Loading...
HomeMy WebLinkAboutRice Fergus Miller Final Design and Construction Admin South Fire Station AIA B133 Item#17. C� fIEN , IN4, IDAHG-. MEMO TO CITY COUNCIL Request to Include Topic on the City Council Agenda From: Keith Watts, Procurement Division Meeting Date: June 15, 2021 Presenter: Consent/ Kris Blume Estimated Time: N/A Topic: Approval of AIA B133 Agreement with Rice Fergus Miller for the Final Design and Construction Administration for the South Fire Station in the Not-To-Exceed amount of$528,971.00 Recommended Council Action: Approval of Agreement and authorize the Procurement Manager to execute agreement and issue a PO for$528,971.00 Background: This agreement is issued as an associated project to Fire Station 6 design per Idaho Statute 67- 2320(4) Page 182 Item#17. AIA Document B133" - 2019 Standard Form of Agreement Between Owner and Architect, Construction Manager as Constructor Edition AGREEMENT made as of the Twenty-seven day of May in the year Two Thousand Twenty-one ADDITIONS AND DELETIONS: (In words, indicate day, month and year.) The author of this document has added information needed for its BETWEEN the Architect's client identified as the Owner: completion.The author may also (Name, legal status, address, and other information) have revised the text of the original AIA standard form.An Additions and City of Meridian,and Idaho Municipal Corporation Deletions Report that notes added c/o Meridian Finance Department information as well as revisions to the 33 E.Broadway Avenue standard form text is available from Meridian,Idaho 86342 the author and should be reviewed.A vertical line in the left margin of this and the Architect: document indicates where the author (Name, legal status, address, and other information) has added necessary information and where the author has added to or Rice Fergus Miller,Inc. deleted from the original AIA text. 275 51h Street,Suite 100 This document has important legal Bremerton,WA 98337 consequences.Consultation with an Telephone Number: 360-377-8773 attorney is encouraged with respect to its completion or modification. for the following Project: This document is intended to be used (Name, location, and detailed description) in conjunction with AIA Documents A201-2017'rm,General Conditions of Meridian South Fire Station Design-Construction Administration the Contract for Construction; RFM Project Number: 2020038.06 A133-2019Tm Standard Form of The Construction Manager(if known): Agreement Between Owner and (Name, legal status, address, and other information) Construction Manager as Constructor where the basis of Engineered Structures,Inc.(ESI Construction) payment is the Cost of the Work Plus 3330 E.Lousie Drive,Suite 300 a Fee with a Guaranteed Maximum Meridian,Idaho 83642 Price;and All 34-2019TM Standard Telephone Number(208)362-3040 Form of Agreement Between Owner and Construction Manager as The Owner and Architect agree as follows. Constructor where the basis of payment is the Cost of the Work Plus a Fee without a Guaranteed Maximum Price.AIA Document A201 TM-2017 is adopted in this document by reference.Do not use with other general conditions unless this document is modified. Init. AIA Document B133'"-2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a / be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 183 User Notes: (1885 Item#17. TABLE OF ARTICLES 1 INITIAL INFORMATION 2 ARCHITECT'S RESPONSIBILITIES 3 SCOPE OF ARCHITECT'S BASIC SERVICES 4 SUPPLEMENTAL AND ADDITIONAL SERVICES 5 OWNER'S RESPONSIBILITIES 6 COST OF THE WORK 7 COPYRIGHTS AND LICENSES 8 CLAIMS AND DISPUTES 9 TERMINATION OR SUSPENSION 10 MISCELLANEOUS PROVISIONS 11 COMPENSATION 12 SPECIAL TERMS AND CONDITIONS 13 SCOPE OF THE AGREEMENT ARTICLE 1 INITIAL INFORMATION § 1.1 This Agreement is based on the Initial Information set forth in this Section 1.1. (For each item in this section, insert the information or a statement such as "not applicable"or "unknown at time of execution.') § 1.1.1 The Owner's program for the Project: (Insert the Owner's program, identify documentation that establishes the Owner's program,or state the manner in which the program will be developed.) The South fire station shall be based on the Meridian Fire Station#6 prototype building with the following major features.The building shall have three(3)drive through apparatus bays and six(6)sleep rooms along with accompanying living,work,and support areas.For more detail refer to the facility planning workshop notes from November 2020.The site includes approximately 4 acres of development included a Meridian Police substation to be constructed at a future date. § 1.1.2 The Project's physical characteristics: (Identify or describe pertinent information about the Project's physical characteristics, such as size;location; dimensions;geotechnical reports;site boundaries;topographic surveys;traffic and utility studies;availability ofpublic and private utilities and services;legal description of the site, etc) As outlined in Rice Fergus Miller/Pivot North Architecture's Meridian Fire Department Facility Planning Workshop document,dated November 13,2020 § 1.1.3 The Owner's budget for the Cost of the Work,as defined in Section 6.1: (Provide total and, if known, a line item breakdown) $4,800,098 § 1.1.4 The Owner's anticipated design and construction milestone dates: .1 Design phase milestone dates,if any: Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a / be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 184 User Notes: (1885 Item#17. 12/15/2021 .2 Construction commencement date: 3/14/2022 .3 Substantial Completion date or dates: 3/28/2023 .4 Other milestone dates: NA § 1.1.5 The Owner intends to retain a Construction Manager pursuant to the following agreement: (Indicate agreement type) [X] AIA Document A133-2019,Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee with a Guaranteed Maximum Price. [ ] AIA Document A134-2019,Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee without a Guaranteed Maximum Price. § 1.1.6 The Owner's requirements for accelerated or fast-track design and construction,or phased construction are set forth below: (List number and type oj'bid/procurement packages) None identified at this time. § 1.1.7 The Owner's anticipated Sustainable Objective for the Project: (Identify and describe the Owner's Sustainable Objective for the Project, if any) None. § 1.1.7.1 If the Owner identifies a Sustainable Objective,the Owner and Architect shall complete and incorporate AIA Document E234Tm-2019,Sustainable Projects Exhibit,Construction Manager as Constructor Edition,into this Agreement to define the terms,conditions and services related to the Owner's Sustainable Objective.If E234-2019 is incorporated into this Agreement,the Owner and Architect shall incorporate the completed E234-2019 into the agreements with the consultants and contractors performing services or Work in any way associated with the Sustainable Objective. § 1.1.8 The Owner identifies the following representative in accordance with Section 5.4: (List name, address, and other contact information) Stacy Redman Facilities Project Manager City of Meridian,Public Works Department 33 E. Broadway Avenue Meridian,Idaho 83642 sredman(&meridiancit y�org (Office Phone)208-489-0374 (Cell Phone)208-985-4234 (Fax)208-898-9551 Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 185 User Notes: (1 885 Item#17. § 1.1.9 The persons or entities,in addition to the Owner's representative,who are required to review the Architect's submittals to the Owner are as follows: (List name, address, and other contact information) Not applicable. § 1.1.10 The Owner shall retain the following consultants and contractors: (List name, legal status, address, and other contact information) .1 Construction Manager: (The Construction Manager is identified on the cover page.If a Construction Manager has not been retained as of the date of this Agreement,state the anticipated date of retention. If the Architect is to assist the Owner in selecting the Construction Manager, complete Section 4.1.1.1) Engineered Structures,Inc. .2 Land Surveyor: Not by Owner;included in services of Architect. .3 Geotechnical Engineer: By owner,Atlas Geotechnical Services .4 Civil Engineer: Not by Owner;included in services of Architect. .5 Other consultants and contractors: (List any other consultants and contractors retained by the Owner.) None identified at this time. § 1.1.11 The Architect identifies the following representative in accordance with Section 2.4: (List name, address, and other contact information) Gunnar R.Gladics,Project Manager ggladics@rfinarch.com phone:360.377.8773 Rice Fergus Miller,Inc. 275 51h St.4100 Bremerton,WA 98337 § 1.1.12 The Architect shall retain the consultants identified in Sections 1.1.12.1 and 1.1.12.2: (List name, legal status, address, and other contact information) § 1.1.12.1 Consultants retained under Basic Services: .1 Structural Engineer: KPFF Judsen Williams SE Principal Engineer Judsen.williams@kpff.com Phone: 208.336.6985 412 E. Parkcenter Blvd. Suite 200 Boise,ID 83706 Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 186 User Notes: (1885 Item#17. .2 Mechanical Engineer: Cator Ruma Brittany Austin Project Engineer baustin@caton-uma.com Phone:208.343.3663 420 S.Orchard Street Boise,ID 83705 .3 Electrical Engineer: Cator Ruma Kyle Olsen PE Project Engineer kolsen@catorruma.com Phone:208.343.3663 420 S.Orchard Street Boise,ID 83705 .4 Associate Architect: Pivot North Architecture Clint Sievers AIA,Project Architect clint@pivotnorthdesi ng com Phone:208.690.3108 1101 West Grove St. Boise,ID 83702 § 1.1.12.2 Consultants retained under Supplemental Services: .5 Civil Engineer(included in Architect's Basic Services fee): Eric Cronin PE, Project Engineer eric(&thelandgroupinc.com Phone:208.939.4041 462 E Shore Dr.#100 Eagle,ID 83616 .6 Landscape Architecture(included in Architect's Basic Services fee): Bob Schafer,Landscape Architect bob(a-)thelandaroupinc.com Phone: 208.939.4041 462 E Shore Dr.#100 Eagle,ID 83616 .7 IT Design(included in Architect's Basic Services fee): Kyle Olsen PE,Project Engineer kolsen(&catornuna.com Phone:208.343.3663 420 S.Orchard Street Boise,ID 83705 § 1.1.13 Other Initial Information on which the Agreement is based: Init. AIA Document B133'"—2019.Copyright 02014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a / be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 187 User Notes: (1 885 Item#17. § 1.2 The Owner and Architect may rely on the Initial Information.Both parties,however,recognize that the Initial Information may materially change and,in that event,the Owner and the Architect shall appropriately adjust the Architect's services,schedule for the Architect's services,and the Architect's compensation(if required) § 1.3 The parties shall agree upon protocols governing the transmission and use of Instruments of Service or any other information or documentation in digital form. § 1.3.1 Any use of,or reliance on,all or a portion of a building information model without agreement to protocols governing the use of,and reliance on,the information contained in the model and without having those protocols set forth, shall be at the using or relying parry's sole risk and without liability to the other party and its contractors or consultants, the authors of,or contributors to,the building information model,and each of their agents and employees. ARTICLE 2 ARCHITECT'S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement.The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement,or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances.The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall provide its services in conjunction with the services of a Construction Manager as described in the agreement identified in Section 1.1.5.The Architect shall not be responsible for actions taken by the Construction Manager. § 2.4 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.5 Except with the Owner's knowledge and consent,the Architect shall not engage in any activity,or accept any employment,interest or contribution that would reasonably appear to compromise the Architect's professional judgment with respect to this Project. § 2.6 Insurance.The Architect shall maintain the following insurance until termination of this Agreement.If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains,the Owner shall pay the Architect as set forth in Section 11.9. § 2.6.1 Commercial General Liability with policy limits of not less than Two Million Dollars($2,000,000.00.)for each occurrence and Two Million Dollars($2,000,000.00.) in the aggregate for bodily injury and property damage. § 2.6.2 Automobile Liability covering vehicles owned,and non-owned vehicles used,by the Architect with policy limits of not less than One Million Dollars($1,000,000.00)per accident for bodily injury,death of any person,and property damage arising out of the ownership,maintenance and use of those motor vehicles,along with any other statutorily required automobile coverage. § 2.6.