Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Independent Contractor Agreement with PreCom for WWTP Process Control Network Upgrades
AGREEMENT FOR INDEPENDENT CONTRACTOR SERVICES (WWTP PROCESS CONTROL NETWORK UPGRADES) PROJECT # 10382a y ~HISAGREEMENTFORINDEPENDENTCONTRACTORSERVICESismadethis g=¢day of September, 2013, and entered into b and between the Cit of Meridian a -=~-- Y Y , municipal corporation organized underthe laws ofthe State of Idaho, hereinafter referred to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and Precision Communications dba PreCom, hereinafter referred to as "CONTRACTOR" whose business address is 710 S. Orchard St., Boise, ID 83705 and whose Public Works Contractor License # is C-12640-A-4. INTRODUCTION Whereas, the City has a need for services involving WWTP PROCESS CONTROL NETWORK UPGRADES; and WHEREAS, the Contractor is specially trained, experienced and com etent p to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS 1. Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City u on execution of this . p Agreement and receipt of the City s written nonce to proceed, all services and work and comply in all respects, as specified in the document titled "Sco e of Work" a p copy ofwhich isattached heretoasAttachment"A"and incor orated herein b this p Y reference, together with any amendments that may be a reed to in writin b the g 9Y parties. . 1.2 All documents, drawings and written workproduct pre ared or roduced b P, p Y the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the Cit shall have the Y right to reproduce, publish and use all such work, or an art thereof in an Yp y manner and for any purposes whatsoever and to authorize others to do so. If an . Y such work ~s copyr~ghtable, the Contractor may copyright the same, exce t that as . p , to anywork which is copyrighted by the Contractor, the City reserves a ro alt -free, . Y Y non-exclusive, and irrevocable Incense to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. WWTP PROCESS CONTROL NETWORK UPGRADES page 1 of 11 Project 10382a 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. The Contractor represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part of the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in atimely manner in accordancewith a Schedule of Work, which the parties hereto shall agree to. The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall becompensated on aNot-To-Exceed basis as provided in Attachment B "Payment Schedule" attached hereto and by reference made a part hereof for the Not-To-Exceed amount of 342167.00. Compensation is scheduled to be paid from two different fiscal years, FY13 and FY14. The City of Meridian's fiscal year is October 1 -September 30. Currently $73,000.00 has been budgeted for FY13 and the remainder of $269,167.00 in FY14 which City Council approved at its Council Meeting on 8127/13. Contractor must NOT complete work that exceeds $73,000.00 prior to October 1, 2013. It is the contractor's responsibilityto schedule all work and to adhere to the schedule and the. amounts listed above. 2.2 The Contractor shall. provide the City with a monthly statement, as the work warrants, of fees earned and costs incurred for services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the Cityanyadditionalconsideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shallnot beentitled byvirtue ofthisAgreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. WWTP PROCESS CONTROL NETWORK UPGRADES page 2 of 11 Project 10382a 3. Term: 3.1 This agreement shall become effective upon execution by both arties, and p shall expire upon ~a) completion of the agreed upon work, fib) Se tember 30, 2014 p or ~c}unless sooner terminated as provided below or unless some other method or time of termination is listed in Attachment A. 3.2 Should Contractordefault in the performance ofthisAgreementormateriall . ., Y breach any of its prov~s~ons, City, at City's option, may terminate this A reement b ,. .. g Y giving written not~ficat~on to Contractor. 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Attachment B of this Agreement on the date due, Contractor, atthe Contractor's option, may terminate this Agreement if the failure is not remedied b the Cit . Y Y within thirty X30) days from the date payment is due. 3.4 TIME FOR EXECUTING CONTRACT AND LIQUIDATED DAMAGES Upon receipt of a Notice to Proceed, the Contractor shall have 90 ninet calendar ~ Y) days to complete the work as described herein. Contractor shall be liable to the City for any delay beyond this time eriod in the amount of five hundred doll r p as ($500.00} per calendar day. Such payment shall be construed to be li uidated q damages by the Contractor in lieu of any clam or lama a because of such Bela g y and not be construed as a penalty. 4. Termination: 4.1 If, through any cause, CONTRACTOR, its officers, emplo ees, or a ents fails ,. Y 9 to fulfill in a timely and proper manner its obligations underthis A reement, violates 9 any of the covenants, agreements, or stipulations of this Agreement, falsifies an Y record or document required to be prepared under this agreement, en a es in g9 fraud, dishonesty, or any other act of misconduct in the erformance of this p. contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITYshall thereupon have the ri htto terminate this .. g Agreement by giving written nonce to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen X15) days before the effective date of such termination. CONTRACTOR may terminate this a reement at an .. g Y time by giving at least sixty X60) days nonce to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR underthis A reement g shall, atthe option ofthe CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation for an work satisfactoril Y Y complete hereunder. 4.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liabilit to Y the CITY for damages sustained by the CITY by virtue of an breach of this Y Agreement by CONTRACTOR, and the CITY may withhold an a ments to YpY WWTP PROCESS CONTROL NETWORK UPGRADES page 3 of 11 Project 10382a CONTRACTOR forthe purposes of set-off until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR of its liability to the CITY for damages. 