wasn't budgeted to begin with, I think is not a fair statement to Council. I don't understand if -- if we have a housing budgeted for next year, why we didn't have this budgeted for this year. Is this an unexpected -- I'm just trying to understand the sequence of events. Radek: Apparently I haven't explained this properly, because we did budget for this this year. We budgeted 600,000 dollars for design, pilot testing, and equipment procurement. We budgeted 600,000 dollars. We budgeted too little. De Weerd: Okay. Now I get it. Thank you Radek: We budgeted 175,000 dollars too little. We did budget for equipment procurement, though, and so that's why we are coming over here saying -- it's no different than if we would have bid out a project in a low bid situation and if a water line extension was budgeted 400,000 dollars and our -- De Weerd: So, our estimate fell short. Radek: Our estimate fell short and for the reasons that I explained earlier, which was -- it was a larger pump, it needs three cells instead of two, which the first two needed -- the first two facilities needed two and it has a restriction in how much we can back flush the Meridian City Council June 23, 2015 Page 34 of 40 filter into the sewer, because of the size of the sewer at that location, so those are the drivers why we missed on this one. We missed on the budget. De Weerd: Sorry. I was not getting it. That was my -- my slip. Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: I move we approve the budget amendment for fiscal year 2015 in the amount of 175,000 dollars for equipment procurement for a Well 27 water treatment facility. Cavener: Second. De Weerd: I have a motion and a second. Any discussion? Madam Clerk, will you call roll. Roll Call: Rountree, yea; Bird, nay; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes -- or no. Five ayes and one nay. MOTION CARRIED: FIVE AYES. ONE NAY. De Weerd: And I apologize. I started it. That was my bad. E. Public Works: Budget Amendment for FY2015 in the Amount of $444,699.00 for the Design of the Wastewater Resource Recovery Facility Capacity Expansion Project Allison: Madam Mayor, Members of the Council, my name is David Allison. De Weerd: Welcome. Welcome said the spider to the fly. Allison: I feel maybe I need more notes. The budget amendment before you, which I am going to discuss, is for 444,699 dollars. This money reflects the amount of work that Brown & Caldwell, the consultant I will describe here a little bit more, the amount of work that they say they would be able to complete from a mid July start date until the end of this fiscal year. This money would be allocated to begin the design of the capacity enhancement at the wastewater treatment plant. This is the third step of -- of this process. The first step that we contracted with Brown and Caldwell was to evaluate the capacity, excuse me, of our plant, of our existing systems, based on the current capacity that we determined through their study, through their modeling efforts, we put together an alternatives analysis. It compared about 12 different treatment technologies, comparing capital costs and operating costs, some of which were very substantial. We came to our final decision on which alternative to select and ultimately construct based on it's favorable conditions and this amendment would be to fund the design portion for FY -- remaining Meridian City Council June 23, 2015 Page 35 of 40 portion of FY -15. Our designers gave us a 15 month design schedule and based on where we were at in our current fiscal year and where we would end up next year, we felt it would be prudent to get started as soon as possible, that way a complete set of design documents would be ready, so we could begin construction beginning in FY -17 or soon thereafter, right around that time. We'd also like to have more of a -- of an idea of what the construction would look like, what those elements would look like, what would be required for that construction. So, that way when we come forward about a year from now for our next budget we would have a -- we could be better informed to put our enhancements together for that. I guess I will stand for any questions. De Weerd: Thank you. Bird: Madam Mayor? De Weerd: Mr. Bird. Bird: Mr. Allison, I got a question. What is the -- what is the total estimate cost of this -- what we -- what we are designing? Allison: The design portion is about two point -- Bird: No. How much -- Allison: Excuse me. The design portion is about 2.8 million and we are looking for a total construction of about 30 to 35 million. Bird: And this -- this is -- is this the complete recovery redo -- addition I mean? Allison: Councilman Bird, this would be for the capacity expansion. This is part of capacity to increase the growth, as well as the -- Bird: Yeah. Okay. So, one point -- 1.2 or two million to design? Allison: Yeah. About two, 2.5. Bird: And about 31 or 32 million total project? Allison: That's our very preliminary estimate. And, like I said, it would be -- Bird: So, we are paying about eight or nine percent of our total estimated cost for design? Allison: Yes. De Weerd: And this is -- is really a major component in meeting future growth and having the capacity to do so. Meridian City Council June 23, 2015 Page 36 of 40 Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: I just -- so that it comes as no surprise, this is another one of those where there are a series of projects that will be coming over the next ten to 20 years. This is probably the first step -- actually, it's not the first step. We have already taken steps and in the past ten years or so have done capacity upgrades and inclusion. This particular one needs to be accelerated a little bit more than we originally anticipated, because it's actually being impacted by two things. The city continues to grow at a pace that we all know is just breathtaking. On that basis alone we aren't necessarily threatening our current capacity, although we are reaching 80 percent of it, which is where you want to start designing the next phase. But Tom Barry, the director, has also explained to me that in anticipating some of the new requirements about phosphate removal and some other things that we are going to have to remove to much greater stringent than we have been, the method for doing that takes longer. So, it's likely that we will be putting out the reclarified water, slower than we are taking it in, because the process is going to take a little bit longer, which means we need greater storage capacity -- not really storage, because it's still moving through the plant, but it's moving slower and that does take up capacity to be holding it longer. So, we are in danger of running out of capacity if we don't get this accelerated pretty quick. So, I just thought I would throw that in and, then, don't be surprised if there is a couple more in the next few years right after it. De Weerd: Any other questions for David? Borton: Madam Mayor? De, Weerd: Mr. Borton. Borton: David, if you can, are you able to articulate Finance's position and opposition to the amendment request? Allison: To this point, Councilman Borton, I haven't heard any opposition to this. We haven't had any -- we haven't heard anything. Borton: Okay. De Weerd: I don't think that -- she had a question and when Councilman Rountree and I were looking at this, she was not available to answer it, but she has since replied and -- Rountree: And I haven't seen that. Borton: I'm just making reference to the budget amendment form is all. There was a checkbox -- Allison: Oh. Meridian City Council June 23, 2015 Page 37 of 40 Borton: -- under Finance it said no and so I thought I'd ask. Okay. De Weerd: She was just asking what event triggered the additional request and she just didn't have time to completely review it, so she just didn't want people to miss that, especially since Todd is really pushing the deadlines and she did talk with Mike about -- asking what -- what had changed and I don't know what response she got, but I can just tell you what I got in an e-mail, because I asked the same thing. And so, David, I guess she had asked the question is what -- what event triggered the additional need for -- for the budget amendment. Allison: Madam Mayor, for us when we talk with the consultant about what they are anticipating design timeline would look like, they indicated it would be right around 15 months and we felt that put us in a great position to be able to have a design completed at the end of FY -16 and, then, be able to have the next enhancements and the next fiscal FY -17 for construction. De Weerd: And I think this was what Mr. Barry was talking about in terms of an accelerated need to address the capacity. This addresses load versus slow, is that how I understand it? Allison: Madam Mayor, this is for the capacity, but, in turn, we also are -- as Councilman Zaremba was stating, with the pending NPDES permit that we have coming up, the removal of the treatment of our existing capacity right now is lowered. Our treatment capacity has diminished -- De Weerd: Right. Allison: -- but if we were to have those limits put in place now this would be able to meet our current capacity, as well as the limits that are proposed in the NPDES permit and would also help us anticipate or build capacity for future expansion. De Weerd: Okay. Thank you. Any other questions? Zaremba: Madam Mayor? De Weerd: Mr. Zaremba. Zaremba: I move we approve the budget amendment for fiscal year 2015 in the amount of 444,699 dollars for beginning the design of the wastewater recovery -- wastewater resource recover facility capacity expansion project. Cavener: Second. De Weerd: I have a motion and a second. Any discussion? Meridian City Council June 23, 2015 Page 38 of 40 Borton: Madam Mayor? De Weerd: Mr. Borton. Borton: I don't support the request at this time. I'd like to see this included in -- in the budget book in next year's budget. I will also allow -- if there is other follow-up concerns from Finance, then, they can provide us with other additional info. So, it didn't sound like there was the necessary urgency to do it now versus 96 days from now or part of next year's budget, so that's where I would prefer to see it. De Weerd: Okay. Madam Clerk, will you call roll. Roll Call: Rountree, nay; Bird, nay; Zaremba, yea; Borton, nay; Milam, yea; Cavener, yea De Weerd: Aye. MOTION CARRIED: THREE AYES. THREE NAYS. MAYOR AYE. Allison: Thank you. Item 9: Ordinances A. Ordinance No. 15-1648: An Ordinance (RZ 15-006 Three Corners Subdivision) for the Re -zone of a parcel of land located in the NW'/4 of the NW'/4 of Section 29, Township 4 North, Range 1 East, Boise Meridian, City of Meridian, Ada County, Idaho Establishing and Determining the Land Use Zoning Classification of Said Lands from C -C (Community Business) zoning district, R-8 (Medium Density Residential) zoning district and R-4 (Medium -Low Density Residential) zoning district to C -C (Community Business) zoning district (9.38 acres), R-8 (Medium Density Residential) zoning district (2.76 acres) and R-4 (Medium -Low Density Residential) zoning district (0.51 acres. De Weerd: Okay. Thank you, David. Item 9-A under Ordinance 15-1648, 1 Will ask Madam Clerk to, please, read this by title. Holman: Thank you, Madam Mayor. City of Meridian Ordinance No. 15-1648, an Ordinance RZ 15-006, Three Corners Subdivision for the rezone of a parcel of land located in the northwest one quarter of the northwest one quarter, Section 29, Township 4 North, Range 1 East, Boise, Meridian, city of Meridian, Ada County, Idaho. Establishing and determining the zoning classification of C -C, community business zoning district, R-8, medium density residential zoning district and R-4, medium low density residential zoning district to C -C, community business zoning district, 9.38 acres, R-8, medium density residential, 2.76 acres, and R-4, medium low density residential zoning district, .51 acres in the Meridian City Code. Providing that copies of this ordinance shall be filed with the Meridian City Council June 23, 2015 Page 39 of 40 Ada County assessor, the Ada County recorder, and the Idaho State Tax Commission as required by law and providing for a summary of the ordinance and providing for a waiver of the reading rules and providing an effective date. De Weerd: Okay. You have heard this read by title. I don't see anyone wanting to hear it in its entirety, so do I have a motion? Milam: Madam Mayor? De Weerd: Mrs. Milam. Milam: I move that we approve Ordinance 15-1648 with suspension of rules. Bird: Second. De Weerd: I have a motion and a second to approve Item 9-A. Madam Clerk, will you call roll. Roll Call: Rountree, yea; Bird, yea; Zaremba, yea; Borton, yea; Milam, yea; Cavener, yea. De Weerd: All ayes. Motion carried. MOTION CARRIED: ALL AYES. Item 10: Future Meeting Topics De Weerd: Council, under future meeting topics I would ask would you have availability for a special meeting next Monday on the 29th around 5:00 o'clock? It should only last -- Mr. Nary, less than an hour? Bird: Sure. Set it. Let's go. Rountree: 5:00 o'clock? De Weerd: Yes. Rountree: Is it a special meeting or is it executive session? De Weerd: A special meeting executive session. Rountree: Okay. De Weerd: Okay. Thank you. Any other items for consideration under future meeting topics? Okay. Hearing none, I would entertain a motion to adjourn. Rountree: So moved. Meridian City Council June 23, 2015 Page 40 of 40 Bird: Second. De Weerd: All those in favor say aye. All ayes. MOTION CARRIED: ALL AYES. MEETING ADJOURNED AT 7:42 P.M. (AUDIO RECORDING ON FILE OF THESE PROCEEDINGS) DATE APPROVED C. Parra, ATTEST: uw. O¢C�liPfbD.\((C� T� CITY CLE fi� p r,cityo; z IDAryn 7 Fyr SEAL. J fP ,n. ca5�a Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: FP 15-020 ITEM TITLE: Paramount Square Subdivision FP 15-020 Paramount Square Subdivision by Brighton Investments, LLC Located Northwest Corner of N. Meridian Road and W. McMillan Road Request: Final Plat Approval Consisting of Twenty (20) Commercial Buildable Lots and One (1) Multi -Family Residential Lot on Approximately 31.95 Acres in the C -G and R-40 Zoning Districts MEETING NOTES —Mo' APPROIED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: RZ 15-006 ITEM TITLE: Three Corners by Sweet Land Development Findings of Fact, Conclusions of Law: RZ 15-006 Three Corners by Sweet Land Development, Inc. Located Southeast Corner of N. Locust Grove Road and Chinden Boulevard Request: Rezone of Approximately 12.65 Acres of Land from the C -C (Community Business), R-8 (Medium Density Residential) and R-4 (Medium -Low Density Residential) Zoning District to the C -C (9.38 Acres), R-8 (2.76 acres) and R-4 (0.51 Acres) Zoning Districts MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting TE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: CPAM 15-001 ITEM TITLE: Hill Properties/Century Farm Findings of Fact, Conclusions of Law: CPAM 15-001 Hill Properties/Century Farm School by Martin Hill, Hill & Hill Properties and Brighton Investments Located East Side of S. Eagle Road and South Side of E. Amity Road Request: Amendment to the Comprehensive Plan Future Land Use Map to Change the Future Land Use Designation on 87.01 Acres of Land from Low Density Residential to Mixed -Use Neighborhood MEETING NOTES APPROVED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: AZ 15-004 ITEM TITLE: Hill Properties/Century Farm Findings of Fact, Conclusions of Law: AZ 15-004 Hill Properties by Martin Hill and Hill & Hill Properties Located East Side of S. Eagle Road and the South Side of E. Amity Road Request: Annexation of 78.62 Acres of Land with the R-8 (39.83 Acres) and C -N (38.79 Acres) Zoning Districts MEETING NOTES PROVED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 5E PROJECT NUMBER: RZ 15-007 ITEM TITLE: Century Farm School Findings of Fact, Conclusions of Law: RZ 15-007 Century Farm School by Brighton Investments Located 1/4 Mile South of E. Amity Road and 1/2 Mile East of S. Eagle Road Request: Rezone of 8.39 Acres of Land From the R-8 to the C -N Zoning District MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 5F PROJECT NUMBER: FP 15-019 ITEM TITLE: Oak Leaf Subdivision Final Order for Approval: FP 15-019 Oak Leaf Subdivision No. 2 by Oak Leaf Development Company, Inc. Located North of Chinden Boulevard and West of N. Jayker Way Request: Final Plat Approval Consisting of Eleven (1 1) Single Family Residential Lots on Approximately 7.99 Acres in the R-2 Zoning District MEETING NOTES j. �. Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 5G PROJECT NUMBER: ITEM TITLE: Professional Services/Animal Control Addendum B to September 23, 2013 Professional Services Agreement for Animal Control Services and Dog Licensing Between the City of Meridian and the Idaho Humane Society MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS ADDENDUM B to PROFESSIONAL SERVICES AGREEMENT FOR ANIMAL CONTROL SERVICES AND DOG LICENSING BETWEEN THE CITY OF MERIDIAN AND THE IDAHO HUMANE SOCIETY This ADDENDUM B TO THE PROFESSIONAL SERVICE AGREEMENT FOR ANIMAL CONTROL SERVICES AND DOG LICENSING BETWEEN THE CITY OF MERIDIAN AND THE IDAHO HUMANE SOCIETY is made this 2,3" ay of June, 2015 ("Effective Date"), by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho (hereinafter "City"), and the Idaho Humane Society, Inc., a nonprofit corporation organized under the laws of the State of Idaho (hereinafter "IHS"). WHEREAS, City and IHS entered into a Professional Service Agreement for Animal Control Services and Dog Licensing Between the City of Meridian and the Idaho Humane Society on September 24, 2013 ("September 24, 2013 Agreement"); WHEREAS, IHS has purchased land at 8506 Overland Road near South Vinnell Way, in Boise, Idaho, and is constructing a new building in order to accommodate the growing need for animal control services within Ada County, which growth includes the extension of animal control services to City pursuant to the September 24, 2013 Agreement; WHEREAS, the Meridian City Council has determined that the building formerly used as City's animal shelter should be repurposed for use by the Public Works Department as part of the wastewater treatment plant expansion project, and as the building was purchased using general funds, City Council directed the transfer of the net book value of the asset (thirty-six thousand, seven hundred forty-five dollars ($36,745)), from the City enterprise fund to the City general fund, which transfer was accomplished by a budget amendment approved on June 9, 2015; WHEREAS, City finds that IHS has the necessary qualifications and capabilities to continue to provide a full range of animal control services to the Meridian community, to protect the community's health and welfare, and to assure that the animals are maintained consistent with the provisions of Meridian City Code, and directs that the amount realized by the general fund from the transfer of the former animal shelter facility to the enterprise fund be provided to IHS for the purpose of contributing to the cost of constructing the new IHS building; NOW, THEREFORE, for good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged and agreed, and in consideration of the mutual promises and covenants herein contained, the Parties agree as follows: L CONTRIBUTION. City shall contribute to IHS thirty-six thousand, seven hundred forty-five dollars ($36,745), in recognition of the growth of IHS due in part to the provision of animal control services to City pursuant to the September 24, 2013 Agreement. Payment of all taxes and other assessments on such sums shall be the sole responsibility of IHS. ADDENDUM B TO SEPTEMBER 24, 2013 PROFESSIONAL SERVICES AGREEMENT WITH IHS FOR ANIMAL CONTROL AND DOG LICENSING SERVICES PAGE 1 of 2 IL SEPTEMBER 24, 2013 AGREEMENT FULLY IN EFFECT. The intent and effect of this Addendum is to extend the term and increase the payment amount for services provided by IHS as set forth in the September 24, 2013 Agreement. Except as expressly set forth herein, this Addendum does not otherwise modify or alter any term or condition of the September 24, 2013 Agreement in any way. The September 24, 2013 Agreement remains in full effect, and all terms and conditions thereof are incorporated in this Addendum as though fully set forth herein. IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day of June, 2015. IDAHO HUMANE SOCIETY, INC.: Jeff Rosenthal, DVM Chief Executive Officer CITY OF MERIDIAN: BY:%"yl1�Ii' G��QJn Te�n� �N Tammy dei $erd, Mayor s City'[ E II71A i�i� Attest: Jaycee 101man, City Clerk FP �H °�:4e (At A9C�b ADDENDUM B TO SEPTEMBER 24, 2013 PROFESSIONAL SERVICES AGREEMENT WITH IHS FOR ANIMAL CONTROL AND DOG LICENSING SERVICES PAGE 2 of 2 Meridian City Council Meeting TE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: C & A Paving Company Approval of Award of Bid and Agreement to C & A Paving Company for the "CITY HALL WEST SIDE PARKING LOT" Project for a Not -To -Exceed amount of $239,540.75 MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS CITY OF MERIDIAN CONTRACT/AGENDA REQUEST CHECKLIST Date: 6/16/2015 REQUESTING DEPARTMENT PUBLIC WORKS Fund: 1 Department: 1850 GL Account: Construction: X Project Name: Project Manager: Max Jensen Department Representative: n/a Contractor/Consultant/Design Engineer: C&A Paving Company/ Civil Survey Budget Available (Attach Report): Yes Contract Amount: $239,540.75 Will the project cross fiscal years? Yes No X Wf-119 92401 Project # Task Order: CITY HALL WEST SIDE PARKING LOT Budget Information: FY Budget: 15 Enhancement#: 2 Grant#: Other: Type of Grant: CONTRACT CHECKLIST BASIS OF AWARD Low Bidder X Highest Rated Master Agreement (Bid Results Attached) (Ratings Attached) (Category) Typical Award Yes X No If no please state circumstances and conclusion: 10 Day Waiting Period Complete: June 19, 2015 Date Award Posted: June 9, 2015 PW License # PW -C-10359 Current? (attach print out) Corporation Status Goodstanding Insurance Certificates Received (Date): June 16, 2015 Rating: A Payment and Performance Bonds Received (Date): June 16, 2015 Rating: A+ Builders Risk Ins. Req'd: Yes No X If yes, has policy been purchased? n/a (Only applicabale for projects above $1,000,000) Date Submitted to Clerk for Agenda: June 17, 2015 Approved by Council Issue Purchase Order No. Date Issued: WH5 submitted Issue Notice of Award: Date: NTP Date: (Only for non Public Works Project) 10459 Memo To: Jaycee L. Holman, City Clerk, From: Keith Watts, Purchasing Manager CC: Jacy Jones, Max Jensen Date: 6/16/2015 Re: June 23rd City Council Meeting Agenda Item The Purchasing Department respectfully requests that the following item be placed on the June 23rd City Council Consent Agenda for Council's consideration. Approval of Award of Bid and Agreement to C & A Paving Company for the "CITY Recommended Council Action: Award of Bid and Approval of Agreement to C&A PAVING COMPANY for the Not -To -Exceed amount of $239,540.75. Thank you for your consideration. • Page 1 CONTRACT FOR PUBLIC WORK CONSTRUCTION CITY HALL WEST SIDE PARKING LOT PROJECT # 10459 THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this 18r' day of June, 2015, and entered into by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho, hereinafter referred to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and C&A Paving Company, Inc., hereinafter referred to as "CONTRACTOR", whose business address is P.O. Box 15187, Boise, ID 83714-5187 and whose Public Works Contractor License # is 10359-U- 2-4. INTRODUCTION Whereas, the City has a need for services involving PARKING LOT CONSTRUCTION; and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Contract and receipt of the City's written notice to proceed; all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Exhibit "A" and incorporated herein by this reference, together with any amendments that may be agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. If any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrighted by the Contractor, the City reserves a royalty -free, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, CITY HALL WEST SIDE PARKING LOT page 1 of 14 Project 10459 state and city laws, ordinances, regulations and resolutions. The Contractor represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part of the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in a timely manner in accordance with a Schedule of Work, which the parties hereto shall agree to. The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall be compensated on a Not -To -Exceed basis as provided in Exhibit B "Payment Schedule" attached hereto and by reference made a part hereof for the Not -To -Exceed amount of $239,540.75. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, of fees earned and costs incurred for services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a) completion of the agreed upon work, (b) or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time of termination is listed in Exhibit A. CITY HALL WEST SIDE PARKING LOT page 2 of 14 Project 10459 3.2 Should Contractor default in the performance of this Agreement or materially breach any of its provisions, City, at City's option, may terminate this Agreement by giving written notification to Contractor. 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's option, may terminate this Agreement if the failure is not remedied by the City within thirty (30) days from the date payment is due. 4. Liquidated Damages: Substantial Completion shall by September 11, 2015. This project shall be considered Substantially Complete when the Owner has full and unrestricted use and benefit of the facilities, both from an operational and safety standpoint, and only minor incidental work, corrections or repairs remain for the physical completion of the total contract. Contractor shall be liable to the City for any delay beyond this time period in the amount of $500.00 (five hundred dollars) percalendarday. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. Final Completion shall be achieved by September 22, 2015 for the work as described herein. Contractor shall be liable to the City for any delay beyond this time period in the amount of $500.00 (five hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. See Milestones listed below in the Payment Schedule for Substantial Completion. 5. Termination: 5.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails to fulfill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen (15) days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty (60) days notice to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation for any work satisfactorily complete hereunder. CITY HALL WEST SIDE PARKING LOT page 3 of 14 Project 10459 5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to the CITY for damages sustained by the CITY by virtue of any breach of this Agreement by CONTRACTOR, and the CITY may withhold any payments to CONTRACTOR for the purposes of set-off until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR of its liability to the CITY for damages. 6. Independent Contractor: 6.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided in Exhibit A, Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 6.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 6.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of Contractor in fulfillment of this Agreement. If in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. 7. Sub -Contractors: Contractor shall require that all of its sub -contractors be licensed per State of Idaho Statute # 54-1901 8. Removal of Unsatisfactory Employees: The Contractor shall only furnish employees who are competent and skilled for work under this contract. If, in the opinion of the City, an employee of the Contractor is incompetent or disorderly, refuses to perform in accordance with the terms and conditions of the contract, threatens or uses abusive language while on City property, or is otherwise unsatisfactory, that employee shall be removed from all work under this contract. CITY HALL WEST SIDE PARKING LOT page 4 of 14 Project 10459 9. Indemnification and Insurance: 9.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's elected officials, officers, employees, agents, and volunteers from and for any and all losses, claims, actions, judgments for damages, or injury to persons or property and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall maintain, and specifically amounts as follow: General Liability One Million Dollars ($1,000,000) per incident or occurrence, Automobile Liability Insurance One Million Dollars ($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or judgments for damages or injury to persons or property and other costs, including litigation costs and attorneys' fees, arising out of, resulting from , or in connection with the performance of this Agreement by the Contractor or Contractor's officers, employs, agents, representatives or subcontractors and resulting in or attributable to personal injury, death, or damage or destruction to tangible or intangible property, including use of. CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (10) days prior to the date Contractor begins performance of its obligations under this Agreement. In the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. 9.2 Insurance is to be placed with an Idaho admitted insurer with a Best's rating of no less than A-. 9.3 Any deductibles, self-insured retention, or named insureds must be declared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 9.4 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City or the City's elected officers, officials, employees and volunteers shall be excess of CITY HALL WEST SIDE PARKING LOT page 5 of 14 Project 10459 the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 9.5 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 9.6 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 9.7 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 10. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. 11. Bonds: Payment and Performance Bonds are required on all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. Contractor is required to furnish faithful performance and payment bonds in the amount of 100% of the contract price issued by surety licensed to do business in the State of Idaho. In the event that the contract is subsequently terminated for failure to perform, the contractor and/or surety will be liable and assessed for any and all costs'for the re -procurement of the contract services. 12. Warranty: All construction and equipment provided under this agreement shall be warranted for 2 years from the date of the City of Meridian acceptance per the ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items found to be defective during a warranty inspection and subsequently corrected will require an additional two (2) year warranty from the date of City's acceptance of the corrected work. 13. Changes: The CITY may, from time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written CITY HALL WEST SIDE PARKING LOT page 6 of 14 Project 10459 amendments which shall be executed with the same formalities as this Agreement. 14. Taxes: The City of Meridian is exempt from Federal and State taxes and will execute the required exemption certificates for items purchased and used by the City. Items purchased by the City and used by a contractor are subject to Use Tax. All other taxes are the responsibility of the Contractor and are to be included in the Contractor's Bid pricing. 15. Meridian Stormwater Specifications: All construction projects require either a Storm Water Pollution Prevention Plan (SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of Meridian Construction Stormwater Management Program (CSWMP) manual. The CSWMP manual containing the procedures and guidelines can be found at this address: http://www.meridiancity.oro/environmental.aspx?id=13618. 16. ACHD: Contractor shall be responsible for coordinating with the City to obtain appropriate ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs due to Contractor's violation of any ACHD policy. City shall certify to ACHD that Contractor is authorized to obtain a Temporary Highway and Right -of -Way Use Permit from ACHD on City's behalf. The parties acknowledge and agree that the scope of the agency granted by such certification is limited to, and conterminous with, the term and scope of this Agreement. 17. Reports and Information: 17.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 17.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement for a minimum of four (4) years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographic and every other means of recording upon any tangible thing, any form of communication or representation including letters, words, pictures, sounds or symbols or any combination thereof. 18. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or CITY HALL WEST SIDE PARKING LOT page 7 of 14 Project 10459 transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. 19. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 20. Equal Employment Opportunity: In performing the work herein, Contractor agrees to comply with the provisions of Title VI and VII of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code Section 2176. Specifically, the Contractor agrees not to discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. Contractor will take affirmative action during employment or training to insure that employees are treated without regard to race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. In performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. 21. Employment of Bona Fide Idaho Residents: Contractor must comply with Idaho State Statute 44-1002 which states that the Contractor employ ninety-five percent (95%) bona fide Idaho residents. 22. Advice of Attorney: Each party warrants and represents that in executing this Agreement. It has received independent legal advice from its attorney's or the opportunity to seek such advice. 23. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. 24. Construction and Severability: If any part of this Agreement is held to be invalid or unenforceable, such holding will CITY HALL WEST SIDE PARKING LOT page 8 of 14 Project 10459 not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 25. Waiver of Default: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. 26. Entire Agreement: This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. 27. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent of CITY. 28. Payment Request: Payment requests shall be submitted to City of Meridian through the City's project management software. The Project Manager will compare the invoice against the Payment Schedule in the Agreement for compliance. Upon approval that the work has been done and is in compliance with the Agreement, the Project Manager will approve the pay request for processing. City of Meridian payment terms are Net 30 from the date City receives a correct invoice. Final payment will not be released until the City has received a tax release from the Tax Commission. 29. Cleanup: Contractor shall keep the worksite clean and free from debris. At completion of work and prior to requesting final inspection, the Contractor shall remove all traces of waste materials and debris resulting from the work. Final payment will not be made if cleanup has not been performed. 30. Order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted bid document. 31. Compliance with Laws: In performing the scope of work required hereunder, CONTRACTOR shall comply CITY HALL WEST SIDE PARKING LOT page 9 of 14 Project 10459 with all applicable laws, ordinances, and codes of Federal, State, and local governments. 32. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 33. Notices: Any and all notices required to be given by either of the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY CONTRACTOR City of Meridian C&A PAVING COMPANY, INC. Purchasing Manager Attn: Brian Callahan 33 E Broadway Ave P.O. Box 15187 Meridian, ID 83642 Boise, ID 83715-5187 208-489-0417 Phone: 208-362-4244 Email: jesse@capaving.com Idaho Public Works License #10359-U-2-4 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 34. Approval Required: This Agreement shall not become effective or binding until approved by the City of Meridian. CITY OOF ME-RIf3t BY: TAMMYde D, MAYOR Dated: l' /� / / S Approved by Counci JAYCEE CLE CITY HALL WEST SIDE PARKING LOT Project 10459 C&A PAVING COMPANY, INC. BY: z_ BRIAN CALLAHAN. PRESIDENT Dated: l m�onxo SES, Py , ��bt 'iflf ASUA` page 10 of 14 Purchasing Approval BY:/� KEIT14 TTS, urchasing Manager Dated:: (a - / (o - 1-6 Project Manager Max Jensen, Capital Projects Manager CITY HALL WEST SIDE PARKING LOT Project 10459 m FEWART, Engineering Manager page 11 of 14 EXHIBIT A SCOPE OF WORK REFER TO INVITATION TO BID PW -15-10459 ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation to Bid Package # PW -15-10459, are by this reference made a part hereof. SPECIFICATIONS / SCOPE OF WORK All construction work shall be done in accordance with the 2012 version of the Idaho Standards for Public Works Construction (ISPWC), the 2013 City of Meridian Supplemental Specifications to the ISPWC (and any Addendums). See separate attached documents: • PLANS NAME BY CIVIL SURVEY CONSULTANTS, INC. dated 5-13-2015 (14 of pages) • SPECIAL PROVISIONS by CIVIL SURVEY CONSULTANTS, INC dated 5/13/15 (95 of pages) CITY HALL WEST SIDE PARKING LOT page 12 of 14 Project 10459 Exhibit B CITY HALL WEST SIDE PARKING LOT MILESTONE / CONTRACT PRICING SCHEDULE 706.4.1.B.1 Concrete Valley Gutter 37 LF $33.50 706.4.1.H.1 Pedestrian Ramp W/Detectable Warning Domes, Type C4 2 EA $775.00 801.4.1.6.1 6" Minus Uncrushed Aggregate Base 1,452 TON $13.00 802.4.1.B.1 T P Crushed Aggregate for Base, 667 TON $18.00 810.4.1.A.1 Plant Mix Pavement 390 TON $75.00 1001.4.2.A.1 Staging Area 1 EA $1,025.00 1001.4.2.6.1 Stabilized Construction Entrance 2 EA $150.00 1003.4.1.GA Straw Wattle 844 LF $2.25 1006.4.1.C.1 Inlet Protection 5 EA $80.00 1103.4.1.A.1 Construction Traffic Control 1 LS $2,600.00 1104.4.1.A.1 Pavement Markings 460 SF $.70 2010.4.1.A.1 Mobilization 1 LS $6,400.00 SP -1a Drain Trench #1 1 LS $9,300.00 SP -ib Drain Trench #2 1 LS $9,300.00 SP -2 Adjust Water Service to Grade 2 EA $2,100.00 SP -3 Edge Drain 1,025 LF $8.00 SP -4 Landscape Grading 1 LS $2,400.00 SP -5 Landscape Irrigation 15,197 SF $1.50 SP -6 Landscape Plants 1 LS $18,879.75 SP -7 Landscape Turf and Grasses 8,397 SF $6,400.00 SP -8 Abandon Existing Water Service 1 EA $675.00 SP -9 Electrical 1 LS $23,100.00 CITY HALL WEST SIDE PARKING LOT page 14 of 14 Project 10459 H J D LU w Bond No, 0190040 CONSTRUCTION CONTRACT Date: June 16, 2015 Amount: $ 239,540.75 Two Hundred Thirty Nine Thousand Five Hundred Forty Dollars and 75/100 Description: (Name and location) City Hall West Side Parking Lot Project No. 10459 BOND Date: June 16, 2015 (Not earlier than Constxrction Contract Date) Amount: $239,540.75 Two Hundred Thirty Nine Thousand Five Hundred Forty Dollars and 751100 ;Modifications to this Bond: xl None ❑ sec section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Couporate Seal) Company: (Corporate Seal) C & A Paving Company, Inc. Berkley Insurance Company Signature: �¢, iiL�C..