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance,provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages required under Sections 2.6.1 and 2.6.2,and in no event shall any excess or umbrella liability insurance provide narrower coverage than the primary policy.The excess policy shall not require the exhaustion of the underlying limits only through the actual payment by the underlying insurers. § 2.6.4 Workers' Compensation at statutory limits. § 2.6.5 Intentionally Deleted. § 2.6.6 Professional Liability covering negligent acts,errors and omissions in the performance of professional services, with policy limits of not less than Five Million Dollars($5,000,000.00)per claim and Five Million Dollars ($5,000,000.00)in the aggregate. Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 188 User Notes: (1885 Item#17. § 2.6.7 Additional Insured Obligations.The Architect shall cause the primary and excess or umbrella polices for Commercial General Liability and Automobile Liability to include the Owner as an additional insured.The additional insured coverage shall be primary and non-contributory to any of the Owner's insurance policies and shall apply to both ongoing and completed operations. § 2.6.8 The Architect shall provide certificates of insurance to the Owner that evidence compliance with the requirements in this Section 2.6. ARTICLE 3 SCOPE OF ARCHITECT'S BASIC SERVICES § 3.1 The Architect's Basic Services consist of those described in this Article 3 and include usual and customary structural,mechanical,and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect's services,research applicable design criteria,attend Project meetings, communicate with members of the Project team,and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner,the Construction Manager, and the Owner's consultants.The Architect shall be entitled to rely on,and shall not be responsible for,the accuracy, completeness,and timeliness of,services and information furnished by the Owner,the Construction Manager,and the Owner's consultants.The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error,omission,or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement,the Architect shall submit,for the Construction Manager's review and the Owner's approval,a schedule for the performance of the Architect's services.The schedule shall include design phase milestone dates,as well as the anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information.The schedule shall include allowances for periods of time required for the Owner's review,for the Construction Manager's review,for the performance of the Construction Manager's Preconstruction Phase services,for the performance of the Owner's consultants,and for approval of submissions by authorities having jurisdiction over the Project.Once approved by the Owner,time limits established by the schedule shall not,except for reasonable cause,be exceeded by the Architect or Owner.With the Owner's approval, the Architect shall adjust the schedule,if necessary,as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall submit information to the Construction Manager and participate in developing and revising the Project schedule as it relates to the Architect's services.The Architect shall review and approve,or take other appropriate action upon,the portion of the Project schedule relating to the performance of the Architect's services. §3.1.5 The Architect shall not be responsible for an Owner's directive or substitution,or for the Owner's acceptance of non-conforming work,made or given without the Architect's written approval. § 3.1.6 The Architect shall,in coordination with the Construction Manager,contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project.The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.7 The Architect shall assist the Owner and Construction Manager in connection with the Owner's responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project. § 3.1.8 Prior to the Owner's acceptance of the Construction Manager's Guaranteed Maximum Price proposal,or the Owner's approval of the Construction Manager's Control Estimate,as applicable,the Architect shall consider the Construction Manager's requests for substitutions and,upon written request of the Construction Manager,provide clarification or interpretations pertaining to the Drawings,Specifications,and other documents submitted by the Architect.The Architect and Construction Manager shall include the Owner in communications related to substitution requests,clarifications,and interpretations. § 3.1.9 Concept Design and Entitlement Support PROVIDED UNDER SEPARATE CONTRACT Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 189 User Notes: (1885 Item#17. §3.2 Review of the Construction Manager's Guaranteed Maximum Price Proposal or Control Estimate-NOT INCLUDED IN CONTRACT OR FEE § 3.2.1 At a time to be mutually agreed upon by the Owner and the Construction Manager,the Construction Manager shall prepare,for review by the Owner and Architect,and for the Owner's acceptance or approval,a Guaranteed Maximum Price proposal or Control Estimate.The Architect shall assist the Owner in reviewing the Construction Manager's proposal or estimate.The Architect's review is not for the purpose of discovering errors,omissions,or inconsistencies;for the assumption of any responsibility for the Construction Manager's proposed means,methods,sequences,techniques,or procedures;or for the verification of any estimates of cost or estimated cost proposals.In the event that the Architect discovers any inconsistencies or inaccuracies in the information presented,the Architect shall promptly notify the Owner and Construction Manager. § 3.2.2 Upon authorization by the Owner,and subject to Section 4.2.1.14,the Architect shall update the Drawings, Specifications,and other documents to incorporate the agreed upon assumptions and clarifications contained in the Guaranteed Maximum Price Amendment or Control Estimate. § 3.3 Schematic Design Phase Services-PROVIDED UNDER SEPARATE CONTRACT § 3.3.1 The Architect shall review the program,and other information furnished by the Owner and Construction Manager, and shall review laws,codes,and regulations applicable to the Architect's services. § 3.3.2 The Architect shall prepare a preliminary evaluation of the Owner's program,schedule,budget for the Cost of the Work,Project site,and other Initial Information,each in terms of the other,to ascertain the requirements of the Project. The Architect shall notify the Owner of(1)any inconsistencies discovered in the information,and(2)other information or consulting services that may be reasonably needed for the Project. § 3.3.3 The Architect shall present its preliminary evaluation to the Owner and Construction Manager and shall discuss with the Owner and Construction Manager alternative approaches to design and construction of the Project.The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.3.4 Based on the Project requirements agreed upon with the Owner,the Architect shall prepare and present,to the Owner and Construction Manager,for the Owner's approval,a preliminary design illustrating the scale and relationship of the Project components. § 3.3.5 Based on the Owner's approval of the preliminary design,the Architect shall prepare Schematic Design Documents for Construction Manager's review and the Owner's approval.The Schematic Design Documents shall consist of drawings and other documents including a site plan,if appropriate,and preliminary building plans,sections and elevations;and may include some combination of study models,perspective sketches,or digital representations. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.3.5.1 The Architect shall consider sustainable design alternatives,such as material choices and building orientation, together with other considerations based on program and aesthetics,in developing a design that is consistent with the Owner's program,schedule and budget for the Cost of the Work.The Owner may obtain more advanced sustainable design services as a Supplemental Service under Section 4.1. § 3.3.5.2 The Architect shall consider with the Owner and the Construction Manager the value of alternative materials, building systems and equipment,together with other considerations based on program and aesthetics,in developing a design for the Project that is consistent with the Owner's program,schedule,and budget for the Cost of the Work. § 3.3.6 The Architect shall submit the Schematic Design Documents to the Owner and the Construction Manager.The Architect shall meet with the Construction Manager to review the Schematic Design Documents. § 3.3.7 Upon receipt of the Construction Manager's review comments and cost estimate at the conclusion of the Schematic Design Phase,the Architect shall take action as required under Section 6.4,and request the Owner's approval of the Schematic Design Documents.If revisions to the Schematic Design Documents are required to comply with the Owner's budget for the Cost of the Work at the conclusion of the Schematic Design Phase,the Architect shall incorporate the required revisions in the Design Development Phase. Init. AIA Document B133'"—2019.Copyright 02014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 190 User Notes: (1 885 Item#17. § 3.3.8 In the further development of the Drawings and Specifications during this and subsequent phases of design,the Architect shall be entitled to rely on the accuracy of the estimates of the Cost of the Work,which are to be provided by the Construction Manager under the Construction Manager's agreement with the Owner. § 3.4 Design Development Phase Services § 3.4.1 Based on the Owner's approval of the Schematic Design Documents,and on the Owner's authorization of any adjustments in the Project requirements and the budget for the Cost of the Work,the Architect shall prepare Design Development Documents for the Construction Manager's review and the Owner's approval.The Design Development Documents shall be based upon information provided,and estimates prepared by,the Construction Manager and shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans,sections,elevations,typical construction details,and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural,structural,mechanical and electrical systems,and other appropriate elements.The Design Development Documents shall also include outline specifications that identify major materials and systems and establish in general their quality levels. § 3.4.2 Prior to the conclusion of the Design Development Phase,the Architect shall submit the Design Development Documents to the Owner and the Construction Manager.The Architect shall meet with the Construction Manager to review the Design Development Documents. § 3.4.3 Upon receipt of the Construction Manager's information and estimate at the conclusion of the Design Development Phase,the Architect shall take action as required under Sections 6.5 and 6.6 and request the Owner's approval of the Design Development Documents. § 3.5 Construction Documents Phase Services § 3.5.1 Based on the Owner's approval of the Design Development Documents,and on the Owner's authorization of any adjustments in the Project requirements and the budget for the Cost of the Work,the Architect shall prepare Construction Documents for the Construction Manager's review and the Owner's approval.The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work.The Owner and Architect acknowledge that,in order to perform the Work,the Construction Manager will provide additional information,including Shop Drawings,Product Data,Samples and other similar submittals,which the Architect shall review in accordance with Section 3.6.4. § 3.5.2 The Architect shall incorporate the design requirements of governmental authorities having jurisdiction over the Project into the Construction Documents. § 3.5.3 During the development of the