HomeMy WebLinkAboutSonntag Recreation, LLC - Discovery Park Playground Equipment and InstallationCONTRACT FOR DESIGN, SUPPLY AND INSTALLATION OF THE
DISCOVERY PARK PLAYGROUND, SPLASH PAD & CLIMBING MAP
PROJECT # 10121.G
INTRODUCTION
Whereas, the City has a need for services involving Plavqround Desiqn &
installation ;and
WHEREAS, the Contractor is specially trained, experienced and competent
to perform and has agreed to provide such services;
NOW, THEREFORE, in consideration of the mutual promises, covenants,
terms and conditions hereinafter contained, the parties agree as follows:
TERMS AND CONDITIONS
1. Scope of Work:
1.2 All documents, drawings and written work product prepared or produced by
the Contractor under this Agreement, including without limitation electronic data
files, are the property of the Contractor; provided, however, the City shall have the
right to reproduce, publish and use all such work, or any part thereof, in any
manner and for any purposes whatsoever and to authorize others to do so. lf any
such work is copyrightable, the Contractor may copyright the same, except that, as
to any work which is copyrighted by the Contractor, the City reserves a royalty-free,
non-exclusive, and irrevocable license to reproduce, publish and use such work, or
any part thereof, and to authorize others to do so.
1.3 The Contractor shall provide services and work under this Agreement
consistent with the requirements and standards established by applicable federal,
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING I\4AP
Project 10121.G
page 1 of '13
THIS CONTRACT FOR DESIGN, SUPPLY AND INSTALLATION OF THE
DISCOVERY PARK PLAYGROUND, SPLASH PAD AND CLIMBING MAP is made this
1Oth day of July, 2018, and entered into by and between the City of Meridian, a municipal
corporation organized under the laws of the State of ldaho, hereinafter referred to as
"CITY', 33 East Broadway Avenue, Meridian, Idaho 83642, and Sonntaq Recreation. LLC,
hereinafter referred to as "CONTRACTOR", whose business address is 4245 Panorama
Cir.. Salt Lake Citv, UT 84124 and whose Public Works Contractor License # is 034438.
1 .1 CONTRACTOR shall perform and furnish to the City upon execution of this
Contract and receipt of the City's written notice to proceed, all services and work,
and comply in all respects, as specified in the document titled "Scope of Work" a
copy of which is attached hereto as Exhibit "A" and incorporated herein by this
reference, together with any amendments that may be agreed to in writing by the
parties.
Meridian City Council Meeting Agenda July 10, 2018 – Page 428 of 522
state and city laws, ordinances, regulations and resolutions. The Contractor
represents and warrants that it will perform its work in accordance with generally
accepted industry standards and practices for the profession or professions that
are used in performance of this Agreement and that are in effect at the time of
performance of this Agreement. Except for that representation and any
representations made or contained in any proposal submitted by the Contractor
and any reports or opinions prepared or issued as part of the work performed by
the Contractor underthis Agreement, Contractor makes no other warranties, either
express or implied, as part of this Agreement.
1 .4 Services and work provided by the Contractor at the City's request under this
Agreement will be performed in a timely manner in accordance with a Schedule of
Work, which the parties hereto shall agree to. The Schedule of Work may be
revised from time to time upon mutual written consent of the parties.
2.Consideration
2.1 The Contractor shall be compensated on a Not-To-Exceed basis as provided
in Exhibit B "Payment Schedule" attached hereto and by reference made a part
hereof for the Not-To-Exceed amount of $547,825.84.
2.2 The Contractor shall provide the City with a monthly statement and
supporting invoices, as the work warrants, of fees earned and costs incurred for
services provided during the billing period, which the City will pay within 30 days of
receipt of a correct invoice and approval by the City. The City will not withhold any
Federal or State income taxes or Social Security Tax from any payment made by
City to Contractor under the terms and conditions of this Agreement. Payment of
all taxes and other assessments on such sums is the sole responsibility of
Contractor.
2.3 Except as expressly provided in this Agreement, Contractor shall not be
entitled to receive from the City any additional consideration, compensation, salary,
wages, or other type of remuneration for services rendered under this Agreement
including, but not limited to, meals, lodging, transportation, drawings, rendedngs or
mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement
to consideration in the form of overtime, health insurance benefits, retirement
benefits, paid holidays or other paid leaves of absence of any type or kind
whatsoever.
