HomeMy WebLinkAboutIndependent Contractor Services Agreement with Brown Constrution for Victory Road Sewer Connector Pipeline~~i~E IDIAN~-
Public ~ D A H O
Works Department
TO: Mayor Tammy de Weerd
Members of the City Council
FROM: John Boyd
Engineering Technician II
DATE: January 26, 2011
Mayor Tammy de Weerd
City Council Members:
Keith Bird
Brad Hoaglun
Charles Rountree
David Zaremba
SUBJECT: APPROVE THE BID AMOUNT OF $365,115.75 FROM BROWN
CONSTRUCTION FOR THE VICTORY ROAD SEWER CONNECTOR
PIPELINE AND AUTHORIZE THE MAYOR TO SIGN THE
AGREEMENT
I. RECOMMENDED ACTION
A. The Public Works Department recommends the City Council move to:
1. Approve the Bid Amount of $365,115.75 for the Victory Road Sewer
Connector Pipeline Installation Project with Brown Construction.
2. Authorize the Mayor to sign the agreement.
II. DEPARTMENT CONTACT PERSONS
John Boyd, Engineering Technician II (Project Manager)
Clint Dolsby, Asst. City Engineer
Warren Stewart, PW Engineering Manager
Tom Barry, Director of Public Works
489-0364
489-0341
489-0350
489-0372
Page 1 of 4
VICTORY ROAD SEWER CONNECTOR PROJECT
III. DESCRIPTION
A. Proposed Project
The proposed project consists of constructing a connecting segment of the Black
Cat trunk sewer, approximately 2,600 feet along Victory Road, east of Meridian
Road. The City intends to move the project forward into construction as a City
initiated and managed Public Works project.
A portion of this project also includes existing power poles to be held up or
relocated during construction by Idaho Power Company (IPCO). After the sewer
main is completed, IPCO will need to reset those poles that were relocated and
reinstall the electrical lines.
B. Background
In 2007, the Black Cat trunkline network was extended to the corner of Meridian
Road and Victory Road. At that time planned development was tasked to extend
the trunkline network to the east on Victory Road to connect it to a portion of
south Meridian. Due in a large part to the slowdown of the economy, this trunk
sewer has not been constructed and development in this portion of Meridian,
south of the freeway, has been restricted since 2007 as a result of sewer system
capacity concerns. This situation has precipitated requirements for off-peak lift
stations for some developments. With this project, approximately 2,600 feet of
trunk sewer associated with the Victory Road connector will be constructed which
could eliminate the capacity concerns and the need for off-peak lift stations. This
trunk sewer will run from the intersection of Meridian Road and Victory Road
east to the diversion structure near the Observation Point subdivision to connect a
portion of south Meridian to the Black Cat Lift Station.
IV. IMPACT
A. Strate ig c Impact
This project supports the Public Works Mission and Vision for strategic growth
and meets our mission requirements to indentify and prioritize work to anticipate,
plan and provide public services and facilities that support the needs of our
growing community, ensuring modern reliable facilities while maintaining
financial stewardship.
B. Service/Delivery Impact:
The installation of this sewer trunkline will allow the Observation Point lift
station to be removed from service. It will also remove the requirement for several
other proposed small lift stations and off-peak pumping stations to be built as the
effluent will now be channeled through this trunkline to the Black Cat Lift
Station.
Page 2 of 4
VICTORY ROAD SEWER CONNECTOR PROJECT
IV.
IMPACT (Continued)
C. Fiscal Impact /Project Costs
The City received bids for the above project on January 13, 2011 at 2:30 PM.
The low bidder was Brown Construction with a bid amount of $365,115.75 for
the sewer line installation in Victory Road and we recommend not to award the
Bid Alternate as the benefits were not sufficient to warrant installing the stored
materials.
A portion of this project will include existing power poles to be held up or
relocated during construction by Idaho Power Company (IPCO). This cost was
not included in the bid as IPCO was not able to provide firm costs to the
contractors due to unknown construction circumstances, such as length of time the
poles will need to be held. IPCO estimated this cost at $40,000 to $60,000. We
will process a change order that will fall within the approved budget for this
project when these costs are finalized.
D. Project Cost
Bid Amount ...........................................................................................$365,115.75
Total Cost .............................................................................................$365,115.75
E. Project Funding
This project is expected to be reimbursed in it's entirety by eight (8) developers,
of which five (5) have contributed approximately $260,000 to date. At the
completion of the project, developer reimbursement will be adjusted based on
final project cost and reimbursement will come prior to those developers
receiving Final Plat signatures or releasing of their existing sureties.
The project will be funded with existing City funds from the following account.
Sewer Line Extensions (3590-93505) ...................................................$461,627.33
Funding .................................................................................................$461,627.33
V.
ALTERNATIVES
A. The City could defer this sewer connector project thus requiring several small lift
stations and off-peak pumping stations to be built by current developments.
However, once effluent flows are to a point that the present sewer mains cannot
handle the flow anymore, this connector will have to be built and the City may
have to provide 100% funding for installation.