Construction Documents,if requested by the Owner,the Architect shall assist the Owner and Construction Manager in the development and preparation of(1)the Conditions of the Contract for Construction(General,Supplementary and other Conditions)and(2)a project manual that includes the Conditions of the Contract for Construction and Specifications,and may include sample forms. § 3.5.4 Prior to the conclusion of the Construction Documents Phase,the Architect shall submit the Construction Documents to the Owner and the Construction Manager.The Architect shall meet with the Construction Manager to review the Construction Documents. § 3.5.5 Upon receipt of the Construction Manager's information and estimate at the conclusion of the Construction Documents Phase,the Architect shall take action as required under Section 6.7,and request the Owner's approval of the Construction Documents. § 3.6 Construction Phase Services § 3.6.1 General § 3.6.1.1 The Architect shall provide administration of the Contract between the Owner and the Construction Manager as set forth below and in AIA Document A201T114-2017,General Conditions of the Contract for Construction.If the Owner and Construction Manager modify ATA Document A201-2017,those modifications shall not affect the Architect's Init. AIA Document B133'"—2019.Copyright 02014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 191 User Notes: (1885 Item#17. services under this Agreement unless the Owner and the Architect amend this Agreement.The term"Contractor"as used in A201-2017 shall mean the Construction Manager. § 3.6.1.2 Subject to Section 4.2,the Architect's responsibility to provide Construction Phase Services commences upon the Owner's acceptance of the Construction Manager's Guaranteed Maximum Price proposal,the Owner's approval of the Construction Manager's Control Estimate,or by a written agreement between the Owner and Construction Manager which sets forth a description of the Work to be performed by the Construction Manager prior to such acceptance or approval. Subject to Section 4.2,and except as provided in Section 3.6.6.5,the Architect's responsibility to provide Construction Phase Services terminates on the date the Architect issues the final Certificate for Payment. § 3.6.1.3 The Architect shall advise and consult with the Owner and Construction Manager during the Construction Phase Services.The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement. The Architect shall not have control over,charge of,or responsibility for the construction means,methods,techniques, sequences or procedures,or for safety precautions and programs in connection with the Work,nor shall the Architect be responsible for the Construction Manager's failure to perform the Work in accordance with the requirements of the Contract Documents.The Architect shall be responsible for the Architect's negligent acts or omissions,but shall not have control over or charge of,and shall not be responsible for,acts or omissions of the Construction Manager or of any other persons or entities performing portions of the Work. § 3.6.2 Evaluations of the Work § 3.6.2.1 The Architect shall visit the site at intervals appropriate to the stage of construction,or as otherwise required in Section 4.2.3,to become generally familiar with the progress and quality of the portion of the Work completed,and to determine,in general,if the Work observed is being performed in a manner indicating that the Work,when fully completed,will be in accordance with the Contract Documents.However,the Architect shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work.On the basis of the site visits,the Architect shall keep the Owner reasonably informed about the progress and quality of the portion of the Work completed, and promptly report to the Owner(1)known deviations from the Contract Documents,(2)known deviations from the most recent construction schedule submitted by the Construction Manager,and(3)defects and deficiencies observed in the Work. § 3.6.2.2 The Architect has the authority to reject Work that does not conform to the Contract Documents.Whenever the Architect considers it necessary or advisable,the Architect shall have the authority to require inspection or testing of the Work in accordance with the provisions of the Contract Documents,whether or not the Work is fabricated,installed or completed.However,neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Construction Manager, Subcontractors,suppliers,their agents or employees,or other persons or entities performing portions of the Work. § 3.6.2.3 The Architect shall interpret and decide matters concerning performance under,and requirements of,the Contract Documents on written request of either the Owner or Construction Manager.The Architect's response to such requests shall be made in writing within any time limits agreed upon or otherwise with reasonable promptness. § 3.6.2.4 Interpretations and decisions of the Architect shall be consistent with the intent of,and reasonably inferable from,the Contract Documents and shall be in writing or in the form of drawings.When making such interpretations and decisions,the Architect shall endeavor to secure faithful performance by both Owner and Construction Manager,shall not show partiality to either,and shall not be liable for results of interpretations or decisions rendered in good faith.The Architect's decisions on matters relating to aesthetic effect shall be final if consistent with the intent expressed in the Contract Documents subject to written approval of the Owner. § 3.6.2.5 Unless the Owner and Construction Manager designate another person to serve as an Initial Decision Maker,as that term is defined in AIA Document A201-2017,the Architect shall render initial decisions on Claims between the Owner and Construction Manager as provided in the Contract Documents. § 3.6.3 Certificates for Payment to Construction Manager § 3.6.3.1 The Architect shall review and certify the amounts due the Construction Manager and shall issue certificates in such amounts.The Architect's certification for payment shall constitute a representation to the Owner,based on the Architect's evaluation of the Work as provided in Section 3.6.2 and on the data comprising the Construction Manager's Application for Payment,that,to the best of the Architect's knowledge,information and belief,the Work has progressed Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 192 User Notes: (1885 Item#17. to the point indicated,the quality of the Work is in accordance with the Contract Documents,and that the Construction Manager is entitled to payment in the amount certified.The foregoing representations are subject to(1)an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion,(2)results of subsequent tests and inspections,(3)correction of minor deviations from the Contract Documents prior to completion,and(4)specific qualifications expressed by the Architect. § 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has(1)made exhaustive or continuous on-site inspections to check the quality or quantity of the Work,(2)reviewed construction means,methods, techniques,sequences or procedures,(3)reviewed copies of requisitions received from Subcontractors and suppliers and other data requested by the Owner to substantiate the Construction Manager's right to payment,or(4)ascertained how or for what purpose the Construction Manager has used money previously paid on account of the Contract Sum. § 3.6.3.3 The Architect shall maintain a record of the Applications and Certificates for Payment. § 3.6.4 Submittals § 3.6.4.1 The Architect shall review the Construction Manager's submittal schedule and shall not unreasonably delay or withhold approval of the schedule.The Architect's action in reviewing submittals shall be taken in accordance with the approved submittal schedule or,in the absence of an approved submittal schedule,with reasonable promptness while allowing sufficient time,in the Architect's professional judgment,to permit adequate review. § 3.6.4.2 The Architect shall review and approve,or take other appropriate action upon,the Construction Manager's submittals such as Shop Drawings,Product Data and Samples,but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents.Review of such submittals is not for the purpose of determining the accuracy and completeness of other information such as dimensions, quantities,and installation or performance of equipment or systems,which are the Construction Manager's responsibility. The Architect's review shall not constitute approval of safety precautions or construction means,methods,techniques, sequences or procedures.The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. § 3.6.4.3 If the Contract Documents specifically require the Construction Manager to provide professional design services or certifications by a design professional related to systems,materials,or equipment,the Architect shall specify the appropriate performance and design criteria that such services must satisfy.The Architect shall review and take appropriate action on Shop Drawings and other submittals related to the Work designed or certified by the Construction Manager's design professional,provided the submittals bear such professional's seal and signature when submitted to the Architect.The Architect's review shall be for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents.The Architect shall be entitled to rely upon,and shall not be responsible for,the adequacy and accuracy of the services,certifications,and approvals performed or provided by such design professionals. § 3.6.4.4 Subject to Section 4.2,the Architect shall review and respond to requests for information about the Contract Documents.The Architect shall set forth,in the Contract Documents,the requirements for requests for information. Requests for information shall include,at a minimum,a detailed written statement that indicates the specific Drawings or Specifications in need of clarification and the nature of the clarification requested.The Architect's response to such requests shall be made in writing within any time limits agreed upon,or otherwise with reasonable promptness.If appropriate,the Architect shall prepare and issue supplemental Drawings and Specifications in response to the requests for information. § 3.6.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Construction Manager in accordance with the requirements of the Contract Documents. § 3.6.5 Changes in the Work § 3.6.5.1 Subject to Owner's approval,the Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. Subject to Section 4.2,the Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with the Contract Documents. § 3.6.5.2 The Architect shall maintain records relative to changes in the Work. Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 193 User Notes: (1885 Item#17. § 3.6.6 Project Completion—NOT INCLUDED IN CONTRACT OR FEE § 3.6.6.1 The Architect shall: .1 conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; .2 issue Certificates of Substantial Completion; .3 forward to the Owner,for the Owner's review and records,written warranties and related documents required by the Contract Documents and received from the Construction Manager;and .4 issue a final Certificate for Payment based upon a final inspection indicating that,to the best of the Architect's knowledge,information,and belief,the Work complies with the requirements of the Contract Documents. § 3.6.6.2 The Architect's inspections shall be conducted with the Owner to(1)check conformance of the Work with the requirements of the Contract Documents and(2)verify the accuracy and completeness of the list submitted by the Construction Manager of Work to be completed or corrected. § 3.6.6.3 When Substantial Completion has been achieved,the Architect shall inform the Owner about the balance of the Contract Sum remaining to be paid the Construction Manager,including the amount to be retained from the Contract Sum, if any,for final completion or correction of the Work. § 3.6.6.4 The Architect shall forward to the Owner the following information received from the Construction Manager:(1) consent of surety or sureties,if any,to reduction in or partial release of retainage or the making of final payment;(2) affidavits,receipts,releases and waivers of liens,or bonds indemnifying the Owner against liens;and(3)any other documentation required of the Construction Manager under the Contract Documents. § 3.6.6.5 Upon request of the Owner,and prior to the expiration of one year from the date of Substantial Completion,the Architect shall,without additional compensation,conduct a meeting with the Owner to review the facility operations and performance. ARTICLE 4 SUPPLEMENTAL AND ADDITIONAL SERVICES § 4.1 Supplemental Services § 4.1.1 The services listed below are not included in Basic Services but may be required for the Project.The Architect shall provide the listed Supplemental Services only if specifically designated in the table below as the Architect's responsibility,and the Owner shall compensate the Architect as provided in Section 11.2.Unless otherwise specifically addressed in this Agreement,if neither the Owner nor the Architect is designated,the parties agree that the listed Supplemental Service is not being provided for the Project. (Designate the Architect's Supplemental Services and the Owner's Supplemental Services required for the Project by indicating whether the Architect or Owner shall be responsible for providing the identified Supplemental Service.Insert a description of the Supplemental Services in Section 4.1.2 below or attach the description of services as an exhibit to this Agreement.) Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 194 User Notes: (1 885 Item#17. Supplemental Services Responsibility Architect, Owner, or notprovided) 4.1.1.1 Assistance with Selection of Construction Manager Not Provided 4.1.1.2 Programming Provided under previous contract 4.1.1.3 Multiple Preliminary Designs Not Provided 4.1.1.4 Measured drawings Not Provided 4.1.1.5 Existing facilities surveys Not Provided 4.1.1.6 Site evaluation and planning Provided under previous contract 4.1.1.7 Building Information Model management responsibilities Not Provided § 4.1.1.8 Development of Building Information Models for post Not Provided construction use 4.1.1.9 Civil engineering Architect under Basic Services 4.1.1.10 Landscape design Architect under Basic Services 4.1.1.11 Architectural interior design Architect under Basic Services 4.1.1.12 Value analysis Not Provided 4.1.1.13 Cost estimating Not Provided 4.1.1.14 On-site project representation Not Provided 4.1.1.15 Conformed documents for construction Not Provided 4.1.1.16 As-designed record drawings Not Provided 4.1.1.17 As-constructed record drawings Not Provided 4.1.1.18 Post-occupancy evaluation Not Provided 4.1.1.19 Facility support services Not Provided 4.1.1.20 Tenant-related services Not Provided 4.1.1.21 Architect's coordination of the Owner's consultants Not Provided § 4.1.1.22 Alerting and emergency response systems,including Not Provided antennas and audio equipment Row deleted 4.1.1.23 Security evaluation and planning Not Provided 4.1.1.24 Commissioning Not Provided 4.1.1.25 Sustainable Project Services pursuant to Section 4.1.3 Not Provided 4.1.1.26 Historic preservation Not Provided 4.1.1.27 Furniture,furnishings,and equipment design Not Provided 4.1.1.28 Other services provided by specialty Consultants Not Provided 4.1.1.29 Other Supplemental Services Not Provided § 4.1.1.30 Entitlements Provided under previous contract 4.1.1.31 Fire Station Traffic Si nalization Design Not Provided 4.1.1.32 IT and Data Design Architect under Basic Services § 4.1.2 Description of Supplemental Services § 4.1.2.1 A description of each Supplemental Service identified in Section 4.1.1 as the Architect's responsibility is provided in: None § 4.1.2.2 A description of each Supplemental Service identified in Section 4.1.1 as the Owner's responsibility is provided below. None Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," AIA,'the AIA Logo,and"AIA Contract Documents'are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 195 User Notes: (1885 Item#17. § 4.1.3 Intentionally Deleted. § 4.2 Architect's Additional Services The Architect may provide Additional Services after execution of this Agreement without invalidating the Agreement. Except for services required due to the fault of the Architect,any Additional Services provided in accordance with this Section 4.2 shall entitle the Architect to compensation pursuant to Section 11.3 and an appropriate adjustment in the Architect's schedule. § 4.2.1 Upon recognizing the need to perform the following Additional Services,the Architect shall notify the Owner with reasonable promptness and explain the facts and circumstances giving rise to the need.The Architect shall not proceed to provide the following Additional Services until the Architect receives the Owner's written authorization: .1 Services necessitated by a change in the Initial Information,previous instructions or recommendations given by the Construction Manager or the Owner,approvals given by the Owner,or a material change in the Project including size,quality,complexity,the Owner's schedule or budget for Cost of the Work,or bid packages in addition to those listed in Section 1.1.6; .2 Making revisions in Drawings,Specifications,or other documents(as required pursuant to Section 6.7), when such revisions are required because the Construction Manager's estimate of the Cost of the Work, Guaranteed Maximum Price proposal,or Control Estimate exceeds the Owner's budget,except where such excess is due to changes initiated by the Architect in scope,capacities of basic systems,or the kinds and quality of materials,finishes,or equipment; .3 Services necessitated by the enactment or revision of codes,laws,or regulations,including changing or editing previously prepared Instruments of Service; .4 Changing or editing previously prepared Instruments of Service necessitated by official interpretations of applicable codes,laws or regulations that are either(a)contrary to specific interpretations by the applicable authorities having jurisdiction made prior to the issuance of the building permit,or(b)contrary to requirements of the Instruments of Service when those Instruments of Service were prepared in accordance with the applicable standard of care; .5 Services necessitated by decisions of the Owner or Construction Manager not rendered in a timely manner or any other failure of performance on the part of the Owner or the Owner's consultants or contractors; .6 Preparing digital models or other design documentation for transmission to the Owner's consultants and contractors,or to other Owner-authorized recipients; .7 Preparation of design and documentation for alternate bid or proposal requests proposed by the Owner or Construction Manager; .8 Preparation for,and attendance at,a public presentation,meeting or hearing; .9 Preparation for,and attendance at,a dispute resolution proceeding or legal proceeding,except where the Architect is party thereto; .10 Consultation concerning replacement of Work resulting from fire or other cause during construction;or .11 Assistance to the Initial Decision Maker,if other than the Architect; .12 Services necessitated by replacement of the Construction Manager or conversion of the Construction Manager as constructor project delivery method to an alternative project delivery method; .13 Services necessitated by the Owner's delay in engaging the Construction Manager; .14 Making revisions to the Drawings,Specifications,and other documents resulting from agreed-upon assumptions and clarifications included in the Guaranteed Maximum Price Amendment or Control Estimate;and .15 Making revisions to the Drawings,Specifications,and other documents resulting from substitutions included in the Guaranteed Maximum Price Amendment or Control Estimate. § 4.2.2 (Paragraphs deleted) Intentionally Deleted. § 4.2.3 The Architect shall provide Construction Phase Services exceeding the limits set forth below as Additional Services.When the limits below are reached,the Architect shall notify the Owner: 1 Two ( 2 )reviews of each Shop Drawing,Product Data item,sample and similar submittals of the Construction Manager .2 Thirty Two ( 32 )visits to the site by the Architect during construction Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 196 User Notes: (1885 Item#17. 3 Two ( 2 )inspections for any portion of the Work to determine whether such portion of the Work is substantially complete in accordance with the requirements of the Contract Documents .4 Two ( 2 )inspections for any portion of the Work to determine final completion § 4.2.4 Except for services required under Section 3.6.6.5 and those services that do not exceed the limits set forth in Section 4.2.3,Construction Phase Services provided more than 60 days after(1)the date of Substantial Completion of the Work or(2)the initial date of Substantial Completion identified in the agreement between the Owner and Contractor, whichever is earlier,shall be compensated as Additional Services to the extent the Architect incurs additional cost in providing those Construction Phase Services. § 4.2.5 Subject to the Owner's prior approval,the services covered by this Agreement have not been completed within twelve(24)months of the date of this Agreement,through no fault of the Architect,extension of the Architect's services beyond that time may be compensated as Additional Services. ARTICLE 5 OWNER'S RESPONSIBILITIES § 5.1 Unless otherwise provided for under this Agreement,the Owner shall provide information in a timely manner regarding requirements for and limitations on the Project,including a written program which shall set forth the Owner's objectives;schedule;constraints and criteria,including space requirements and relationships;flexibility;expandability; special equipment; systems;and site requirements. § 5.2 The Owner shall retain a Construction Manager to provide services,duties,and responsibilities as described in the agreement selected in Section 1.1.5. § 5.3 The Owner shall establish the Owner's budget for the Project,including(1)the budget for the Cost of the Work as defined in Section 6.1;(2)the Owner's other costs;and,(3)reasonable contingencies related to all of these costs.The Owner shall update the Owner's budget for the Project as necessary throughout the duration of the Project until final completion.If the Owner significantly increases or decreases the Owner's budget for the Cost of the Work,the Owner shall notify the Architect and Construction Manager.The Owner and the Architect,in consultation with the Construction Manager,shall thereafter agree to a corresponding change in the Project's scope and quality. § 5.3.1 The Owner acknowledges that accelerated,phased or fast-track scheduling provides a benefit,but also carries with it associated risks. Such risks include the Owner incurring costs for the Architect to coordinate and redesign portions of the Project affected by procuring or installing elements of the Project prior to the completion of all relevant Construction Documents,and costs for the Construction Manager to remove and replace previously installed Work.if the Owner selects accelerated,phased or fast-track scheduling,the Owner agrees to include in the budget for the Project sufficient contingencies to cover such costs. § 5.4 The Owner shall identify a representative authorized to act on the Owner's behalf with respect to the Project.The Owner shall render decisions and approve the Architect's submittals in a timely manner in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. § 5.5 The Owner shall furnish surveys to describe physical characteristics,and legal limitations and utility locations for the site of the Project,and a written legal description of the site.The surveys and legal information shall include,as applicable,grades and lines of streets,alleys,pavements and adjoining property and structures;designated wetlands; adjacent drainage;rights-of-way,restrictions,easements,encroachments,zoning,deed restrictions,boundaries and contours of the site;locations,dimensions,and other necessary data with respect to existing buildings,other improvements and trees;and information concerning available utility services and lines,both public and private,above and below grade,including inverts and depths.All the information on the survey shall be referenced to a Project benchmark. § 5.6 The Owner shall furnish services of geotechnical engineers,which may include test borings,test pits,determinations of soil bearing values,percolation tests,evaluations of hazardous materials,seismic evaluation,ground corrosion tests and resistivity tests,including necessary operations for anticipating subsoil conditions,with written reports and appropriate recommendations. § 5.7 The Owner shall provide the Supplemental Services