-/ signature: ! �� )�-Q,L&V Name ?y j G,UI Loi Name li2ab th Ann Schneider and Title: Missal zlLo t and Title: Attorney -in -Fact (Xny additional signatures appear on the last page of this Peifonnance Bond) (FOR INFOP61,L 1770N0NL1'— Man ie, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Moreton & Company (drehirect Engineer or other party:) 12639 West Explorer Dr., Suite 200 Boise ID 83713 208-321-9300 S-1852/AS 8110 MM Document A312 TM -2010 Conforms with The American Institute of Architects AIA Document 312 Performance Bond CONTRACTOR: SURETY: (iVame, legal status and address) (Nmne, legal slants and princlpal place of husiness) C &A Paving Company, Inc. Berkley Insurance Company 4015 South Banner Street 475 Steamboat Road This document has Important legal Boise ID83709 Greenwich CT 06830 consequences. Consultation with Mailing Address for Notices an attorney Is encouraged with respect to Its completion or modification. OWNER: Any singular reference to (Name, legal status and address) Contractor, Surety, Owner or City of Meridian other party shall be considered 33 East Broadway Ave., Ste. 106 plural where applicable. Meridian ID 83642 CONSTRUCTION CONTRACT Date: June 16, 2015 Amount: $ 239,540.75 Two Hundred Thirty Nine Thousand Five Hundred Forty Dollars and 75/100 Description: (Name and location) City Hall West Side Parking Lot Project No. 10459 BOND Date: June 16, 2015 (Not earlier than Constxrction Contract Date) Amount: $239,540.75 Two Hundred Thirty Nine Thousand Five Hundred Forty Dollars and 751100 ;Modifications to this Bond: xl None ❑ sec section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Couporate Seal) Company: (Corporate Seal) C & A Paving Company, Inc. Berkley Insurance Company Signature: �¢, iiL�C..-/ signature: ! �� )�-Q,L&V Name ?y j G,UI Loi Name li2ab th Ann Schneider and Title: Missal zlLo t and Title: Attorney -in -Fact (Xny additional signatures appear on the last page of this Peifonnance Bond) (FOR INFOP61,L 1770N0NL1'— Man ie, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Moreton & Company (drehirect Engineer or other party:) 12639 West Explorer Dr., Suite 200 Boise ID 83713 208-321-9300 S-1852/AS 8110 MM § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner docs not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owners notice. If the Owner, the Contractor and the Surely agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terns of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 6.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 6.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 6.3 Obtain bids or negotiated proposals from quali fed contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Ommcr and a contractor selected with the Owners concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. - S-1852/AS 8/10 § 7 I the Surety elects to act under Section 5.1, 5.2 or 5,3, then the responsibilities of the Surely to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the. Concoction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surely refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in thejurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so fumishcd, the intent is that this Bond shall be construed as a statutory bond and not as a common Iry bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the tern Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shalt be deemed to be Contractor. S-1852/AS 8/10 § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: Signature: Signature: Name and Title: Name and. Address Address 5-1852/AS 8/10 (Cotpw•ate Seal) Bond No. 0190040 Payment Bond CONTRACTOR: (varve, legal status and address) Document A312 TM —2010 Conforms with The American Institute of Architects AIA Document 312 C &A Paving Company, Inc. 4015 South Banner Street Boise ID 83709 OWNER: (Mame, legal status and address) City of Meridian 33 East Broadway Ave., Ste. 106 Meridian ID 83642 CONSTRUCTION CONTRACT Date: June 16, 2015 Amount: 6239,540.75 SURETY: (Name, legal status and principal place of business) Berkley Insurance Company 475 Steamboat Road Greenwich CT 06830 Mailing Address for Notices This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. Two Hundred Thirty Nine Thousand Five Hundred Forty Dollars and 75/100 Description: (Name and location) City Hall West Side Parking Lot Project No. 10459 BOND Date: June 16, 2015 (Not earlier than Construction Contract Date) Amount: $ 239,540.75 Two Hundred Thirty Nine Thousand Five Hundred Forty Dollars and 75/100 Modifications to this Bond: Q None ❑ See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) C &A Paving Company, Inc. Berkley Insurance Company ) f i It r j�., A it V Signature: ' `'/ Signature: !2 /tl.& ' 11 Eli th Ann Schneider Name ! IVV\ l0, CaN1 Name Attorney -in -Fact and Title: �r ,, A , a .�- and Title: (Any additional signatures appear on the last page of this Payment Bond.) (FOR INFORAUTION ONLY —Name, address and telephone) AGENT or BROKER: Moreton & Company 12639 West Explorer Dr., Suite 200 Boise ID 83713 208-321-9300 S-21491AS 8/10 OWNER'S REPRESENTATIVE: (Architect, Engineer or other parry:) A § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms, § 2 I the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's properly by any person or entity seeking payment for labor, materials or equipment famished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and tit the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 6.1 Claimants, who do not have a direct contract with the Contractor, .1 have famished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1,1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § $ The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. 5-2149/AS 8/10 § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that arc unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract -is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph arc void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been firmished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of.this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shalt permit a copy to be made. § 16 Definitions § 16.1 Clalm. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant' to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .6 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and at other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. S-2149/AS 8110 § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contractor to perform and complete or comply with the other material terms of the Construction Contract. § 16.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: (Space is p'avided belory for additional signatra•es ofadded parties, orherthan (hose appearing on the cove, -page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: Signature: Name and Address S4149/AS 8110 Signature: _ Name and Title: Address (Corporate Seal) No. BI -2768a POWER OF ATTORNEY BERKLEY INSURANCE COMPANY WILMINGTON. DELAWARE NOTICE: The warning found elsewhere in this Power of Attorney affects the validity thereof. Please review carefully. KNOW ALL MEN BY THESE PRESENTS, that BERKLEY INSURANCE COMPANY (the "Company"), a corporation duly organized and existing under the laws of the State of Delaware, having its principal office in Greenwich, CT, has made, constituted ., and appointed, and does by these presents make, constitute and appoint: Kinn Ward, Tura Coleman, Phil Waller, Allan Ranstrom, Colleen Thompson, Robin Stroud or Elizabeth Ann Schneider of Moreton Insurance of Idaho, Inc. dba Fred A. Moreton & Company of Boise, ID its true and lawful Attorney -in -Fact, to sign its name as surety only as delineated below and to execute, seal, acknowledge and deliver any and all bonds and undertakings, with the exception of Financial Guaranty Insurance, providing that no single obligation shall exceed Twenty Five Million and 00/100 U.S. Dollars (U.S.$25,000,000.00), to the same extent as if such bonds had been duly executed and acknowledged by the regularly elected officers of the Company at its principal office in 3I their own proper persons. This Power of Attorney shall be construed and enforced in accordance with, and governed by, the laws of the State of Delaware, without giving effect to the principles of conflicts of laws thereof. This Power of Attorney is granted pursuant to the following resolutions which were duly and validly adopted at a meeting of the Board of Directors of the Company held on January 25, 2010: RESOLVED, that, with respect to the Surety business written by Berkley Surety Group, the Chairman of the Board, Chief Executive Officer, President or any Vice President of the Company, in conjunction with the Secretary or any Assistant Secretary are hereby authorized to execute powers of attorney authorizing and qualifying the attorney-in-fact named therein to execute bonds, undertakings, recognizances, or other suretyship obligations on behalf of the Company, and to affix the corporate seal of the Company to powers of attorney executed pursuant hereto; and said officers may remove any such attorney-in-fact and revoke any power of attorney previously granted; and further RESOLVED, that such power of attorney limits the acts of those named therein to the bonds, undertakings, recognizances, or other suretyship obligations specifically named therein, and they have no authority to bind the Company except in the manner and to the extent therein stated; and further RESOLVED, that such power of attorney revokes all previous powers issued on behalf of the attomey-in-fact named; and further RESOLVED, that the signature of any authorized officer and the seal of the Company may be affixed by facsimile to any power of attorney or certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligation of the Company; and such signature and seal when so used shall have the same force and effect as though manually affixed. The Company may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Company, notwithstanding the fact that they may have ceased to be such at the time when such instruments shall be issued. IN WITNESS WHEREOF, the Company has caused these presents to be signed and attested by its appropriate officers and its ,corporate seal hereunto affixed this '.)?-day of �U�, 2013. Attest: V Berkley Insurance Company (Seal) By By Ir S. Lederman Je 1 after Senior Vice President & Secretary e i President WARNING: THIS POWER INVALID IF NOT PRINTED ON BLUE "BERKLEY" SECURITY PAPER. STATE OF CONNECTICUT) ss: COUNTY OF FAIRFIELD ) Sworn to before me, a Notary Public in the State of Connecticut, this2day of(, 2013, by Ira S. Lederman and Jeffrey M. Hatter who are swom to me to be the Senior Vice President and Secretary and h Senior Vice Pre�ident, respectively, of Berkley Insurance Company. KAnitEENCOREY NOTARYPUSUG Nota Public, State of Con EcnCUT Notary �5�11SSION EXPIRES OCTOBER CERTIFICATE I, the undersigned, Assistant Secretary of BERKLEY INSURANCE COMPANY, DO HEREBY CERTIFY that the foregoing is a true, correct and complete copy of the original Power of Attorney; that said Power of Attorney has not been revoked or rescinded 'and that the authority of the Attomey-in-Fact set forth therein, who executed the bond or undertaking to which this Power of Attorney is attached, is in full force and effect as of this date. Given under my hand and seal of the Company, this � l0 day of _ A. (Seal) Andrew4vl. Uma Client#: 1178 CAPAV ACORD. CERTIFICATE OF LIABILITY INSURANCE DATE -- TYPE OF INSURANCE 6/10/2/DD/YVYY) 6/10/2015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONT IT Liz Schneider Moreton &Company -Idaho PHONE 208 321-9300 FAX 208-321-0107 AIC AC, No P.O. Box 191030 EMAIL eschneider@moreton.com ADDRESS: Boise, ID 83719 MED EXP (Any one person) $15,000 208 321-9300 INSURER(S) AFFORDING COVERAGE NAIC // INSURER A: Liberty Mutual Insurance Compan 23043 GENE AGGREGATE LIMIT APPLIES PER: POLICY X JECPRO PRO- LOG INSURED C & A Paving Company, Inc. INSURER B: Alaska National Insurance CO. 38733 -- A PO Box 15187 INSURER C: INSURERD: _ Boise, ID 83715-5187 INSURER E 9/18/2014 INSURER F: COMBINED SINGLE LIMIT CO accident 1,000,000 COVERAGES CEKI IFICATE NUMBER: REVISION NUMBER' THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS, AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR -- TYPE OF INSURANCE ADDLSUBR INSR WVD - .POLICY NUMBERMMIDDIriYY POLICY EFF POLICY EXP IMM LIMITS A GENERAL LIABILITY X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE aOCCUR x CG 000112/07 BKS55626904 9/18/2014 __I 09/18/201 _ EACHOCCURRENCE $11000,000 D MAGE TO RENTED P�EMISEs Ea occunence -$1,000,000 MED EXP (Any one person) $15,000 PERSONAL S ADV INJURY $1,000,000 GENERAL AGGREGATE $2,000,000 GENE AGGREGATE LIMIT APPLIES PER: POLICY X JECPRO PRO- LOG PRODUCTS-COMP/OP AGG $2,000,000 $ A AUTOMOBILE -_ X LIABILITY ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS HIRED AUTOS X NON -OWNED AUTOS BAS55626904 9/18/2014 - 09/18/201 COMBINED SINGLE LIMIT CO accident 1,000,000 BODILY INJURY (Per person) $ - BODILY INJURY (Per accident) $ X PROPERTY DAMAGE Per accident $ A X UMBRELLA LIAB EXCESS LAB X OCCUR CLAIMS -MADE US055626904 EACH OCCURRENCE $5,000,000 AGGREGATE $5 000 000 DED X RETENTION$10000 $ BWC WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YINRY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? � (Mandatory In NH) If yes, describe under DESCRIPTION OF OPERATIONS below NIA 14JWS08527 1T06/01/201410/01/201!^_ �— STATU- OTH- LT& MLT. ER E.L. EACH ACCIDENT $1,000000 E.L. DISEASE -EA EMPLOYEE $1,000,000 EL.DISEASE-POLICYLIMIT $1,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS /VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required) Re: City Hall West Side Parking Lot City of Meridian 33 E Broadway Ave., Ste. 106 Meridian, ID 83642 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE cc)1QRA-9Mn ACnRn CnoGno ATInkl All :;..4..-......... A ACORD 25 (2010105) 1 of 1 The ACORD name and logo are registered marks of ACORD #S723692/M654174 ELISC eTRAKiT Home I Setup an Account ILog In Contractor,v Username Passvrord LOGIN ❑REMEMBERME Forgot Password Permits Apply Search Pay Fees Licenses Search Trade Licenses Search Public Works Inspections Schedule Cancel Elevators Search Elevators Violations Search Shopping Cart Pay All Fees Contact Contact us Page 1 of 1 Public Works Search m> SoarchAgaln CowmaadReruhs Prirtablevler MEM amm BE C B, A Paving Co., Inc. I PWC -C-10359 100002, 02500 12, 4 I UNLIMITED I ACTIVE I C& A Paving Co., Inc. First Prev Page: 1 of 1 Next Last Details - License Number: PWC -C-10359 Registration#: PWC -C-10359 Issue: 4114/2015 Expire: 4/3012016 Type: PUBLIC WORKS Sub -Type: UNLIMITED Status: ACTIVE Company: C 8 A Paving Co., Inc. Phone: (208)362-4244 Cell: Pager: Fax: (208)362-4190 Owner Name: The ONisium of Building Safety, makes every effort to produce and publish the most current and accursteinformatan possible No warranties, expressed or implied, are provided for the data herein, its use, or its interpretationformation of this vmbste indicates understanding and acceptance of this statement. 