HomeMy WebLinkAboutQuality Electric, Inc - West Chateau Street LightingCONTRACT FOR PUBLIC WORKS CONSTRUCTION
W CHATEAU STREET LIGHTING
PROJECT # 6003.82
THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this Aday
of April , 2018, and entered into by and between the City of Meridian, a municipal
corporation organized under the laws of the State of Idaho, hereinafter referred to as
"CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and QUALITY ELECTRIC,
INC. , hereinafter referred to as "CONTRACTOR", whose business address is 5272 Irving
St. Boise, ID 83706 and whose Public Works Contractor License # is C-10145
Whereas, the City has a need for services involving W CHATEAU STREET
LIGHTING; and
WHEREAS, the Contractor is specially trained, experienced and competent
to perform and has agreed to provide such services;
NOW, THEREFORE, in consideration of the mutual promises, covenants,
terms and conditions hereinafter contained, the parties agree as follows:
TERMS AND CONDITIONS
1. Scope of Work:
1.1 CONTRACTOR shall perform and furnish to the City upon execution of this
Contract and receipt of the City's written notice to proceed, all services and work,
and comply in all respects, as specified in the document titled "Scope of Work" a
copy of which is attached hereto as Exhibit "A" and incorporated herein by this
reference, together with any amendments that may be agreed to in writing by the
parties.
1.2 All documents, drawings and written work product prepared or produced by
the Contractor under this Agreement, including without limitation electronic data
files, are the property of the Contractor; provided, however, the City shall have the
right to reproduce, publish and use all such work, or any part thereof, in any
manner and for any purposes whatsoever and to authorize others to do so. If any
such work is copyrightable, the Contractor may copyright the same, except that, as
to any work which is copyrighted by the Contractor, the City reserves a royalty -free,
non-exclusive, and irrevocable license to reproduce, publish and use such work, or
any part thereof, and to authorize others to do so.
1,3 The Contractor shall provide services and work under this Agreement
consistent with the requirements and standards established by applicable federal,
W CHATEAU STREET LIGHTING
page 1 of 13
Project 6003.82
state and city laws, ordinances, regulations and resolutions. The Contractor
represents and warrants that it will perform its work in accordance with generally
accepted industry standards and practices for the profession or professions that
are used in performance of this Agreement and that are in effect at the time of
performance of this Agreement. Except for that representation and any
representations made or contained in any proposal submitted by the Contractor
and any reports or opinions prepared or issued as part of the work performed by
the Contractor under this Agreement, Contractor makes no other warranties, either
express or implied, as part of this Agreement.
1.4 Services and work provided bythe Contractor at the City's request underthis
Agreement will be performed in a timely manner in accordance with a Schedule of
Work, which the parties hereto shall agree to. The Schedule of Work may be
revised from time to time upon mutual written consent of the parties.
2.1 The Contractor shall be compensated on a Not-To-Exceed basis as provided
in Exhibit B "Payment Schedule" attached hereto and by reference made a paft
hereof for the Not-To-Exceed amount of $ 66.667.58 .
2.2 The Contractor shall provide the City with a monthly statement and
supporting invoices, as the work warrants, of fees earned and costs incurred for
services provided during the billing period, which the City will pay within 30 days of
receipt of a correct invoice and approval by the City. The City will not withhold any
Federal or State income taxes or Social Security Tax from any payment made by
City to Contractor under the terms and conditions of this Agreement. Payment of
all taxes and other assessments on such sums is the sole responsibility of
Contractor.
2.3 Per the requirements of the CDBG Grant, weekly certified payroll reports
shall be submitted to the City of Meridian.
2.4 Except as expressly provided in this Agreement, Contractor shall not be
entitled to receive from the City any additional consideration, compensation, salary,
wages, or other type of remuneration for services rendered under this Agreement
including, but not limited to, meals, lodging, transportation, drawings, renderings or
mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement
to consideration in the form of overtime, health insurance benefits, retirement
benefits, paid holidays or other paid leaves of absence of any type or kind
whatsoever-
3. Term:
3.1 This agreement shall become effective upon execution by both parties, and
shall expire upon (a) completion of the agreed upon work, (b) or unless sooner
terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some
other method or time of termination is listed in Exhibit A.