Page 3 of 4
VICTORY ROAD SEWER CONNECTOR PROJECT
VI. LIST OF ATTACHMENTS
A. Agreement for Construction - Signed by Brown Construction
B. Bid Tabulation Spreadsheet
C. Engineering Construction Cost Estimate from Consultant
D. Purchase Order Requisition
l
Approved for Council Agenda:
D to
Page 4 of 4
AGREEMENT FOR INDEPENDENT CONTRACTOR SERVICES
VICTORY ROAD SEWER CONNECTOR TRUNK -CONSTRUCTION
PROJECT # 10191
THIS AGREEMENT FOR PROFESSIONAL SERVICES is made this day of
January , 2011, and entered into by and between the City of Meridian, a municipal
corporation organized under the laws of the State of Idaho, hereinafter referred to as "CITY",
33 East Broadway Avenue, Meridian, Idaho 83642, and BROWN CONSTRUCTION, INC. ,
hereinafter referred to as "CONTRACTOR", whose business address is P O Box 495,
Nampa, ID 83653 and whose Public Works Contractor License # is C-10436-AAA-1.
INTRODUCTION
Whereas, the City has a need for services involving the construction of VICTORY
ROAD SEWER CONNECTOR TRUNK; and
WHEREAS, the Contractor is specially trained, experienced and competent to
perform and has agreed to provide such services;
NOW, THEREFORE, in consideration of the mutual promises, covenants, terms
and conditions hereinafter contained, the parties agree as follows:
TERMS AND CONDITIONS
Scope of Work:
1.1 CONTRACTOR shall perform and furnish to the City upon execution of this
Agreement and receipt of the City's written notice to proceed, alt services and
work, and comply in all respects, as specified in the document titled "Scope of
Work" a copy of which is attached hereto as Attachment "A" and incorporated
herein by this reference, together with any amendments that may be agreed to in
writing by the parties.
1.2 All documents, drawings and written work product prepared or produced by
the Contractor under this Agreement, including without limitation electronic data
files, are the property of the Contractor; provided, however, the City shall have the
right to reproduce, publish and use all such work, or any part thereof, in any
manner and for any purposes whatsoever and to authorize others to do so. If any
such work is copyrightable, the Contractor may copyright the same, except that,
as to any work which is copyrighted by the Contractor, the City reserves a royalty-
Victory Road Sewer Connector Trunk -Construction page 1 of 12
Project 10191
free, non-exclusive, and irrevocable license to reproduce, publish and use such
work, or any part thereof, and to authorize others to do so.
1.3 The Contractor shall provide services and work under this Agreement
consistent with the requirements and standards established by applicable federal,
state and city laws, ordinances, regulations and resolutions. The Contractor
represents and warrants that it will perform its work in accordance with generally
accepted industry standards and practices for the profession or professions that
are used in performance of this Agreement and that are in effect at the time of
performance of this Agreement. Except for that representation and any
representations made or contained in any proposal submitted by the Contractor
and any reports or opinions prepared or issued as part of the work performed by
the Contractor under this Agreement, Contractor makes no other warranties,
either express or implied, as part of this Agreement.
1.4 Services and work provided by the Contractor at the City's request under
this Agreement will be performed in a timely manner in accordance with a
Schedule of Work, which the parties hereto shall agree to. The Schedule of Work
may be revised from time to time upon mutual written consent of the parties.
2. Consideration
2.1 The Contractor shall be compensated on a Lump Sum basis as
provided in Attachment B "Payment Schedule" attached hereto and by
reference made a part hereof for the Not-To-Exceed amount of
$365,115.75.
2.2 The Contractor shall provide the City with a monthly statement, as the work
warrants, of fees earned and costs incurred for services provided during the
billing period, which the City will pay within 30 days of receipt of a correct invoice
and approval by the City. The City will not withhold any Federal or State income
taxes or Social Security Tax from any payment made by City to Contractor under
the terms and conditions of this Agreement. Payment of all taxes and other
assessments on such sums is the sole responsibility of Contractor.
2.3 Except as expressly provided in this Agreement, Contractor shall not be
entitled to receive from the City any additional consideration, compensation,
salary, wages, or other type of remuneration for services rendered under this
Agreement including, but not limited to, meals, lodging, transportation, drawings,
renderings or mockups. Specifically, Contractor shall not be entitled by virtue of
this Agreement to consideration in the form of overtime, health insurance
Victory Road Sewer Connector Trunk -Construction page 2 of 12
Project 10191
benefits, retirement benefits, paid holidays or other paid leaves of absence of any
type or kind whatsoever.
3. Term:
3.1 This agreement shall become effective upon execution by both parties,
and shall expire upon (a) completion of the agreed upon work, (b) September 30,
2011 or (c) unless sooner terminated as provided below or unless some other
method or time of termination is listed in Attachment A.
3.2 Should Contractor default in the performance of this Agreement or
materially breach any of its provisions, City, at City's option, may terminate this
Agreement by giving written notification to Contractor.