3. Term:
3.1 This agreement shall become effective upon execution by both parties, and
shall expire upon (a) completion of the agreed upon work, (b) or unless sooner
terminated as provided in sections 3.2, 3-3, and section 4 below or unless some
other method or time of termination is listed in Exhibit A.
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING MAP
Project 10121.c page 2 of 13
Meridian City Council Meeting Agenda July 10, 2018 – Page 429 of 522
3.2 Should Contractor default in the performance of this Agreement or materially
breach any of its provisions, City, at City's option, may terminate this Agreement by
giving written notification to Contractor.
3.3 Should City fail to pay Contractor all or any part of the compensation set forth
in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's
option, may terminate this Agreement if the failure is not remedied by the City
within thirty (30) days from the date payment is due.
4. Liquidated Damages:
Substantial Completion shall be accomplished within 180 (one hundred eighty)
calendar days from Notice to Proceed. This project shall be considered
Substantially Complete when the Owner has full and unrestricted use and benefit
of the facilities, both from an operational and safety standpoint, and only minor
incidental work, corrections or repairs remain for the physical completion of the
total contract. Contractor shall be liable to the City for any delay beyond this time
period in the amount of $300.00 (three hundred dollars) per calendar day. Such
payment shall be construed to be liquidated damages by the Contractor in lieu of
any claim or damage because of such delay and not be construed as a penalty.
Upon receipt of a Notice to Proceed, the Contractor shall have 210 (two hundred
ten) calendar days to complete the work as described herein. Contractor shall be
liable to the City for any delay beyond this time period in the amount of $300.00
(three hundred dollars) per calendar day. Such payment shall be construed to be
liquidated damages by the Contractor in lieu of any claim or damage because of
such delay and not be construed as a penalty. See Milestones listed in the
Payment Schedule for Substantial Completion.
5. Termination:
5.1 lf, through anycause, CONTRACTOR, its officers, employees, oragentsfails
to fulfill in a timely and proper manner its obligations under this Agreement, violates
any of the covenants, agreements, or stipulations of this Agreement, falsifies any
record or document required to be prepared under this agreement, engages in
fraud, dishonesty, or any other act of misconduct in the performance of this
contract, or if the City Council determines that termination of this Agreement is in
the best interest of CITY, the CITY shall thereupon have the right to terminate this
Agreement by giving written notice to CONTRACTOR of such termination and
specifying the effective date thereof at least fifteen (15) days before the effective
date of such termination. CONTRACTOR may terminate this agreement at any
time by giving at least sixty (60) days notice to CITY.
ln the event of any termination of this Agreement, all finished or unfinished
documents, data, and reports prepared by CONTRACTOR under this Agreement
shall, at the option of the CITY, become its property, and CONTRACTOR shall be
entitled to receive just and equitable compensation for any work satisfactorily
complete hereunder.
DISCOVERY PARK PLAYGROUND, SLASH PAO & CLIMBING MAP
Project 10121.G
page 3 of '13
Meridian City Council Meeting Agenda July 10, 2018 – Page 430 of 522
5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liabilityto
the CITY for damages sustained by the CITY by virtue of any breach of this
Agreement by CONTRACTOR, and the CITY may withhold any payments to
CONTRACTOR forthe purposes of set-off until such time as the exact amount of
damages due the CITY from CONTRACTOR is determined. This provision shall
survive the termination of this agreement and shall not relieve CONTRACTOR of
its liability to the CITY for damages.
6.'1 ln all matters pertaining to this agreement, CONTRACTOR shall be acting as
an independent contractor, and neither CONTRACTOR nor any officer, employee
or agent of CONTRACTOR will be deemed an employee of CITY. Except as
expressly provided in Exhibit A, Contractor has no authority or responsibility to
exercise any rights or power vested in the City and therefore has no authority to
bind or incur any obligation on behalf of the City. The selection and designation of
the personnel of the CITY in the performance of this agreement shall be made by
the CITY.
6.2 Contractor, its agents, officers, and employees are and at alltimes during the
term of this Agreement shall represent and conduct themselves as independent
contractors and not as employees of the City.