5. Independent Contractor: 5.1 In all matters pertaining to this agreement, CONTRACTOR. shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided in Attachment A,Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind orincuranyobligation on behalfofthe City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 5.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 5.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor underthis Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of ContractorinfulfillmentofthisAgreement. If inthe performance ofthisAgreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. 6. Indemnification and Insurance: 6.1 CONTRACTOR shall indemnify and save and hold harmless CITY from and for any and all losses, claims, actions, judgments for damages, or injury to persons orproperty and losses and expenses and othercosts including litigation costs and attorney'sfees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall maintain, and specificall~agrees that it will maintain, throughout the term of this Agreement, liability insurance, in which the CITY shall be named an additional insured in the minimum amounts as follow: General Liability One Million Dollars ($1,000,000) per incident or occurrence, Automobile Liability Insurance One Million Dollars ($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in the statutory limits as required by law.. The limits of insuranceshall notbedeemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or judgments for WWTP PROCESS CONTROL NETWORK UPGRADES page 4 of 11 Project 10382a damages or injury to persons or property and other costs, including litigation costs and attorneys' fees, arising out of, resulting from , or in connection with the performance ofthisAgreement bythe ContractororContractor'sofficers, employs, agents, representatives or subcontractors and resulting in or attributable. to personal injury, death, ordamage ordestruction to tangible or intangible property, including use of. ~ CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (10) days prior to the date Contractor begins performance of it's obligations under this Agreement. In the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. 6.2 Any deductibles,self-insured retention, ornamed insureds mustbedeclared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 6.3 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance orself-insurance maintained by the City orthe City's elected officers, officials, employees and volunteersshall beexcess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 6.4 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 6.5 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 6.6 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees orsubcontractors. 7. Bonds: Payment and Performance Bonds are required on .all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. 8. Warranty: All construction and equipment provided underthis agreementshall be warranted for 2 years from the date of the City of Meridian acceptance per the WWTP PROCESS CONTROL NETWORK UPGRADES page 5 of 11 Project 10382a ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items found to be defective during a warranty inspection and subsequently corrected will .require an additional two ~2) year warranty from the date of City's acceptance of the corrected work. 9. Notices: Any and all notices required to be given by either of the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY City of Meridian Purchasing Manager 33 E Broadway Ave Meridian, ID 83642 208-888-4433 CONTRACTOR Precision Communications, Inc dba PreCom Attn: Heidi Woodhead 710 S. Orchard St. Boise, ID 83705 . Phone: 208-344-3660 Email: hwoodhead@precom-inc.com Idaho Public Works License # C-12640-A-4 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 10. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined bya Courtofcompetentjurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. 11. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respectto each and everyterm, condition and provision hereof, and thatthe failure to timely perform any ofthe obligations hereundershall constitute a breach of, and a default under, this Agreement by the party so failing to perform. 12. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights underthis Agreement except upon the prior express written consent of CITY. 13. Discrimination Prohibited: In performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of anyfederal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. WWTP PROCESS CONTROL NETWORK UPGRADES page 6 of 11 Project 10382a 14. Reports and Information: 14.1 At such. times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 14.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement for a minimum of four (4} years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographicand every other means of recording upon anytangible thing, any form of communication or representation including letters, words, pictures, sounds or symbols or any combination thereof. 15. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered bythis Agreement. 16. Publication, Reproduction and Use of Material: No material produced in whole or in part underthis Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, dataorothermaterialsprepared under this Agreement. 17. Compliance with Laws: In performing the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 18. Changes: The CITYmay, from timetotime, requestchanges inthe Scope ofWork to be performed hereunder. Such changes, including any increase or decrease in the amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the sameformalities as this Agreement. 19. Construction and Severability: If anypart ofthisAgreement isheld to beinvalid or unenforceable, such holding will not affect the validity or enforceability of anyother part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 20. Waiver of Default: Waiver of default by either partyto this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent WWTP PROCESS CONTROL NETWORK UPGRADES page 7 of 11 Project 10382a breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. 21. Advice of Attorney: Each party warrants and represents that in executing this Agreement. It has received independent legal advice from its attorney's or the opportunity to seek such advice. 