1-800955-3044, 1090 E Walertovrer St, Suite 150 Mendian 10 83542 ECML I CONTACT httDs://web.dbs.idaho.iaov/etrakit3/Custom/fdaho PublicWorksSearchRslts.aspx 6/16/2015 IDSOS Viewing Business Entity Page 1 of 2 w,� Stat IDAHO SECRETARY OF STATE x Q Viewing Business Entity ���TE 'p44Q Lawerence Denney, Secretary of State [ New Search ] [ Back to Summary ] [ Get a certificate of existence for C & A PAVING COMPANY ] [ Monitor C & A PAVING COMPANY business filings ] C & A PAVING COMPANY 4015 S BANNER ST BOISE, ID 83709 Type of Business: CORPORATION, GENERAL BUSINESS Status: GOODSTANDING 30 Jan 1997 State of Origin: IDAHO Date of 30 Jan 1997 Origination/Authorization: View Initial Registered Agent: BRIAN L CALLAHAN ANNUAL REPORT 1230 BRAITHWAIT LANE Document Online KUNA,ID 83634 Organizational ID / Filing C118078 Number: Report for year 2012 Number of Authorized Stock 100000 Shares: OFF/DIR Date of Last Annual Report: 29 Jan 2015 Annual Report Due: Jan 2016 Original Filing: Document Online [ He(p Me PrintlVlew TIFF ] Filed 30 Jan 1997 INCORPORATION View Image (PDF format} View Image-kTIFF forpaW [ Help Me Pnnt/View TIFF ] Report for year 2015 ANNUAL REPORT View Document Online Report for year 2014 ANNUAL REPORT View Document Online Report for year 2013 ANNUAL REPORT View Document Online Report for year 2012 ANNUAL REPORT View Document Online Report for year 2012 CHNG View image (PDF format} View OFF/DIR Image (TIFF format) Report for year 2011 ANNUAL REPORT View Document Online Report for year 2010 ANNUAL REPORT View Document Online Report for year 2009 ANNUAL REPORT Report for year 2008 ANNUAL REPORT Report for year 2007 ANNUAL REPORT View Image (PDF format) View Image TIFF format] View Image (PDF formats View Image (TIFF format) View Image (PDF format) View Ima99-kTIFF format} htti)://www.accessidaho.ory/public/sos/corp/Cl 18078.html 6/16/2015 City Of Meridian Detailed Statement of Revenues and Expenditures - Rev and Exp Report - Keith - Unposted Transactions Included In Report 1850 - City Hall 01 - General Fund From 10/1/2014 Through 9/30/2015 Percent of Budget with Current Year Budget Budget Amendments Actual Remaining Remaining Capital Outlay 92401 Improvement - pavement sidewalks 10459 City Hall West Parking Lot 320-000.04 41,185 00 278,815.04 87.13% Total Capital Outlay 320,000.04 41,185.00 278,815.04 87.13% TOTAL EXPENDITURES 320,000.04 41,185.00 278,815.04 87.13% Date: 6/16/15 05:00:14 PFS Page: 1 W O 0 O O O WI�I NINI OO 0 0 :Y � J O 1 0 00 m a 'Do v OL O N 'o E O ° O N V C w cd F � W ® u f0 W @ « O> ~ O F LL 7Ui E m v d m O a �* v o u C O O - N YN O � E vp E c 0 p C a N m W o W m a s m E l U � c i o o Cd W LL W m o0 I\ C N W o� O 3 F> n z E c 7 LL W 3 � � LL r � 0 a c 0 0 0 0 0 0 0 W O 0 O O O OO 0 0 :Y � J O 1 0 00 m a 'Do v OL O N 'o E O ° O N V d C j0 O w cd F � W ® u f0 W @ « u ~ O F LL 7Ui E m v O C v v o u C O O - p � { m p C Nv W C � N O b u E l U i o o c m o0 Q Z45:1 W o� ca 3 F> n 0 c 7 LL W 3 � h � 0 a c 0 0 0 0 0 0 0 W mo tO O V N N M In O O N O N N N O N O a v v a v a a v 0 0 0 0 0 0 0 0 V1 V1 V1 V1 V1 vl N V1 i1. LL a > Y LL o O Lo r v a c O � c ° N w N 0 0 0 a LL v > v a Eo 0 d c � H U N H LL V c S� 00 y ai L N O O \O I V O M. M Of O iJ ' c� C > O U vin {n iii. u U a` p, F c � tt (D 0 O 0 O O O OO 0 0 :Y � J O 1 0 00 m a 'Do v OL O N 'o E O ° O N V d C j0 O w cd F � W ® u f0 W @ « u ~ O F c 7Ui O C v v h b C O O - p p Nv � E E l w o o _O m o0 Q Z45:1 W o� 3 F> n 0 c 7 LL W 3 � h � 0 a w 0 0 0 0 0 0 0 0 O tO O V N N M In O O N O N N N O N O a v v a v a a v 0 0 0 0 0 0 0 0 V1 V1 V1 V1 V1 vl N V1 i1. LL a > LL o O d ------------- E 0 H c o a V W O 0 O O O OO 0 O :Y � J O 1 0 00 m a 'Do v OL O N 'o E O ° O N V d C j0 O W W' cd F � W ® � f0 W @ « E ~ O F m 7Ui O C v v h b C O O - w VT Nv av a V o 6 o o m o0 m W O � V a c c c � h � 0 o ro E O `y c p ° etl a m y LL i1. LL a > LL o ------------- E 0 H c o a V W O 0 O O O OO 0 O N N M J O 1 0 00 m a 'Do v OL O N 'o E O ° O d C j0 O W W' cd F � W ® � f0 W @ « E ~ O F m O C v v h V C O O - w VT 6 x x o m o0 m m V a c c c � 0 o ro E O `y J > LL � O d E � � N 0 0 0 0 0 0 > v 0 d U N V c W N O.. 0 00 y ai N O O \O I V O M. M Of iJ ' c� C O U vin {n iii. y a If O c o 0 0 0 0 o y> 0 0 0 0 0 0 0 0 0 0 0 0 0 O O 0 0 0 0 0 0 0 0 0 0 0 0 0 ' W W O'J W W N W W W ll1M W W W U F o ��- ------------ O O O O 0 O O O OO 0 O N N M J C 1 0 00 m a 'Do v OL O N 'o E O ° d C j0 O W W' cd F � W ® C f0 W @ « E ~ O F m LL C v v h V C O O L O w U O 0 OO 0 O 1 0 00 N N F V N N LL O x x o m m V a c c c � 0 o ro E J > LL � O d E � � 0 0 0 0 0 0 0 > v 0 d U N W N O.. 0 00 y N O O \O I V O M. M Of iJ ' O U vin {n iii. If O c o 0 0 0 0 o y> A w w w oo ao w w c O �y LL O a s «o U F o ��- U C) 0 r W E O LL C a) U C co W 0) m LO C) LL M a) O �a A J m C C , O o c 00 y N @ N C ` O N N y a c ,o � a @ W V @ a � L v a UI — wY — c v E O ¢ ,O c o v v a Y 0 o L c 3 o w N C c p @ a Yn v u H v @ .O @ @ W UJ 9 j u o v' C v v ¢ Q E ^' Ul � v a a � > u U C C W N o- v o v v v N � Y � Y � w w Y @ r 3 Y a o „ I a ° -p o v Y � N O � ya c v c ° a •u vp N u y � U L 9 N @ 9 v c V V C ` @ y Q � C I I (O ¢ @ I v m + m Q @ v Y I c u { 0 U cfa O I v I i -O i s 1 I:z EiL n Y >•i. of O ¢i'v I I ( N 1 Y o N >O � I' I I �I Y o �. o v 2i ° 12 n uiv `w «i� u{0 3 :5 w o m w i'WI � m4 Y 00 tL y Y 6 I C! C i Y Oa O Q OC E N v a 1•' C v>@ 0 w, p Y u Y a¢ ! n m U .; @ t. O m @ c o ¢ !aI aI. oo w � C m14 p Vf E a i o« w C !: > N: P•c > ! Y O N C V u ap ❑ ! a v' a 13 v ^' � `o E w 1 12 �. j. w � y !. w o. a Y v � Y' o @ U ° :n 3 k 6 7 N @ 1 :E C° in WO F vi ui Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 51 PROJECT NUMBER: ITEM TITLE: West Ada School District West Ada School District Water Easement MEETING NOTES APPk�®! R UED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS ADA COUNTY RECORDER Christopher D. Rich _ BOISE IDAHO Pgs=7 BONNIE 2015-056381 MERIDIAN CITY 06/25/201511:59 AM III IIII III I1111111111111111111111111111111 IN III NO FEE 00114152201600663810070076 WATER 1y1AIN EASEMENT �3 THIS INDENTURE, made this day ofJWAf 20 l5 between the West Ada School District, the parties of the first part, and hereinafter called the GRANTORS, and the City of Meridian, Ada County, Idaho, the party of the second part, and hereinafter called the GRANTEE; WITNESSETH: WHEREAS, the GRANTORS desire to provide a water main right-of-way across the premises and property hereinafter particularly bounded and described; and WHEREAS, the water main is to be provided for through an underground pipeline to be constructed by others; and WHEREAS, it will be necessary to maintain, service and subsequently connect to said pipeline from time to time by the GRANTEE; NOW, THEREFORE, in consideration of the benefits to be received by the GRANTORS, and other good and valuable consideration, the GRANTORS do hereby give, grant and convey unto the GRANTEE the right-of-way for an easement over and across the following described property: (SEE ATTACHED EXHIBIT A and B) The easement hereby granted is for the purpose of construction and operation of a water line and their allied facilities, together with their maintenance, repair, replacement and subsequent connection at the convenience of the GRANTEE, with the free right of access to such facilities at any and all times. TO HAVE AND TO HOLD, the said easement and right-of-way unto the said GRANTEE, it's successors and assigns forever. IT IS EXPRESSLY UNDERSTOOD AND AGREED, by and between the parties hereto, that after making repairs, performing maintenance, replacements or subsequent connections to the water mains, GRANTEE shall restore the area of the easement and adjacent property to that existent prior to undertaking such procedures. However, GRANTEE shall not be responsible for repairing, replacing or restoring anything placed within the area described in this easement that was placed there in violation of this easement. Water Main Easement EASMT WAT.doc THE GRANTORS hereby covenant and agree that they will not place or allow to be placed any permanent structures, trees, brush, or perennial shrubs or flowers within the area described for this easement, which would interfere with the use of said easement, for the purposes stated herein. THE GRANTORS hereby covenant and agree with the GRANTEE that should any part of the right-of-way and easement hereby granted shall become part of, or lie within the boundaries of any public street, then, to such extent, such right-of-way and easement hereby granted which lies within such boundary thereof or which is a part thereof, shall cease and become null and void and of no further effect and shall be completely relinquished. THE GRANTORS do hereby covenant with the GRANTEE that they are lawfully seized and possessed of the aforementioned and described tract of land, and that they have a good and lawful right to convey said easement, and that they will warrant and forever defend the title and quiet possession thereof against the lawful claims of all persons whomsoever. IN WITNESS WHEREOF, the said parties of the first part have hereunto subscribed their signatures the day and year first herein above written. GRAN OR: strirr f3aM ara s A:dm++wAfftter A� i s �a ttit St�pu i Vutc ►� det� t West Ada School District 1303 E. Central Dr., Meridian, ID 83642 Address STATE OF IDAHO ) : ss. County of Ada ) On this 114 day of JV4u— 20 lS before me, the undersigned, a Notary Public in and for said State, personally appeared and DOY 6eiw- LMA6, , known or identified to me to be the PfegWeeat &4, and Seeretery, respectively, of the corporation that executed the within instrument, and 61"iacknowledged to me that such corporation executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal the day and year first above written. ,`o,,�p.uwey0000 aqe ���� °°•° i, °ae Ater inr�j��x ®® J e eeBee�E1OFie Q•°e°e° NOTARY PUBLIC FOR IDAHO Residing at: ? wrt r ddA-4w Commission Expires: EASMT WAT.doc GRANTEE: CITY OF MERIDIAN Tammy e e r, tayot e°iinTeo N 7� v° 9 r 'ity of Attesf by J cee L. Holman, City Clerk EIDR IANC AHO Approved By City Council On: / Fq Or Ibe 10.E S�QO STATE OF IDAHO, ) : as County of Ada ) On this 2�3 day of �' , 20 � , before me, the undersigned, a Notary Public in and for said State, personally appeared Tammy de Weerd and Jaycee L. Holman, known to me to be the Mayor and City Clerk, respectively, of the City of Meridian, Idaho, and who executed the within instrument, and acknowledged to me that the City of Meridian executed the same. IN WITNESS WHEREOF, l have hereunto set my hand and affixed my official seal the day and year first above written. (SEAL) nr� SS NOTARY tB ICI HO Residing at: d Commission Expires: Z a� Water Main Easement EASMT WAT.doc li m fi. MEMEW 9233 WEST STATE STREET I BOISE, ID 83714 1 208.639.6939 1 FAX 208.639.6930 May 21, 2015 City of Meridian Water Project No. 12-M6 Legal Description City of Meridian Water Easement Exhibit A A parcel of land for a City of Meridian Water Easement situated in a portion of the Southeast 1/4 of the Northeast 1/4 of Section 11, Township 3 North, Range 1 West, Boise Meridian, City of Meridian, Ada County, Idaho and more particularly described as follows: Commencing at a found brass cap marking the East 1/4 corner of said Section 11, which bears 589°39'03"E a distance of 2655.26 feet from a found brass cap marking the Center 1/4 corner of said Section 11, thence following the southerly line of said Southeast 1/4 of the Northeast 1/4, N89°39'03"W a distance of 742.23 feet to a point; Thence leaving said southerly line, N00°20'57"E a distance of 30.00 feet to a point of the northerly right-of- way line of Pine Avenue and being the POINT OF BEGINNING. Thence follow said northerly line, N89°39'03"W a distance of 15.00 feet to a point; Thence leaving said northerly line, N00°04'24"E a distance of 269.95 feet to a point; Thence N42441'52"E a distance of 24.68 feet to a point; Thence N00°22'01"W a distance of 107.51 feet to a point; Thence N89°51'42"W a distance of 78.33 feet to a point; Thence N44051'11"W a distance, of 2.6.76 feet to a point; Thence N89651'11"W a distance of 272.02 feet to a point; Thence N00022'01"W a distance of 31.51 feet to a point; Thence S89032'49"E a distance of 20.00 feet to a point; Thence S00°22'01"E a distance of 11.41 feet to a point; Thence S89°51'11"E a distance of 260.48 feet to a point; Thence 544°51'11"E a distance of 26.75 feet to a point; Thence 589"51'43"E a distance of 6.94 feet to a point; Thence N00°08'49"E a distance of 32.99 feet to a point; Thence S89°51'11"E a distance of 10.00 feet to a point; Thence 500°08'49"W a distance of 32.99 feet to a point; Thence S89°51'43"E a distance of 287.38 feet to a point; Thence N00°07'56"E a distance of 17.02 feet to a point; Thence 589'52'04"E a distance of 10.00 feet to a point; Thence 500°07'56"W a distance of 17.02 feet to a point; Thence S89°51'43"E a distance of 39.92 feet to a point; Thence 589°52'04"E a distance of 127.42 feet to a point; Thence N00"17'26"E a distance of 157.35 feet to a point; Thence N89"42'34"W a distance of 69.00 feet to a point; Thence N44°32'12"W a distance of 27.16 feet to a point; Thence N00'27'48"E a distance of 126.25 feet to a point; Thence N89°33'11"W a distance of 34.39 feet to a point; ENGINEERS 1 SURVEYORS I PLANNERS Thence N00°26'49"E a distance of 20.00 feet to a point; Thence S89°33'11"E a distance of 54.39 feet to a point; Thence S00°27'48"W a distance of 137.97 feet to a point; Thence S44°32'12"E a distance of 10.55 feet to a point; Thence S89°42'34"E a distance of 80.68 feet to a point; Thence 500617'26"W a distance of 151.26 feet to a point; Thence 589°32'26"E a distance of 252.94 feet to a point on the westerly right-of-way line of Linder Road; Thence following said westerly line, S00007'57"W a distance of 15.00 feet to a point; Thence leaving said westerly line, N89°32'26"W a distance of 252.99 feet to a point; Thence S00°17'26"W a distance of 31.04 feet to a point; Thence NW52'04"W a distance of 65.74 feet to a point; Thence S00°27'48"W a distance of 19.64 feet to a point; Thence N89°32'12"W a distance of 20.00 feet to a point; Thence N00°27'48"E a distance of 19.53 feet to a point; Thence N89°52'04"W a distance of 81.74 feet to a point; Thence N89°51'42"W a distance of 249.08 feet to a point; Thence S00022'01"E a distance of 113.30 feet to a point; Thence 542°41'52"W a distance of 24.75 feet to a point; Thence S00°04'24"W a distance of 264.17 feet to the POINT OF BEGINNING. Said easement contains a total of 35,867 square feet (0.823 acres), more or less, and is subject to all existing easements and/or rights-of-way of record or implied. Attached hereto is EXHIBIT B and by this reference made a part of. PAGE 12 PAt2.016\CAD\%-REF\PHA5E 2\32-016 WATER EASEMENT.DWG, CRAIG DRAPER, 5(2112015, SAVIN C9010 PCL5C (6&W).PC3, — �L wI co 1co1 mmo t ILn O2 z im z n I NI Irn m' Ni 1cr,r m Iw o— z � r r Z n I�I N __ 0 C7 N00'04`2 — 269.— L3 gl I N o N r-- > .00`04'24"W 264.17' ! -L37 � I I Uj 4, 2 (/ 03 i--+ to M z I I -1 O D I� 0 OR C d z (JI o ZZE I I'1i I m° m N I I P N W Z O I A 0 G 0 r r 011, o rn1 irvai L22 uNi L4 Im o1 N NL26 E r Nl Lig IW v ��__--� -D rn m w w , ca L29 Z m fI Z'1 I 1---30.00' m I Im 00 �`I ITT m�mm I NI IN �n Nn J O NI IN 00 nm ? m Iio zm LD ? zom N H N No- LINDER ROAD z � g $ " EXHIBIT B oow � � a r• CITY OF MERIDIAN WATER oN� Q wp.pA m TI O o�W N WATER EASEMENT SE 1/4 OF THE NE 1/4 SEC 11 T3N., R1W., B.M. ADA COUNTY, ID I N a V 3 a i mss; z :7 3 c ENGINEERS. SURVEYORS. PLANNERS 9233 WEST STATE STREET BOISE, IDAHO 83714 PHONF 170815396939 ? FAX i2OH) 639,6930 pRO Te 05/21/2015 TECT; 72016 EET: 2OF2 LINE TABLE LINEN LINE TABLE LINE N LENGTH DIRECTION Lt 15.00 N89'39'03'W 1-2 24.68 N424 1'52"E L3 107.51 NO'22'01'W L4 78.33 N89'51'42"W L5 26.76 N44'5VII"W L6 31.51 NO'22'OI"W L7 20.00 S89'32'491 L8 11.41 SO'22'01"E L9 26.75 S44'51'11"E L10 6.94 S89 -51'43"E L11 32,99 NO -08'49"E L12 10.00 S89'5111111E L13 32.99 SO'08'49'W L14 17.02 NO -07'56"E L15 10.00 S89'52'04"E L16 17.02 SO'07'560W L17 39,92 S89'51'43"E L18 127.42 S89'52'04"E L19 157.35 NO'17'26"E LINE TABLE LINEN I LENGTH I DIRECTION L20 MOO N89'42'34'W L21 27.16 N44'32'12 W L22 126.25 NO'27'48"E L23 34.39 N89'33'11"W L24 20.00 NO'28'49"E L25 54,39 S89'33'11"E L25 137,97 SO -27'48"W L27 10.55 S44'32'12"E L28 80.68 S89'42'34"E L29 151.26 SO'17'26"W L30 15,00 SO'07'57"W L31 31.04 SO -17'26'W L32 65.74 N89'52'04'W L33 19.64 50'27'48'3 L34 20.00 N89'32'12"W L35 19.53 NO -27'48"E L36 81.74 N89'52'04"W L37 113.30 50'22'01"E L38 24.75 S42'41'52"W EXHI BIT B CITY OF MERIDIAN WATER WATER EASEMENT SE 1/4 OF THE NE 1/4 SEC 11 T3N., R1W,, B.M. ADA COUNTY, ID Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 5J PROJECT NUMBER: ITEM TITLE: Meridian Joint School Release of Wafer Easement Instrument # 103007924 for Meridian Joint School District No. 2 MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS ADA COUNTY RECORDER Christopher D. Rich 2015-056382 BOISE IDAHO Pgs=4 BONNIE- 061251201511:59 AM MERIDIAN CITY _ _ NO FEE 001141 1320160 1638 0040 43 CITY OF MERIDIAN RELEASE OF EASEMENT WHEREAS, by easement dated January 7, 2003, and recorded on January 16, 2003 as Instrument Number 103007924 of the records of Ada County, State of Idaho, Joint School District No. 2 granted to the City of Meridian, an Idaho Municipal Corporation, a water main easement for the construction, operation and maintenance of a water line over and across the real property legally described and visually depicted on Exhibits A and 13, attached hereto and incorporated herein. WHEREAS, the continuance of this easement is no longer necessary or desirable because the easement description does not accurately reflect the current location of the easement due to remodeling and reconstruction at the site. A separate easement that correctly identifies the new location of the easement has been recorded and will not be affected by this release. NOW, THEREFORE, in consideration of the premises, the said City of Meridian does hereby release and abandon the said rights and easements hereinabove referred to and described, with the intent that the same shall forthwith cease and be extinguished. IN WITNESS WHEREOF, THE CITY OF MERIDIAN has caused these presents to be executed by its proper officers thereunto duly authorized this 0?3 day of June, 2015. CNYIIY�I�r�1�1:717/_V I Fjjq �r 123F weerq-mayor, — onxo e� ty Holman, City Clerk RE 8 A STATE OF IDAHO ss County of Ada On this 0Z day of June, 2015, before me, a Notary Public, personally appeared Tammy de Weerd and Jaycee L. Holman, know or identified to me to be the Mayor and Clerk, respectively, of the City of Meridian, who executed the instrument of behalf of said City, and acknowledged to me that such City executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal the day and year in this certificate first above written. rya �ro ,a (SEAL) t A JF"� Notary Public for Idaho Residing at: rex vC� to n Commission expires: `\ohYA m a OV;3 �Ib :p YA (4 ffi 192 i DESCRIPTION OF EASEMENT BEING RELEASED AND ABANDONED EXHIBIT A PERMANENT EASEMENT DESCRIPTION FOR THE CITY OF MERIDIAN, IDAHO An easement for waterline purposes located in the SE '/4 of the NE '/4 of Section 11, Township 3 North, Range 1 West, Boise Meridian, Ada County, Idaho, more particularly described as follows: Commencing at an aluminum cap monument marking the southeasterly corner of said SE '/4 of the NE '/a; Thence N 0°09'43" E along the easterly boundary of said SE '/4 of the NE i/4 a distance of 463.34 feet to the POINT OF BEGINNING; Thence continuing N 0°09'43" E a distance of 15.00 feet to a point; Thence leaving said easterly boundary S 89°45'50" W a distance of 395.66 feet to a point; Thence N 0'56'14" E a distance of 284.92 feet to a point; Thence N 89°03'46" W a distance of 15.00 feet to a point; Thence S 0'56'14" W a distance of 285.16 feet to a point; Thence N 89°30'53" W a distance of 365.41 feet to a point; Thence N 0°29'07" E a distance of 11.12 feet to a point; Thence N 89'30'53" W a distance of 10.00 feet to a point; Thence S 0029'07" W a distance of 11.53 feet to a point; Thence S 85°02'20" W a distance of 13.19 feet to a point; Thence N 89°23' 15" W a distance of 312.23 feet to a point; Thence S 0°36'45" W a distance of 15.00 feet to a point; Thence S 89'23'15" E a distance of 312.96 feet to a point; Thence N 85°02'20" E a distance of 17.58 feet to a point; Thence S 89°30'53" E a distance of 39.58 feet to a point; Waterline Easement Page 2 Thence S 0°23'43" E a distance of 141.99 feet to a point; Thence S 41 °36'22" W a distance of 21.38 feet to a point; Thence S 0°23'50" W a distance of 301.56 feet to a point on the southerly boundary of said SE '/4 of the NE ''/4; Thence S 89137'17" E along said southerly boundary a distance of 15.00 feet to a point; Thence leaving said southerly boundary N 0°23'50" E a distance of 295.92 feet to a point; Thence N 41136'22" E a distance of 21.50 feet to a point; Thence N 0023'43" W a distance of 147.51 feet to a point; Thence S 89°30'53" E a distance of 321.38 feet to a point; Thence N 89°45'50" E a distance of 405.13 feet to the POINT OF BEGINNING. This parcel contains 0.64 acres and is subject to any other easements existing or in use. Prepared by: Glenn K. Bennett, PLS Civil Survey Consultants, Incorporated October 29, 2002 4t or OF fk s V��f Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Idaho Power Su Acknowledgement of Terms of Idaho Power Surplus Property Bill of Sale to City of Meridian of Wooden Distribution Pole MEETING NOTES [Y-6 7 Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS P R® Surplus Property Bill of Sale N2 10322 An IDACORP company For valuable consideration in the amount of$ / ,Idaho Power Company,whose address is 1221 West Id o Street,dtpoise,Idaho 83702("IPC")effective ,20X d s hereby d convey to (id' Mai aah' ,whose address is , L. YD- ,1 laic ( fW, ,Z er i yer") and Buyer hereby hccepts title to and ownership of the following: l Quantity Description Price / Wain dish Jbuiya pie lack){,aelz;. 