3.3 Should City fail to pay Contractor all or any part of the compensation set
forth in Attachment B of this Agreement on the date due, Contractor, at the
Contractor's option, may terminate this Agreement if the failure is not remedied by
the City within thirty (30) days from the date payment is due.
3.4 This Agreement shall terminate automatically on the occurrence of any of
the following events:
a. Bankruptcy or insolvency of either party;
b. Sale of Contractor's business; or
c. Death of Contractor
3.5 TIME FOR EXECUTING CONTRACT AND LIQUIDATED DAMAGES
Upon receipt of a Notice to Proceed, the Contractor shall have 90 calendar
days to complete the work as described herein. Contractor shall be liable to
the City for any delay beyond this time period in the amount of 1 000.00
(one thousand dollars) per calendar day. Such payment shall be
construed to be liquidated damages by the Contractor in lieu of any claim or
damage because of such delay and not be construed as a penalty.
The Contractor must complete the Kennedy Lateral crossing in its entirety by
March 15, 2011. See SP-2101 -Construction Phasing & Scheduling, Part
3, Section 3.1, Item A for further information. Contractor shall be liable to
the City for any delay beyond this time period in the amount of 1000.00
(one thousand dollars) per calendar day. Such payment shall be
construed to be liquidated damages by the Contractor in lieu of any claim or
damage because of such delay and not be construed as a penalty.
Victory Road Sewer Connector Trunk -Construction page 3 of 12
Project 10191
4. Termination:
4.1 If, through any cause, CONTRACTOR, its officers, employees, or agents
fails to fulfill in a timely and proper manner its obligations under this Agreement,
violates any of the covenants, agreements, or stipulations of this Agreement,
falsifies any record or document required to be prepared under this agreement,
engages in fraud, dishonesty, or any other act of misconduct in the performance
of this contract, or if the City Council determines that termination of this
Agreement is in the best interest of CITY, the CITY shall thereupon have the right
to terminate this Agreement by giving written notice to CONTRACTOR of such
termination and specifying the effective date thereof at least fifteen (15) days
before the effective date of such termination. CONTRACTOR may terminate this
agreement at any time by giving at least sixty (60) days notice to CITY.
4.2 In the event of any termination of this Agreement, all finished or unfinished
documents, data, and reports prepared by CONTRACTOR under this Agreement
shall, at the option of the CITY, become its property, and CONTRACTOR shall be
entitled to receive just and equitable compensation for any work satisfactorily
complete hereunder.
4.3 Notwithstanding the above, CONTRACTOR shall not be relieved of liability
to the CITY for damages sustained by the CITY by virtue of any breach of this
Agreement by CONTRACTOR, and the CITY may withhold any payments to
CONTRACTOR for the purposes of set-off until such time as the exact amount of
damages due the CITY from CONTRACTOR is determined. This provision shall
survive the termination of this agreement and shall not relieve CONTRACTOR of
its liability to the CITY for damages.
5. Independent Contractor:
5.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting
as an independent contractor, and neither CONTRACTOR, nor any officer,
employee or agent of CONTRACTOR will be deemed an employee of CITY.
Except as expressly provided in Attachment A, Contractor has no authority or
responsibility to exercise any rights or power vested in the City and therefore has
no authority to bind or incur any obligation on behalf of the City. The selection
and designation of the personnel of the CITY in the performance of this
agreement shall be made by the CITY.
5.2 Contractor, its agents, officers, and employees are and at all times during
the term of this Agreement shall represent and conduct themselves as
independent contractors and not as employees of the City.
Victory Road Sewer Connector Trunk -Construction page 4 of 12
Project 10191
5.3 Contractor shall determine the method, details and means of performing
the work and services to be provided by Contractor under this Agreement.
Contractor shall be responsible to City only for the requirements and results
specified in this Agreement and, except as expressly provided in this Agreement,
shall not be subjected to City's control with respect to the physical action or
activities of Contractor in fulfillment of this Agreement. If in the performance of
this Agreement any third persons are employed by Contractor, such persons shall
be entirely and exclusively under the direction and supervision and control of the
Contractor.
6. Indemnification and Insurance:
6.1 CONTRACTOR shall indemnify and save and hold harmless CITY from
and for any and all losses, claims, actions, judgments for damages, or injury to
persons or property and losses and expenses and other costs including litigation
costs and attorney's fees, arising out of, resulting from, or in connection with the
performance of this Agreement by the CONTRACTOR, its servants, agents,
officers, employees, guests, and business invitees, and not caused by or arising
out of the tortious conduct of CITY or its employees. CONTRACTOR shall
maintain and specifically agrees that it will maintain throughout the term of this
Agreement liability insurance in which the CITY shall be named an additional
insured in the minimum amounts as follow: General Liability One Million Dollars
($1,000,000) per incident or occurrence, Automobile Liability Insurance One
Million Dollars ($1,000,000) per incident or occurrence and Workers'
Compensation Insurance, in the statutory limits as required by law.. The limits of
insurance shall not be deemed a limitation of the covenants to indemnify and
save and hold harmless CITY; and if CITY becomes liable for an amount in
excess of the insurance limits, herein provided, CONTRACTOR covenants and
agrees to indemnify and save and hold harmless CITY from and for all such
losses, claims, actions, or judgments for damages or injury to persons or property
and other costs, including litigation costs and attorneys' fees, arising out of,
resulting from , or in connection with the performance of this Agreement by the
Contractor or Contractor's officers, employs, agents, representatives or
subcontractors and resulting in or attributable to personal injury, death, or
damage or destruction to tangible or intangible property, including use of.
CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof
of insurance evidencing CONTRACTOR'S compliance with the requirements of
this paragraph and file such proof of insurance with the CITY at least ten (10)
days prior to the date Contractor begins performance of it's obligations under this
Agreement. In the event the insurance minimums are changed, CONTRACTOR
shall immediately submit proof of compliance with the changed limits. Evidence
Victory Road Sewer Connector Trunk -Construction page 5 of 12
Project 10191
of all insurance shall be submitted to the City Purchasing Agent with a copy to
Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642.
6.2 Any deductibles, self-insured retention, or named insureds must
be declared in writing and approved by the City. At the option of the City, either:
the insurer shall reduce or eliminate such deductibles, self-insured retentions or
named insureds; or the Contractor shall provide a bond, cash or letter of credit
guaranteeing payment of losses and related investigations, claim administration
and defense expenses.
6.3 To the extent of the indemnity in this contract, Contractor's
Insurance coverage shall be primary insurance regarding the City's elected
officers, officials, employees and volunteers. Any insurance or self-insurance
maintained by the City or the City's elected officers, officials, employees and
volunteers shall be excess of the Contractor's insurance and shall not contribute
with Contractor's insurance except as to the extent of City's negligence.
6.4 The Contractor's insurance shall apply separately to each insured against
whom claim is made or suit is brought, except with respect to the limits of the
insurer's liability.
6.5 All insurance coverages for subcontractors shall be subject to all of the
insurance and indemnity requirements stated herein.
6.6 The limits of insurance described herein shall not limit the liability of the
Contractor and Contractor's agents, representatives, employees or
subcontractors.
7. Bonds: Payment and Performance Bonds are required on all Public Works
Improvement Projects.
8. Notices: Any and all notices required to be given by either of the parties hereto,
unless otherwise stated in this agreement, shall be in writing and be deemed
communicated when mailed in the United States mail, certified, return receipt
requested, addressed as follows:
City of Meridian
Purchasing Agent
33 E. Broadway Avenue
Meridian, Idaho 83642
Victory Road Sewer Connector Trunk -Construction page 6 of 12
Project 10191
Brown Construction, Inc
Attn: Richard Brown
P O Box 495
Nampa, ID 83653
208-465-0274
bcipipe(c~hotmail.com
Idaho Public Works License #: C-10436-AAA-1
Either party may change their address for the purpose of this paragraph by giving
written notice of such change to the other in the manner herein provided.
9. Attorney Fees: Should any litigation be commenced between the parties hereto
concerning this Agreement, the prevailing party shall be entitled, in addition to any
other relief as may be granted, to court costs and reasonable attorneys' fees as
determined by a Court of competent jurisdiction. This provision shall be deemed
to be a separate contract between the parties and shall survive any default,
termination or forfeiture of this Agreement.
10. Time is of the Essence: The parties hereto acknowledge and agree that time is
strictly of the essence with respect to each and every term, condition and
provision hereof, and that the failure to timely perform any of the obligations
hereunder shall constitute a breach of, and a default under, this Agreement by the
party so failing to perform.
11. Assignment: It is expressly agreed and understood by the parties hereto, that
CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell
any of its rights under this Agreement except upon the prior express written
consent of CITY.
12. Discrimination Prohibited: In performing the Work required herein,
CONTRACTOR shall not unlawfully discriminate in violation of any federal, state
or local law, rule or regulation against any person on the basis of race, color,
religion, sex, national origin or ancestry, age or disability.
13. Reports and Information:
13.1 At such times and in such forms as the CITY may require, there shall be
furnished to the CITY such statements, records, reports, data and information as
the CITY may request pertaining to matters covered by this Agreement.
13.2 Contractor shall maintain all writings, documents and records prepared or
compiled in connection with the performance of this Agreement for a minimum of
four (4) years from the termination or completion of this or Agreement. This
Victory Road Sewer Connector Trunk -Construction page 7 of 12
Project 10191
includes any handwriting, typewriting, printing, photo static, photographic and
every other means of recording upon any tangible thing, any form of
communication or representation including letters, words, pictures, sounds or
symbols or any combination thereof.