22. Entire Agreement: This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. 23. Order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted. bid document. 24. Public Records Act: Pursuant to Idaho Code Section 9-335, et seq., information or documents received from the Contractor maybe open to public inspection and copying unless exempt from disclosure. The Contractor shall clearly designate individual documents as "exempt" on each page of such documents and shall indicate the basis for such exemption. The CITY will not accept the marking of an entire document as exempt. In addition, the CITY will not accept a legend or statement on one (1~ page that all, or substantially all, of the document is exempt from disclosure. The Contractor shall indemnify and defend the CITY against all liability, claims, damages, losses, expenses, actions, attorney fees and suits whatsoever for honoring such a designation or for the Contractor's failure to designate individual documents asexempt. The Contractor'sfailuretodesignate as exempt any document or portion of a document that is released bythe CITY shall constitute a complete waiver of any and all claims for damages caused by any such release. 25. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 26. Approval Required: This Agreement shall not become effective or binding until approved by the City of Meridian. END OF TEXT. SIGNATURES TO FOLLOW ON NEXT PAGE. WWTP PROCESS CONTROL NETWORK UPGRADES page 8 of 11 Project 10382a CITY OF MERIDIAN ~" T MY de RD, MAYOR Dated: ~ - ~- ~~ ~ ~- _ ~ ~ ~ ~ a > ~~- ~~ PRECISION COMMUNICATIONS INC, dba PreCom BY: ,. HEIDI OODHEA ,Vice Presi ent Dated: ~,~ ~ ~~~~' Approved by Council: ~ ~~.~ a~~~~n ~ uG~~rl Attest: ~ ~~~~ ~~~o~ ~ a~ ~E ,- L. L A , ~, ~DIAI~~ j IgAHO Purchasin A royal ~~~~~ ~~~~ e a ' n 9 pp p e t Appro a BY: KEITH ATTS, Purc asing Manager .. ~ ~' Dated.. l3 WWTP PROCESS CONTROL NETWORK UPGRADES Project 10382a Y: WA R N STEWA Engineering Manager Dated: ~ 3 page 9 of 11 Attachment A SCOPE OF WORK REFER TO INVITATION TO BID PW-13-10382a ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation to Bid Package # PW-13-10382a, are by this reference made a part hereof. WWTP PROCESS CONTROL NETWORK UPGRADES page 10 of 11 Project 10382a Attachment B MILESTONE /PAYMENT SCHEDULE A. Total and complete compensation for this A reement shall no x g t e ceed $342,167.00. MILESTONE DATES/SCHEDULE.. Milestone 1 Substantial C m o plet~on 80 (eighty} days Milestone 2 Final Completion 1.0 ten da s ~ } y PRICING SCHEDULE Contract includes furnishing all labor, materials, a ui ment, and incidentals as re uire q p q d for the WWTP PROCESS CONTROL NETWORK UPGRADES er IFB PW-13-10382a p Total Bid Schedule ...................$320,206.00 Total Bid Add Alternate 1 ...................$21,961.00 CONTRACT TOTAL ....................... X342,167.00 CONTRACT IS A NOTTO EXCEED AMOUNT. LINE ITEM PRICING BELOW WILL BE USED FOR INVOICE VERIFICATION AND ANY ADDITIONAL INCREASES OR DECREASES IN WORK REQUESTED BY CITY. Pricing Schedule. Item No. Descri tion Quantit Unit Unit Price 1 Mobilization & Demobilization 1 LS $275.00 2 Trenching 3 900 LF $6.88 3 Conduit -including installation labor 6150 LF $1.94 4 Asphalt Patching 1400 SF $6.33 5 Fiber Optic Cable -including installation cost 6 375 LF $8.80 6 Fiber Optic Cable Terminations -including labor and materials 168 EA $60.00 Communication Panels -including all power supplies, UPS's and 7 installation labor 6 EA $11,917.00 8 Network Switches -No Equal -including installation labor 5 EA $12,100.00 Fiber Optic Transceivers - No Equal -for new and existing network 9 switches 26 EA $995.00 10 Testing of fiber optic cable and terminations 1 LS $1,760.000 11 Chemical Feed Line 660 LF $7.15 12 Manholes 2 EA $2,090.00 13 Other Misc 1 LS $37,595.00 Add Alternate 1 Pricing Schedule 1 Fermentation Building (Tie-In) 1 LS $21,961.00 Travel expenses, if applicable, will be paid at no more than fhe Cify of Meridian's Travel and Expense Reimbursement Policy. WWTP PROCESS CONTROL NETWORK UPGRADES page 11 of 11 Project 10382a PAYMENT Travelers Casualty and Surety Company of America 60~11D Hartford, Connecticut 06'f83 Bond No.; 105953657 CONTRACTOR: (Name, legal status and address} SURETY: (Name, legal status and principal place of business} Precision Communications, Inc. dba PreCom 710 South Orchard St. Boise, I D 83705 O'U~NER: (Name, legal status and address} City of Meridian 33 E. Broadway Ave. Meridian, I D 83642 Travelers Casualty and Surety Company of America ~.~-- One Tower Square Hartford, CT 06183 CONSTRUCTION CONTRACT Date: September 6, 2013 Amount: $ 342,167.00 Three Hundred Forty Two Thousand One Hundred Sixty Seven Dollars and 00/100 Description: {Name and location} wWTP Process Control Network Upgrades - Project No.10382a BOND Date: September 6, 2013 (Not earlier than Construction Contract Date} Amount: $ 342,167.00 Three Hundred Forty Two Thousand One Hundred Sixty Seven Dollars and 00/100 Modifications to this Bond: ~ None ~ See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: Precision Communications, Inc. dba PreCom Company: (Co orate Seal} Signature: _ - `,~ ...~ .~ ~ ~,~ . ~,~ Signature: Name and ~ `' ~~ Name and Title: Title: (Any additional signatures appear on the last page of this Payment Bond.) Travelers Casualty and Surety Company of America (Corporate Seal) ,~ Attorney-in-Fact (FOR INFORMATION ONLY -Name, address and telephone} AGENT or BROKER: O~1ER'S REPRESENTATIVE: Architect, Engineer or other party:} Paynewest Insurance, Inc. 960 Broadway Avenue, Suite 100 Boise, I D 83706 208-424-2900 The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition j § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and halls harmless the owner from claims, demands, liens or suits by any person ar entity seeking payment for Iabor, materials or a ui ment furnished for use in the performance of the Construction Contract then q p the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety fat the address described in Section 13} of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for Iabor, materials or equipment furnished for use ~n the performance ofthe Construction Contract and tendered defense of such claims, demands, lens orsutts to the Contractorand the Surety. § ~ when