designated as the Owner's responsibility in Section 4.1.1. Init. AIA Document B133'"—2019.Copyright 02014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA -19 software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 197 User Notes: (1 885 Item#17. § 5.8 If the Owner identified a Sustainable Objective in Article 1,the Owner shall fulfill its responsibilities as required in AIA Document E234Tw-2019,Sustainable Projects Exhibit,Construction Manager as Constructor Edition,attached to this Agreement. § 5.9 The Owner shall coordinate the services of its own consultants with those services provided by the Architect.Upon the Architect's request,the Owner shall furnish copies of the scope of services in the contracts between the Owner and the Owner's consultants.The Owner shall furnish the services of consultants other than those designated as the responsibility of the Architect in this Agreement,or authorize the Architect to furnish them as an Additional Service,when the Architect requests such services and demonstrates that they are reasonably required by the scope of the Project.The Owner shall require that its consultants and contractors maintain insurance,including professional liability insurance,as appropriate to the services or work provided. § 5.10 The Owner shall furnish tests,inspections and reports required by law or the Contract Documents,such as structural,mechanical,and chemical tests,tests for air and water pollution,and tests for hazardous materials. § 5.11 The Owner shall furnish all legal,insurance and accounting services,including auditing services,that may be reasonably necessary at any time for the Project to meet the Owner's needs and interests. § 5.12 The Owner shall provide prompt written notice to the Architect and Construction Manager if the Owner becomes aware of any fault or defect in the Project,including errors,omissions or inconsistencies in the Architect's Instruments of Service. § 5.13 The Owner shall include the Architect in all communications with the Construction Manager that relate to or affect the Architect's services or professional responsibilities.The Owner shall promptly notify the Architect of the substance of any direct communications between the Owner and the Construction Manager otherwise relating to the Project. Communications by and with the Architect's consultants shall be through the Architect. § 5.14 The Owner shall coordinate the Architect's duties and responsibilities set forth in the Agreement between the Owner and the Construction Manager with the Architect's services set forth in this Agreement.The Owner shall provide the Architect a copy of the executed agreement between the Owner and Construction Manager,including the General Conditions of the Contract for Construction. § 5.15 The Owner shall provide the Architect access to the Project site prior to commencement of the Work and shall obligate the Construction Manager to provide the Architect access to the Work wherever it is in preparation or progress. § 5.16 Within 15 days after receipt of a written request from the Architect,the Owner shall furnish the requested information as necessary and relevant for the Architect to evaluate,give notice of,or enforce lien rights. ARTICLE 6 COST OF THE WORK § 6.1 For purposes of this Agreement,the Cost of the Work shall be the total cost to the Owner to construct all elements of the Project designed or specified by the Architect and shall include the Construction Manager's general conditions costs, overhead,and profit.The Cost of the Work also includes the reasonable value of labor,materials,and equipment,donated to,or otherwise furnished by,the Owner.The Cost of the Work does not include the compensation of the Architect;the compensation of the Construction Manager for Preconstruction Phase services;the costs of the land,rights-of-way, financing,or contingencies for changes in the Work;or other costs that are the responsibility of the Owner. § 6.2 The Owner's budget for the Cost of the Work is provided in the Initial Information,and shall be adjusted throughout the Project as required under Sections 5.3 and 6.4.Evaluations of the Owner's budget for the Cost of the Work represent the Architect's judgment as a design professional. § 6.3 The Owner shall require the Construction Manager to include appropriate contingencies for design,bidding or negotiating,price escalation,and market conditions in estimates of the Cost of the Work.The Architect shall be entitled to rely on the accuracy and completeness of estimates of the Cost of the Work the Construction Manager prepares as the Architect progresses with its Basic Services.The Architect shall prepare,as an Additional Service,revisions to the Drawings,Specifications or other documents required due to the Construction Manager's inaccuracies or incompleteness in preparing cost estimates,or due to market conditions the Architect could not reasonably anticipate.The Architect may Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA in software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 198 User Notes: (1 885 Item#17. review the Construction Manager's estimates solely for the Architect's guidance in completion of its services,however, the Architect shall report to the Owner any material inaccuracies and inconsistencies noted during any such review. § 6.3.1 If the Architect is providing cost estimating services as a Supplemental Service,and a discrepancy exists between the Construction Manager's cost estimates and the Architect's cost estimates,the Architect and the Construction Manager shall work together to reconcile the cost estimates. § 6.4 If,prior to the conclusion of the Design Development Phase,the Construction Manager's estimate of the Cost of the Work exceeds the Owner's budget for the Cost of the Work,the Architect,in consultation with the Construction Manager, shall make appropriate recommendations to the Owner to adjust the Project's size,quality or budget for the Cost of the Work,and the Owner shall cooperate with the Architect in making such adjustments. § 6.5 If the Construction Manager's estimate of the Cost of the Work at the conclusion of the Design Development Phase exceeds the Owner's budget for the Cost of the Work,the Owner may .1 give written approval of an increase in the budget for the Cost of the Work; .2 intentionally deleted .3 in consultation with the Architect and Construction Manager,revise the Project program,scope,or quality as required to reduce the Cost of the Work;or .4 implement any other mutually acceptable alternative. § 6.6 If the Owner chooses to proceed under Section 6.5.3,the Architect,without additional compensation,shall incorporate the revisions in the Construction Documents Phase as necessary to comply with the Owner's budget for the Cost of the Work at the conclusion of the Design Development Phase Services,or the budget as adjusted under Section 6.5.1.The Architect's revisions in the Construction Documents Phase shall be the limit of the Architect's responsibility under this Article 6. § 6.7 Intentionally Deleted. ARTICLE 7 COPYRIGHTS AND LICENSES § 7.1 The Architect and the Owner warrant that in transmitting Instruments of Service,or any other information,the transmitting party is the copyright owner of such information or has permission from the copyright owner to transmit such information for its use on the Project. § 7.2 The Architect and the Architect's consultants shall be deemed the authors and owners of their respective Instruments of Service,including the Drawings and Specifications,and shall retain all common law,statutory and other reserved rights,including copyrights.Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the Architect and the Architect's consultants. § 7.3 The Architect grants to the Owner a nonexclusive license to use the Architect's Instruments of Service solely and exclusively for purposes of constructing,using,maintaining,altering and adding to the Project,provided that the Owner substantially performs its obligations under this Agreement,including prompt payment of all sums due,pursuant to Article 9 and Article 11.The Architect shall obtain similar nonexclusive licenses from the Architect's consultants consistent with this Agreement.The license granted under this section permits the Owner to authorize the Construction Manager,Subcontractors,Sub-subcontractors,and suppliers,as well as the Owner's consultants and separate contractors, to reproduce applicable portions of the Instruments of Service,subject to any protocols established pursuant to Section 1.3,solely and exclusively for use in performing services or construction for the Project.If the Architect rightfully terminates this Agreement for cause as provided in Section 9.4,the license granted in this Section 7.3 shall terminate. § 7.3.1 In the event the Owner uses the Instruments of Service without retaining the authors of the Instruments of Service, the Owner releases the Architect and Architect's consultant(s)from all claims and causes of action arising from such uses. The Owner,to the extent permitted by law,further agrees to indemnify and hold harmless the Architect and its consultants from all costs and expenses,including the cost of defense,related to claims and causes of action asserted by any third person or entity to the extent such costs and expenses arise from the Owner's use of the Instruments of Service under this Section 7.3.1.The terms of this Section 7.3.1 shall not apply if the Owner rightfully terminates this Agreement for cause under Section 9.4. Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 199 User Notes: (1885 Item#17. § 7.4 Except for the licenses granted in this Article 7,no other license or right shall be deemed granted or implied under this Agreement.The Owner shall not assign,delegate,sublicense,pledge or otherwise transfer any license granted herein to another party without the prior written agreement of the Architect.Any unauthorized use of the Instruments of Service shall be at the Owner's sole risk and without liability to the Architect and the Architect's consultants. § 7.5 Except as otherwise stated in Section 7.3,the provisions of this Article 7 shall survive the termination of this Agreement. ARTICLE 8 CLAIMS AND DISPUTES § 8.1 General § 8.1.1 The Owner and Architect shall commence all claims and causes of action against the other and arising out of or related to this Agreement,whether in contract,tort,or otherwise,in accordance with the requirements of the binding dispute resolution method selected in this Agreement and within the period specified by applicable law,but in any case not more than 10 years after the date of Substantial Completion of the Work.The Owner and Architect waive all claims and causes of action not commenced in accordance with this Section 8.1.1. § 8.1.2 To the extent damages are covered by property insurance,the Owner and Architect waive all rights against each other and against the contractors,consultants,agents and employees of the other for damages,except such rights as they may have to the proceeds of such insurance as set forth in AIA Document A201-2017,General Conditions of the Contract for Construction.The Owner or the Architect,as appropriate,shall require of the Construction Manager,contractors, consultants,agents and employees of any of them,similar waivers in favor of the other parties enumerated herein. § 8.1.3 The Architect shall indemnify and hold the Owner and the Owner's officers and employees harmless from and against damages,losses and judgments arising from claims by third parties,including reasonable attorneys' fees and expenses recoverable under applicable law,but only to the extent they are caused by the negligent acts or omissions of the Architect,its employees and its consultants in the performance of professional services under this Agreement.The Architect's obligation to indemnify and hold the Owner and the Owner's officers and employees harmless does not include a duty to defend.The Architect's duty to indemnify the Owner under this Section 8.1.3 shall be limited to the available proceeds of the insurance coverage required by this Agreement. § 8.1.4 The Architect and Owner waive consequential damages for claims,disputes,or other matters in question arising out of or relating to this Agreement.This mutual waiver is applicable,without limitation,to all consequential damages due to either parry's termination of this Agreement,except as specifically provided in Section 9.7. § 8.2 Mediation § 8.2.1 Any claim,dispute,or other matter in question arising out of or related to this Agreement shall be subject to mediation as a condition precedent to binding dispute resolution.If such matter relates to or is the subject of a lien arising out of the Architect's services,the Architect may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the matter by mediation or by binding dispute resolution. § 8.2.2 The Owner and Architect shall endeavor to resolve claims,disputes and other matters in question between them by mediation,which,unless the parties mutually agree otherwise,shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of this Agreement.A request for mediation shall be made in writing,delivered to the other party to this Agreement,and filed with the person or entity administering the mediation.The request may be made concurrently with the filing of a complaint or other appropriate demand for binding dispute resolution but,in such event,mediation shall proceed in advance of binding dispute resolution proceedings,which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order.If an arbitration proceeding is stayed pursuant to this section,the parties may nonetheless proceed to the selection of the arbitrator(s)and agree upon a schedule for later proceedings. § 8.2.3 The parties shall share the mediator's fee and any filing fees equally.The mediation shall be held in the place where the Project is located,unless another location is mutually agreed upon.Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. § 8.2.4 If the parties do not resolve a dispute through mediation pursuant to this Section 8.2,the method of binding dispute resolution shall be the following: Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 42 software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 200 User Notes: (1 885 Item#17. (Check the appropriate box.) [ ] Arbitration pursuant to Section 8.3 of this Agreement [X] Litigation in a court of competent jurisdiction [ ] Other: (Spec) If the Owner and Architect do not select a method of binding dispute resolution,or do not subsequently agree in writing to a binding dispute resolution method other than litigation,the dispute will be resolved in a court of competent jurisdiction. (Paragraphs deleted) § 8.3 Intentionally Deleted ARTICLE 9 TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement,such failure shall be considered substantial nonperformance and cause for termination or,at the Architect's option,cause for suspension of performance of services under this Agreement.If the Architect elects to suspend services,the Architect shall give seven days'written notice to the Owner before suspending services.In the event of a suspension of services,the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services.Before resuming services,the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect's services.The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project,the Architect shall be compensated for services performed prior to notice of such suspension.When the Project is resumed,the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect's services.The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days'written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days'written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days'written notice to the Architect for the Owner's convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5,or the Architect terminates this Agreement pursuant to Section 9.3,the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred,and costs attributable to termination,including the costs attributable to the Architect's termination of consultant agreements. § 9.7 (Paragraphs deleted) Intentionally Deleted § 9.8 Intentionally Deleted § 9.9 The Owner's rights to use the Architect's Instruments of Service in the event of a termination of this Agreement are set forth in Article 7 and Section 9.7. Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 201 User Notes: (1885 Item#17. ARTICLE 10 MISCELLANEOUS PROVISIONS § 10.1 This Agreement shall be governed by the law of the place where the Project is located,excluding that jurisdiction's choice of law rules.If the parties have selected arbitration as the method of binding dispute resolution,the Federal Arbitration Act shall govern Section 8.3. § 10.2 Terms in this Agreement shall have the same meaning as those in AIA Document A201-2017,General Conditions of the Contract for Construction,except as modified in this Agreement.The term"Contractor"as used in A201-2017 shall mean the Construction Manager. § 10.3 The Owner and Architect,respectively,bind themselves,their agents,successors,assigns,and legal representatives to this Agreement.Neither the Owner nor the Architect shall assign this Agreement without the written consent of the other,except that the Owner may assign this Agreement to a lender providing financing for the Project if the lender agrees to assume the Owner's rights and obligations under this Agreement,including any payments due to the Architect by the Owner prior to the assignment. § 10.4 If the Owner requests the Architect to execute certificates,the proposed language of such certificates shall be submitted to the Architect for review at least 14 days prior to the requested dates of execution.If the Owner requests the Architect to execute consents reasonably required to facilitate assignment to a lender,the Architect shall execute all such consents that are consistent with this Agreement,provided the proposed consent is submitted to the Architect for review at least 14 days prior to execution.The Architect shall not be required to execute certificates or consents that would require knowledge,services,or responsibilities beyond the scope of this Agreement. § 10.5 Nothing contained in this Agreement shall create a contractual relationship with,or a cause of action in favor of,a third party against either the Owner or Architect. § 10.6 Unless otherwise required in this Agreement,the Architect shall have no responsibility for the discovery,presence, handling,removal or disposal of,or exposure of persons to,hazardous materials or toxic substances in any form at the Project site. § 10.7 The Architect shall have the right to include photographic or artistic representations of the design of the Project among the Architect's promotional and professional materials.The Architect shall be given reasonable access to the completed Project to make such representations.However,the Architect's materials shall not include the Owner's confidential or proprietary information if the Owner has previously advised the Architect in writing of the specific information considered by the Owner to be confidential or proprietary.The Owner shall provide professional credit for the Architect in the Owner's promotional materials for the Project.This Section 10.7 shall survive the termination of this Agreement unless the Owner terminates this Agreement for cause pursuant to Section 9.4. § 10.8 If the Architect or Owner receives information specifically designated as"confidential"or"business proprietary," the receiving party shall keep such information strictly confidential and shall not disclose it to any other person except as set forth in Section 10.8.1.This Section 10.8 shall survive the termination of this Agreement. § 10.8.1 The receiving party may disclose"confidential"or"business proprietary"information after 7 days'notice to the other parry,when required by law,arbitrator's order,or court order,including a subpoena or other form of compulsory legal process issued by a court or governmental entity,or to the extent such information is reasonably necessary for the receiving party to defend itself in any dispute.The receiving party may also disclose such information to its employees, consultants,or contractors in order to perform services or work solely and exclusively for the Project,provided those employees,consultants and contractors are subject to the restrictions on the disclosure and use of such information as set forth in this Section 10.8. § 10.9 The invalidity of any provision of the Agreement shall not invalidate the Agreement or its remaining provisions.If it is determined that any provision of the Agreement violates any law,or is otherwise invalid or unenforceable,then that provision shall be revised to the extent necessary to make that provision legal and enforceable.In such case the Agreement shall be construed,to the fullest extent permitted by law,to give effect to the parties'intentions and purposes in executing the Agreement. ARTICLE 11 COMPENSATION § 11.1 For the Architect's Basic Services described under Article 3,the Owner shall compensate the Architect as follows: Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 202 User Notes: (1885 Item#17. 1. Stipulated Sum Design Development-Bidding Support:Three Hundred Forty-five Thousand Seven Hundred Eighty-one Dollars ($345,781.00) 2. Time&Expense to a Maximum Construction Administration:One Hundred Sixty-three Thousand One Hundred Ninety Dollars($163,190.00) 3. Reimbursable Expenses Time and Expense at architects'cost to a Maximum of Twenty Thousand Dollars($20,000.00). Any request for reimbursement must be substantiated by a receipt. § 11.2 For the Architect's Supplemental Services designated in Section 4.1.1 and for any Sustainability Services required pursuant to Section 4.1.3,the Owner shall compensate the Architect as follows: (Insert amount of, or basis for, compensation. If necessary, list specific services to which particular methods of compensation apply.) Included in Architect's Basic Services fee listed above § 11.3 For Additional Services that may arise during the course of the Project,including those under Section 4.2,the Owner shall compensate the Architect as follows: To be negotiated prior to the performance of Additional Services. § 11.4 Compensation for Supplemental and Additional Services of the Architect's consultants when not included in Sections 11.2 or 11.3,shall be the amount invoiced to the Architect plus percent( %),or as follows: Not applicable. § 11.5 When compensation for Basic Services is based on a stipulated sum or a percentage basis,the proportion of compensation for each phase of services shall be as follows: Design Development Phase Thirty-five percent ( 35%) Construction Documents Phase Fifty-five percent ( 55%) Bidding Support Ten percent ( 10%) Total Basic Compensation One Hundred percent ( 100%) Design—Bidding Support The Owner acknowledges that with an accelerated Project delivery,multiple bid package process,or Construction Manager as constructor project delivery method,the Architect may be providing its services in multiple Phases simultaneously.Therefore,the Architect shall be permitted to invoice monthly in proportion to services performed in each Phase of Services,as appropriate. § 11.6 When compensation identified in Section 11.1 is on a percentage basis,progress payments for each phase of Basic Services shall be calculated by multiplying the percentages identified in this Article by the Owner's most recent budget for the Cost of the Work.Compensation paid in previous progress payments shall not be adjusted based on subsequent updates to the Owner's budget for the Cost of the Work. § 11.6.1 When compensation is on a percentage basis and any portions of the Project are deleted or otherwise not constructed,compensation for those portions of the Project shall be payable to the extent services are performed on those portions.The Architect shall be entitled to compensation in accordance with this Agreement for all services performed whether or not the Construction Phase is commenced. § 11.7 The hourly billing rates for services of the Architect and the Architect's consultants are set forth below.The rates shall be adjusted in accordance with the Architect's and Architect's consultants'normal review practices. (If'applicable, attach an exhibit of'hourly billing rates or insert them below) Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA 134 software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 203 User Notes: (1885 Item#17. As described in Exhibit A § 11.8 Compensation for Reimbursable Expenses § 11.8.1 Reimbursable Expenses are in addition to compensation for Basic,Supplemental,and Additional Services and include expenses incurred by the Architect and the Architect's consultants directly related to the Project,as follows: .1 Pre-Authorized out-of-town travel