14. Audits and Inspections: At any time during normal business hours and as often
as the CITY may deem necessary, there shall be made available to the CITY for
examination all of CONTRACTOR'S records with respect to all matters covered
by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and
make excerpts or transcripts from such records, and to make audits of all
contracts, invoices, materials, payrolls, records of personnel, conditions of
employment and other data relating to all matters covered by this Agreement.
15. Publication, Reproduction and Use of Material: No material produced in whole
or in part under this Agreement shall be subject to copyright in the United States
or in any other country. The CITY shall have unrestricted authority to publish,
disclose and otherwise use, in whole or in part, any reports, data or other
materials prepared under this Agreement.
16. Compliance with Laws: In performing the scope of work required hereunder,
CONTRACTOR shall comply with all applicable laws, ordinances, and codes of
Federal, State, and local governments.
17. Changes: The CITY may, from time to time, request changes in the Scope of
Work to be performed hereunder. Such changes, including any increase or
decrease in the amount of CONTRACTOR'S compensation, which are mutually
agreed upon by and between the CITY and CONTRACTOR, shall be
incorporated in written amendments which shall be executed with the same
formalities as this Agreement.
18. Construction and Severability: If any part of this Agreement is held to be invalid
or unenforceable, such holding will not affect the validity or enforceability of any
other part of this Agreement so long as the remainder of the Agreement is
reasonably capable of completion.
19. Waiver of Default: Waiver of default by either party to this Agreement shall not
be deemed to be waiver of any subsequent default. Waiver or breach of any
provision of this Agreement shall not be deemed to be a waiver of any other or
subsequent breach, and shall not be construed to be a modification of the terms
of this Agreement unless this Agreement is modified as provided above.
Victory Road Sewer Connector Trunk -Construction page 8 of 12
Project 10191
20. Advice of Attorney: Each party warrants and represents that in executing this
Agreement. It has received independent legal advice from its attorney's or the
opportunity to seek such advice.
21. Entire Agreement: This Agreement contains the entire agreement of the parties
and supersedes any and all other agreements or understandings, oral of written,
whether previous to the execution hereof or contemporaneous herewith.
22. Order of Precedence: The order or precedence shall be the contract agreement,
the Invitation for Bid document, then the winning bidders submitted bid document.
23. Applicable Law: This Agreement shall be governed by and construed and
enforced in accordance with the laws of the State of Idaho, and the ordinances of
the City of Meridian.
24. Approval Required: This Agreement shall not become effective or binding until
approved by the City of Meridian.
CITY OF MERIDIAN
.~ ~ /
TAMMY.dQv'WEERD, MAYOR
/°
Dated: a't I ~~ ~ ~
BROWN CONSTRUCTION
~,,
BY: Richard Brown
Dated: ',,~~ ~l l
Approved by Council: ~ ~~- own!/
i`~1~5111111111////~/
~`~~~~~ ~ M~jO~9'L ~~''-.
Attest:
= S L
~ ~Q~
ST15~•~ ~;''
JAYCEE HOLMAN, CITY CLERK /0,9 `~Q-,A,,,<
~; .,
cave ; ,.~~
rlr;r;:~,~1",
Victory Road Sewer Connector Trunk -Construction
Project 10191
page 9 of 12
Approved as to Content
BY:
KEIT ATTS, PURCHASING MANAGER
Dated: 1-- ~ y - ~
Approved as to Form
CITY ATTORNEY
Victory Road Sewer Connector Trunk -Construction
Project 10191
Departure t Appr al
BY:
NAME: (~Jw.ti~R„gN -n..Q T-
TITLE: ~1c-zN~.R-zzh~ N~tA.~-Ac.~,
Dated: r -
page 10 of 12
Attachment A
SCOPE OF WORK
REFER TO INVITATION TO BID PW-11-10191
ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation
to Bid Package # PW-11-10191, are by this reference made a part hereof.
Victory Road Sewer Connector Trunk -Construction page 11 of 12
Project 10191
Attachment B
MILESTONE /PAYMENT SCHEDULE
A. Total and complete compensation for this Agreement shall not exceed $365,115.75.
PRICING SCHEDULE
Furnish all labor, materials, equipment, and incidentals as required for the VICTORY ROAD SEWER
CONNECTOR TRUNK - (CONSTRUCTION), per Bid # PW-11-10191.
Spec Payment Item Description Est Uni Unit Price Total Price
Reference Qnt t
205.4.1.8.1 Dewaterin 1 LS $ 1.00 $ 1
00
304.4.1.A.1 Trench Foundation Stabilization 500 CY $ .00 .
$ 500
00
306.4.1.D.1 Im orted Trench Backfill 500 CY $ 10.75 .
$ 5
375
00
307.4.1.F.1 T e P Surface Restoration 245 LF $ 93.00 ,
.
$ 22
785
00
501.4.1.6.1 Gravi Sewer Pi e - 8" PVC 158 LF $ 93.50 ,
.
$ 14
773
00
501.4.1.8.1 Gravit Sewer Pi e - 27" PVC 2661 LF $ 83.75 ,
.