the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name afthe party to wham the materials were, or equipment was, furnished or supplied or far whom the labor was done,or performed, ~vithin ninety (90}days after having last performed labor or last furnished materials or equipment included ~n the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13), § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety fat the address described in Section 13}. § 6 Ifa notice ofnon-payment required by Section S.l.l is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice ofnon-payment under Section ~.I.1. § 7 when a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § '1'.1 Send an answer to the Claimant, with a copy to the owner, within sixty X60} days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety ar Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement, If, however, the Surety fails to discharge its obligations under Section 7.1 or Section ~'.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attomey's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction The Company executing this bond vouches that this document conforms to American Institute of Architects Document A3i2, 200 edition z Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's riorit t use the funds far the completion of the work. ~ p y o § 1 O The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of an Claimant under this Band, and shall have under this Bond no obli atian to snake y g payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § I l The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shalt be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the .sate in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1} on which the Claimant sent a Claim to the Surety pursuant to Section 5,1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of ~l} or (2}first occurs. If the provisions of this Paragraph are void ar prohibited b law, the minimum Y period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears, Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14'W'hen this Bond has been furnished to comply with a statutory ar other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions. conforming to such statutory or other legal requirement shall be deemed incorporated herein, when so furnished, the intent is that this Bond shall be construed as a statutory bond and nat as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Band or shall permit a copy to be made, § 16 Definitions § 16.1 Claim. A written staterraent by the Claimant including at a minimum: .l the name of the Claimant; .2 the name of the person for whom the labor was done, ar materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on tivhich the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .S the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance ofthe Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located, The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, ail, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the Jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract, The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition § I6.5 Contract Documents. All the documents that comprise the agreement between the Owner a nd Contractor. § I7 If this Bond is issued for an agreement between a Contractor and subcontractor the term Contractor ' ' deemed to be Subcontractor and the term Owner ~n this Bond shall be shall be deemed to be Contractor. § 1 S Modifications to this bond areas follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL, Company: Corporate Seal} SURETX Company: (Corporate Seal) Signature; Name and Title: Address; Signature; Name and Title: Address; „~~ tiv~~,~a~~Y ~~~~.ut~«y ~~s~~ ~v~3a vouches ~nai ants aocament con~orms to Amerman tnstitut~ of Architects Document A312, 2010 edition 7RAVELERSJ~ POWER OF ATTORNEY Farmington Casualty Company fidelity and Guaranty Insurance Company fidelity and Guaranty Insurance Underwriters, inc. St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company Surety Bond No, 105953657 Principal: Precision Communications, Inc. dba PreCom OR Project Description: WWTP Process Control Network Upgrades Qbligee; City of Meridian - Project No.10382a KNQW All. MEN BY THESE PRESENTS; That Farmfngtan Casualty Company, St, Paul Fire and Marine Insurance Company, St, Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, are carporat~'ons duty organized under the laws of the State of Connecticut, that fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc- fis a corporation duly organized under the laws of the State of Wisconsin therein collectively called the "Companies"}, and that the Companies do hereby make, constitute and appoint Brenda J. Smith of the City of Boise ,State of ID ,their true and lawful Attorney-in-Fact, to sign, execute, seal and acknowledge the surety bonds) referenced above. IN WITNESS WHEREQF, the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this i0th day of September, 2012, Farmfngtan Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Fre and Marine Insurance Company St. Paul Guardian Insurance Company St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company State of Connecticut City of Hartford ss. By: Robert L. Raney, Senior Vice President On this the 10th day of September, 2012, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty insurance Company, Fidelity and Guaranty insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St, Pau! Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Carnpany, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. In Witness Whereof, I hereunto set my hand and official seal, My Commission expires the 30th day of June, 201fi. a•~~ ~ ~~~U~ Marie C. Tetreault, Notary Public This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Farm' Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters Inc, St, Paul Fire and ~ ington Company, St. Paul Guardian Insurance Company, St Paul Mercury Insurance Company, Travelers Casual and Sure Manne Insurance Surety Company of America, and United States Fideli and Guaran Com an ~ ty Company, Travelers Casualty and ty ty p y, which resolutions are now in full force and effect, reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, an Vice President any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secreta or an Assistant S y Attorneys-in-Fact and Agents to act for and on behalf of the Com an and ma ive such ry Y ecretary may appoint P Y Y 9 appoEntee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company}s seal bonds, recognizances, contracts of indemni and other writmgs obligatory m the nature of a bond, recognizance, or conditional undertakin and an of sal tY, any time may remove an such a ointee and revoke the ~ ~ . 