and subsistence per GSA allowance .2 Long distance services,dedicated data and communication services,teleconferences,Project web sites, and extranets; .3 Permitting and other fees required by authorities having jurisdiction over the Project; .4 Printing,reproductions,plots,and standard form documents; .5 Postage,handling,and delivery; .6 Deleted .7 Renderings,physical models,mock-ups,professional photography,and presentation materials requested by the Owner or required for the Project; .8 Deleted .9 All taxes levied on professional services and on reimbursable expenses; .10 Deleted. .11 Deleted. .12 Deleted. (Paragraph deleted) § 11.9 Deleted § 11.10 Payments to the Architect § 11.10.1 Initial Payments § 11.10.1.1 An initial payment of zero dollars($0.00)shall be made upon execution of this Agreement and is the minimum payment under this Agreement.It shall be credited to the Owner's account in the final invoice. § 11.10.1.2 Deleted § 11.10.2 Progress Payments § 11.10.2.1 Unless otherwise agreed,payments for services shall be made monthly in proportion to services performed. Payments are due and payable net 30 from the Owner's receipt of a correct invoice. (Insert rate of monthly or annual interest agreed upon) Zero percentage(0%) § 11.10.2.2 The Owner shall not withhold amounts from the Architect's compensation to impose a penalty or liquidated damages on the Architect,or to offset sums requested by or paid to contractors for the cost of changes in the Work,unless the Architect agrees or has been found liable for the amounts in a binding dispute resolution proceeding. § 11.10.2.3 Records of Reimbursable Expenses,expenses pertaining to Supplemental and Additional Services,and services performed on the basis of hourly rates shall be available to the Owner at mutually convenient times. ARTICLE 12 SPECIAL TERMS AND CONDITIONS Special terms and conditions that modify this Agreement are as follows: (Include other terms and conditions applicable to this Agreement.) Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 204 User Notes: (1885 Item#17. Limitation of Liability Rice Fergus Miller's total liability to the Owner for any and all injuries,claims,losses,expenses, damages or claims expenses arising out of this agreement from any cause or causes,shall not exceed the total available amount of Rice Fergus Miller's Professional Liability insurance policy(Rice Fergus Miller's current available amount of Professional Liability Insurance is the full policy of$5,000,000). ARTICLE 13 SCOPE OF THE AGREEMENT § 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations,representations or agreements,either written or oral.This Agreement may be amended only by written instrument signed by both the Owner and Architect. § 13.2 This Agreement is comprised of the following documents identified below: .1 AIA Document B133TW-2019,Standard Form Agreement Between Owner and Architect,Construction Manager as Constructor Edition (Paragraphs deleted) .3 Exhibits: Exhibit A-Rice Fergus Miller 2021 Hourly Billing Rates This Agreement entered into as of the day and year first written above. OWNER(Signature) Robert ImISOn, Mayor- ARCHI CT(Signature City of Meridian,and Idaho Municipal Corporation David A.Fergus,Principal (Printed name and title) 6-29-2021 (Printed name, title, and license number, if required) Init. AIA Document B133'"—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a I be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 205 User Notes: (1885 Item#17. Additions and Deletions Report for AIA®Document 8133TM - 2019 This Additions and Deletions Report,as defined on page 1 of the associated document,reproduces below all text the author has added to the standard form AIA document in order to complete it,as well as any text the author may have added to or deleted from the original AIA text.Added text is shown underlined.Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AIA document.This Additions and Deletions Report and its associated document were generated simultaneously by AIA software at 18:21:39 ET on 06/03/2021. PAGE AGREEMENT made as of the Twen .-seven day of May in the year Two Thousand Twen .-one City of Meridian,and Idaho Municipal Corporation c/o Meridian Finance Department 33 E.Broadway Avenue Meridian,Idaho 86342 Rice Fergus Miller,Inc. 275 5th Street,Suite 100 Bremerton,WA 98337 Telephone Number: 360-377-8773 Meridian South Fire Station Design—Construction Administration RFM Project Number: 2020038.06 Engineered Structures,Inc.(ESI Construction) 3330 E.Lousie Drive,Suite 300 Meridian,Idaho 83642 Telephone Number(208)362-3040 PAGE 2 The South fire station shall be based on the Meridian Fire Station#6 prototype building with the following major features.The building shall have three(3)drive through gpparatus bays and six(6)sleep rooms along with accompanying living,work,and support areas.For more detail refer to the facility planning workshop notes from November 2020.The site includes approximately 4 acres of development included a Meridian Police substation to be constructed at a future date. As outlined in Rice Fergus Miller/Pivot North Architecture's Meridian Fire Department Facility Planning Workshop document,dated November 13,2020 Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail page 206 copyright@aia.org. User Notes: (1885 425) Item#17. $4,800,098 PAGE 3 12/15/2021 3/14/2022 3/28/2023 NA [X AIA Document A133-2019,Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee with a Guaranteed Maximum Price. None identified at this time. None. Stacy Redman Facilities Project Manager City of Meridian,Public Works Department 33 E.Broadway Avenue Meridian,Idaho 83642 sredman(&meridiancit y�org (Office Phone)208-489-0374 (Cell Phone)208-985-4234 (Fax)208-898-9551 PAGE 4 Not applicable. Engineered Structures,Inc. Not by Owner,included in services of Architect. By owner,Atlas Geotecbnical Services Additions and Deletions Report for AIA Document 13133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,a-mail Page 207 copyright@aia.org. User Notes: (1885625) Item#17. Not by Owner:included in services of Architect. None identified at this time. Gunnar R.Gladics,Project Manager gg1adics(d,)rfinarch.com phone:360.377.8773 Rice Ferps Miller,Inc. 275 5th St.4100 Bremerton,WA 98337 KPFF Judsen Williams SE Principal Engineer Judsen.williams&kpff.com Phone: 208.336.6985 412 E. Parkcenter Blvd. Suite 200 Boise,ID 83706 PAGE 5 Cator Ruma Brittany Austin Project Engineer baustin(&caton uma.com Phone:208.343.3663 420 S.Orchard Street Boise,ID 83705 Cator Ruma Kyle Olsen PE Project Engineer kolsen(a,catorruma.com Phone:208.343.3663 420 S.Orchard Street Boise,ID 83705 .4 Associate Architect: Pivot North Architecture Clint Sievers AIA,Project Architect clint(&pivotnorthdesing com Phone:208.690.3108 1101 West Grove St. Boise,ID 83702 .5 Civil Engineer(,included in Architect's Basic Services fee): Eric Cronin PE,Project Engineer Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,a-mail page 208 copyright@aia.org. User Notes: (1885 25) Item#17. eri c(&thelandgroupinc.com Phone:208.939.4041 462 E Shore Dr.#100 Eagle,ID 83616 .6 Landscape Architecture(included in Architect's Basic Services feet Bob Schafer,Landscape Architect boWthelandgroupinc.com Phone: 208.939.4041 462 E Shore Dr.#100 Eagle,ID 83616 .7 IT Design(included in Architect's Basic Services feed Kyle Olsen PE,Project Engineer kolsenkcaton uma.com Phone:208.343.3663 420 S.Orchard Street Boise,ID 83705 PAGE 6 § 1.2 The Owner and Architect may rely on the Initial Information.Both parties,however,recognize that the Initial Information may materially change and,in that event,the Owner and the Architect shall appropriately adjust the Architect's services,schedule for the Architect's services,and the Architect's eempensation.The Owner-shalm!adjust the OA%er-'s budget for-the Cast of the Wer-k and the Owner-'s anfieipated design and eanstnaefien milestones,as .compensation(if required) § 1.3 The parties shall agree upon protocols governing the transmission and use of Instruments of Service or any other information or documentation in digital form.he pa44ies��'�„1l use 4 L^ Deew=eRt E203TM 2012 Building development,144ma4ion Wdeling and Digital Data Exhibit,to establish the pr-oteeals fieff the, use,tFexeliange of digital data. § 1.3.1 Any use of,or reliance on,all or a portion of a building information model without agreement to protocols governing the use of,and reliance on,the information contained in the model and without having those protocols set ,forth,shall be at the using or relying party's sole risk and without liability to the other party and its contractors or consultants,the authors of,or contributors to,the building information model,and each of their agents and employees. § 2.6.1 Commercial General Liability with policy limits of not less than Two Million Dollars($2,000,000.00.)for each occurrence and Two Million Dollars($2,000,000.00.) in the aggregate for bodily injury and property damage. § 2.6.2 Automobile Liability covering vehicles owned,and non-owned vehicles used,by the Architect with policy limits of not less than( }One Million Dollars($1,000,000.00)per accident for bodily injury,death of any person, and property damage arising out of the ownership,maintenance and use of those motor vehicles,along with any other statutorily required automobile coverage. § 2.6.5 'Liability with pehey hinits fiet less than ($ )eaeh aeeidefft, (S )eaeh effiplayee,a-ad ($ pahey Deleted. § 2.6.6 Professional Liability covering negligent acts,errors and omissions in the performance of professional services,with policy limits of not less than($hex c $ Five Million Dollars($5,000,000.00)per claim and Five Million Dollars($5,000,000.00)_in the aggregate. PAGE 7 Additions and Deletions Report for AIA Document 13133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail Page 209 copyright@aia.org. User Notes: (1885 Item#17. § 2.6.7 Additional Insured Obligations.T^tho fidlw#extent pefmi#ed by!a--A,,the The Architect shall cause the primary and excess or umbrella polices for Commercial General Liability and Automobile Liability to include the Owner as an additional ' .insured.The additional insured coverage shall be primary and non-contributory to any of the Owner's insurance policies and shall apply to both ongoing and completed operations. § 3.1.9 Concept Design and Entitlement Support PROVIDED UNDER SEPARATE CONTRACT §3.2 Review of the Construction Manager's Guaranteed Maximum Price Proposal or Control Estimate—NOT INCLUDED IN CONTRACT OR FEE PAGE 8 §3.3 Schematic Design Phase cer"i,.es § 3.3 Schematic Design Phase Services—PROVIDED UNDER SEPARATE CONTRACT PAGE 10 § 3.6.2.4 Interpretations and decisions of the Architect shall be consistent with the intent of,and reasonably inferable from,the Contract Documents and shall be in writing or in the form of drawings.When making such interpretations and decisions,the Architect shall endeavor to secure faithful performance by both Owner and Construction Manager, shall not show partiality to either,and shall not be liable for results of interpretations or decisions rendered in good faith.The Architect's decisions on matters relating to aesthetic effect shall be final if consistent with the intent expressed in the Contract Documents subject to written approval of the Owner. PAGE 11 § 3.6.5.1 T4tt-Subj ect to Owner's approval,the Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time.Subject to Section 4.2,the Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with the Contract Documents. PAGE 12 § 3.6.6 Protect Completion—NOT INCLUDED IN CONTRACT OR FEE PAGE 13 Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail Page 210 copyright@aia.org. User Notes: (1885 25) Item#17. 