$222
858
75
501.4.1.E.1 Abandon Existin Sewer Lift Station 1 LS $ 4,000.00 ,
.
$ 4
000
00
502.4.1.A.1 Sanita Sewer Manhole - 48" T e A 2 EA $ 4,090.00 ,
.
$ 8
180
00
502.4.1.A.3 Sanita Sewer Manhole - 60" T e B 5 EA $ 6,471.00 ,
.
$ 32
355
00
502.4.1.F.1 Connection to Existin Manhole, 27" 2 EA $ 7,600.00 ,
.
$ 15
200
00
706.4.1.B.1 Concrete Valle Gutter 8 LF $ 28.00 ,
.
$ 224
00
1103.4.1.A.1 Construction Traffic Control 1 LS $ 2,500.00 .
$ 2
500
00
2010.4.1.A.1 Mobilization 1 LS $ 5,000.00 ,
.
$ 5
000
0
SP-2105.4.1.A.1 Sewa e B ass Plan 1 LS $ 200.00 ,
.
$ 200
00
SP-2105.4.1.8.1 Sewa e B ass Control S stem 1 LS $ 2,340.00 .
$ 2
340
00
SP-2216.4.1.A.1 Storm Water Mana ement 1 LS $ 3,485.00 ,
.
$ 3
485
00
SP-2217.4.1.A.1 IPCO Power Pole Support 1 LS Direct Cost ,
.
Direct Cost
SP-2218.4.1.A.1
Kenned Lateral Crossin
1
LS Reimbursement**
$25
339
00 Reimbursement''*
$ 25
339
00
,
. ,
.
TOTAL C ONTR ACT AMOUNT .... ... $365,115.75
** Contractor is responsible for utilizing Idaho Power personnel in a professional responsible manner as to keep the
costs of the Power Pole Support to a minimum. Additional costs incurred which are out of the control of the contractor,
including but not limited, to the lack of scheduling or due to contractors negligence shall be borne by the contractor.
Travel expenses will be paid at no more than the City of Meridian's Travel and Expense
Reimbursement Policy.
Victory Road Sewer Connector Trunk -Construction page 12 of 12
Project 10191
~ o
0 o
0 o
0 o
o ~n
n o
o o
0 o
0 o
0 o
0 0
0 0
0 0
0 0
0 0
0 0
o .n
n
°o
°o
F ~~
_ O
O
O O
~
N O
y
E N
O~
IO (O
O
01 O
Q
t0 O
(p
M O
~
n N
~
.- O
0
ap O
0 ~(1
0 0
0 0
0 0
0 ~ O
O h
N E O
O O
O
O
D_ ~
n
~
N
~
~
N
(p
~
M N
M O
~ M O
M ~
O O
N O
~ d ry
D
V
m
~ Z
O F
m M
N M
N
W Hi to A (A M f9 (9 Yi f9 to fA f9 H3 H3 fA f9 f9 fA N l. 1 t o f9
r
Q
~
0
o
v
0
~n
N
0
o
N
0
o
V
~n
n
m
0
o
0
0
o
0
0
o
0
0
0
0
o
0
0
0
0
0 0
0 0
0
0
0
o w
~
Z
o°
K
U~ f, ~
'
'
rn
n
M
~ ~
m
in ~
M <6
n
N
o
-- o
o ui
o oo
oo o
0 o
0 ~Q «~
' ~
~
C
LL _
N _
M O_ N . N
M O
?
N M O
M ~
O O
s{
N ~ ~ d`
f9 fA f9 f 9 f A f A f A f 9 U3 ( A f 9 f9 f9 fA f9 f9 fA fA f9
0
0 0
0 0
0 0
0 0
0 0
0 0
0 0 0
0 0 0
0 0 0 0 0 0 0 O O
0 0 0 0 0 0 O O
O
O
f
(n E
d~ 0
0
N 0
0
N 0
0
~ ( N t
0
O ~ 0
M
tl 0
N
M 0
O
O 0 0
0 0
V~ 0
0
V f 0 0 0 0 0 0 0
W 0 0 0 0 0 O N
0 0
F;
~~
p
p
Z _ O
D~
`"-
o
O)
n
~
Q
~
O~
Qi
~
O N
N 0 Kl O M ~ V
n N M ~ (p
N
Z .-~
F N
N N
~
O m m N
~ U 9
m N o
p
y. fa f» f» w we » wf n e>v ~F n fn f»wf»fn en u> w
D
~
f»
O
t~ 0
0 0
0 0
0 0
0 0
0 0
0 0
0 0 0
0 0 0
0 0 0 0 0 0 0 0
0 0 0 0 0
K
O
°
O
O
,,,, U
C .C
O
O
N
W
W
.-
M
n
N
W
e
0
N
-
0
0
O
0 0
0 0
N M
0
0
N 0 o
0 0 0 0 0 0 ~ O
~ 0 0 0 0 0 O
~ O O N LL
~
rt1
U o
~
m
~ a
~
m c
ri ~n
~
O M h
~ in of ~ co n
N N
m
7 a ~
EA f9 fA c 9 f 9 f 9 t o E A fA E A Y 3 f9 43 fA E9 to (A fA f9
0
O 0 0 0
O O O
t 0
p 0
O 0
O 0 0
O O 0
V 0 0 0 0 0 O
O 0 0 0 0 O
~ E
N N
N
M 0 0
O N O
n N 0
. n C
O N
- ~ O O
O
N O
> Q
V O O
'O O
N n N
V
M O O N O O ~ O fV
N O V V O 01
(O W M W O r t+7
~ E
~~ '
OZ D_ F N ~ (
~ O ~ O ~ V I M V W N (O ~ N Z D F
V m " ~ a V m
w F»f »ww F »» f n u ~wr n w F»`»En wviww w
~
~
~
~ O
O O O O
V N N O
N N
W O
0 O
0 O O
0 0 O
c O O O O O O
D O O O O O O f
fq
Q
~
V
"~
C
N
M ~ O O
a > N
p O O
.