W CHATEAU STREET LIGHTING
Project 6003.82 Page 2 of 13
2. Consideration
Meridian City Council Meeting Agenda April 24, 2018 – Page 549 of 717
3.2 Should Contractor default in the performance of this Agreement or materially
breach any of its provisions, City, at Clty's option, may terminate this Agreement by
giving written notification to Contractor.
3.3 Should City failto pay Contractor all or any part ofthe compensation set forth
in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's
option, may terminate this Agreement if the failure is not remedied by the City
within thirty (30) days from the date payment is due.
4. Liquidated Damages:
Substantial Completion shall be accomplished within 60 (sixty) calendar days from
Notice to Proceed. This project shall be considered Substantially Complete when
the Owner has full and unrestricted use and benefit of the facilities. both from an
operational and safety standpoint, and only minor incidental work, corrections or
repairs remainforthe physicalcompletion of the total contract. Contractor shall be
liable to the City for any delay beyond this time period in the amount of $500.00
(five hundred dollars) per calendar day. Such payment shall be construed to be
liquidated damages by the Contractor in lieu of any claim or damage because of
such delay and not be construed as a penalty.
Upon receipt of a Notice to Proceed, the Contractor shall have g0 (ninety) calendar
days to complete the work as described herein. Contractor shall be liable to the
City for any delay beyond this time period in the amount of 9500.00 (five hundred
dollars) per calendar day. Such payment shall be construed to be liquidated
damages by the Contractor in lieu of any claim or damage because of such delay
and not be construed as a penalty. See l\y'ilestones listed in the Payment Schedule
for Substantial Completion.
5. Termination
5.1 lf, through any cause, CONTRACTOR, its officers, employees, or agents fails
to fulfill in a timely and proper manner its obligations underthis Agreement, violates
any of the covenants, agreements, or stipulatjons of this Agreement, falsifies any
record or document required to be prepared under this agreement, engages in
fraud, dishonesty, or any other act of misconduct in the performance of this
contract, or if the City Council determines that termination of this Agreement is in
the best interest of CITY, the CITY shall thereupon have the right to terminate this
Agreement by giving written notice to CONTRACTOR of such termination and
specifying the effective date thereof at least fifteen (15) days before the effective
date of such termination. CONTRACTOR may terminate this agreement at any
time by giving at least sixty (60) days notice to CITY.
ln the event of any termination of this Agreement, all finished or unfinished
documents, data, and reports prepared by CONTRACTOR under this Agreement
shall, at the option ofthe CITY, become its property, and CONTRACTOR shall be
W CHATEAU STREET LIGHT]NG
Project 6003.82
paqe 3 of 13
Meridian City Council Meeting Agenda April 24, 2018 – Page 550 of 717
entitled to receive just and equitable compensation for any work satisfactorily
complete hereunder.
5.2 Notwithstanding the above, CONTRACTOR shall notbe relieved ofliabilityto
the CITY for damages sustained by the CITY by virtue of any breach of this
Agreement by CONTRACTOR, and the CITY may withhold any payments to
CONTRACTOR for the purposes of set-off until such time as the exact amount of
damages due the CITY from CONTRACTOR is determined. This provision shall
survive the termination of this agreement and shall not relieve CONTRACTOR of
its liability to the CITY for damages.
This project is being funded by a Community Development Block Grant. The Davis-
Bacon Act applies to this project and it is the responsibility of the Contractor to
comply in allaspects ofthe law. This contract, will be subject to H UD-4010 Federal
Labor Standards Provisions attached hereto as "Attachment C" and made a pari
hereof. Paragraph 2 on page 2 of 5 of HUD-4010 states that the City may withhold
payment to Contractor for failure to pay wages when due. Davis-Bacon requires
wages to be paid not less often than once a week. All subcontractors and any lower
tier subcontractors are subject to the same Davis-Bacon Wage requirements as the
general contractor.