104rctI et o ewio-ez. ..49 Subtotal 49 ❑Cash ❑ Check# ❑Tax Exempt Tax . Total Buyer acknowledges and agrees that: 1) Buyer has been afforded the opportunity by IPC to inspect or have third parties inspect the goods, declined to inspect the Goods or inspected the Goods, concluded their condition is satisfactory and agreed to purchase the Goods. 2) IPC has made no representations or warranties of any kind to Buyer regarding the condition, usability, value,safety or otherwise with respect to the Goods. The Goods are being sold to Buyer "AS IS WHERE IS" and "WITH ALL FAULTS". Buyer agrees that this disclaimer is conspicuous and binding. 3) IPC MAKES NO WARRANTY, EXPRESSED OR IMPLIED, INCLUDING THOSE OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, WITH RESPECT TO THE GOODS IDENTIFIED HEREIN. 4) Buyer waives any claims, demands, right of action against IPC, its officers, directors, employees and parent company arising from or relating to the Goods or this purchase. Buyer shall indemnify, defend and hold harmless IPC and its successors and their respective directors, officers, members, employees, representatives, and agents, from and against any and all allegations, claims, liens, losses, demands, damages, expenses, suits,judgments, and costs of any kind whatsoever, including settlement costs, court costs, and reasonable attorneys' fees and expenses, arising out of, or relating to the Goods after the effective date of transfer to Buyer; 5) Buyer has authority to purchase the Goods and the person signing below on behalf of Buyer is authorized to sign on behalf of Buyer and by signing Buyer is bound to the terms in this Bill of Sale; and 6) IPC verified for Buyer that IPC has good title to the Goods, IPC has authority to sell and transfer the Goods and the Goods are being sold free and clear of all liens, encumbrances, liabilities or adverse claims. AGREED AND ACCEPTED Buyer. IDAHO P WER P• / . if ,e,...ale ____ Signature ii Signat Printed Name afiSignor Printed Name of Signor - 1/ /6 ;c,Jo / O �0V4, L Title of Sigg c / Titlrsof Signor 0 3/1/3 7/7/7Y Date Date IPC Surplus Property Bill of Sale LGL 042(5/26/10) Page 1 of 2 Cat.ID 43132 PR an IDACORP company LI V211 DC Wood Products Some of these wood products or parts of these wood products may have been treated with EPA-registered wood preservatives. Reuse of treated wood is appropriate with certain restrictions. Treated wood should not be used in the interiors of buildings. It should not be used where children are likely to be in frequent contact with the wood unless it is covered by at least two coats of appropriate sealant. It should not be used where domestic animals or livestock may crib (bite) or lick the wood. It should not be used where it is in contact with food, feed, or drinking water (other than incidental contact). Never burn treated wood, as the smoke and/or ash may be toxic. Dispose of treated wood by ordinary trash collection or burial. If you have any questions on your intended use of this material, please contact your local or state solid waste disposal agency. Electronic Equipment Electronic equipment and components may contain hazardous materials. These materials may include, but are not limited to the following items: • lead in solder, batteries, and CRT glass • silver in some batteries and connections • mercury in some batteries and mercury switches Disposal of these components, and electronic waste in general, may be regulated. You should consult your local or state solid waste disposal agency prior to disposing of waste electrical equipment or components. Page 2 of 2 Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Professional Agreement/ DesignWorks Professional Services Agreement with DesignWorks Creative Inc. for Website Management Services for the Meridian Anti -Drug Coalition for a Not -to -Exceed Amount of $4,812.00 Annually for Four Years MEETING NOTES APPROVED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS PROFESSIONAL SERVICES AGREEMENT FOR WEBSITE MANAGEMENT SERVICES FOR MERIDIAN ANTI-DRUG COALITION This PROFESSIONAL SERVICES AGREEMENT FOR WEBSITE MANAGEMENT SERVICES FOR MERIDIAN ANTI-DRUG COALITION is made this � � y of ' f 2015 ("Effective Date"), and entered into by and between the City of Meridian, a mumcipa corporation organized under the laws of the State of Idaho ("City"), and DesignWorks Creative, Inc., a general business corporation organized under the laws of the state of Idaho ("Contractor"). WHEREAS, City, by and through the Meridian Anti -Drug Coalition ("MADC"), has received a Strategic Prevention Framework State Incentive Grant ("SPF/SIG") from the Idaho Office of Drug Policy; WHEREAS, MADC has invested SPF/SIG monies in programs that seek to reduce substance abuse among youth and adults by, among other things, publicizing via website MADC's work to address substance abuse prevention, community drug education and treatment; WHEREAS, Contractor is specially trained, experienced, and competent to provide, and has agreed to provide, website management services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: I. TERMS AND CONDITIONS A. Scope of Services. 1. Contractor shall perform and furnish to City, on behalf of MADC, services and deliverables services described in Exhibit A hereto. 2. Contractor shall provide services and work under this Agreement consistent with the SPF/SIG requirements and any other applicable standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. Contractor represents and warrants that Contractor will perform all work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. B. Consideration. 1. In the first grant year, City shall pay Contractor for services rendered in the form of a lump sum payment not to exceed four thousand eight hundred and twelve dollars ($4,812.00). 2. In subsequent grant years, City shall pay Contractor for services rendered in the form of a firm fixed amount, divided into monthly payments, through the completion and delivery of evaluation of services throughout the grant year. The amount paid by City to Contractor under this Agreement shall not exceed four thousand eight hundred and twelve dollars ($4,812.00) per year. PROFESSIONAL SERVICES AGREEMENT -WEBSITE MANAGEMENT SERVICES PAGE r Of 6 3. To receive payment, Contractor shall provide a written, itemized invoice to the Meridian Police Department certifying Contractor's completion of the specified work. Following verification of such delivery and conformance by the Meridian Police Department, City shall pay Contractor within thirty (30) days of receipt of such invoice. Contractor shall submit the final invoice to City no later than thirty (30) days after the expiration or termination of this Agreement. 4. Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement, including, but not limited to, meals, lodging, or transportation. Further, without limitation, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. C. Time of performance. 1. This Agreement shall become effective as of the Effective Date upon execution by both parties, and shall expire on July 31, 2018, unless earlier terminated or mutually extended by separate written agreement. 2. The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. D. Independent contractor. In all matters pertaining to this Agreement, Contractor shall be acting as an independent contractor, and neither Contractor nor any officer, employee or agent of Contractor shall be deemed an employee or agent of City in any manner or for any purpose. Specifically, without limitation, Contractor understands, acknowledges, and agrees: 1. Contractor is free from actual and potential control by City in the provision of services under this Agreement. 2. Contractor is engaged in an independently established trade, occupation, profession, or business. 3. Contractor has the authority to hire subordinates. 4. Contractor owns and/or will provide all major items of equipment necessary to perform services under this Agreement. 5. Neither Contractor nor City shall be liable to the other for a peremptory termination of the business relationship described under this Agreement. E. Indemnification and insurance. Contractor shall indemnify and save and hold harmless City from and for any and all losses, claims, actions, judgments for damages, and/or injury to persons or property and losses and expenses and other costs including litigation costs and attorneys' fees, arising out of, resulting from, or in connection with the performance of this Agreement by Contractor and/or Contractor's officers, employs, agents, representatives and/or subcontractors and resulting in and/or attributable to personal PROFESSIONAL SERVICES AGREEMENT- WEBSITE MANAGEMENT SERVICES PAGE 2 of 6 injury, death, and/or damage and/or destruction to tangible or intangible property and not caused by or arising out of the tortious conduct of City or its employees. 2. Contractor shall not be required by this Agreement to obtain worker's compensation insurance because Contractor is acting as a sole practitioner; however, should Contractor, in the course of work related to this Agreement, employ any person, Contractor shall notify City and shall obtain Worker's Compensation Insurance in the statutory limits as required by law. C. Notices. Any and all notices, invoices, and/or reports required to be provided by either of the parties hereto, unless otherwise stated in this Agreement, shall be in writing and be deemed communicated when mailed by United States Mail, addressed as follows: Lt. Scott Colaianni DesignWorks Creative, Inc. Meridian Police Department 138 S. 5th Street 1401 E. Watertower Street Boise, Idaho 83702 Meridian, Idaho 83642 Either party may change its address for the purpose of this section by giving written notice of such change to the other in the manner herein provided. D. Attorney fees. Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. E. Assignment. It is expressly agreed and understood by the parties hereto, that Contractor shall not have the right to assign, transfer, hypothecate, sell, or subcontract any of Contractor's rights or obligations under this Agreement except upon the prior express written consent of City. F. Discrimination prohibited. In performing the services required hereunder, Contractor shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. G. Reports and information. At such times and in such forms as City may require, there shall be furnished to City such statements, records, reports, data and information as City may request pertaining to matters covered by this Agreement. H. Audits and inspections. At any time during normal business hours and as often as City may deem necessary, there shall be made available to City for examination all of Contractor's records with respect to all matters covered by this Agreement. Contractor shall permit City to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, PROFESSIONAL SERVICES AGREEMENT- WEBSITE MANAGEMENT SERVICES PAGE 3 Of 6 conditions of employment and other data relating to all matters covered by this Agreement. I. Publication, reproduction and use of material. No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. City shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. I Compliance with laws. In performing the scope of services required hereunder, Contractor shall comply with all applicable laws, ordinances, and codes of federal, state, and local governments. K. Termination: 1. Grounds for termination of this Agreement shall include, but shall not be limited to: a. Any act or omission by Contractor and/or Contractor's officers, employees, or agents, by which Contractor fails to fulfill in a timely and proper manner Contractor's obligations under this Agreement, violates any of the covenants, agreements, and/or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract. b. A determination by the Meridian City Council that termination of this Agreement is in the best interest of City. c. An act or omission by either party which breaches any term of this Agreement. d. An act of nature, loss of grant funding, or other unforeseeable event which precludes or makes impossible the performance of the terms of this Agreement by either party. e. A change in circumstances that renders the performance by either party a detriment to the public health, safety, or welfare. 2. Either party may terminate this Agreement by providing written notice of intention to terminate. Such written notice shall include a description of the breach or circumstances providing grounds for termination. A seven (7) day cure period shall commence upon mailing of the notice of intention to terminate. If, upon the expiration of such cure period, cure of the breach or circumstances providing grounds for termination has not occurred, this Agreement may be terminated upon mailing of written notice of termination. 3. In the event of any termination of this Agreement for any reason and/or by either party, all finished or unfinished documents, data, and reports prepared by Contractor under this Agreement shall become City's property, and Contractor shall be entitled to receive just and equitable compensation for any work satisfactorily completed hereunder, not to exceed the maximum amount set forth herein. 4. Notwithstanding the above or any other provision of this Agreement, Contractor shall not be relieved of liability to City for damages sustained by City by virtue of any breach of this Agreement by Contractor, and City may withhold any payments to Contractor for the purposes of set-off until such time as the exact amount of damages PROFESSIONAL SERVICES AGREEMENT- WEBSITE MANAGEMENT SERVICES PAGE 4 of 6 due City from Contractor is determined. This provision shall survive the termination of this agreement and shall not relieve Contractor of liability to City for damages. L. Construction and severability. If any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. M. Advice of attorney. Each party warrants and represents that in executing this Agreement, it has received independent legal advice from its respective attorney and/or has received the opportunity to seek such advice. N. Non -waiver. Failure of either party to promptly enforce the strict performance of any term of this Agreement shall not constitute a waiver or relinquishment of any party's right to thereafter enforce such term, and any right or remedy hereunder may be asserted at any time after the governing body of either party becomes entitled to the benefit thereof, notwithstanding delay in enforcement. O. Entire agreement. This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. P. Applicable law. This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho. Q. Non -Appropriation. Contractor acknowledges that City is a governmental entity, and the validity of this Agreement is based upon the availability of public funding under the authority of its statutory mandate. In the event of termination for non -appropriation of funds, Contractor shall be paid fees and expenses earned up to the date of such termination. R. Approval required. This Agreement shall not become effective or binding until approved by the governing body of City. CONTRA¢ BY: lly Mitc ell CIT AF-ME32ID c.��tdi"TEDAU��rT t s oma, n � Cityof Tammy d� Wird, Mayor onxo iaycee Aman, City Clerk CL// SE y, IhI I ).E AS�A�yny PROFESSIONAL SERVICES AGREHMENT— WEBSITE MANAGEMENT SERVICES PAGE 5 Of 6 EXHIBIT A SCOPE OF SERVICES PROFESSIONAL SERVICES AGREEMENT— WEBSITE MANAGEMENT SERVICES PAGE 6 of 6 B 138 S 5th St, Boise, ID 83702 �� �� Phone 208-344-0024 krmoey,rore wnsono.srynwora,, k[. www.DesignWorksCreative.com April 23, 2015 Kendall Nagy <knagy@meridiancity.org> Lieutenant Scott Colaianni <scolaianni@meridiancity.org> MADC C57ttdTUC v2o Project: Web site Hosting: Wordpress Business Web Hosting ($9.99/month currently on sale 50%off - 1 year prepay min.) $120.00 GoDaddy Business Managed Wordpress Web Hosting. We can setup and bill you, or we could tie this to your credit card and you would be responsible for renewing and paying. Project: Web site design and development: $3,000.00 Hosting setup, existing (http://meridianmadc.org) Domain to be pointed (or transferred) to new Hosting DNS/ Design/Production/Posting/Testing of new Wordpress based site. Number of pages or sections similar to existing site with refinements. Project: Web site Maintenance: Month-to-month option: Time spent/time billed $75/hr Per above stated estimate approval we will: • Begin work upon receipt of 1/3 down retainer ($1,000,00) for website design and development, with the remaining balance ($2,000.00) due at completion of final website posting. • Provide instructions for setting up Wordpress Hosting on MADC end for billing/payment to be controlled by MADC, or set up the hosting and bill MADC for 1 year prepayment and bill renewing fees each year or longer (depending upon hosting prepayment term chosen). Note: the longer the term paid for the better per month price cost. Also, costs for hosting are constantly changing and going on and off sale price. The above estimate was based on cost when initial estimate was provided at the beginning of April. I think it may have gone down in cost since then. • After initial site is posted, refined and approved, any further updates to the site will be billed at $75/hr. Depending upon amount of time spent on updates, we can bill monthly or every other month. Please let me know if you have any questions or need anything else. Kelly Mitchell 208-344-0024 1 kelly@designworkscreative.com Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 5M PROJECT NUMBER: ITEM TITLE: Professional Agreement/ Monte Stiles Professional Services Agreement with Monte Stiles for Policy and Advocacy Consultant Services for the Meridian Anti -Drug Coalition for the Not -to -Exceed Amount of $15,000.00 Annually for Four Years MEETING NOTES APPROIED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS PROFESSIONAL SERVICES AGREEMENT FOR POLICY AND ADVOCACY CONSULTANT SERVICES FOR MERIDIAN ANTI-DRUG COALITION This PROFESSIONAL SERVICES AGREEMENT FOR POLICY AND ADVOCACY CONSULTANT SERVICES FOR MERIDIAN ANTI-DRUG COALITION is made this` -t 03 day of 2015 ("Effective Date"), and entered into by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho ("City"), and Monte Stiles, LLC, a limited liability company organized under the laws of the state of Idaho ("Contractor"). WHEREAS, City, by and through the Meridian Anti -Drug Coalition ("MADC"), has received a Strategic Prevention Framework State Incentive Grant ("SPF/SIG") from the Idaho Office of Drug Policy; WHEREAS, MADC has invested SPF/SIG monies in programs that seek to reduce substance abuse among youth and adults by, among other things, advocating for local and state policy and legislative changes to address substance abuse prevention, community drug education and treatment; WHEREAS, Contractor is specially trained, experienced, and competent to provide, and has agreed to provide, services related to developing advocacy strategies and leading MADC in strategic thinking to empower MADC to effect such change; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: I. TERMS AND CONDITIONS A. Scope of Services. 