.- O
- m
N O
N
N O O
u7 m
cp a N
V
D O O N O O' O
N O V V O
(O ap M OD O Q
p~
.J U
~ ~ a m N n .- - V aD N cp V
M ~ ~ a
Fp W fA (A f A f9 H 3 fA fA fA fA E9 fA M FA t9 EA f9 f9
0
O 0 0 0
O O h 0
O
n 0
0 0
0 0 0
0 0 0
0 0 0 0 0 0 O h
0 0 0 0 0 O N
O
O
~~
_ ~-- N u1 N
O
M ~
~ M
O N
A
« O
N
M N
V
~ O O
t0 ~
V ~ W
tD
N ¢l O r .- O' M O
O~ O N N 00
O O (p
~~
~
N
W
~_ F
m
~
r
n
O
N
N
(O (O
N
V OD V N n
~
~
W
D F p~
h m
N
n
~
W
F9
Hi f9 fA
W N
fA
H
3 fA
fA fA
M ~'!
f9 Yi f9 fA !A lfl W H
,
~ m r
fA •
-
(A
~-
Z O
O 0
O O N 0
h
n 0
O 0
0 0 0
0 0 0
N 0 0 0 0 0 O
0 0 0 0 0 O LL
Z ~
n
Y «~
~~ ~ oo<o
v v
v ~
rn o
m
M ~
n
n NVi
rn~n
c~ 0 ai
M mo~.-o ri
rnO N .n
0 0 co
Y
-- ~
'c n
°'
~ a Sr i iv u> M v m v ~n
N _
~ a`
f9 f A fA fA fA fA M A fA W fA fA W EA fA FA fA EA fA
Z O
O O O O
O O O O
O N
n O
0 0
0 0 0
0 0 0
0 0 0 0 0 0 O N
0 0 0 0 0 O f~
Z O O
O
F ~~ ~ o
O
N u~ ui
n GO
M n M
n
n co
N
~D 0
0
O o
00
.-- ui o
~ O
M v
N o 0 0 o u~ of vi
0 0 0 00 M r
~ O E °o °o
V
~
O
D_ F
uJ N
V
.-
N
V
N
N
~ N
N
~ O N
V M r
N N N M ~ ~
V ~
- O
.O
~
M
~p
pj
F m N M ~
~ F
m
N
2 F»f »(n f» w F» w en F»w F» wrn en»f»w» w ti
Z ~ w
~
l.7 O O
O O N O
n O O
N N
n 0
0 0
0 0 0
0 0 0
0 0 0 0 0 0 O
0 0 0 0 0 O O
U p
O
Z
3 ~, ~
~ •- ~ O M
~rn M
rn M
ao O
o
o O
rn
o ~ O
no
vco (O
N O O O O N m
OOOVw M
u>oNMa M
Z
3
~, ~
'c
N
O ~ a o v co ~ N ui cv of in O ~ 'c
a
m '~' ~~'~ ~ w w f» f»u> ~ N
wf»wF»w wen ~
m ~
-c
~ ~ Y
U Y J
U W
J J UJ
J ¢
W ¢¢
W W LL
J ~ O~ U U¢ O D
J J J W J '"
C
J
W
pp ~ V
d ~
m~
E
o
~ N
ou~
N N
m
~
~
O
~
N
N N
W W
Q
~ m D ~.