7. lndependentContractor:
7.1 ln all matters pertaining to this agreement, CONTRACTOR shall be acting as
an independent contractor, and neither CONTRACTOR norany officer, employee
or agent of CONTRACTOR will be deemed an employee of ClTy. Except as
expressly provided in Exhibit A, Contractor has no authority or responsibility to
exercise any rights or power vested in the City and therefore has no authority to
bind orincur anyobligation on behalfofthe City. The selection and designation of
the personnel of the CITY in the performance of this agreement shall be made by
the CITY.
7.2 Contractor, its agents, officers, and employees are and at alltimes during the
term of this Agreement shall represent and conduct themselves as independent
contractors and not as employees of the City.
7.3 Contractor shall determine the method, details and means of performing the
work and services to be provided by Contractor under this Agreement. Contractor
shall be responsible to City only for the requirements and results specified in this
Agreement and, except as expressly provided in this Agreement, shall not be
subjected to City's control with respect to the physical action or activities of
Contractor in fulflllment of this Agreement. lfin the performance ofthisAgreement
any third persons are employed by Contractor, such persons shall be entirely and
exclusively under the direction and supervision and control of the Contractor.
W CHATEAU STREET LIGHTING
Projecl6003.82
page 4 of 13
6. CDBG Grant Requirements:
Meridian City Council Meeting Agenda April 24, 2018 – Page 551 of 717
8. Sub-Contractors:
Contractor shall require that all of its sub-contractors be licensed per State of ldaho
Statute # 54-1901
9. Removal of Unsatisfactory Employees:
The Contractor shall only furnish employees who are competent and skilled forwork
under this contract. lf, in the opinion of the City, an employee of the Contractor is
incompetent or disorderly, refuses to perform in accordance with the terms and
conditions of the contract, threatens or uses abusive language while on City
property, or is otherurrise unsatisfactory, that employee shall be removed from all
work under this contract.
10. lndemnification and lnsurance:
10.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's
elected officials, officers, employees, agents, and volunteers from and for any and
all losses, claims, actions, judgments for damages, or injury to persons or property
and losses and expenses and other costs including litigation costs and attorney's
fees, arising out of, resulting from, or in connection with the performance of this
Agreement by the CONTRACTOR, its servants, agents, officers, employees,
guests, and business invitees, and not caused by or arising out of the tortious
conduct of CITY or its employee s. CONTRACTOR shall maintain. and s pecifically
aqrees that it will maintain, throuq hout the term of this Aq reement, liability
insurance. in whi ch the CITY shall be named an add itional insured in the minimum
amounts as follow: General Liability One Million Dollars (91 ,000,000) per incident
oroccurrence, Automobile Liability lnsurance One Million Dollars (91,000,000) per
incident or occurrence and Workers' Compensation lnsurance, in the statutory
Iimits as required by law.. The limits of insurance shall not be deemed a limitation
of the covenants to indemnify and save and hold harmless CITY; and if ClTy
becomes liable for an amount in excess of the insurance limits, herein provided,
CONTRACTOR covenants and agrees to indemnify and save and hold harmless
CITY from and for all such losses, claims, actions, or judgments for damages or
injury to persons or property and other costs, including litigation costs and
attorneys' fees, arising out of, resulting from , or in connection with the
performance of this Agreement by the Contractor or Contractols officers, employs,
agents, representatives or subcontractors and resulting in or attributable to
personal injury, death, or damage or destruction to tangible or intangible property,
including use of. CONTRACTOR shall provide CITY with a Certificate of
lnsurance, or other proof of insurance evidencing CONTRACTOR'S compliance
with the requirements of this paragraph and file such proof of insurance with the
CITY at least ten (10) days prior to the date Contractor begins performance of it,s
obligations under this Agreement. ln the event the insurance minimums are
changed, CONTRACTOR shall immediately submit proof of compliance with the
changed limits. Evidence of all insurance shall be submitted to the City purchasing
W CHATEAU STREET LIGHTING
Project 6003.82
page 5 of 13
Meridian City Council Meeting Agenda April 24, 2018 – Page 552 of 717
Agent with a copy to lvleridian City Accounting, 33 East Broadway Avenue,
I\.4eridian. ldaho 83642.