6.3 Contractor shall determine the method, details and means of performing the
work and services to be provided by Contractor under this Agreement. Contractor
shall be responsible to City only for the requirements and results specified in this
Agreement and, except as expressly provided in this Agreement, shall not be
subjected to City's control with respect to the physical action or activities of
Contractor in fulfillment of this Agreement. lf in the performance of this Agreement
any third persons are employed by Contractor, such persons shall be entirely and
exclusively under the direction and supervision and control of the Contractor.
7. Sub-Contractors:
Contractor shall require that all of its sub-contractors be licensed per State of ldaho
Statute # 54-19O1
8. Removal of Unsatisfactory Employees:
The Contractor shall only furnish employees who are competent and skilled for work
under this contract. lf, in the opinion of the City, an employee of the Contractor is
incompetent or disorderly, refuses to perform in accordance with the terms and
conditions of the contract, threatens or uses abusive language while on City
property, or is othenrvise unsatisfactory, that employee shall be removed from all
work under this contract.
DISCOVERY PARK PLAYGROUND. SLASH PAD & CLIMBING MAP
Prqect'10'121.G
page 4 of 13
6. lndependentContractor:
Meridian City Council Meeting Agenda July 10, 2018 – Page 431 of 522
9.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's
elected officials, officers, employees, agents, and volunteers from and for any and
all losses, claims, actions, judgments for damages, or injury to persons or property
and losses and expenses and other costs including litigation costs and attorney's
fees, arising out of, resulting from, or in connection with the performance of this
Agreement by the CONTRACTOR, its servants, agents, officers, employees,
guests, and business invitees, and not caused by or arising out of the tortious
conduct of CITY or its employee s. CONTRACTOR shall maintain, and specificallv
aq rees that it will maintain thro UO hout the term of this Aqreement. liabilitv
rnsu rance in which the CITY shall be named an additional insured in the minimum
amounts as follow: General Liabil ity One IMillion Dollars ($1,000,000) per incident
or occurrence, Automobile Liability lnsurance One Million Dollars ($1 ,000,000) per
incident or occurrence and Workers' Compensation lnsurance, in the statutory
limits as required by law.. The limits of insurance shall not be deemed a limitation
of the covenants to indemnify and save and hold harmless CITY; and if CITY
becomes liable for an amount in excess of the insurance limits, herein provided,
CONTRACTOR covenants and agrees to indemnify and save and hold harmless
CITY from and for all such losses, claims, actions, or judgments for damages or
injury to persons or property and other costs, including litigation costs and
attorneys' fees, arising out of, resulting from , or in connection with the
performance of this Agreement by the Contractor or Contractor's officers, employs,
agents, representatives or subcontractors and resulting in or attributable to
personal injury, death, or damage or destruction to tangible or intangible property,
including use of. CONTRACTOR shall provide CITY with a Certificate of
lnsurance, or other proof of insurance evidencing CONTRACTOR'S compliance
with the requirements of this paragraph and file such proof of insurance with the
CITY at least ten (10) days prior to the date Contractor begins performance of it's
obligations under this Agreement. ln the event the insurance minimums are
changed, CONTRACTOR shall immediately submit proof of compliance with the
changed limits. Evidence of all insurance shall be submitted to the City Purchasing
Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue,
Meridian, ldaho 83642.
9.2 lnsurance is to be placed with an ldaho admitted insurerwith a Best's rating
of no less than A-.
9.3 Any deductibles, self-insured retention, or named insureds must be declared
in writing and approved by the City. At the option of the City, either: the insurer
shall reduce or eliminate such deductibles, self-insured retentions or named
insureds; or the Contractor shall provide a bond, cash or letter of credit
guaranteeing payment of losses and related investigations, claim administration
and defense expenses.
9.4 To the extent of the indemnity in this contract, Contractor's lnsurance
coverage shall be primary insurance regarding the City's elected officers, officials,
employees and volunteers. Any insurance or self-insurance maintained by the City
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLII\4BING MAP
Project 10121.c
page 5 of 13
9. lndemnification and lnsurance:
Meridian City Council Meeting Agenda July 10, 2018 – Page 432 of 522
or the City's elected officers, officials, employees and volunteers shall be excess of
the Contractor's insurance and shall not contribute with Contractor's insurance
except as to the extent of City's negligence.
9.6 All insurance coverages for subcontractors shall be subject to all of the
insurance and indemnity requirements stated herein.