1. Contractor shall perform and furnish to City, on behalf of MADC, at least ten (10) hours of work monthly, or as requested by MADC, to include the following services: a. Serve as a speaker, trainer, facilitator, and/or panel member for community drug education events, including training at monthly coalition meetings. b. Research and track local and national developments, policies, and legislation that impact or may impact substance abuse prevention, education, and treatment. c. Identify relevant voter initiatives and legislative proposals, and effectively describe to MADC the concerns of drug prevention to which they relate. d. Provide technical assistance and training to assist MADC membership, community partners and others in organizing advocacy efforts related to substance abuse prevention and treatment. e. Communicate relevant information to MADC membership, through email messages, memos, and trainings. I. Provide expertise and experience regarding effective community drug education programs. g. Provide information for the MADC website, and social media, to include relevant PROFESSIONAL SERVICES AGREEMENT—POLICY/ADVOCACY CONSULTATION PAGE I of 6 facts and resources relating to substance abuse prevention, education and treatment. h. Provide information to MADC membership and the general public regarding drug trends. i. Prepare and/or identify documents that can be used by coalition members to educate the community. j. Represent MADC at local, state and national conferences. 2. Contractor shall provide services and work under this Agreement consistent with the SPF/SIG requirements and any other applicable standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. Contractor represents and warrants that he will perform all work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. B. Consideration. 1. City shall pay Contractor for services rendered in the amount of one hundred and twenty-five dollars per hour ($125/hour), and for travel expenses up to five thousand dollars ($5,000) annually. Payment to Contractor under this Agreement shall not exceed fifteen thousand dollars ($15,000) annually. 2. To receive payment for services rendered, Contractor shall provide a written, itemized invoice to the Meridian Police Department certifying Contractor's completion of the specified work. Following verification of such delivery and conformance by the Meridian Police Department, City shall pay Contractor within thirty (30) days of receipt of such invoice. Contractor shall submit the final invoice to City no later than thirty (30) days after the expiration or termination of this Agreement. 3. City shall reimburse Contractor for travel expenses where such travel is related to services rendered under this Agreement, including, but not limited to, costs related to Contractor's event registration fees, air or ground travel, baggage check or carry -on fees, tips, ground transportation, rental car, lodging, and meals. City shall not pay for travel upgrades, phone calls, internet usage, entertainment, alcoholic beverages, laundry services, valet, banking or ATM fees, or expenses paid on behalf of others, including family members. All travel must be pre -approved by City and must be undertaken via the most economical means practical. Following approved travel, Contractor shall submit an invoice, with an itemized travel expense report and receipts, to the Meridian Police Department within fourteen (14) days of travel. Following verification of such delivery and conformance by the Meridian Police Department, City shall pay Contractor within thirty (30) days of receipt of such invoice. Contractor shall submit the final invoice to City no later than thirty (30) days after the expiration or termination of this Agreement. PROFESSIONAL SERVICES AGREEMENT—POLICY/ADVOCACY CONSULTATION PAGE 2 of 6 4. Contractor shall not be entitled to receive from City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement. Further, without limitation, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. C. Time of performance. 1. This Agreement shall become effective as of the Effective Date upon execution by both parties, and shall expire on July 31, 2018, unless earlier terminated or mutually extended by separate written agreement. 2. The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. D. Independent contractor. In all matters pertaining to this Agreement, Contractor shall be acting as an independent contractor, and neither Contractor nor any officer, employee or agent of Contractor shall be deemed an employee or agent of City in any manner or for any purpose. Specifically, without limitation, Contractor understands, acknowledges, and agrees: 1. Contractor is free from actual and potential control by City in the provision of services under this Agreement. 2. Contractor is engaged in an independently established trade, occupation, profession, or business. 3. Contractor has the authority to hire subordinates. 4. Contractor owns and/or will provide all major items of equipment necessary to perform services under this Agreement. 5. Neither Contractor nor City shall be liable to the other for a peremptory termination of the business relationship described under this Agreement. E. Indemnification and insurance. 1. Contractor shall indemnify and save and hold harmless City from and for any and all losses, claims, actions, judgments for damages, and/or injury to persons or property and losses and expenses and other costs including litigation costs and attorneys' fees, arising out of, resulting from, or in connection with the performance of this Agreement by Contractor and/or Contractor's officers, employs, agents, representatives and/or subcontractors and resulting in and/or attributable to personal injury, death, and/or damage and/or destruction to tangible or intangible property and not caused by or arising out of the tortious conduct of City or its employees. 2. Contractor shall not be required by this Agreement to obtain worker's compensation insurance because Contractor is acting as a sole practitioner; however, should Contractor, in the course of work related to this Agreement, employ any person, Contractor shall notify City and shall obtain Worker's Compensation Insurance in the statutory limits as required by law. PROFESSIONAL SERVICES AGREEMENT— POLICY/ADVOCACY CONSULTATION PAGE 3 of 6 C. Notices. Any and all notices, invoices, and/or reports required to be provided by either of the parties hereto, unless otherwise stated in this Agreement, shall be in writing and be deemed communicated when mailed by United States Mail, addressed as follows: Lt. Scott Colaianni Monte Stiles, LLC Meridian Police Department 3671 Daisy Way 1401 E. Watertower Street Boise, Idaho 83709 Meridian, Idaho 83642 Either party may change its address for the purpose of this section by giving written notice of such change to the other in the manner herein provided. D. Attorney fees. Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. E. Assignment. It is expressly agreed and understood by the parties hereto, that Contractor shall not have the right to assign, transfer, hypothecate, sell, or subcontract any of Contractor's rights or obligations under this Agreement except upon the prior express written consent of City. F. Discrimination prohibited. In performing the services required hereunder, Contractor shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. G. Reports and information. At such times and in such forms as City may require, there shall be furnished to City such statements, records, reports, data and information as City may request pertaining to matters covered by this Agreement. H. Audits and inspections. At any time during normal business hours and as often as City may deem necessary, there shall be made available to City for examination all of Contractor's records with respect to all matters covered by this Agreement. Contractor shall permit City to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. I. Publication, reproduction and use of material. No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. City shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. PROFESSIONAL SERVICES AGREEMENT—POLICY/ADVOCACY CONSULTATION PAGE 4 of 6 J. Compliance with laws. In performing the scope of services required hereunder, Contractor shall comply with all applicable laws, ordinances, and codes of federal, state, and local governments. K. Termination: 1. Grounds for termination of this Agreement shall include, but shall not be limited to: a. Any act or omission by Contractor and/or Contractor's officers, employees, or agents, by which Contractor fails to fulfill in a timely and proper manner Contractor's obligations under this Agreement, violates any of the covenants, agreements, and/or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract. b. A determination by the Meridian City Council that termination of this Agreement is in the best interest of City. c. An act or omission by either party which breaches any term of this Agreement. d. An act of nature, loss of grant funding, or other unforeseeable event which precludes or makes impossible the performance of the terns of this Agreement by either party. e. A change in circumstances that renders the performance by either party a detriment to the public health, safety, or welfare. 2. Either party may terminate this Agreement by providing written notice of intention to terminate. Such written notice shall include a description of the breach or circumstances providing grounds for termination. A seven (7) day cure period shall commence upon mailing of the notice of intention to terminate. If, upon the expiration of such cure period, cure of the breach or circumstances providing grounds for termination has not occurred, this Agreement may be terminated upon mailing of written notice of termination. 3. In the event of any termination of this Agreement for any reason and/or by either party, all finished or unfinished documents, data, and reports prepared by Contractor under this Agreement shall become City's property, and Contractor shall be entitled to receive just and equitable compensation for any work satisfactorily completed hereunder, not to exceed the maximum amount set forth herein. 4. Notwithstanding the above or any other provision of this Agreement, Contractor shall not be relieved of liability to City for damages sustained by City by virtue of any breach of this Agreement by Contractor, and City may withhold any payments to Contractor for the purposes of set-off until such time as the exact amount of damages due City from Contractor is determined. This provision shall survive the termination of this agreement and shall not relieve Contractor of liability to City for damages. L. Construction and severability. If any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. PROFESSIONAL SERVICES AGREEMENT- POLICY/ADVOCACY CONS UCfKnON PAGE 5 of 6 M. Advice of attorney. Each party warrants and represents that in executing this Agreement, it has received independent legal advice from its respective attorney and/or has received the opportunity to seek such advice. N. Non -waiver. Failure of either party to promptly enforce the strict performance of any term of this Agreement shall not constitute a waiver or relinquishment of any party's right to thereafter enforce such term, and any right or remedy hereunder may be asserted at any time after the governing body of either party becomes entitled to the benefit thereof, notwithstanding delay in enforcement. O. Entire agreement. This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. P. Non -Appropriation. Contractor acknowledges that City is a governmental entity, and the validity of this Agreement is based upon the availability of public funding under the authority of its statutory mandate. In the event of termination for non -appropriation of funds, Contractor shall be paid fees and expenses earned up to the date of such termination. Q. Applicable law. This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho. R. Approval required. This Agreement shall not become effective or binding until approved by the governing body of City. CONTRACTOR: BY: onte Stiles CITY OF MERIDIAN: Tanuny�Ke Weerd, Mayor K" � AHO Atte 5; SERI, ����� i0.4 Abu4 Jaycee Holman, City PROFESSIONAL SERVICES AGREEMENT — POLICY/ADVOCACY CONSULTATION PAGE 6 of 6 Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Items moved from consent agenda MEETING NOTES I" Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: FP 15-022 ITEM TITLE: Caven Ridge Subdivision FP 15-022 Coven Ridge Subdivision No. 1 by New Cavanaugh, LLC Located East Side of S. Meridian Road and South of the Ridenbaugh Canal Request: Final Plat Approval Consisting of Thirty -Seven (37) Building Lots and Nine (9) Common Area Lots on 14.06 Acres of Land in the R-8 Zoning District MEETING NOTES * ? ?/� Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: FP 15-021 ITEM TITLE: Fall Creek Subdivision FP 15-021 Fall Creek Subdivision No. 2 by Coleman Homes, LLC Located South of W. Overland Road and East of S. Linder Road Request: Final Plat Approval Consisting of Thirty -Nine (39) Building Lots and Four (4) Common Lots on 12.51 Acres of Land in the R-8 Zoning District MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: ITEM TITLE: PROJECT NUMBER: PP 15-008 Subdivision Public Hearing: PP 15-008 Normandy Subdivision by Schultz Development Located at 4145 S. Locust Grove Road Request: Preliminary Plat Approval Consisting of 1 10 Building Lots and 9 Common Lots on 26.93 Acres of Land in an R-8 Zoning District MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS DATE CITY OF MERIDIAN CITY COUNCIL PUBLIC HEARING SIGN-UP SHEET June 23, 2015 ITEM # 7C Project Number: PP 15-008 Project Name: Normandy PLEASE PRINT NAME m FOR I AGAINST I NEUTRALI Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: AZ 15-003 ITEM TITLE: Shelburne Subdivision Public Hearing: AZ 15-003 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request: Annexation and Zoning of 30.21 Acres of Land with an R-4 Zoning District MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 7E PROJECT NUMBER: PP 15-005 ITEM TITLE: Shelburne Subdivision Public Hearing: PP 15-005 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request: Preliminary Plat Approval Consisting of Seventy -Eight (78) Building Lots and Fifteen (15) Common Lots on 30.2 Acres of Land MEETING NOTES APPROVED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 7F PROJECT NUMBER: VAC 15-006 ITEM TITLE: Shelburne Subdivision Public Hearing: VAC 15-006 Shelburne Subdivision by Shelburne Properties, LLC Located 3405, 3497 and 3801 E. Zaldia Lane Request MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS CITY OF MERIDIAN CITY COUNCIL PUBLIC HEARING SIGN-UP SHEET DATE June 23, 2015 ITEM # 7D/E/F Project Number: AZ 15-003 / PP 15-005 / VAC 15-006 Project Name: Shelburne PLEASE PRINT NAME FOR AGAINST NEUTRAL ` JUN `! 3 200 CITY OFC` FIIQL CITY CLERKS OFFICE Ci t y C o u n c i l M e e t i n g Ju n e 2 3 , 2 0 1 5 h2 Sl i d e 1 h2 Ag e n d a I t e m N u m b e r s / O r d e r : ho o d c , 1 2 / 1 9 / 2 0 0 6 It e m # 7 B : F a l l C r e e k S u b d i v i s i o n N o . 2 Vi c i n i t y M a p Ap p r o v e d P r e l i m i n a r y P l a t Pr o p o s e d F i n a l P l a t La n d s c a p e P l a n It e m # 7 C : N o r m a n d y – V i c i n i t y M a p No r m a n d y S u b d i v i s i o n – P r e l i m i n a r y P l a t & P h a s i n g P l a n RE V I S E D P l a t No r m a n d y S u b d i v i s i o n – L a n d s c a p e P l a n Co n c e p t u a l B u i l d i n g E l e v a t i o n s Br y a n & J u d y W h i t e Re q u e s t s i n g l e - s t o r y h o m e s ac r o s s t h e c a n a l a d j a c e n t to t h e i r p r o p e r t y It e m # 7 D , E , F : S h e l b u r n e S u b d i v i s i o n Zo n i n g & A e r i a l M a p s Ex i s t i n g C o n d i t i o n s Shelburne Subdivision Preliminary Plat & Phasing Plan Sh e l b u r n e S u b d i v i s i o n – L a n d s c a p e P l a n Ph o t o s o f E x i s t i n g H o m e on P r o p o s e d L o t 3 , B l o c k 4 Sh o w i n g E x i s t i n g G r a d e Co n c e p t B u i l d i n g El e v a t i o n s Ea s e m e n t s P r o p o s e d t o b e V a c a t e d Pi x l e y Re s i d e n c e Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: $A PROJECT NUMBER: ITEM TITLE: Department Reports/Legal and Fire Dept. Continued from June 16, 2015: Legal and Fire Departments: Memorandum of Understanding and Agreement between the City of Meridian and the Meridian Rural Fire Protection District MEETING NOTES L -7 /A POM Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Legal Department Reports Legal Department Report: Updates to Meridian City Code to comply with updates to Idaho Code and to reclassify penalties MEETING NOTES '-�?, I I IaAr Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Updates Meridian City Code Ordinance No. : Updates to Meridian City Code to comply with 2015 updates to Idaho Code and to reclassify violation penalties MEETING NOTES ATROVED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS CITY OF MERIDIAN ORDINANCE NO. /( - i(.0 q1 BY THE CITY COUNCIL: BIRD, BORTON, CAVENER, MILAM, ROUNTREE, ZAREMBA AN ORDINANCE OF THE CITY OF MERIDIAN IN ADA COUNTY, IDAHO, AMENDING OR REPEALING THE FOLLOWING PROVISIONS OF MERIDIAN CITY CODE: SECTION 1-7-5(C), REGARDING CITY COUNCIL MEETINGS; SECTION 1-14-7, REGARDING STATUTORY STANDARDS; SECTION 6-4-1(D), REGARDING JUVENILE CURFEW; SECTION 6-4-2, REGARDING MINORS IN POSSESSION OF CIGARETTES OR TOBACCO; SECTION 5-4-12(A), REGARDING PENALTIES FOR FIREWORKS CODE VIOLATIONS; SECTION 6-2-8(A), REGARDING BARKING DOGS; SECTION 6-2-8(B), REGARDING CRUELTY TO ANIMALS; SECTION 6-2-8(D), REGARDING DOG AT LARGE IN PUBLIC PLACE; SECTION 6-3-1, REGARDING ADOPTION OF TITLE 18, IDAHO CODE; SECTION 6-3-4, REGARDING MALICIOUS INJURY TO PROPERTY; SECTION 6-3-5, REGARDING TRESPASSING; SECTION 6-3-9(A), REGARDING PUBLIC URINATION; SECTION 6-3-11, REGARDING UNLAWFUL SALE AND POSSESSION OF ILLEGAL SMOKING PRODUCTS; SECTION 6-4-3, REGARDING MINOR IN POSSESSION OF ALCOHOLIC BEVERAGE; SECTION 6-4-4, REGARDING MINORS IN POOL HALLS; SECTION 6-4-5, REGARDING ENCOURAGING DELINQUENCY; SECTION 6-4-6, REGARDING RUNAWAYS AND DELINQUENTS; SECTION 7-1-1, REGARDING ADOPTION OF STATE VEHICLE LAWS; SECTION 7-1-6(C), REGARDING SPEED RESTRICTIONS IN SCHOOL ZONES; ADOPTING A SAVINGS CLAUSE; AND PROVIDING AN EFFECTIVE DATE. WHEREAS, in its 2015 session, the Idaho Legislature passed the Idaho Transparent and Ethical Government Act, codified at Title 74, Idaho Code, which renumbers the Idaho Public Records Act, Open Meetings laws, and Ethics in Government Act, thereby necessitating an update to references thereto in Meridian City Code; WHEREAS, in its 2015 session, the Idaho Legislature passed updates to Idaho Code sections 20-549 (regarding curfew violations), 39-2609 (regarding fireworks sales and use violations), and 39- 5703 (regarding possession and distribution of tobacco by minors), which reclassify violations of these provisions from misdemeanors to infractions; WHEREAS, the Public Defense subcommittee of the Idaho Criminal Justice Commission has recommended that certain provisions of Idaho municipalities' city codes currently designated as misdemeanors be reclassified as infractions, in an effort to address public defender workload and jail overcrowding; WHEREAS, the City Attorney's Office has recommended that additional enumerated penalties under Meridian City Code that are currently classified as misdemeanors be reclassified as infractions, and that some regulations that are now redundant with provisions of Idaho Code be repealed; WHEREAS, the City Council of the City of Meridian finds that it is in the best interest of the health, safety, and welfare of the people of Meridian to update the following provisions of Meridian City Code to be consistent with these recommendations and changes in Idaho Code; NOW, THEREFORE, BE IT ORDAINED BY THE MAYOR AND CITY COUNCIL OF THE CITY OF MERIDIAN, ADA COUNTY, IDAHO: 2015 LEGISLATION CITY CODE UPDATES PAGE I OP 5 Section 1. That Meridian City Code section 1-7-5(C), regarding City Council meetings, shall be amended as follows: C. Open Meetings: Meetings of the city council shall be open to the public pursuant to Title 74 Chapter 2, Idaho Code section 67 '� " X41 et-sN, Section 2. That Meridian City Code section 1-14-7, regarding statutory standards, shall be amended as follows: 1-14-7: STATUTORY STANDARDS: There are eei4aia provisions in the eriminal statutes of the state which shoHid, While not set forth h0fei but ineeTperated herein, be eansidefed an integral part of this chaptef. Aeeorclingly, the proN4sieas e the follo..A,,, sections of trah Code-, The Idaho Transparent and Ethical Government Act, as may be amended, are is hereby incorporated herein by this reference and made a part of this chapter and shall apply to the mayor, all council members, board members, committee members, commission members, or employees of the city, whenever applicable.