9' Y d officers or the Board of Directors at Y Pp power given hem or her; and it is FURTHER RESOLVED, that the Chairman, the President, any Uce Chairman, any Executive Vice President, any Senior Vice President or an Vice President may delegate all or any part of the foregoing authority to one or mare officers or em to ees of this Com an Y each such delegation is in writing and a copy thereof is filed in the office of the Secret p Y p Y~ p~~ded that ary; and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or condit~ona(undertaking shat! be valid and binding upon the Company when (a}signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b} duly executed sunder seal, if required} by one or more Attorneys-in-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and cert+fied by such facsimile signature and facsimile sea( shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached, I, Kevin E. Hughes, the undersigned, Assistant Secretary, of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc,, St. Pau! Fire and Marine Insurance Company, St Paui Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, do hereby certify that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which is in full force and effect and has not been revoked, zN TESTxMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 6th day of September 2013 ~~ f~~~~. Kevin E. Hughes, Assistant Secretary ~~' ; , ~. ~ ~ r~ * 4°'~'' a, ,~~' ~a ''~' •y, 4~S s`ue' . 4~ ~t(?~ ~ ~~ ~ ~9~ ~~ ~~ ~ s~~~ ~ ~ ~~~~ x ~ ~' ~ l~~ ~ a !.. ra verify the awthenticlty of th/s Power of Attorney, call 1-800-411-3880 or contact us at www,trave/ersbond,com, Please refer fo the Attorney-In-Fact number, the above-named Individuals and the details of the bond to which the power is attached PERFORMANCE BOND Travelers Casualty and Surety Company of America Hartford, Connecticut 06183 Bond No.: 105953657 CONTRACTOR: Name, legal status and address) Precision Communications, lnc. dba PreCom 710 South Orchard St. Boise, !D 83705 OWNER: (Name, legal status and address) City of Meridian 33 E, Broadway Ave. Meridian, I D 83642 SURETY: {Name, legal status and principal place of busit7ess) Travelers Casualty and Surety Company of America One Tower Square Hartford, CT 06183 CONSTRUCTION CONTRACT Date: September 6, 2013 Amount: $ 342,167,00 Three Hundred Forty Two Thousand One Hundred Sixty Seven Dollars and 001100 Description: (~la~ne and location) WWTP Process Control Network Upgrades - Project No.10382a BOND Date: September 6, 2013 Not earlier than Construction Contract Date) Amount: $ 342,167.00 Three Hundred Forty Two Thousand One Hundred Sixty Seven Dollars and 001100 Modifications to this Bond. x None See Section 1 b CONTRACTOR AS PRINCIPAL SURETY Company: Precision Communications, Inc. dba PreCom Company: Travelers Casualty and Surety Company of America 1, ~~ I 1~ l~~ i b~ l i i t- t F! ! r' 11 t (Corpa~`ate Seal) Corporate Seat) ~`~,~ ~~~ ~~~~,~, ~~,,,h P ~ ~, +r ~q~ t . ~ r ~ al ~ atur ~ ~ - ... ,c 4i~ Y ~i St ature. ,~. d ~~ ~ / ~~ ~ ~.-~'~'~' Stgn e ~ elf ~ , ~ ~ ~ Y'~ ~ ` " `" `~ me and Brenda J. Sm~~r~ Name and Na Title: Title: Attorney-in-Fact (Any additional signatures appear on the last page of this Performance Bond,) (FOR INFORMATION ONLY -Name, address and telephone) AGENT or ~R~KER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party:} PayneWest Insurance, Inc. 960 Broadway Avenue, Suite 100 Boise, ID 83706 208-424-2900 ?~~, ~~~ ~ ,~•' ~' The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312y 2010 edition 1 ~~ § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. _ § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is nv Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner #irst provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default, Such notice shad indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five {5}business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (I0~ business days of the Surety's receipt of the Owner's notice. Ifthe Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, xf any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected #o perform the Construction Contract, § ~ Failure an the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § ~ when the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § ~.1 Arrange far the Contractor, with the consent of the Owner, to perform and complete the Canstcuetion Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals fi~~n qualified contractors acceptable to the Owner far a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess ofthe Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; yr § 5.4 waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount far which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons far denial. § 6 If the Surety does rat proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Band seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole ar in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. § ~ If the Surety elects to act under ~ectian. ~.1, ~.2 ar 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities ofthe Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance ornon-performance of the Contractor. The Company executing this bond vouches that this document conforms to American Institute of Architects Document A31Z, 2410 edition Z § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.~, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns, § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract ar to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Band may be instituted in any court of competent jurisdiction in the location in which the work ar part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs flrst~ If the provisi€~ns of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown an the page on which their signature appears. § 13 when this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein, When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after al! proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract, § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Doc~zments. § 14.3 Contractor Default, Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.E Owner Default, Failure of the Otivner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14,5 Contract Documents. AlI the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond areas follows; (Space is provided below for additional signatures of added parties, other than those appearing on the cover pogo.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title; Address: Signature; Name and Title: Address: The Company executing this bond vouches that this document conforms to American Institute of Architects llocument A31Z, X010 edition 3 i 1 ACC~I~D® ~ DATE (MMJDaYYYY) CERTIFICATE OF LIABiLITYINSURAN E 08/19f1013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR ~~'ODUCER,AND THE CERTIFICATE HOLDER, . ORTANT: if the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed, If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder ----- PRODUCER coNTACT CLIENT CONTACT CENTER FEDERATED MUTUAL INSURANCE COMPANY yoNE q HOME OFFICE: P.O, BOX 328 A1C No Ext ; 888-333-4949 AIC No ; 507-446.4664 OWATONNA, MN 55060 EMAIL , CLIENTCONTACTCENTER FEDINS.COM INSURER S AFFORDING COVERAGE NAIL # INSURER A: FEDERATED MUTUAL INSURANCE COMPANY 13935 INSURED 343-054-3 INSURER B; FEDERATED SERVICE INSURANCE COMPANY ~ ~ 28304 PRECISION COMMUNICATION INC, PRECOM INSURER C: 710 S ORCHARD ST BOISE, ID 83705 INSURER D; INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 39 REVISION NUMBER; 0 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ILTR TYPE OF INSURANCE INSR SWVD POLICY NUMBER MMIDDYIYYYY MMlDDlYI~'YPY LIMITS GE NERAL LIABILITY EACH OCCURRENCE $1,000,000 X COMMERCIAL GENERAL LIABILITY DAMAGE TO RENTED PREMISES Ea occurrence $100 000 CLAIMS-MADE X~ OCCUR MED EXP (Any one person) $5,000 B Y N 9024741 07!01!2013 07101/2014 PERSONAL & ADV INJURY $1,000,000 GENERAL AGGREGATE $2,000,000 GE N'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMPIOP AGG $2,000,000 X POLICY JECT LOC U ' TOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident 1 000 000 $ > > ~ ANY AUTO NED ULED BODILY INJURY (Per person) B AUTOS AUTOS Y N 9024741 0710112013 0710112014 BODILY INJURY (Per accident) HIRED AUTOS NON-OWNED AUTOS Pe~acciden DAMAGE X UMBRELLA LIAR X OCCUR EACH OCCURRENCE $S,000,OOO A EXCESS LlAB CLAIMS-MADE N N 9024743 07101!2013 0710112014 AGGREGATE $5,000,000 DED RETENTION WORKERS COMPENSATION AND EMPLOYERS LIABILITY ORY AIM TS OER- ANY PROPRIETORlPARTNERIEXECUTIVE OFFICERIMEMBER EXCLUDED? N 1 A E.L. EACH ACCIDENT (Mandatory in NH) E.L. DISEASE - EA EMPLOYEE If yes, describe under DESCRIPTION OF OPERATIONS below E.L DISEASE -POLICY LIMIT DESCRIPTION OFOPERATIONS / LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required) SEE ATTACHED PAGE CERTIFICATE HOLDER CANCELLATION 343-054-3 ~ CITY OF MERIDIAN 3? ~ BROADWAY AVE STE 210 ( )IAN, ID 83642.2619 39 0 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ©1988.2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD A~ ~ AGENCY CUSTOMER ID: 343-054-3 LOC #: ADDITIONAL REMARKS SCHEDULE Page ~ of ~ ENCY .tDERATED MUTUAL INSURANCE OOMPANY POUCYNUMBER SEE CERTIFICATE # 39.0 CARRIER SEE CERTIFICATE # 39.0 DE NAMED INSURED PRECISION COMMUNICATION INC, PRECOM 710 S ORCHARD ST BOISE, ID 83705 EFFECTIVE DATE: SEE CERTIFICATE # 39.0 ADDITIONAL REMARKS _ THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER; 25 FORM TITLE; CERTIFICATE OF LIABILITY INSURANCE CITY OF MERIDIAN 33 E. BROADWAY AVENUE MERIDIAN, ID 83642. CERTHOLDER HAS BEEN AMENDED TO INCLUDE: CITY OF MERIDIAN AND ITS ELECTED OFFICIALS, OFFICERS, EMPLOYEES, AGENTS, AND VOLUNTEERS THE CERTIFICATE HOLDER IS AN ADDITIONAL INSURED SUBJECT TO THE CONDITIONS OF THE ADDITIONAL INSURED BY CONTRACT ENDORSEMENT FOR GENERAL LIABILITY. THE CERTIFICATE HOLDER IS AN ADDITIONAL INSURED SUBJECT TO THE CONDITIONS OF THE ADDITIONAL INSURED BY CONTRACT ENDORSEMENT FOR BUSINESS AUTO LIABILITY. INSURANCE PROVIDED BY THE GENERAL LIABILITY IS PRIMARY AND NONCONTRIBUTORY OVER OTHER INSURANCE. INSURANCE PROVIDED BY THE BUSINESS AUTO LIABILITY IS PRIMARY AND NONCONTRIBUTORY OVER OTHER INSURANCE. ACORD 101(2008101) ©2008 ACORD CORPORATION. A!I rights reserved, The ACORD name and logo are registered marks of ACORD •i ~J:. i. / i~~ . •; i i ~~ i •'I. Ii ~'Ji ,/ ': J•. /. r /.'... r i ~ f : . / • .ti : •~ i !: •i •f: ' •J THIS E~IDQRSEMENT CHANGES 7NE POLICY. PLEASE i2EAd IT GARfFULLY. PRIMARY AND NON-CONFRfiBUTORY CLAUSE ENCi0R5EMENT ~'~is ~~~~~~~~~~~ ~~cdi~~~ €~su~~~~c p.~o~~~~~ ~~d~~ t~G ~0€~~~1i~~; €~ €s ~~~~~~ €h~~ 3ns~~~~c~ ~~c~~i~e~ ~y ~n~ ~~~i~i~~~~i €~s~r~~ ~~}ci~~~~~~~~.~ €s ~r€~~.~ c~~f~~~~e, ~ ~Ii€i ~~~ ~e~k ~a~~~~u~ic~ ~~~ any ~k~e~ in~~~~~ ~~i'~~~ i~s~~~~~$ ~~ a ~o~~v~~r#~i~~ ~~~~s €~ ~~~~€~~~ ~~ ec~~~ac~, 1~€~~~~ copy/rt~#~~e~ r~a.~~~al c~~ €;~s~r~~c~ ~e~~ices ~c~, €~c~ ~~i~h ~~ ~c~€~~€a~. ~~-~-~5 {~}~8-c~3} ~~€€~~r'~~~b~r: ~#}~~~4~ T~~~s~~~a~ ~C~~~tiv~ ~a~~: ~8-~~•~~~~ ~~i~ i.Si~~~~L'.~~if~f~ ~p-~~i.~ ~~~ ~~'1~~~1 i ~~I.ltL 7)ii~~ ~~ ~~i~1~i ~J~~~~ PRIMARY AND NON-GON7RIBUTORY GL4USE ENDORSEMENT "~h~~ e~~~~s~rr~e~~ d~~~e~ En~~~~~e~ pr~~~~~P~ ~~~~~~h~ f~~~~~~~~~: ~~~i~~ s~ A~`~~ C~3~~i~~~~ ~t~~~ ~A~A~ ~~~~~~ ~~~~ ~~frth ~~~p~~ ~~ ~~~~~~ ~f~~~~gd ~~ ~h~s e~~~~se~r~n~;:: ~€~~;:~~~~~~~a~~: ~f~?~.>~~~~~~.~~ ~~~~; ~~~~~~~~<.~~~~s~;. ~~ ~;r the ~nd~r~~~~~~. ~~ ~~, ~~~~~~ ~~~ ~ ~~s~€~~r~u~ ~~a~~iu~~ ~y ~n~~~~~~~~g ~~yur~~ ~nci~~s~~~~~ ~s ~~~~~ ~1~~~ pr~m~~ ~~~~~~ ~s r~~c~r~d ~r~ ~ ~~r~f~~~ ~~";t~~c~. ~ ~~rE~l ~i~# ~~~~ co~~i~~~~a~ f~~t~ any ~~s~~~~ u~~h~~ ~~y~f~~~~ ~'; a t?~e~- .ntrEb~:~n~ b~~~s Es ~~~~i~-~~ its ~ ~ri~t~~ ~o~'~~~t, i~~~r ~a~~r~g~ ~~ ~p~~~~, ~h~ ~r~i~~~ c~~~t~~~ ~~~~;~ h~~r~ ~~ . ~~~ . :; ~~ ~~ ~~ ~ ~~2~~:~ Y~l L~~~~~~~~~ ~~~L~ t ~i~ ~~~t~~~ ~i.1.~~b 11~~~ ~~ ~irl ~Tr~~~ ALlQ1Tf0~A~. [f~SURE~ BY ~CE3MTR~tCT ~NQ~3RSE~~NT Tres ~~darsar~ent ~a~ifiCs i~sura~ae p~o~ided under the ~iiawi: Ga~~~i~~ A-.~~ ~r~Ti~..~~;T~€~~ ~'~~~'~Titf~ #.i.~~~#.i i~' ~~~1~~~ ~~~~' .~. ~ec~on ~I ~ i~o ~~ #~ ~~sur~~d ~ emended #~ i~ci~c~ ~~ ari additianai ins3.