10. Time is of the Essence:
The parties hereto acknowledge and agree that time is strictly of the essence with
respect to each and every term, condition and provision hereof, and that the failure
to timely perform any of the obligations hereunder shall constitute a breach of, and
a default under, this Agreement by the party so failing to perform.
11. Bonds:
Payment and Performance Bonds are required on all Public Works lmprovement
Projects per the ISPWC and the City of Meridian Supplemental Specifications &
Drawings to the ISPWC, which by this reference are made a part hereof.
Contractor is required to furnish faithful performance and payment bonds in the
amount of 100o/o of the contract price issued by surety licensed to do business in
the State of ldaho. ln the event that the contract is subsequently terminated for
failure to perform, the contractor and/or surety will be liable and assessed for any
and all costs for the re-procurement of the contract services.
12, Warranty:
All construction and equipment provided under this agreement shall be warranted
for 2 years from the date of the City of Meridian acceptance perthe ISPWC and the
Meridian Supplemental Specifications & Drawings to the ISPWC and any
modifications, which by this reference are made a part hereof.
All items found to be defective during a warranty inspection and subsequenfly
corrected will require an additional two (2) year warranty from the date of City's
acceptance of the corrected work.
13. Changes:
The CITY may, from time to time, request changes in the Scope of Work to be
performed hereunder. Such changes, including any increase or decrease in the
amount of CONTRACTOR'S compensation, which are mutually agreed upon by and
DISCOVERY PARK PLAYGROUND, SLASH PAO & CLIMBING MAP
Project 10121.G
page 6 of 13
9.5 The Contractor's insurance shall apply separately to each insured against
whom claim is made or suit is brought, except with respect to the limits of the
insureis liability.
9.7 The limits of insurance described herein shall not limit the liability of the
Contractor and Contractor's agents, representatives, employees or subcontractors.
Meridian City Council Meeting Agenda July 10, 2018 – Page 433 of 522
between the CITY and CONTRACTOR, shall be incorporated in written
amendments which shall be executed with the same formalities as this Agreement.
14. Taxes:
The City of Meridian is exempt from Federal and State taxes and will execute the
required exemption certificates for items purchased and used by the City. ltems
purchased by the City and used by a contractor are subject to Use Tax. All other
taxes are the responsibility of the Contractor and are to be included in the
Contractor's Bid pricing.
15. Meridian StormwaterSpecifications:
All construction projects require either a Storm Water Pollution Prevention Plan
(SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of
Meridian Construction Stormwater Management Program (CSWMP) manual. The
CSWMP manual containing the procedures and guidelines can be found at this
address: http://www.meridiancitv.orq/environmental aspx?id=13618.
Contractor shall retain all stormwater and erosion control documentation generated
on site during construction including the SWPPP manual, field inspections and
amendments. Prior to final acceptance of the job by the City the contractor shall
return the field SWPPP manual and field inspection documents to the City for
review. A completed Contractor Request to File Project N.O.T. with the EPA form
shall be provided to the City with the documents. These documents shall be
retained, reviewed and approved by the City prior to final acceptance of the project.
16. ACHD:
lf required, Contractor shall be responsible for coordinating with the City to obtain
appropriate ACHD permit(s) and will reimburse the City for fees, fines, or penalties
City incurs due to Contractor's violation of any ACHD policy. City shall certify to
ACHD that Contractor is authorized to obtain a Temporary Highway and Right-of-
Way Use Permit from ACHD on City's behalf. The parties acknowledge and agree
that the scope of the agency granted by such certification is limited to, and
conterminous with, the term and scope of this Agreement.
17. Reports and Information:
17.1 At such times and in such forms as the CITY may require, there shall be
furnished to the CITY such statements, records, reports, data and information as
the CITY may request pertaining to matters covered by this Agreement.
17.2 Conlractor shall maintain all writings, documents and records prepared or
compiled in connection with the performance of this Agreement for a minimum of
four (4) years from the termination or completion of this or Agreement. This
includes any handwriting, typewriting, printing, photo static, photographic and every
other means of recording upon any tangible thing, any form of communication oi
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING I\4AP
Project 10121.G
page 7 of 13
Meridian City Council Meeting Agenda July 10, 2018 – Page 434 of 522
representation including letters, words, pictures, sounds or symbols or any
combination thereof.