-. Section 3. That Meridian City Code section 6-4-1(D), regarding juvenile curfew, shall be amended as follows: D. Penalty For Parent Or Guardian: Any parent, guardian, or other adult person having the care and custody of any person under the age of eighteen (18) years who shall violate the provisions of this section, upon conviction thereof, shall be subject to penalty as provided in Idaho Code section 20 - Section 4. That Meridian City Code section 6-4-2, regarding minors in possession of cigarettes or tobacco, shall be repealed. 2015 LEGISLATION CITY CODE, UPDATES PAGE 2 of 5 Section 5. That Meridian City Code section 5-4-12(A), regarding penalties for fireworks code violations, shall amended as follows: A. It shall be unlawful for any person, firm or corporation to violate any of the provisions of this chapter. Any violation thereof shall constitute an infraction and shall be punishable by a fine of one hundred dollars ($100)^ ^a� ' ^' ' ^''�' •• ^ aI Section 6. That Meridian City Code section 6-2-8(A), regarding barking dogs, shall be amended as follows: A. Barking Dog: It shall be unlawful for any dog owner to permit a dog owned by such person to carry on excessive, continuous or untimely barking or noise. A violation of this subsection shall constitute an infraction punishable by a fine of one hundred dollars ($100 00) of ______ ______d_d d___a_., ($300.00) and ninety (9 0) .. Jam.. Section 7. That Meridian City Code section 6-2-8(B), regarding cruelty to animals, shall be repealed. Section 8. That Meridian City Code section 6-2-8(D), regarding dog at large in public place, shall be amended as follows: D. Dog At Large In Public Place: Except as otherwise allowed by law, it shall be unlawful for any dog owner to allow or cause any dog owned by such person to be or remain in any public place, unless such dog is controlled by a leash not exceeding six feet (6) in length. A person's first violation of this subsection shall constitute an infraction punishable by a fine of twenty five dollars ($25.00). A person's second violation of this subsection shall constitute an infraction punishable by a fine of fifty dollars ($50.00). A person's third violation of this subsection shall constitute an infraction punishable by a fine of one hundred dollars ($100.00) ($300.00) and nines• i00'rn� . The animal control officer may seize and impound any dog found in violation of this subsection. Section 9. That Meridian City Code section 6-3-1, regarding adoption of Title 18, Idaho Code, shall be repealed. Section 10. That Meridian City Code section 6-3-4, regarding malicious injury to property, shall be repealed. Section 11. That Meridian City Code section 6-3-5, regarding trespassing, shall be repealed. Section 12. That Meridian City Code section 6-3-9(A), regarding public urination, shall be amended as follows: A. To promote and protect the public health of the inhabitants of the city of Meridian it shall be an infraction punishable by a fine of one hundred dollars$10( 0 00)sde eano,- for any person to excrete human waste upon the ground within the corporate city limits. Section 13. That Meridian City Code section 6-3-11, regarding unlawful sale and possession of illegal smoking products, shall be repealed. 2015 LEGISLATION CITY CODE UPDATES PAGE 3 OF 5 Section 14. That Meridian City Code section 6-4-3, regarding minor in possession of alcoholic beverage, shall be repealed. Section 15. That Meridian City Code section 6-4-4, regarding minors in pool halls, shall be repealed. Section 16. That Meridian City Code section 6-4-5, regarding encouraging delinquency, shall be repealed. Section 17. That Meridian City Code section 6-4-6, regarding runaways and delinquents, shall be repealed. Section 18. That Meridian City Code section 7-1-1, regarding adoption of state vehicle laws, shall be repealed. Section 19. That Meridian City Code section 7-1-6(C), regarding speed restrictions in school zones, shall be repealed. Section 20. All City of Meridian ordinances, or resolutions, or parts thereof, which are in conflict herewith, are hereby repealed. Section 21. That this ordinance shall be effective immediately upon its passage and publication. , c� PASSED by the City Council of the City of Meridian, Idaho, this j" day of June, 2015. APPROVED by the Mayor of the City of Meridian, Idaho, this day of June, 2015. APPROVED: 4200 On TED.,Lw3T 9 ATTEST: o, 0 /9 cityw Tammy d, Mayor SEAL A Z'4' IDEASUP�' City Cleric 2015 LEGISLATION CITY CODE UPDATES PAGE 4 OF 5 NOTICE AND PUBLISHED SUMMARY OF ORDINANCE PURSUANT TO I.C. § 50-901(A) CITY OF MERIDIAN ORDINANCE NO. 15- &117 AN ORDINANCE OF THE CITY OF MERIDIAN IN ADA COUNTY, IDAHO, AMENDING OR REPEALING THE FOLLOWING PROVISIONS OF MERIDIAN CITY CODE: SECTION 1-7-5(C), REGARDING CITY COUNCIL MEETINGS; SECTION 1-14-7, REGARDING STATUTORY STANDARDS; SECTION 6-4-1(D), REGARDING JUVENILE CURFEW; SECTION 6-4-2, REGARDING MINORS IN POSSESSION OF CIGARETTES OR TOBACCO; SECTION 5-4-12(A), REGARDING PENALTIES FOR FIREWORKS CODE VIOLATIONS; SECTION 6-2-8(A), REGARDING BARKING DOGS; SECTION 6-2-8(B), REGARDING CRUELTY TO ANIMALS; SECTION 6-2-8(D), REGARDING DOG AT LARGE IN PUBLIC PLACE; SECTION 6-3-1, REGARDING ADOPTION OF TITLE 18, IDAHO CODE; SECTION 6-3-4, REGARDING MALICIOUS INJURY TO PROPERTY; SECTION 6-3-5, REGARDING TRESPASSING; SECTION 6-3-9(A), REGARDING PUBLIC URINATION; SECTION 6-3-11, REGARDING UNLAWFUL SALE AND POSSESSION OF ILLEGAL SMOKING PRODUCTS; SECTION 6-4-3, REGARDING MINOR IN POSSESSION OF ALCOHOLIC BEVERAGE; SECTION 6-4-4, REGARDING MINORS IN POOL HALLS; SECTION 6-4-5, REGARDING ENCOURAGING DELINQUENCY; SECTION 6-4-6, REGARDING RUNAWAYS AND DELINQUENTS; SECTION 7-1-1, REGARDING ADOPTION OF STATE VEHICLE LAWS; SECTION 7-1-6(C), REGARDING SPEED RESTRICTIONS IN SCHOOL ZADOPTING A SAVINGS CLAUSE; AND PROVIDING AN EFFECTIVE DA �eJn Te°'O o 64H0 Mayor and City Council m � By: Jaycee Holman, City Clerk e SFAl. P �Ide'lBEd5�0.� First Reading: -a3-6-- Adopted after first reading by suspension of the Rule as allowed pursuant to Idaho Code § 50-902: YES I% NO Second Reading: -- Third Reading: -- STATEMENT OF MERIDIAN CITY ATTORNEY AS TO ADEQUACY OF SUMMARY OF ORDINANCE NO. 15- /&1/7 The undersigned, William L.M. Nary, City Attorney of the City of Meridian, Idaho, hereby certifies that he is the legal advisor of the City and has reviewed a copy of the attached Ordinance no. 15--&—q—% of the City of Meridian, Idaho, and has found the same to be true and complete and provides adequate notice to the public pursuant to Idaho Code § 50-901A(3). DATED this day of 2015. William L.M. Nary City Attorney 2015 LEGISLATION Cn'Y CODE. UPDATES PAGF 5 OF 5 Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Public Works Budget Amendment Public Works: Budget Amendment for FY2015 in the Amount of $175,000.00 for Well 27 Water Treatment Facility Equipment Procurement MEETING NOTES VL Community Item/Presentations Presenter Contact Info./Notes APPROVED CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS i . . . m 0 3 0 v I I W A m p � i W A W A W A W A W A W A o 0 m 0 m 0 W 0 O cc m 0 4 C � < O O i in W N N' S O trt t N a y n c N N b O m 0 V WV p) N O a O O O o 1 on ME mm y � m w jiB 0 _ n • ,� Q v � 3 ] . . . m 0 Jul I I I W A W A W A W A W A W A W A W A o 0 m 0 m 0 W 0 o 0 cc m 0 4 mo O O O a 3 m W N N' S O N N a y n c N N b O m 0 1 a o �n on ME mm � v\i w _ n ] i O N VA m 0 m 0 m 0 m 0 m 0 m 0 m 0 m 0 W A W A W A W A W A W A W A W A o 0 m 0 m 0 W 0 o 0 cc m 0 4 mo O O O a 3 m W N N' S O N N a y n c N N b O m 0 VA m 0 m 0 m 0 m 0 m 0 m 0 m 0 m 0 W A W A W A W A W A W A W A W A o 0 m 0 m 0 W 0 o 0 o 0 m 0 y 0 O O O O W N N N N w N N A O m 0 1 a o �n ➢ � v\i w _ n ] i O N J z W :Y 0 ■ § ^2 �\\ § TO: Mayor Tammy de Weerd Members of the City Council FROM: Kyle Radek, Assistant City Engineer Mayor Tammy de Weerd City Council Members: Keith Bird Joe Borten Luke Cavener Genesis Milam Charlie Rountree David Zaremba DATE: May 28, 2015 SUBJECT: BUDGET AMENDMENT FOR FY2015 IN THE AMOUNT OF $175,000 FOR WELL 27 WATER TREATMENT FACILITY EQUIPMENT PROCUREMENT I. RECOMMENDED ACTION A. Move to: 1. Approve the FY2015 Budget Amendment for $175,000; and 2. Authorize the Mayor to sign the amendment. II. DEPARTMENT CONTACT PERSONS Kyle Radek, Assist City Engineer 489-0343 Warren Stewart, PW Engineering Manager 489-0350 Tom Barry, Director of Public Works 489-0372 III. DESCRIPTION A. Background The Well 27 Treatment Facility project was initiated to continue the process of mitigating brown water in the City's potable water system by improving the water quality. This is year one of this two-year project which includes pilot testing, equipment specification development, and equipment procurement. Pilot testing and specification development have been completed for the equipment needed and equipment proposals have been evaluated. The cost of equipment for the winning proposal is more than the FY 15 project budget. Public Works Department . 33 E. Broadway Avenue, Suite 200, Meridian, ID 83642 Phone 208-898-5500 . Fax 208-898-9551 . www.ineridiancity.org B. Proposed Project This budget amendment will provide funding required to complete the equipment procurement for Well 27 Water Treatment and allow the project to move forward. IV. IMPACT A. Strategic Impact: IN This project supports the Public Works Mission and Vision for enhancing and protecting water quality. B. Service/Delivery Impact: This project will improve the water quality delivered to our customers. C. Fiscal Impact: Proiect Costs Well 27 Treatment Design Commitments $217,300 Well 27 Treatment Equipment $557,700 Total Cost $775,000 Project Funding FY 15 Budget $600,000 Budget Amendment $175,000 Total Funding $775,000 ALTERNATIVES A. The City could choose not to approve the budget amendment, Without this amendment, equipment procurement for the Water Treatment Facility at Well 27 will not be completed in FY 2015 and will have to be postponed. VI. TIME CONSTRAINTS Council approval will allow the contract for equipment to be completed in FY 2015 so it can be included in the construction of the building in FY 2016. VII. LIST OF ATTACHMENTS A. Budget amend t mul Approved for Council Agenda: (� 7 to N (U N N N (D lU (D N (D A W N N 1#+ tip W V T l�It A W N N rn 0 v n �< D om c a N �^ 3 D O m 0 N a m � 0 Uf UH W���� 3 p Ex2 n 3 f D N Q (D po A o _tD N r V p j O. 3 OJ C 0 et....rt. $ rt T O v W N D N e D ®.� a C (D i'D ; (D 3 M N O pj O X n LY iR in N � W H d V W O ® Q 0 07 O W O W N w N N 00 W O W M trt vi. v. vt ifF y/} {n. i/}LU in in in in p FU W A p N A V I W U O O A O 0o Q C A O O W (000u O W N O Ul O V O O N l0 (D O o� O A O VI O O Ut l0 O l0 O O .N, i V W N 4 N N O N M W 4 W W V O O W to O V 00 0 0 0 0 D o n W 0 0 0 0 0 0 0 Ln 0 0 0 0 0 0 0 to W N In H W A W N N N O N J lD U1 W VI N Ol F+ 0 0 0 0 0 0 0 O N O U� lC 0 l9 1p F+ o 0 o A 9 D 0 � eeY N I+Z siA m l nl � Iwl o h: 0 � eeY N l nl Iwl h: 0 � eeY N N 0 w G l0 w V Ol lA A W N F+ O N U1 Gl U1 Ol V N W W M w W O Ol A Q1 W V m N w o to cn vl vl vl vl to v. vs N O1 O to Vt Vr VI N VI O O1w vAi tAii lAn tAii tAii N Lt ih 1A V1 L) N L1 W O W V O O O O 0000 O O O 0 0 0 0 0 Vi N O tD N O O W OO O O O O tip O INJI O X 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 0 F+ N N W to N O tD N N O A W O O In VI N Vt 4l O V l-4 V D O 0 0 0 0 0 0 o pl O N A 0 0 p� 0 0 O O O O O O O w O 61 F+ O t0 m F+ O O O O O O O O O lJl O A Ol F+ W pl N O O 0 0 0 0 0 0 O O O A a1 w In 0 0 0 0 �FFF�F�F�F�F� v���M�aavrt��v, N N N F+ N N F+ N F+ F+ t+ N 1 }J W W F„y > O tD A NV N lD to r i Ln 'Ul UI U9 2 W O W¢ m v Q El 3 v iP m W c a a ET m a a a a c v a. d N w 3 u W K W H III ro y 3 (_ ro e ,N 3 a t (D d O � n rDPw 3 l 3 s N a CL N � 1R D Z W � O e+ � cin V w O a e s m N -I 0 3 In X m X O N 1 0 N O i 0..09 f0 1 �C W A W W to V O N m Ln Vl 000 C, 0 (n 0 O O O In In A O O O j' 0 O N O o 000000 00 O O 41 O o 000000 00 0 0 0 0 0 0 0 0 0 J 4 L} ih ifF '{!} V! Ls 1n JA in N i/1 N 1R i/* N N 1A 1 I p� 'p W W 11 V ON m N W O `W (n ^W m O O O tNn UNi A O o O O `VNi ? O O Ui O O O V O N O O 0 0 0 0 0 0 0 0 O O O O) O rr Z m m lu `O m m C 0 w 0 H: D O H � n 0 r > O 0 `. O ':O O C V� N D � m z O � N ,Q. :U1 Q U�9 0 >,.z 0 z y Y > 3 r 3 Z m v z Z:.X9 M m m M 2 0 3 '3 '3 'D N Z 2 m ( c Z.pp U T W T m m v� Y: W W M M W..1ND W O F+ N W O W V Y i0 A V W `pV.r Jl AW.. UPoI N O T T G1 0 oa 1 f0 � {/T 'O x N a x a O 0 `. O ':O O C V� $nua � m N :U1 VI U�9 U9 D.. D y Y > 3 3 3 3 M M M (D 3 3 '3 '3 'D N '..=s @ . 0 '(D m M � a 3w rap :rap c rp 3 3 N ( D OJ 3 3 � �y 'a 3 O 0 0 d � f) 3 e4 CD ro W N v G1 0 oa 1 f0 � {/T 'O x a x a @ ro O w m O � m O Z D r N O UI W C m 1 D z v N O N D m m Z v m m Z N Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: ITEM TITLE: Public Works Budget Amend ment/Wastewater Public Works: Budget Amendment for FY2015 in the Amount of $444,699.00 for the Design of the Wastewater Resource Recovery Facility Capacity Expansion Project MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes ��1 OL M ties CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS O m a 3 (0 Z N a`; O v C m m N m m m m m m m m m m 0 0 0 0 0 0 0 0 0 0 0 0 0 W N w N w N W UI wwwwww Vl UI N N N N w w wtu N VI O 0 A N A t A P l0 A l N t0 ID 00O O O O 0 O0 O 0 o o0 O O 0 O O Cl W N 1N+ A D0 O m v_ 71 C O v 3o o m O 3 < 1 yTT? V x < N_ C 'w o � w m m to to <n to c n C �> z / > ;id � 7� f n c VF (/h Vn V4 iR t? in iR in LY trt in m m m m m m m m 0 0 0 0 0 0 0 0 w w w w w w w w N N w w w w w w 0 O O O N O b O W O O N O O 0 A A A A A P A A N N N N F+ 4+T F+ O O O O W N N N VNi W N 1N+ A D0 O m v_ 71 C O v 3o o m O 3 < 1 N x < C 'w o � w m m to to <n to c W W, I 3 3 z m d d m ry T N !U 3 u � x o T u�a a w o O W, I m N N Z p< w m N N 'o 'a o m m I w n v c- m m m m A .moi. a -- a2 -_.-� 3 a n m O1 io 3 m ' h n. D a "'� o o. 3. awn n N�" j p v. 3 man { 3 v 5-g S j rt 41 p p K m m D o �- o -nom m w O. ° W 3 On q0 rY W V�a o a C v �. �� `G. m OG O m J^ m O _nva m a n c i 3a s m m N a N w d a 3 v ver J 3 n n N m_ 0 O m I pj- °' bq b m 0, � ° 3 i U N C N w O m M 'o n s o�j`y�3HA 1'fl fe�\ n 'v- Y Oy rM o 3 w o' ani a °,, d m R o N ° w�� N 71, W TO: Mayor Tammy de Weerd Members of the City Council FROM: David Allison, Staff Engineer DATE: June 12, 2015 Mayor Tammy de Weerd City Council Members: Keith Bird Joe Borten Luke Cavener Genesis Milam Charlie Rountree David Zaremba SUBJECT: BUDGET AMENDMENT FOR FY2015 IN THE AMOUNT OF $444,699 FOR THE DESIGN OF THE WRRF CAPACITY EXPANSION PROJECT. I. RECOMMENDED ACTION A. Move to: 1. Approve the FY2015 Budget Amendment for $444,699; and 2. Authorize the Mayor to sign the amendment. II. DEPARTMENT CONTACT PERSONS David Allison, Staff Engineer II 489-0370 Clint Dolsby, Assistant City Engineer 489-0341 Warren Stewart, PW Engineering Manager 489-0350 Tom Barry, Director of Public Works 489-0372 III. DESCRIPTION A. Bacic rg ound In the fall of 2014, influent wastewater flows at the Wastewater Resource Recovery Facility (WRRF) nearly reached eighty percent of the design capacity of the wastewater facility. The benchmark in the wastewater industry recommends initiating design of capacity improvements to the facility when the influent flows reach approximately eighty percent of the design capacity. As a result of this, Brown and Caldwell was contracted to complete an evaluation of the existing WRRF treatment capacity and an alternatives evaluation for capacity related upgrades to the WRRF. Based on their modeling efforts and the pending Public Works Department . 