~red a~~ persc~a or or~~ai~atioa: ~#~le~' #~'f~~ ~,~glni ~'~n~ur~; ~Ckr t~i~o~~n ~'ou are .per€orr~ing Cp~r~ti~ana ~r~~e~ ~~u end sua~ p4rsor~ or or~~-- Giza#ion ha~~e ~~reed ~~ ~rdtinc~ it ~ ~ aa~#rac# or a~reeme~€ that s~rc~ person ar c~rg~~i~ation ~e ~dc~ed as a.r~ addi~onai i~~s~r~d ta!na ~a~r pra~iic~S'•~ ~~}ac,#~~y~rp~r~~saY~ car orc~~:!~~a~arl~ i~ ass addi~~~o~a! ias~red aptly ~~i+~ r~sp~c# '~a ~~akri~~~+,~ far t~~~di~~~ ~S {~4r~Ftf~ Ifp+rL'~Ai Glr ~J~{ 3141~~~11 C! „~e~~~I i~R~ ~~~ Ad Y~~ s~~i41~ ~Y t~Lil,~lf ~~~3~~1,1~ 17 i YPt11fJtGy ~S~ ~t i pGi(S~ 3J~R~~ ~. The aG#~ cr omissi~r~s of #hosa ~~#ir:~ cn y~}~r be#saif its the pe~'orrn~r~ae. of ~r~our o~~air~ aeratia~s for the eddi#iar~~l iasu~~ed. A ~~sa~`~ ~~ +~fg~n~~~'~ ~#~#us ~~ ~~ ~ddi~i~r~~ ir~~u~ ~r~d~r finis ~nd~r~~~ea# e~~~ ~~~~;~ y~~~r operations for ghat ~dditio~a~ insured are caieted. Tr~is adi;i~ir~~si i~~+aref~~;~ ~.~a~s ~~t~~ a~~i~ ~~; ... ..,. n er~pi~,yee~, assocEatio~i a€ e~ployees~ .... ..:.. ~ ...... .... . .. ... . o~ iahar ~un~~n~:::e~c~p~ ~u~~#~ .~~.spe ~ ~~ u~~~k~:p~r~~r~~~~~ ~~~±:or ~~r you i"o~ ~~~;~~ a~x~play~ee, ~a~ya#~an of erriplaye~~:~:~~~~~~~~~.ur~~~E:~'~~~~~~.~t~~~~~~#~~i:~~~ra~~t~.k~~~~~:~i: ~ ~~-~~~~~: .. n~ra~tar and s~ah en~pitiye~;, sss'~c'ietio:~ of e~~~~~~~~~~~i~~~~:~t:~~io~:~~s~:~f~~~~;i~s~~~ ~, r~y~(y~ r~iiyroad~y~~sy.f~~pyay~[y~ ~~}~c~pp~i~yy~riyf ~ree~sy~pre~}~#~~y~~e~~~ ~~re~~(f~~~~(d~~ ~~`~/~~~'yyf~1~~ ~lat(i~f~~~:s~~~~ ra~iiroad ~c~r~~~a~y U}iLd~~~?~e~~ LVF{{r~.i{l~iJ~ t:(~~GCii}Se}14 ~felgY~ei1 ~'~li~ G~ JUVS~ SCt~~i1~A~~ ~~ll}(pGt~~~j'J~ 3, ~~y parson ar org~aiza#~n ~~~ase pra~~an, ~~si~es~ ar aact,~p~ti i~ #~~# oi' ~~ arr~i#ec#, ~3~~~11~~CC ~r ea~Eneer Ith respao# ~#o li~h~;ct~ ar~a~ acct of the preparation a~ appra~tai of o~ #~e fa~iufe ~~ prep~ra#iQ~ ar ~ppr+~~~ of ~~p~, ship drav~f'sf3g a! ~pir~~~s, ro~r~~, St,~c~E:r~~, f~€d t~?'~Cr~, c~~n~e c~r~c~, d~si~n.ys c~rawln~s; s~pec~~caio~s car the peri~ar~ra~~e of ~~~ ati~er pr~essiQnai se~iees ~y such persa~f ar ar~ar~EZa~~an;. ~. ~a~ of your ~u~ontr~e~ors, ac ~~~ pa;°kner, affio~r, ~~e~~# ar empioyee o~ such ~ub~,ar~~ac~c;, ~. Tie ~oYeruce ex#e~ded #v ~r~y addr#i~~~i injured ~y #~is e~dor~e~en~ i~ ii~it~d ta, ~ ~u~sjecfi ~~ ail #e~~~ ~a^;ditiQ~~, aid ~xc~c~~irros ~# ~hC ~over~{~~ pad #o ~~~i~ich ~ ~nd~~rs~en# i•~ e~aci~eti, ~r~ a~di~on ~QV~~'~f~~e ~hc~l~ i"f0~~ e~cce~d #i~e tCC~~ ~~~ Co~~i~ir~ns ~%',~~~ are ~`~~u13' ~y e Perms t3~ ~hC ~rrii:#er~ ~gra~m~nt tC ~d~f ~a~ it~~~rad, Cr #a pracut~ in~~r~a~ ~. in ~~e e~re~~t ~ha# the ~,If~~iEs o~ in~uran~x s~a~~~n in tie ~e~r~aretian~, e~cee~~ tie limits of iia~iii~~ required ire ~ wrier co~frac# ar w~rier~ a~reemen# fog a:n ~ddi#ioaai +rsured, the insurat~~e prQ~ridef~ to the a~ditiar~al ~r~sur~d s~eii ~~ I~~~~ed #c~ the i~rn~~ a# i~~~ki~ty ret~~tr~ci by ~#~~k ~tr~ti~n c~nira~,# or ~~rr~t#e~ a~reermm~~ ~, ~ddi~iar~ei exric~siar~s. `,e ins~trr.;nae of#~rded #a any person dr or~an~ation as an insured under t€~s endarsen~a~~ does no# ap~~. ~a ~o~~i~ ~~ ~~ ~, ' ~ " ~ ~", ~proper~y ~aa~e~ ar ``personal and ac#~e~isin~ ir~~ury{~ which accs~rs prior ~o tie d~.~ of .y~~r CCat~~a~ r~r~#h s~~~ peen Cr Cf~c~~E~'~~:#C~1; ~. ~'a ~'~oc~iiy ir~~uryrR ar''prr~perty dama~en included ~~i#F~ i~ the "produ~stcc~rnpleted apera:ion~ hazard," ~, ~'~ ``~odii~t ir~ju~y,~t "properly damn,: ar S`p.e~sanai and a~~~er#i~in~ injury, ari~in~ au# of ~#ha pie r~e~iic~~~~~;~ of ~n~ p~r~c~n or vr~:~i3z~~~~ t~e~ ~s~~fd ~4i a~i ias~~ed ~~r~~r# far ihi~ ~:~d~xs~~nt. ~:~1Y,:~~t~~"a.. ~C4p~:~'i~~#~~ C~'~~;~.~~'~#,.r~, E~'~3f~:~ri.~'~~~w C~'~~C+~:~::~~#t~•;:~~I~. ~~~~~a"~~~ .e5~#C~. .~ , . :,:~'• , ~f ~~~+r~~LT~~~LiT~~! ~~~~~L~~ 1a1~~~~~M~/~ f ~i.~~~ ~~1.f ~~ ~~il~! li'i.~~~ :~!~~~~f~ ; ~~~~~~:~~ ~~c:~u~: -~~~ : E~~s:~~.~~ :::ail ..~r:~ ~:::e~~ ~~~ ~ a ~~~ ~ ~ ~~ ~~ ~~~, ~ r ~~ :~ ~ : ,, : ~ ~ r ~~ .. ~~: 1~' i,~~:~i~~~~~~#~~~~~ €-~~~h~~i~~ f~j~cr~"~~~~`~``~rc~p~s~~~~ ~~~~~R~~..ff~~ii~i~~~ f~~ ~~~~~~~ ~~ i3~r~~~~~; A~~ rs~~ ter or~a~~i7atior, o~~ar t13~~ a ~a~~~ ~f~~~l~rp} ~~r ~I~i~;h ~~s~ 13~v~ aura ~~ ~v~i~~~€~ ~o~~r«~fi ~ pr~~t~~~ ~r~dll~ f~~~~~y or ~~a~~ ~~~~~~ "~~~o" If~~ilir f~s~,~~~~~ ~~i~-~~ opt of ~~~rr~i~~ ~€ ~ ~~~~x~~ ''a~a~o" ~~f~~ ~o~r ~~r~issio~. I~ov~a~~r, ~I~is ac~di~ior~al ir~s~ra~oo ~v~s ~~ a~f~l~ ~o: (~ ~ ~~a ~tiTY~er ~ any~sn~ ~~~~ ~r~~ ~r~~ you lira ar b~r~~~~ a ~~~~r~~ "a~tc~", his ~x~i~ ~a~s n~~ ~p~€~ i~ tl~o ~o~ered Rata" i~ a "~r~~r~ ;~e~toc~ ~~ a ~~~~a~~ "a~~o" ~ 4s~~~. Lei ~'~~r s'~~.~fo~e~~ f~ tl~~ oo~rerod "a~to~" i~ o~~~n~~ b~ ~i~~~ '`~~~lo~~~'' ~~ a ~~~~~~ a~ Isis ~r I-~er ~-~~1a~f~C~~~. ~3~ ~o~;~e u~i~~ a ~ov~~'a~ ~a~cau ~~f~ile fro o~ ~~ fs ~~orki~~ i~ ~ ~~~€~as~ ol: saliir~g- n~ici~~i ~~~af~~~} :~rl~in~ o~ ~t©r~~~ "~~ttos" ~~~ss ~a~ b~~i~~s~ f-~ yours, ~~~ ~: ~~~Q~~~ 0~~'3~`C ~~8~ ~/o~~' tr'~~'3~~0~~~`~"y ~a~~~~r~ cif yon ara a ~a~; ~er~hi~}~ ~or~~~rs ;s~ yon are a iii#~d,,} ~i~bii~~ c~~4~a~~~, o~r ~ ies~ or bQ~rE~ ar a~~ cif sir "~~p~v~~sR, ~~ii~ ~-fo~i~~ ~~~ ~ ,~~~n~r ~i~ ~o~ are a ~--~r~~rl~~, ~r ~ ~a~~ (~' yQ~ era ~ li~i~~~ fl~~l#i~,~ ~o~~~~~~ for a c~~Yare~ "a~~o°' a~r~~d b~ i~l~ or ~~~r ~r a ~am~ar ~ hi.~ o~ ~~r ~~~~I~o~~. ~, ~'f~~ ~4~ar~~~~ ext~~~e~ ~~ a~~r a~d3tfa~al f~~~~r~+~ ~~~ tf~is ~n~~ors~Ex~~nt i~ ff~i<~ to, a~~ ~~~1~~# ~o aff ~~r~~~, ~ditior~, aid ax~f~~ior~~ c~~ ~~ ~o~r~rag~ f~ar€ #o r~d~i~f~ ~f,,~ ~~~or~or~~~~ i~ atta~lr~ad. fry ~~r~i~ff~r~, ~~~~x~c~~ ~I~~II r~o~ ~xc~~ct #f~~ ~~; rn~ a~tf cv~~iti~n~ tf~a~ art r~~~rir~~ ~y #I'~~ ~~rr~s c~#: ~#?e ~rf~~~ ~, ~~dil~on~t ~xcc~~i~~s.. TI1e i~~~ra~c~ a~ord~d ~Q ~~~ ~~r~~~ or os~a~iz~ti~~ a~ ~~ i~SUr~d U~?~r f,l~i ~~~~o~~~~~c~~ ~~~~ ~o~ a~pi~r; ~. ~o „~SR wl'aici•~ o~~ print #~ t~~o ~a#o o€ ~o~c t~r~:~~~i~~~~~i:~':.~.~~:~„~~~..~~z~;~i'# ~r ~r~~~:~~~~~~t~ ~x~~i ~vr tf~is ~~rd~r~e~a~t. 3. `r~ '~~~~" i'ar ~~~ t~a~~d or r~~t~ "auto" ~r~~n~ ~h~ i~~~,sc~r f~r`hi~ a~r der ~g~r~t ~i~€s~s p~~s~ssi~~ ©f the I~~~e~ ar Y~~t~ "a~~o" or ti~~ pc~l€~r ~orind ~~d~r ~~hi~l~a~ror cc~~r~ #fr~~. ...... . ,.,,.,. ~~i~r~c~~d~~ ~~ ~ ~ i~ C~ ~ ~i ~ `~ '~ ~~~ . ..~~.. .. ~ ~ ~,r>i!3 a~err~ ~~~z~~~~: :~'ra~~~ia ~f ~~~~tir~:.:~` ~~~ .~~ ~~':.::._... Client#: 82677 PRECOM A CORDTM Cj E R DATE (MMIDDIYYYY) TIFICATE OF LIABILITY INS URANCE 910412013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THI CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE P S BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSU OLICIES 'RESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. RER(S), AUTHORIZED ....~ORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, sub'ect to '~ the terms and condltlons of the policy, certain pollcles may require an endorsement. A statement on this certificate does not confer ri hts to the certificate holder in lieu of such endorsement(s). 9 PRODUCER CONTACT PayneWest Insurance, Inc. PHONE A1C, No Ext : FAX University Plaza Alc, No E-MAIL 960 Broadway Avenue, Suite 100 ADDRESS: Boise, ID 83706.3689 INSURER(S) AFFORDING COVERAGE NAIC # INSURER A ;Employers Compensation Insuranc INSURED Precision Communications, InC. INSURER B DBA: PreCom INSURER C 710 S. Orchard St. INSURER D ; Boise, ID $3705 INSURER E ; INSURER F COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDLSUBR LTR TYPE OF INSURANCE POLICY EFF POLICY EXP INSR WVD POLICY NUMBER MMIDDIYYYY MM1DD LIMITS GENERAL LIABILITY EACH OCCURRENCE $ COMMERCIAL GENERAL LIABILITY DAMAGE TO RENTED PREMISES Ea occurrence $ CLAIMS-MADE ~ OCCUR MED EXP (Any one person) $ PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ GEN'L AGGREGATE L1MIT APPLIES PER: PRODUCTS - COMPIOP AGG $ POLICY PRO- JECT LOC $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ ANY AUTO BODILY INJURY (Per person) $ ALL OWNED SCHEDULED AUTOS AUTOS BODILY INJURY (Per accident) $ HIRED AUTOS NON-OWNED PROPERTY DAMAGE AUTOS Per accident $ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION $ A WORKERS COMPENSATION $ AND EMPLOYERS' LIABILITY EIG122580803 710112013 071011201 X f RY L M TS °RH- ANY PROPRIETOR/PARTNEWEXECUTIVE Y 1 N OFFICERlMEMBER EXCLUDED? a N I A E.L. EACH ACCIDENT $100~QQQ (Mandatory in NH) E.L. DISEASE - EA EMPLOYEE $100,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE -POLICY LIMIT $500,000 DESCRIPTION OF OPERATIONS 1 LOCATIONS 1 VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required) RE: Meridian Waste Water Treatment Plant 3401 N Ten Mile Rd. Meridian, ID 83642 CERTIFICATE HOLDER CANCELLATION __ City of Meridian SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 33 E Broadway Ave., Ste 106 ACCORDANRCE I WITH ATHE THEREOF, NOTICE WILL BE DELIVERED !N POLICY PROVISIONS. Meridian, ID 83642 AUTHORIZED REPRESENTATIVE ©1988.2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) 1 pf 1 The ACORD name and logo are registered marks of ACORD #S9602061M933046 KMS1 vii~i~icu 1 arc Login Public Contractor Search PERMITS LICENSE PUBLIC WORKS VIOLATIONS ELEVATORS ~11~t~lDt~ 4~ ~ r ~ x x~ r~. ~o *. ~ .~ ~. 1v~ ~~ ~ ~° ~~, ~~ ~~ _, _~ ,~: rage ~ o~ ~ Public Works Search ~- Search Again Download Results Printable View Company Name License Number UVork Category(s) License Type L Precision Communications, Inc. dba PreCo PWC-C-12640 02500,13850, 16700,16000 4 ~ Page:1 of 1 Details -License Number: PWC-C-12640 u....._~_._. ,....___.____M.._.....__._..___~...._._~ Lic info `Bus Lic ~; Fees $850.00 I ~ ---_____~ ~ ____ L__ ___ _____.. ____ __.- -------- --____-- Registration#: PWC-C-12640 Issue: 5120!2013 Expire: 5/31/2014 Type: PUBLIC WORKS Sub-Type; A Status: ACTIVE Comp/Name: Precision Communications, Inc. dba Pr• Address1: 710 S Orchard St City, State, Zip: BOISE, ID 83705 Phone: (208) 344-3660 Cell: (208) 860-2458 Pager: Fax: (208) 344-0095 Owner Name: Home i CONTACT US ~Ii:Cr?'d~ Qr ~ +f''r ` ~ t ra S ~~s1~t~1~.s https://data.dbs.idaho.gov/Etrakit2/Idaho_PublicWorksSearchRslts.aspx 8/26/2013 ~~-~~-~ ~ ~cw~~~~ ~u~iliCa~ ~~l~~~y rage l o~ ~ "~~r t:....ti~~. FDA 0 C TA 0 SAT ~~~ y F. + ~~ ~. ,~ ~~ ~ !4 j i ~.~~, R ~~ ~j V~w~ i~S~ s.J~ ~~~~ P ;~ ij,r 7 ~, ~~,,, '~~ ~~~ Ben Ysursa, Secretary of State [ New Search ] [Back to Summary ] [ Get a certificate of existence for PRECISION COMMUNICATIONS, INC. ] ~ NA~°~ N, ~N~ 710 S ORCHARD ST BOISE, ID 83705 Type of Business: CORPORATION, GENERAL BUSINESS Status: GOODSTANDING, ANREPT SENT 11 Apr 2013 State of Origin: IDAHO Date of 30 Jun 1993 Origination/Authorization: Current Registered Agent: HEIDI WOODHEAD 710 S ORCHARD ST BOISE, ID 83705 Organizational ID /Filing C102626 Number: Number of Authorized Stock 1000 Shares: Date of Last Annual Report: 13 May 2013 ri i il~ [ Help Me Print/View TIFF ] Filed 30 dun 1993 INCORPORATION View Image PDF format) View Image STIFF format) Report for year 2013 ANNUAL REPORT Report for year 2012 ANNUAL REPORT Report for year 2011 ANNUAL REPORT Report for year 2010 ANNUAL REPORT Report for year 2009 ANNUAL REPORT Report for year 2008 ANNUAL REPORT Report for year 2007 ANNUAL REPORT Report for year 2007 CHANGE ADDRESS Report for year 2007 CHNG RA/ RO Report for year 2007 CHNG 0 FF/DI R Report for year 2006 ANNUAL [ Help Me PrintlView TIFF ] View Document Online View Document Online View Document Online View Document Online View Document Online View Imaae (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Imaae (PDF formats View Image (TIFF format) View Image (PDF format) View http://www.accessidaho.org/public/sos/core/C 102626.html 8/26/2013 REPORT Report for year 2005 ANNUAL REPORT Report for year 2004 ANNUAL REPORT Report for year 2003 ANNUAL REPORT Report for year 2002 ANNUAL REPORT Report for year 2001 ANNUAL REPORT Report for year 1999 ANNUAL REPORT Report for year 1999 CHANGE ADDRESS Report for year 1998 ANNUAL REPORT Report for year 1997 ANNUAL REPORT Report for year 1996 ANNUAL REPORT Report for year 1995 ANNUAL REPORT Report for year 1994 ANNUAL REPORT Report for year 1993 ANNUAL REPORT Idaho Secretary of State's Main Page 1C1~0001G Image STIFF format) View Ima ge~PDF formats View Image TIFF format View Ima qe PDF formats View Imaqe (TIFF format) View Ima qe PDF formats View Image (TIFF format View Ima qe (PDF format) View Image (TIFF format, View Ima ge PDF format) View Imaqe (TIFF format) View Ima ge PDF formats View Image (TIFF format) View Ima ge PDF formats View Imaqe (TIFF format View Ima ge (PDF formal View Image (TIFF format) View Ima g~PDF formats View Imaqe (TIFF format) View Ima ge PDF formats View Imaqe STIFF forma View Ima qe PDF format, View Image (TIFF format) View Imag e PDF formats View Imaqe STIFF format View Ima qe PDF formats View Image STIFF format State of Idaho Home Page Comments, questions or suggestions can be emai(ed to; sosinfo a sos.idaho.gov http://www.accessidaho.orglpublic/sos/corp/C 102626.htm1 8/26/2013