18. Audits and lnspections:
At any time during normal business hours and as often as the CITY may deem
necessary, there shall be made available to the CITY for examination all of
CONTRACTOR'S records with respect to all matters covered by this Agreement.
CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or
transcripts from such records, and to make audits of all contracts, invoices,
materials, payrolls, records of personnel, conditions of employment and other data
relating to all matters covered by this Agreement.
19. Publication, Reproduction and Use of Material:
No material produced in whole or in part under this Agreement shall be subject to
copyright in the United States or in any other country. The CITY shall have
unrestricted authority to publish, disclose and otherwlse use, in whole or in part, any
reports, data or other materials prepared under this Agreement.
20. Equal Employment Opportunity:
ln performing the work herein, Contractor agrees to comply with the provisions of
Title Vl and Vll of the Civil Rights Act, Revenue Sharing Act Title 31 , U.S. Code
Section 2176. Specifically, the Contractor agrees not to discriminate against any
employee or applicant for employment because of race, color, religion, sex, national
origin, age, political affiliation, marital status, or handicap. Contractor will take
affirmative action during employment or training to insure that employees are
treated without regard to race, color, religion, sex, national origin, age, political
affiliation, marital status, or handicap. ln performing the Work required herein,
CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or
local law, rule or regulation against any person on the basis of race, color, religion,
sex, national origin or ancestry, age or disability.
21. Employment of Bona Fide ldaho Residents:
Contractor must comply with ldaho State Statute 44-1002 which states that the
Contractor employ ninety-five percent (95%) bona fide ldaho residents.
22. Advice of Attorney:
23
Each party warrants and represents that in executing this Agreement. lt has
received independent legal advice from its attorney's orthe opportunityto seek such
advice.
Aftorney Fees:
should any litigation be commenced between the parties hereto concernlng this
OISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING MAPProject 10'12'l.c page 8 of 13
Meridian City Council Meeting Agenda July 10, 2018 – Page 435 of 522
Agreement, the prevailing party shall be entitled, in addition to any other relief as
may be granted, to court costs and reasonable attorneys'fees as determined by a
Court of competent jurisdiction. This provision shall be deemed to be a separate
contract between the parties and shall survive any default, termination or forfeiture
of this Agreement.
24. ConstructionandSeverability:
lf any part of this Agreement is held to be invalid or unenforceable, such holding will
not affect the validity or enforceability of any other part of this Agreement so long as
the remainder of the Agreement is reasonably capable of completion.
25. Waiver of Default:
Waiver of default by either party to this Agreement shall not be deemed to be waiver
of any subsequent default. Waiver or breach of any provision of this Agreement
shall not be deemed to be a waiver of any other or subsequent breach, and shall
not be construed to be a modification of the terms of this Agreement unless this
Agreement is modified as provided above.
26. Entire Agreement:
This Agreement contains the entire agreement of the parties and supersedes any
and all other agreements or understandings, oral of written, whether previous to the
execution hereof or contemporaneous herewith.
27. Assignment:
It is expressly agreed and understood by the partles hereto, that CONTRACTOR
shall not have the right to assign, transfer, hypothecate or sell any of its rights under
this Agreement except upon the prior express written consent of CITY.
28. Payment Request:
Payment requests shall be submitted to City of Meridian through the City's project
management software. The Project Manager will compare the invoice against the
Payment Schedule in the Agreement for compliance. Upon approval that the work
has been done and is in compliance with the Agreement, the Project Managerwill
approve the pay request for processing. City of Meridian payment terms are Net 30
from the date City receives a correct invoice. Final payment will not be released
until the City has received a tax release from the Tax Commission.
29. Cleanup:
Contraclor shall keep the worksite clean and free from debris. At completion of
work and prior to requesting final inspection, the contractor shall remove all traces
of waste materials and debris resulting from the work. Final payment will not be
made if cleanup has not been performed.
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING MAP
Prqect'10121.G
page I of 13
Meridian City Council Meeting Agenda July 10, 2018 – Page 436 of 522
3o. Ordor of Pucedeiwo:
.)I, pr6cedencc shad 1.-0 liw dlqvoelllo[T til(, II)IM,71"I i
documlolll. Mall 'millillig Ndd(�,"j ,� jol fill I t;,J imdf do(anylullt
`','1. Conmfianct� with Laws:
;(l poltof I I -III Iq the scopt---1 of Work (':()NiHI",(--, FOR
%vith a;; �ipplit.:aNw. la4vti, ardman-Go,,., mid i;oilius of Fodleral.