10.2 lnsurance is to be placed with an ldaho admitted insurerwith a Best's rating
of no less than A-.
10.3 Any deductibles, self-insured retention, or named insureds must be declared
in writing and approved bythe City. Atthe option ofthe City, either: the insurer
shall reduce or eliminate such deductibles, self-insured retentions or named
insureds; or the Contractor shall provide a bond, cash or letter of credit
guaranteeing payment of losses and related investigations, claim administration
and defense expenses.
10.4 To the extent of the indemnity in thts contract, Contractor's lnsurance
coverage shall be primary insurance regarding the City's elected officers, officials,
employees and volunteers. Any insurance or self-insurance maintained bythe City
or the City's elected officers, offlcials, employees and volunteers shall be excess of
the Contractor's insurance and shall not contribute with Contractor's insurance
except as to the ertent of Crty s negl,gence.
'10.5 The Contractor's jnsurance shall apply separately to each insured against
whom claim is made or suit is brought, except with respect to the limits of the
insurer's liability.
10.6 All insurance coverages for subcontractors shall be subject to all of the
insurance and indemnity requirements stated herein.
10.7 The limits of insurance described herein shall not limit the liability of the
Contractor and Contractor's agents, representatives, employees or subcontractors.
11. Time is of the Essence;
The parties hereto acknowledge and agree that time is strictly of the essence wjth
respect to each and every term, condation and provision hereof, and that the failure
to timely perform any of the obligations hereunder shall constitute a breach of, and
a default under, this Agreement by the party so failing to perform.
12. Bonds:
Payment and Performance Bonds are required on all Public Works lmprovement
Projects per the ISPWC and the City of Meridian Supplemental Specifications &
Drawings to the ISPWC, which by this reference are made a part hereof.
Contractor is required to furnish faithful performance and payment bonds in the
amount of 100% of the contract price issued by surety licensed to do business in
the State of ldaho with a Best's rating of no less than A-. ln the event that the
contract is subsequently terminated for failure to perform, the contractor and/or
surety will be liable and assessed for any and all costs for the re-procurement ofthe
contract services.
W CHATEAU STREET LIGHTING
Prorect 6003 Ez Pase 6 of 13
Meridian City Council Meeting Agenda April 24, 2018 – Page 553 of 717
13. Warranty:
All construction and equipment provided under this agreement shall be warranted
for 2 years from the date of the City of Meridian acceptance per the ISPWC and the
Meridian Supplemental Specifications & Drawings to the ISPWC and any
modifications, which by this reference are made a part hereof.
All items found to be defective during a warranty inspection and subsequently
corrected will require an additional two (2) year warranty from the date of City's
acceptance of the corrected work.
14. Changes:
The CITY may, from time to time, request changes in the Scope of Work to be
performed hereunder. Such changes, including any increase or decrease in the
amount of CONTRACTOR'S compensation, which are mutually agreed upon by and
between the CITY and CONTRACTOR, shall be incorporated in written
amendments which shall be executed with the same formalities as this Agreement.
15. Taxes:
The City of Meridian is exempt from Federal and State taxes and will execute the
required exemption certificates for items purchased and used by the City. ltems
purchased by the City and used by a contractor are subject to Use Tax. All other
taxes are the responsibility of the Contractor and are to be included in the
Contractor's Bid pricing
All construction projects require either a Storm Water Pollution Prevention Plan
(SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of
Meridian Construction Stormwater Management Program (CSWMP) manual. The
CSWMP manual containing the procedures and guidelines can be found at this
address: htto:/iwvw.meri diancitv.oro/environmental.aspx?id=1 361 8
Contractor shall retain all stormwater and erosion control documentation generated
on site during construction including the SWPPP manual, field inspections and
amendments. Prior to final acceptance of the job by the City the contractor shall
return the field SWPPP manual and field inspection documents to the City for
review. A completed Contractor Request to File Project N.O.T. with the EPA form
shall be provided to the City with the documents. These documents shall be
retained, reviewed and approved bythe City priorto final acceptance of the project.