~'"
E N
o
~ d
#
j
a O
W N J
•_ ~
O
~ W
F
p w Z
~ W
J
Q
D
F m
W Q
O _ O
~
d
d' c
~ U
>
a
O
~ ~ ~
7 N
W
Z c
~ ~
E it
W
o
0
O
~ n
~
¢
m ~
o Q
K °
" a
3
~ E c
~ ~ _
~' N o ~ a
i
o
E U
W m c ~ F- F ti E m -
O ~ 4 U > J o cOD c w ~ ~ ~
R
O
K N
a
~ '~
-_o
~ y a
_
W s
i~
N
`m
3
d
0 m
°~ ~
0 ~ m c r
c d o c
O Q E 'y m (7
ul
L L d b
K
O C
~ m LL'
d N N fn A
~ N _N
~
' O
O O N O N~~
~ a U c d U ry
`
~
V ~ c u
~ a
N a
N Y u
f
~ m a m
~ N N~ a 0
~ ~
o ~
'
3
3
~ 3
d 3~
o c
j N
o c ?i d m D
d
m" ff ~
n
a°i a
~
~ u
o m cn o
v
~ omm m 3J
2 N m m 3 a D o
U
m~ o ~> ~> ~c ~° '°' c ~ in = m m E
c o
~~ m m m ~ m m o 0 0
0 o d~ o U~ w
o~- E~ c7 c7 ¢ ~n m0 0 0~~ncnina r ~
Z W
w U .
~ Z
- ~
m¢
~ .-
~ LL
~
m
~
m
~
W
~
¢
M ~
¢ li
~
m ~ ~ ~ ~ ~
~ ~ Q m Q Q Q
a¢ ~ ~ ~ ~ ~ z
W W
~ U
Z
m
.
} W ~
aw v ~
v ~ ~
vo ~
v ~
o «
v .-
v ~ ~
v
v ~
o ~ ~ V V V V O
Q?ooc6~~ }
a~ v
h
W W Q
M n
M
~
~
N N
N ,
N N
N N (O
~ M O N N N
~ O N N (V N N lWi N
N
a~ ch
~ N a a a a a W W a
CITY OF MERIDIAN
VICTORY ROAD SEWER CONNECTOR TRUNK LINE
Engineer's Opinion of Probable Construction Cost
SPEC. PAYMENT EST.
REFERENCE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL PRICE
205.4.1.6.1 Dewatering
1 LS $5,000 $5
000
304.4.1.A.1 Trench Foundation Stabilization ,
500 CY $15 $7
500
306.4.1.D.1 Imported Trench Backfill ,
500 CY $20 $10
000
307.4.1.F.1 YPe ur ace es ora ion spa oa way 259 LF $75 ,
$19
425
501.4.1.6.1 Gravity Sewer Pipe - 8" PVC 175 LF $50 ,
$8,750
501.4.1.6.1 Gravity Sewer Pipe - 27" PVC 2661 LF $175 $465,675
501.4.1.E.1 Abandon Existing Sewer Lift Station 1 LS $10,000 $10,000
502.4.1.A.1 Sanitary Sewer Manhole - 48" Type A 2 EA $3,500 $7,000
502.4.1.A.3 Sanitary Sewer Manhole - 60" Type B 5 EA $12,000 $60,000
502.4.1.F.1 Connection to Existing Manhole, 27" 2 EA $7,500 $15,000
706.4.1.6.1 Concrete Valley Gutter 8 LF $50 $400
1103.4.1.A.1 Construction Traffic Control 1 LS $2,000 $2,000
2010.4.1.A.1 Mobilization 1 LS 25000 $25,000
SP-2105.4.1.A.1 Sewage Bypass Plan 1 LS $1,000 $1,000
SP-2105.4.1.6.1 Sewage Bypass Control System 1 LS $8,000 $8,000
SP-2216.4.1.A.1 Storm Water Management 1 LS $3,000 $3,000
SP-2217.4.1.A.1 IPCO Power Pole Support 12 EA $3,500 $42,000
SP-2218.4.1.A.1 Kennedy Lateral Crossing 1 LS $5,000 $5,000
TOTAL: $694,750
J-U-B ENGINEERS, Inc. Project #: 10-10-050 12/14/2010
Q
r
a
Z
_Q
Q C
m w
Z O
~ ~ ~ r
W rD ? W
w a s °D m n
d Q ~ ~ ~
~ o
C ~ Q N N
F ~ .~ ...
~ ~ a W W X
O L w ~ ~ LL
a
~_
U)
l~
z
Q
H--i
w
c
O M
U ~
7 ~
~, M N
~ ~ ~
U~~(n
x
3m °"~
O c~u 'c
mazes
0
w
w~
O
~w
cn >
w
Q
Z
F-
U
w
O
a
rn
. o
• o
M
M
a ti
N
M ~
M
~ r
~
• ~ ~
~
w
~ }
~ _
~
~ F
z
N m b4 ~
W Z z
(,~ 2
W ~
~'
~ ~ ~ a
~ O
~
G'7 p
o
N
O
Q
O
~
~ M
O
(n
J
~
J
U
7
O
U
N
0
z
O
F-
Q
z
. F-
my
ow
tL O
c~
G
= a •
'
V ~ ~
~a ~ °
a ~ M
~ ~
O
U O N
N ~
~
~ N
O p ~
N ~
, .
0 o~
w U
j
M ~ ~ O
Q W ~ d Q H
aZ m
O Q ~.Q
U ~
~ ~
U ~ O
w z ~
O
> ~ zo
O
O
z ~ U a
U
~}
vm W
r-
~ ~
a Z