!jOv0rIl(II(-!fdS
Apt licablo Law,
!i)f:: I;A%�,: of thol State of Idaho, and ivi, wool u;
33. Noti,,us:
'Iflj oil kli I)Y
mllclll Mailed Uflitc(4 CH"I'i
i 'Whiressad as foitl
CITY
C Otil R AG 10 k,
City ol Pari di, -Irl
ldw:v V(2
L'ukt, Cl!v; IT &W,l
IdWio Pi;'Oltc Llconso Ai 03441'i..3
E,iiiii.;f pany I flay c"lanqa their arltdrci.s tur !",E' purpoa,: of Ihi.q 'E"i q:vIfIq
I iotici� (if chanqu, to HIC Otilol !Ii U"Is.) OMVI,,i:,;J
34, Approval Requirpd-,
f his Mire?!] ont shall riot beconle effectolf" C,!, Uilding tl!llii approved by "ll:', Ci(", (,I!
Me I I i -J in r 1.
IA S ONWi AG RFCRL-*A 1 ION
A-
HY. :5CV-AUkjTvj
A 0
30. Orcier ol Precerlgnce :
I he arder or preeedence shall ire the contr€ct agree,nent, lhe lnvttatr()n i{:}{ fijfl
docunrent. then lhe wtnnirig bidder,i subrnitled bi<j document.
31. Cornpliance with L6ws:
ln performing the scope of work required hsreunder. CONTRACTOR shali .omply
lvith al{ applicabie laws, ordinanc€s, arrcl codes of Fod€ral. Siato. ar:C local
ggvemmonls.
Appllcablo Lawl.t
Thrs Agreonrent shali be govemed by and construed and entorced in ac(pr{::arice
\rltil ihe laws of th6 Slate of idaho. and tiic crdtnancss of tile Oity ol l\,lerirlian.
33, Noticos:
Any and all notices required to bo givon by eith€r of the oerfres hereta, llde:is
othi:r\Alse stated in thrs agreernent, shal! ile in writing a,ld Lre rle$mr)(,
communrcaled when malled ifi the United States mail, certiiad, relurri ieitsipt
teques(ed, addressad as foilows;
cl rr
Cdy of M€ndr.n
Purcllasir'Ig it anager
33 E Broadway Avo
Itroridran. I0 63642
20s-48S-C417
CONTRACTOR
Sorntag Recisalron
Atn: Jeremiah Wcbt)
4245 Panorarna Cir
salr Lakd cily, UT 84124
Ptnfie: 80 ! -?78.9?97
Ernail : l$rebb@sdfl nta grec..am
ldaho Publrc lvorks Licens8 # 034438
Either pariy nray Change thetr addross for the purpos€ of lhis tlaralrrapfi I, grvlnll
wriitsn n{rlice ot.su$h change tc the othe n tho manner herein provirtec!
34^ Approval Required:
f his Agreement shall not b6c,ome e{fective or.binding until approverj by 0r;: i.:itv ot
Meridian.
F,,}
:,i. a-g-t8
$**na.*l1 Lldtb
Meridian City Council Meeting Agenda July 10, 2018 – Page 437 of 522
Approved by Council: ` (o / c)gl k
Attest:
C.JAY COLES, CITJ CLERK
Purchasing A proval
BY: ZZL�
KEITH WTS, Purchasing Manager
Dated:: 7-67-/9
Project Manager
Mike Barton
QOOW ED AUG(11v or
UST
C>V E IDIAN�-
�oA►+o
\yam SEAL
Department Approval
BY:
STEVE SI DOWAY, Parks & Rec Director
Dated::
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING MAP page 11 of 13
Project 10121.G
EXHIBlT A
SCOPE OF WORK
REFER TO REQUEST FOR PROPOSALS PKS.1745.10121.G
ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the
Request for Proposals Package # PKS-1745-10121.G, are by this
reference made a part hereof.
SPECIFICATIONS / SCOPE OF WORK
All construction work shall be done in accordance with the current version
of the ldaho Standards for Public Works Construction (SPWC), and City of
Meridian Supplemental Specifications to the ISPWC (and any Addendums).