33 E. Broadway Avenue, Suite 200, Meridian, ID 83642 Phone 208-898-5500 . Fax 208-898-9551 . www.meridiancity.org NPDES permit requirements, the WRRF needs to design and construct additional treatment capacity and processes to meet the changing regulations and accommodate future growth. B. Proposed Project This amendment is being requested to expedite the design of necessary capacity and compliance process expansion projects required by the pending NPDES permit and to accommodate future growth. The existing Wastewater Resource Recovery Facility does not have the capacity to meet the proposed effluent targets in the NPDES permit. IV. IMPACT A. Strategic Impact: This project supports the Public Works Mission and Vision for enhancing and protecting water quality and is aligned with preparations for Meridian's new NPDES discharge permit. This amendment supports NPDES Implementation Plan No. 41. B. Service/Delivererer acct: The project will ensure that the WRRF will meet fiiture capacity demands as the City continues to grow, as well as completing the first phase of upgrades required to meet the new regulations set forth in the NPDES permit. C. Fiscal Impact: V. ALTERNATIVES The City could choose not to approve the budget amendment. Because time is of the essence, not moving forward with this amendment may impact the City's ability to accommodate future growth. VI. LIST OF A. Budget amend4ly4 form Approved for Council Agenda �U. -��^�� _/ / te M 3 N N Ol vi w o W A O o A o V In O O O O M O O N O O In L1 l/1 i/r N iR N i/� N W I N N O N W W UI W O O O O O O In 0 0 0 O 0 0 0 0 0 0 O 0 0 0 iR 1/1 iR Ll (h in 1/) iR i? VI W F` Vi N N O N J l0 lA W Ut N m V O O O W O In O W O O O O O O O O O N O O O O O O O O O N O O 10 K W % N A A V O O O1 iD l0 W lWp 1p O 0 3 I -mi F• 1� V N N V V� m Jnr to o�i-+N m�,m v 00 O N V O O'i' (Cp Pom o�vo oii Ul Ln Ul d M M '* :M V O 3 tD M 0 m 0 3 : n ^ M rt rt T O R L n N M 3 0'9 - fG -.'m .t X � U31 I:07 O CL O GGGG_ O l0 A iR W l0 N to vi to N i/}LU A N A I C) 01 O ,W A O Ow (D C) O V1 O w O V LD 10 O -P O O O O N 00 00 00 uw {] W N N A O N W S O N F+ O O W W N O Ol O O tD ' O O lO O O W W O In O W l9 1-a O O O A K W % N A A V O O O1 iD l0 W lWp 1p O 0 3 I -mi F• 1� V N N V V� m Jnr to o�i-+N m�,m v 00 O N V O O'i' (Cp Pom o�vo oii 0 w # # # # # # # # # # # # # # # # # # # t0 W V m VI A W N 1-+ O O O J O1 X11 A W N F+ N N In T In Ol V N O> W CO W W o m A m w J V N V N V m F+ W N T o m C A A A NP o w to to to vi to u u u U? Li N N N w A N tp O pl 00 � o W Co M 0 0 0 O O 00 0 0 0 0 0 0 0 0 0 0 0 0 ih u Y/� i/l i/l ih u iA lh i/1 N N N Vt N O 1p N O O W O O O O O O `lop O lN)t O i O O O O O O O O O 0 0 0 0 0 0 0 0 O 0 0 0 0 0 0 0 0 iA t? L} it) N 1/1 Sn 'N N 1/� i/i in Ls Vi i/1 th t/T lh co 0 o to vi in cn m o �n in m m J J vAi o D O O o O o O Ol o V tD A o 0 Ol O o O O O O O O O V� O A Ol F+ VI Ql N O O 0 0 0 0 0 0 0 0 0 A Ol M 4� 0 0 0 0 C m N u u u li �Q X O ON I l Ln -0 N 0 a .N Ln �L .O IN+ twig to N N N O O O N ® o 111 0 O O O VI to C O O O ® p (Tcn ® O O O C/I-j O O O O O O to O 0 0 0 0 0 0 0 O O h 4li i/Y 4h 47) N N 1rt t/� Vry to u to i/' i/1 N th u"� V O Nm N W .!n OO �O Ol F+ VI Vi N N N O O O O N St1 O 'O Ln O O o in In A o O O o O O V O I-` 0 0 0 0 0 0 0 Ol O In 0 0 0 0 O O O O O O O. V O O O O O O O O O O O 1 O_ W (/l A Ln O O (D Q). {/Y {J} {/T n rt O e m N e m D y ti O O y Oy O ~ N K >: D N Z O N :O m O..D p > d ,d N O 3 0 3 3 m m A'.D D O ,r =s Z X m z Z.':X v m O v D Zm Z �^ 2 3 3 -1 m m y m';y p m N N ih L1 L1 N iR O 0 w w W OZL m n o m m (/l A Ln O O (D Q). {/Y {J} {/T n rt O e m N e m Q O O O C_ V V � W Ul U Q 3 9 D 4. 44�� Y p > d ,d N 3 3 3 3 C 1M (D rt 3 =s . N 3 3 3 3 -1 a m p C O 0 CD W OZL 0 L (D W (D -t. (D ro 3 L 3 (D O -rt O 0 � O i 0 N G 0) A 3 rh •G N 3 D1 ro N Q f w O (/l A Ln O O (D Q). {/Y {J} {/T n rt O e m N e m Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: PROJECT NUMBER: RZ 15-006 ITEM TITLE: Rezone Ordinance No. : An Ordinance(RZ 15-006) for the Re -zone of a parcel of land located in the NW'/4 of the NW'/4 of Section 29, Township 4 North, Range 1 East, Boise Meridian, City of Meridian, Ada County, Idaho Establishing and Determining the Land Use Zoning Classification of Said Lands from C -C (Community Business) zoning district, R-8 (Medium Density Residential) zoning district and R-4 (Medium -Low Density Residential) zoning district to C -C (Community Business) zoning district (9.38 acres), R-8 (Medium Density Residential) zoning district (2.76 acres) and R-4 (Medium -Low Density Residential) zoning district (0.51 acres MEETING NOTES &jIPPROVED Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES INITIALS ADA COUNTY RECORDER Christopher D. Rich 2015-056380 BOISE IDAHO Pgs=11 BONNIE 061251201511:59 AM MERIDIAN CITY NO FEE 111111111111111111111111111111111111111111111111111111 00114161201600663800110116 CITY OF MERIDIAN ORDINANCE NO. I �;_ 1 X079 BY THE CITY COUNCIL: BIRD, BORTON, CAVENER, MILAM, ROUNTREE, ZARE MBA AN ORDINANCE (RZ 15-006 — THREE CORNERS SUBDIVISION) FOR THE RE- ZONE OF A PARCEL OF LAND LOCATED IN THE NW 'V4 OF THE NW `/4 SECTION 29, TOWNSHIP 4 NORTH, RANGE 1 EAST, BOISE MERIDIAN, CITY OF MERIDIAN, ADA COUNTY, IDAHO; ESTABLISHING AND DETERMINING THE LAND USE ZONING CLASSIFICATION OF C -C (COMMUNITY BUSINESS) ZONING DISTRICT, R-8 (MEDIUM DENSITY RESIDENTIAL) ZONING DISTRICT, AND R-4 (MEDIUM -LOW DENSITY RE SIDENTIAL)ZONING DISTRICT TO C -C (COMMUNITY BUSINESS) ZONING DISTRICT (9.38 ACRES), R-8 (MEDIUM DENSITY RESIDENTIAL) ZONING DISTRICT (2.76 ACRES), AND R-4 (MEDIUM -LOW DENSITY RESIDENTIAL) ZONING DISTRICT (0.51 ACRES) IN THE MERIDIAN CITY CODE; PROVIDING THAT COPIES OF THIS ORDINANCE SHALL BE FILED WITH THE ADA COUNTY ASSESSOR, THE ADA COUNTY RECORDER, AND THE IDAHO STATE TAX COMMISSION, AS REQUIRED BY LAW; AND PROVIDING FOR A SUMMARY OF THE ORDINANCE; AND PROVIDING FOR A WAIVER OF THE READING RULES; AND PROVIDING AN EFFECTIVE DATE. BE IT ORDAINED BY THE MAYOR AND THE CITY COUNCIL OF THE CITY OF MERIDIAN, COUNTY OF ADA, STATE OF IDAHO: SECTION 1. That the following described land as evidenced by attached Legal Description herein incorporated by reference as Exhibit "A" is within the corporate limits of the City ofMeridian, Idaho, and that the City of Meridian has received a written request for re -zoning by the owner of said property, to -wit: Sweet Lank Development, Inc. SECTION 2. That the above-described real property is hereby re -zoned from the C -C (Community Business) zoning district, R-8 (Medium Density Residential) zoning district and R-4 (Medium -Low Density Residential) zoning district to C -C (Community Business) zoning district (9.38 acres), R-8 (Medium Density Residential) zoning district (2.76 acres) and R-4 (Medium -Low Density Residential) zoning district (0.51 acres), in the Meridian City Code. SECTION 3. That the City has authority pursuant to the laws of the State of Idaho, and the Ordinances of the City of Meridian zone said property. SECTION 4. That the City has complied with all the noticing requirements pursuant to the laws of the State of Idaho, and the Ordinances of the City of Meridian to re -zone said property. REZONE ORDINANCE—THREE CORNERS SUBDIVISION—RZ 15-006 PAGE 1 OF 3 SECTION 5. That the City Engineer is hereby directed to alter all use and area maps as well as the official zoning maps, and all official maps depicting the boundaries and the zoning districts of the City of Meridian in accordance with this ordinance. SECTION 6. All ordinances, resolutions, orders or parts thereof in conflict herewith are hereby repealed, rescinded and annulled. SECTION 7. This ordinance shall be in full force and effect fi•om and after its passage, approval and publication, according to law. SECTION 8. The Cleric of the City of Meridian shall, within ten (10) days following the effective date of this ordinance, duly file a certified copy of this ordinance and a map prepared in a draftsman manner, including the lands herein rezoned, with the following officials of the County of Ada, State of Idaho, to -wit: the Recorder, Auditor, Treasurer and Assessor and shall also file simultaneously a certified copy of this ordinance and map with the State Tax Commission of the State of Idaho. SECTION 9. That pursuant to the affirmative vote of one-half (1/2) plus one (1) of the Members of the full Council, the rule requiring two (2) separate readings by title and one (1) reading in full be, and the same is hereby, dispensed with, and accordingly, this Ordinance shall be in full force and effect upon its passage, approval and publication. �22 PASSED BY THE CITY COUNCIL OF THE CITY OF MERIDIAN, IDAHO, this L✓Kdday of , ) "e- , 2015. APPROVED BY THE MAYOR OF THE CITY OF MERIDIAN, IDAHO, this 2314 day of j L -vx , 2015. MAYOR MY de WEE �90.AT4l��fi '® ATTEST: �6 °O� / � C�Oi-X /_9 CffYof w JAYCEE�L. HOLIYAN, CITY odeTkf 6ll� RE ZONE ORDINANCE - THREE CORNERS SUBDIVISION- RZ 15-006 PAGE 2 OF 3 STATE OF IDAHO, ) ) ss: County of Ada ) On this a -�) day of )ice P _ 2015, before me, the undersigned, a Notary Public in and for said State, personally appeared TAMMY de WEERD and JAYCEE L. HOLMAN, known to me to be the Mayor and City Clerk, respectively, of the City ofMeridian, Idaho, and who executed the within instrument, and acknowledged to me that the City of Meridian executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal the day and year first above written. (SEAL) '<;Ar�il� d Not ra Public for Ida�io n Residin At: My Commission Expires: REZONE ORDINANCE -THREE CORNERS SUBDIVISION -RZ 15-006 PAGE 3 OF 3 EXHIBIT A Sawtooth land 5urveymy, LLC AIN � = I: I.a�l3.�Unrc�n troars;�rs-aro, 2030 5, woslm,0too Ave., CmncU, 10 6:3f317 April 2, 2016 Three; Comors Subdivision Connnorclai Boundary Legal A parcel of land located in the NW1/4 of the NWIM of Section 29j. 4 N., R. 1 E., S.M., City of Meridian, Ada County, Idaho, more particularly described as follows; BEGINNING at a found brass cap maridng the northwest cornor of said Section 29; Thence South 89'20'41' East, coincidont with the north lino of said NW114 of the NWIM of Section 29, a distance of 1002.68 feet; Thence South 0°34'24" West, parallol with said east lino of the NW114 of the NW1/4 of Section 29, a distance of 305.08 feet to the beginning of a non•tangant curm; Thence 210.43 feet along the arc of said curve to tho loft, with a central angle of 12`37'29", a radius of 955.00 feet, subtended by a chord bearing South 83°44'48" West, 210.00 feet; Thence North 89°26 36" West, 82.67 foot; Thonco South 0034'24" West, parallel with said east line of the NW1/4 of the NW1/4 of Section 29, a distance of 15.00 feet; Thonce North 89°26'36" West, 85,14 foot to the beginning of a non -tangent curve on the east right of way line of E. Throo Comers Drive; Thence 304.67 feet along the aro of said eurvo to the left, and coincident with said east right of way line of E. Three Corners Drive, with a central at of 73037'48`, a radlus of 2.37.00 feat, subtended by a chord bearing South 86°27'10" West, 284.04 feet; Thence South 49"38°I6" West, coincident will) said right of way line of E. Throo Corners DrW, 44.78 foot; Thonco North 73°23'30` West, coincident with sold right of way lino of E. Throo Carriers Drive, 20.80 foot; I';5201611G705d20CK SOLID11-11117C CORNERS CORNERS 4 COMMERCIAL. IINDRY LEGAL-REV.docx r,a0o I1 Three Corners Subdivision (RZ 15-006) EXHIBIT A Thenoe North 15030'05" West, coincident with said right of way line of E. Three Corners Drive, 74.85 feet; Thence South 74023'55" West, coincident with said right of way line of E. Three Corners drive, 74.00 feet; Thence South 15°30'05" East, coincident with said right of way line of E. Three Corners Drive, 81.63 feet; Thence South 45028'20" West, coincident with said right of way line of E. Three Corners Drive, 18.87 feet; Thence North 89023'32" West, coincident with said right of way line of E. Three Corners Drive, 180,48 feet to the west line of said Section 29; Thence North 0037'24" East, coincident with said west line of Section 29, a distance of 487.46 feet to the POINT OF BEGINNING. The above described parcel contains 9.38 acres more or less. Together with and subject to covenants, easements and restriction of record, Tluee Corners Subdivision (RZ 15-006) EXHIBIT A Sawtooth Land Surveying, LLC C. f _7 P: (2043) 398.8104 P; (206) 398-5 ( 05 2030 3, W15hmgW,i Ave„ Emmett, ID 83617 March 16, 2015 Three Cornors Subdivision R4 Boundary Legal A parcel of land located in the NW1/4 of the NW1/4 of Section 29, T. 4 N., R. 1 E„ B.M., City of Meridian, Ada County, Idaho, more particularly described as follows; COMMENCING at a found brass cap marking the northwest corner of said Section 29; Thence South 89'26'41" East, coincident with the north line of said NW1/4 of the NW1/4 of Section 29, a distance of 1002,58 feet; Thence South 0034124" West, parallel with the east line of said NW1/4 of the NW1/4 of Section 29, a distance of 40.00 feet; Thence South 89°26'41" East, parallel with said north line of the NW1/4 of the NW1/4 of Section 29, a distance of 324.00 feet; Thence South 0034'24" West, coincident with the west line of Fuller Ranchettes as shown on file in Book 18 of Plats, at Page 1179, Ade County Records, 340.14 feet to the POINT OF BEGINNING; Thence continuing South 0034'24" West, coincident with said west line of Fuller Ranchettes, 25.00 feet; Thence North 89025'36" West, 615.08 foot; Thence North 0034'24" E=ast, 15.00 feet; Thence South 89025'36' Cast, 82.57 feet to the beginning of a non -tangent curve; Thence 219.00 foot along the aro of said curve to the right, with a central angle of 13°08'20", a radius of 956,00 feet, subtended by a chord bearing North 84000'14" East, 218.52 feet; Thence South 89025'36" Cast, 185.43 foot; PA{2014115005•ROCK SOLID-TI-IRFE CORNERS 81Drawinge\Descrlptbnsl3 CORNERS R4 BNDRY LEGAL- REV.doox Pa;le 11 Thee Corners Subdivision (PZ 15-006) EXHIBIT A Thence South 0°34'24° West, '15.00 feet; Thence South 89025'36" East, 130.00 feet to the POINT OF BEGINNING, ALSO TOGETHER WITH: A parcel of land located in the NW1/4 of the NW114 of Section 29, T. 4 N.; R. 1 C., B.M., City of Meridian, Ada County, Idaho, more particularly described as follows; COMMENCING at a found brass cap marking the northwest corner of said Section 29; Thence South 89"20'41" East, coincident with the north line of said NW1/4 of the NW1/4 of Section 29, a distance of 1002,58 feet; Thence South 0°34'24" West, parallel with the east line of said NW1/4 of the NW1l4 of Section 29, a distance of 40.00 feet; Thence South 89°26'41" East, parallel with said north line of the NW714 of the NW114 of Section 29, a distance of 324.00 feet; Thence South 0°34'24" West, coincident with the west line of Fuller Ranchettes as shown on file in Bool< 16 of Plats, at Page 1179, Ada County Records, 365.14 feet; Thence North 89°25'36" West, 630.00 feet to the POINT OF BEGINNING; Thence South 0°34'24" West, parallel with said east line of the NW114 of the NW114-of Section 29, a distance of 95,85 feet to the easterly right of way of E. Three Corners Drive, and the beginning of a non -tangent curve; Thence 129,82 feet along the arc of said curve to the left, with a contras angle of 31023,01", a radius of 237.00 feet, subtended by a chord hearing North 41002'26" West, 128,20 feet; Thence South 89025'36" East, 85.14 feet to the POINT OF BEGINNING. The above described parcel contains 0,51 acres more or less. Together with and subject to covenants, events and restriction of record. End Description C9flF10y�Q —_.. P:12015115005-ROCIt SOLIDfFIREE CORN . grWascriptlOW3 CORNERS R4 ONDRY LEGAL- REV,d06X Pago 12 Three Corners Subdivision (RZ 15-006) EXHIBIT A 5awl:ovt h Land 5urveying, LLC airtlti'l/ ___ — �""':w�-J" Pt (2013) 39b-61 Oji r: (205) 398 3105 2030 S. Wa5hmDton Ave., Emmet;, fe $36! 7 April 2, 2015 Three Corners Subdivision R8 Boundary Legal A parcel of land located in the NW1/4 of the NW1/4 of Section 29, T. 4 N., R. 1 E., B.M., City of Meridian, Ada County, Idaho, more particularly described as follows; COMMCNCING at a found brass cap marking the northwest comer of said Section 29; Thence South 89°26'41" East, coincident with the north line of said NW1/4 of the NW1/4 of Section 29, a distance of 1002.58 feet to the POINT OF BEGINNING; Thence continuing South 89°26'41" Gast, coincident with said north line of NW1/4 of the NW1/4 of Section 29, a distance of 324.00 feet; Thence South 0034'24" West, coincident with the west line of Fuller Ranchettes as shown on file in Book 18 of Plats, at Page 1179, Ada County Records, 380.14 feet; Thence North 89025'36" West, 130,00 feet; Thence North 0034'24" East, 15.00 feet; Thence North 89025136' West, 185.43 feet to the beginning of a non -tangent curve; Thence 8.57 feet along the are of said curve to the left, with a central angle of 0°30'51 ", a radius of 955,00 feet, subtended by a chord bearing North 89°41'02" West, 8.57 feet; Thence North 0034'24" East, parallel with said east line of the NW1/4 of the NW1/4 of Sect 29, a distance of 305.08 feet to the POINT OF BEGINNING. oNA� b The above described parcel contains 2,76 acres more or loss, o 14 Together with and subject to covenants, easements and restriction of record, rL lye f? J Cad Porter, PLS 14221 A_ Date ARC POP End Description P:12o15115005-ROCK SOLJD-'rHREE CORNERS MrawincgsVDesoriplionsl3 CORNERS Rs DNDRY LEGAL- REV,dooX Parra 11 Three Corners Subdivision (RZ 15-006) EXHIBIT B JNOZ IVI,)dJIAIV\O,) POW -M 90,-, :<I Of 'NVIOMIN X;1-90091 LtSE80f 119WWJ 04'A:JCI OMVI MMs W)s 58INWID j"Will If ju lVOl,-)NllqSVA4 'S OVO? ao-, Al Or -�—W-) — 4 Three Comers Subdivision RZ 15-006 iy) IJ 11 6 �lj0 It Three Comers Subdivision RZ 15-006 EXHIBIT B 19 E. (111MA-14 RLVD, .'o 112q 4 24 t" 4000, -Sil TYCI WJ-32.4SO' IU Iv I 04 17.0:82' T1 i THRIJ-. (.',OR[,jEf6 Fk18 SAIMT LANO DEV MFRIDIAW, R4 ZONE 3116 Three Corners Subdivision RZ 15-006 2030 S. WASHiNGTONAVE.� k'MMCTr 10 j lz: TS I OF 1 6 Y92536 c 1 3, lofi_ 1110 3116 Three Corners Subdivision RZ 15-006 2030 S. WASHiNGTONAVE.� k'MMCTr 10 j lz: TS I OF 1 EXHIBIT B 3'l t M Sr'l')',g' J <3 "A"re W40* ,'•.h, k i rc V 21 i�')'. .fly l�f � II ti�:s•r( CURVF TABLE 661 O Loyort'� 64-j5At;1q�a�5 e� xu uc�xxu� tM�5�+.L.(il'1tl M a5r ON ACp _� u�laux �� nrttxxi[cr ._ O'IrkF IM i CORNERS SUIS` s4' Idl RIUTAN I() R8 IONL Urs _,__._ rv10T L nnO ANDE 2030 S. WASNINGYONAK. n)tc n �Gnaee t wa`ex' � t'ALV,fa'1; Ip 81617 308.8104 7.Rwior* R' (20d) 3088105 16005 f Ji g ` NWYSAftYDOYl1lS.COt,T 1 F11 Three Corners Subdivision RZ 15-006 NOTICE AND PUBLISHED SUMMARY OF ORDINANCE PURSUANT TO I.C. § 50-901(A) CITY OF MERIDIAN ORDINANCE NO. 15-JW� PROVIDING FOR RE ZONING ORDINANCE An Ordinance of the City of Meridian granting re -zoning of a parcel of land located in the NW '/4 of the NW 1/4 of Section 29, Township 4 North, Range I East, Boise Meridian, City of Meridian, Ada County, Idaho. This parcel contains 12.65 acres more or less. Also, this parcel is SUBJECT TO all easements and rights-of-way of record or implied. As in attached exhibit `B" and is not based on an actual field survey. A full text of this ordinance is available for inspection at City Hall, City of Meridian, 33 East Broadway Avenue, Meridian, Idaho. This ordinance shall become effective on the V*"- day of junt , 2015. p Mayor al City Council �E city ofIDIAI` By: Jaycee L. Holman, City Clerk oaxo Fy SEAL First Reading: G - Z3 - I �_ r` Adopted after first reading by suspension fill t'fi✓0.f e YES ✓ NO Second Reading: Third Reading: as allowed pursuant to Idaho Code 50-902: STATEMENT OF MERIDIAN CITY ATTORNEY AS TO ADEQUACY OF SUMMARY OF ORDINANCE NO. 15- lbW The undersigned, William L.M. Nary, City Attorney of the City of Meridian, Idaho, hereby certifies that he is the legal advisor of the City and has reviewed a copy of the attached Ordinance No. 15- 16Y� of the City of Meridian, Idaho, and has found the same to be true and complete and provides adequate notice to the public pursuant to Idaho Code § 50-901A (3). DATED this day of 2015. William. L.M. Nary City Attorney RE ZONE ORDINANCE SUMMARY- THREE CORNERS SUBDIVISION -RZ 15-006 PAGE 1 Meridian City Council Meeting DATE: June 23, 2015 ITEM NUMBER: 10 PROJECT NUMBER: ITEM TITLE: Future Meeting Topics MEETING NOTES Community Item/Presentations Presenter Contact Info./Notes CLERKS OFFICE FINAL ACTION DATE: E-MAILED TO STAFF SENT TO AGENCY SENT TO APPLICANT NOTES _ INITIALS