4.1.1.1 Assistance with Selection of Construction Manager Not Provided 4.1.1.2 Programming Provided under previous contract 4.1.1.3 Multiple Preliminary Designs Not Provided 4.1.1.4 Measured drawings Not Provided 4.1.1.5 Existing facilities surveys Not Provided 4.1.1.6 Site evaluation and planning Provided under previous contract 4.1.1.7 Building Information Model management responsibilities Not Provided § 4.1.1.8 Development of Building Information Models for post Not Provided construction use 4.1.1.9 Civil engineering Architect under Basic Services 4.1.1.10 Landscape design Architect under Basic Services 4.1.1.11 Architectural interior design Architect under Basic Services 4.1.1.12 Value analysis Not Provided 4.1.1.13 Cost estimating Not Provided 4.1.1.14 On-site project representation Not Provided 4.1.1.15 Conformed documents for construction Not Provided 4.1.1.16 As-designed record drawings Not Provided 4.1.1.17 As-constructed record drawings Not Provided 4.1.1.18 Post-occupancy evaluation Not Provided 4.1.1.19 Facility support services Not Provided 4.1.1.20 Tenant-related services Not Provided 4.1.1.21 Architect's coordination of the Owner's consultants Not Provided § 4.1.1.22 Alerting and emergency response systems,including Not Provided antennas and audio equipment § 4.1.1.23 Security evaluation and planning Not Provided § 4.1.1.24 Commissioning Not Provided 4.1.1.25 Sustainable Project Services pursuant to Section 4.1.3 Not Provided 4.1.1.26 Historic preservation Not Provided 4.1.1.27 Furniture,furnishings,and equipment design Not Provided 4.1.1.28 Other services provided by specialty Consultants Not Provided 4.1.1.29 Other Supplemental Services Not Provided § 4.1.1.30 Entitlements Provided under previous contract 4.1.1.31 Fire Station Traffic Si nalization Desi n Not Provided § 4.1.1.32 IT and Data Dcsign Architect under Basic Services § 4.1.2.1 A description of each Supplemental Service identified in Section 4.1.1 as the Architect's responsibility is provided below. ineluwed as an`„t ibit to dese-ibe the A -ehiteet', c..pple....eota Seryicee )in. None Additions and Deletions Report for AIA Document 13133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail Page 211 copyright@aia.org. User Notes: (1885 25) Item#17. None § 4.1.3 ,the Mehiteet shall provide, , as provided in Seetion ".'.Intentionally Deleted. PAGE 14 § 4.2.2 To a-void delay in the,Cm-R-st-metion Phase,the A&ehiteet sha4l provide the fbilowing Additional gen,iees,fletify the 0,A%er- *' . . pr-emptness,and explain the faets and eir-eumstaftees gi'Aag rise te the need.if-,Upon by the , .2 Responding to the Constfuetion Manager-'s requests for-infafmation that are not prepared in aeeerdafiee .a, tat sei=viee; 4 F;'Aluting an extensive numbef of Claims as the Ifikial Deeisieft Maker-; Intentionally Deleted. .1 Two ( L)reviews of each Shop Drawing,Product Data item,sample and similar submittals of the Construction Manager .2 Thirty Two ( 2L)visits to the site by the Architect during construction .3 Two ( L)inspections for any portion of the Work to determine whether such portion of the Work is substantially complete in accordance with the requirements of the Contract Documents .4 Two ( L)inspections for any portion of the Work to determine final completion PAGE 15 § 4.2.5 H-Subject to the Owner's prior approval,the services covered by this Agreement have not been completed within(—}twelve(N months of the date of this Agreement,through no fault of the Architect,extension of the Architect's services beyond that time&hall-mav be compensated as Additional Services. § 5.5 The Owner shall furnish surveys to describe physical characteristics,and legal limitations and utility locations for the site of the Project,and a written legal description of the site.The surveys and legal information shall include,as applicable,grades and lines of streets,alleys,pavements and adjoining property and structures;designated wetlands; adjacent drainage;rights-of-way,restrictions,easements,encroachments,zoning,deed restrictions,boundaries and contours of the site;locations,dimensions,and other necessary data with respect to existing buildings,other improvements and trees;and information concerning available utility services and lines,both public and private, above and below grade,including inverts and depths.All the information on the survey shall be referenced to a Project benchmark. PAGE 17 Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail page 212 copyright@aia.org. User Notes: (1885 425) Item#17. § 6.5 If the Construction Manager's estimate of the Cost of the Work at the conclusion of the Design Development Phase exceeds the Owner's budget for the Cost of the Work,the Owner 4,,a# ay .2 te... inane in a da- ee .,it>, Seetien 9.5;intentionally deleted § 6.7 subsequent east estimates,the Qaafan4eed Mffldmum Pr-iee proposal,or-Cai#fel Estimate tha4 exeeed the Owfier-'s systems,E)F the kinds a-ad"ality of materials,finishes or- Intentionally Deleted. PAGE 19 [X Litigation in a court of competent jurisdiction § Si 4 Arhitre#inn elaim,dispiate oi:other-matter-in questien ar4s*out of or-related te this Agr-eefnent subjeet to,but not r-eselved§ 8.3.1 if the par-ties have seleeted afbit-Fation as the methed fer-binding dispwe r-eseletien in this Agr-eement, Hily medimian shall be subjeet to shall be administer-ed-b-y > > > date of d3mis AgFeement.A demand for-ar-bitfation shall be,Made,in 10,witiag,d0iver-ed to the ethef-party to this Agreement,audd Ale,d, 4th the per-sonor-entity administering the ar-bit.•.,t:§ 8.3.1.1 A d-teman d-fiff-ar-h-4-ati R_n isha I I h-e,ma de n R_ ewid i er-t-han P_A-n eui*effltly with the fi ling of a request for-mediati..., , eenstitute the institution of legal or-equitable preeeedings based an the elaim,dispute or-other-ma4ter-in quest § 8.3.2 The foregoing agreement te afbitfate,and other-agr-eements te ar-bitfa4e with an additienal per-seia or-enfity d* § 8.3.3 The award rendeFed by the ar-bitfatar-(s)shall be�PRal,andjudggment may be entered upon it in aeewdaneew applicable- Imo,.,; ,.-r having ,-isdi.+ion thereof-. . > pefmits > e a-ad(3)the afbitr-atians employ materially sifailaf pr-aeedtwal fules and methods for-seleeting af-bitrater-(s). . >at its sole diseretion, e deser-ibed in the,.Fitte eensefA-. Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail page 213 copyright@aia.org. User Notes: (1885 Item#17. § 8.4 The provisions of this Ai4iele 9 shall supxive the tefmination of this Agreement. § 8.3 Intentionally Deleted § 9.7 in addition to any afneunts paid undef Seetion 9.6, pufsuant to Seetion 9.5,or-thiQ.,A-rvh4Pr#kafmina4es this Agreement pur-suan, i R- Steedon 9.3,the Owner-shall pay to the fi,...,..;, r i Temieatien Fee! Intentionally Deleted § 9.8 Substantial Camp! Intentionally Deleted PAGE 21 4-1. Stipulated Sum "ser4 amoun'`Design Development-Bidding Support:Three Hundred Forty-five Thousand Seven Hundred Eighty-one Dollars($345,781.00) 2. Time&Expense to a Maximum Construction Administration:One Hundred Sixty-three Thousand One Hundred Ninety Dollars ($163,190.00) .2 Pereeat-ageBasis ir. ,ere r,,, 'age�w' e 3. Reimbursable Expenses o of the Owner-'s budget fef-the Cost of the Work,as ea4eulated in aeeer-danee with Seetion 11.67 .3 OtheF Time and Expense at architects'cost to a Maximum of Twenty Thousand Dollars($20,000.00,). Any request for reimbursement must be substantiated by a receipt. Included in Architect's Basic Services fee listed above To be negotiated prior to the performance of Additional Services. (1aseA amount of-,or-basis fef eefnpu4ing,Arehiteet's eensultants' eampeasation for-Supplemental er Additional Services-} Not applicable. Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail page 214 copyright@aia.org. User Notes: (1885 425) Item#17. Set,emat a Design Phase Per-eefit ( TO7 Design Development Phase Per-eefit ( TO7 lam.. st etion ll.. ..ram Phas-a per-eent� Pereefit 4-W mil Design Development Phase Thirty-five percent 35%1 Construction Documents Phase Fifty-five percent 55% Bidding Support Ten percent 10%1 Total Basic Compensation One Hundred percent 100%1 Design—Biddina Support PAGE 22 As described in Exhibit A Employee OF GategGFY Rate($0.00) .1 Pre-Authorized out-of-town travel and s•�subsistence per GSA allowance .6 , if au-ther-iZed in advanese by the Owaer•,Deleted .8 ' expenses of pr-afessional liability iasuFmee dedieated exelusively to this Pr-ejeet,or the expense a eensultants;Qeleted .10 Site affiee e Me^^e^•Deleted. .11 Registra4ien fees and any other fees eharged by the Gert&�fig Auffier-ity or-by edief entities as eleted. .12 Othef similaf Prejeet related eiipeaditffes-Deleted. Ar-p-hitteoet"s eenstiltants plus perseM( 0%)of the expenses ifietffed. § 11.9Archetpnt'q IRS' Fame.ifthe bTes and limits of oever-age required in Seetion 2.4 ana,in Addition to the bVes and Deleted Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail Page 215 copyright@aia.org. User Notes: (1885 Item#17. § 11.10.1.1 An initial payment of{$—}zero dollars($0.00)shall be made upon execution of this Agreement and is the minimum payment under this Agreement.It shall be credited to the Owner's account in the final invoice. § 11.10.1.2 ,an initial Payffief4 to the A vehiteet of ShAbe made upon exermition of this Agreement f6FFegis#a6E)a fees a—ad-othew-&-t-As payable to the Gergfyin Auther-ity shall be er-edited te the Ov,%er-'s aeeettnt at the time the expense is .Deleted § 11.10.2.1 Unless otherwise agreed,payments for services shall be made monthly in proportion to services performed.Payments are due and payable sentation A-k#e A rvahiteet's invoiee s unpaid ffifti-w- the,invoie,65 d-ahe ish-All h_e,_Ar_-intiffemst at th-ge;Fats- ten-te-n-Add below,or in the ahb.,st-An6spe t—ho-y-teefat the legal rate pr-evailia -4-A- ,tim-y-to time.,t the principal,.lace- fbusiness of the A e ;te,.+,net 30 from the Owner's receipt of a correct invoice. Zero percentage (0%) PAGE 23 Limitation of Liability Rice Fergus Miller's total liability to the Owner for any and all injuries,claims,losses, expenses,damages or claims expenses arising out of this agreement from any cause or causes,shall not exceed the total available amount of Rice Fergus Miller's Professional Liability insurance policy(Rice Fergus Miller's current available amount of Professional Liability Insurance is the full policy of$5,000,000). A-1 A-Doetifneat E2031M 2013,Building infefma4ion Modeling and Digital D4a Exhibit,dat ir,s r4tc date of the z Ana onlai t ai +,,t this agr-eememt.4 >Sustainable Prejeets E344bit, Genstnaetieff Manager-as f aast,.,,etar-Edition dated a indieated below � 0—ta2f d_eeumeats.: Exhibit A-Rice Fergus Miller 2021 Hourly Billing Rates City of Meridian,and Idaho Municipal Corporation David A.Fergus,Principal Additions and Deletions Report for AIA Document B133'—2019.Copyright©2014,and 2019 by The American Institute of Architects.All rights reserved.The "American Institute of Architects,""AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is one-time use only,and may only be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail Page 216 copyright@aia.org. User Notes: (1885 Item#17. Certification of Document's Authenticity AIA° Document D401 TM — 2003 1, ,hereby certify,to the best of my knowledge,information and belief,that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 18:21:39 ET on 06/03/2021 under Order No. 7610209206 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA®Document B 133TM—2019,Standard Form of Agreement Between Owner and Architect, Construction Manager as Constructor Edition,as published by the AIA in its software, other than those additions and deletions shown in the associated Additions and Deletions Report. (Signed) (Title) (Dated) AIA Document D401'TM—2003.Copyright @ 1992 and 2003 by The American Institute of Architects.All rights reserved.The"American Institute of Architects," "AIA,"the AIA Logo,and"AIA Contract Documents"are registered trademarks and may not be used without permission.This document was produced by AIA software at 18:21:39 ET on 06/03/2021 under Order No.7610209206 which expires on 10/30/2021,is not for resale,is licensed for one-time use only,a be used in accordance with the AIA Contract Documents®Terms of Service.To report copyright violations,e-mail copyright@aia.org. Page 217 User Notes: (1885 Item#17. eYgumILLER ARCHITECTURE INTERIORS PLANNING VIZLAB 275 Fifth Street,Suite 100 Bremerton,WA 98337 Phone: (360) 377-8773 rfmarch.com 2021 Hourly Billing Rates Date of Proposal: May 27, 2021 Project: Meridian South Fire Station Design - Construction Administration Project No.: 2020038.06 The hourly billing rates shall be annually adjusted in accordance with normal salary review practices of Rice Fergus Miller. Principal in Charge: $ 275.00 Senior Planner: $ 175.00 - $ 275.00 Project Manager: $ 130.00 - $ 190.00 Project Architect: $ 120.00 - $ 190.00 Staff Architect: $ 125.00 - $ 160.00 Project Designer: $ 115.00 - $ 190.00 Staff Designer: $ 115.00 - $ 155.00 Interior Designer: $ 90.00 - $ 160.00 Technical Designer: $ 95.00 - $ 155.00 Production Support: $ 85.00 - $ 155.00 Graphics Visualization: $ 115.00 - $ 125.00 Project Coordinator: $ 80.00 - $ 120.00 Administrative Support Staff: $ 80.00 - $ 120.00 Page 218