See separate attached documents;
Photos and layout (7 of pases)a
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING MAP
Pro.iect 10121.G page 12 of 13
Meridian City Council Meeting Agenda July 10, 2018 – Page 439 of 522
Exhibit B
MILESTONE / PAYMENT SCHEDULE
Total and complete compensation for this Agreement shall not exceed
$547,825.84.
MILESTONE DATES/SCHEDULE
Milestone 1 1 B0 Days from Notice to Proceed
Milestone 2 Final Completion 2'10 Days from Notice to Proceed
PRICING SCHEDULE
Contract includes furnishing all labor, materials, equipment, and incidentals as required for the
above named project per IFB PKS-I745-10121.G
NOT TO EXCEED CONTRACT TOTAL $547.825.84
actual quantities of each item of work in accordance with the contract documents.
Contract Pricing Schedule
Item No.Description Quantity Unit
1 Design of Playground Structure Lot s3,681.00
2
3
Playground Structure Lot s284,868.00
Aquatix Custom Pine Tree Shower
Aquatix Stream Jet
1
4 1,Ea s7s0.00
5 Ea 51,2s0.00
6 Aquatix Bubbler 1
7 Aquatix Junior Water Jewel 7 51,700.00
1 Ea s700.00
Aquatix Domestic Water System includes the
following: Aquavator, Control Panel
Sequencing, Drain Box, Distribution Manifold-
Sequencing
1 s18,489.00
10 Engineered Wood Fiber 360
3,200
s24.00
11
72
13
Rocky Mtn. Playground Turf
lnstallation of Playground & Wood Fiber 7 sss,000.00
1 s8s,000.00
74 Payment & Performance Bonds 1 Lot 51s,s88.84
15 Lot
DISCOVERY PARK PLAYGROUND, SLASH PAD & CLIMBING MAP
Project 10121 .G
page'13 of 13
Substantial Completion
Contract is a not to exceed amount. Line item pricing below will be used for invoice verification and any
additional increases or decreases in work requested by city. The City will pay the contractor based on
Unit Price
7
1
s18,000.00
Aquatix Arch Jet 1
Ea.s3,1s0.00
Ea,
8 Aquatix Sea Crawler
9 Lot
Cu.
Yd.
Sq.
Ft.s12.00
Lot
lnstallation of Splash Pad MConcrete Work &
5' Apron Lot
Freight 7 512,609.00
Meridian City Council Meeting Agenda July 10, 2018 – Page 440 of 522
)t
I I
(
iil-it-
tr..--n
tU
',Y oqu(
by landscape
I
ra
II-- 1
)
h,
,
I
I
lI L.
I/l!
I
Meridian City Council Meeting Agenda July 10, 2018 – Page 441 of 522
I
I III
E E oq
by lan
Meridian City Council Meeting Agenda July 10, 2018 – Page 442 of 522
II
I
\
@
R
.p'
(n
C
,g1)
o
.C
o
U)
l)
t
1
I
I
ai
I
{
I
J
I
1
I
,
iI
I
I
I
J
l
/
/
/
//
/
-a
i
rt
.{-l
r
a-r
ru
t
/
It
I
I
il, IT
Meridian City Council Meeting Agenda July 10, 2018 – Page 443 of 522
p
t
t
I
I
lr
t
t
@
R
.rt
G
T
It
1
I
T,-
?.
FIl.k:t
r
I
{
I
1
ai
j
I
I
J
I
{
I
I
!!
I
!I
t
!t
iMeridian City Council Meeting Agenda July 10, 2018 – Page 444 of 522
ooo-
o
Ea,aIg
q,a
3
t
cr'ct
1'
CLos
s
e
I
e
E
aDca
co
Or6I
E
EIto
t
&
!
Ettt
Etr[!
EE
r 3ErE9€68iEe6 o3Pi
=o
"f;PEE
€3:
!€
b,
(o
0)
-oC
r
5
S
[,
Itt'
,
o3.Gp
a
l.
i
-l
t
IMeridian City Council Meeting Agenda July 10, 2018 – Page 445 of 522
16
9igs
o
e.
E3
B>
I
$!I t
I
'sf
i
i!
(..
{s
w-1r
\I
/I
I
o
I
Meridian City Council Meeting Agenda July 10, 2018 – Page 446 of 522