17, ACHD:
Contractor shall be responsible for coordinating with the City to obtain appropriate
W CHATEAU STREET LIGHTING
Project 6003.82
page 7 of 13
16. MeridianStormwaterSpecifications:
Meridian City Council Meeting Agenda April 24, 2018 – Page 554 of 717
18. Reports and lnformation:
18.1 At such times and in such forms as the CITY may require, there shall be
furnished to the CITY such statements, records, reports, data and information as
the CITY may request pertaining to matters covered by this Agreement.
18.2 Contractor shall maintain all writings, documents and records prepared or
compiled in connection with the performance of this Agreement for a minimum of
four (4) years from the termination or completion of this or Agreement. This
includes any handwriting, typewriting, printing, photo static, photographic and every
other means of recording upon any tangible thing, any form of communication or
representation including letters, words, pictures, sounds or symbols or any
combination thereof.
19. Audits and lnspections:
At any time during normal business hours and as often as the CITY may deem
necessary, there shall be made available to the CITY for examination all of
CONTRACTOR'S records with respect to all matters covered by this Agreement.
CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or
transcripts from such records, and to make audits of all contracts, invoices,
materials, payrolls, records of personnel, conditions of employment and other data
relating to all matters covered by this Agreement.
20. Publication, Reproduction and Use of Material:
No material produced in whole or in part under this Agreement shall be subject to
copyright in the United States or in any other country. The CITY shall have
unrestricted authority to publish, disclose and otherwise use, in whole or in part, any
repods, data or other materials prepared under this Agreement.
21. Equal Employment Opportunity:
ln performing the work herein, Contractor agrees to comply with the provisions of
Title Vl and VII of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code
Section 2176. Specifically, the Contractor agrees not to discriminate against any
employee or applicant for employment because of race, color, religion, sex, national
origin, age, political affiliation, marital status, or handicap. Contractor will take
affirmative action during employment or training to insure that employees are
treated without regard to race, color, religion, sex, national origin, age, political
affiliation, marital status, or handicap. ln performing the Work required herein,
W CHATEAU STREET LIGHTING
Project 6003.82 Paqe 8 of 13
ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs
due to Contractor's violation of any ACHD policy. City shall certify to ACHD that
Contractor is authorized to obtain a Temporary Highway and Right-of-Way Use
Permit from ACHD on City's behalf The parties acknowledge and agree that the
scope of the agency granted by such certification is limited to, and conterminous
with, the term and scope of this Agreement.
Meridian City Council Meeting Agenda April 24, 2018 – Page 555 of 717
CONTRACTOR shall not unlaMully discriminate in violation of any federal, state or
local law, rule or regulation against any person on the basis of race, color, religion,
sex, national origin or ancestry, age or disability.
Contractor must comply with ldaho State Statute 44-1002 which states that the
Contractor employ ninety-five percent (95%) bona fide ldaho residents.
23. Advice of Attorney:
Each party warrants and represents that in executing this Agreement. It has
received independent legal advice from its attorney's or the opportunity to seek such
advice.
24. Aftorney Fees:
25. ConstructionandSeverability:
lf any part of this Agreement is held to be invalid or unenforceable, such holding will
not affect the validity or enforceability of any other part of this Agreement so long as
the remainder of the Agreement is reasonably capable of completion.
26. Waiver of Default:
Waiver of default by either party to this Agreement shall not be deemed to be waiver
of any subsequent default. Waiver or breach of any provision of this Agreement
shall not be deemed to be a waiver of any other or subsequent breach, and shall
not be construed to be a modification of the terms of this Agreement unless this
Agreement is modified as provided above.
27. Entire Agreement:
This Agreement contains the entire agreement of the parties and supersedes any
and all other agreements or understandings, oral of written, whether previous to the
execution hereof or contemporaneous herewith.
28, Assignment:
It is expressly agreed and understood by the parties hereto, that CONTRACTOR
W CHATEAU STREET LIGHTING
Project 6003.82
page I of 13
22. Employment of Bona Fide ldaho Residents:
Should any litigation be commenced between the parlies hereto concerning this
Agreement, the prevailing party shall be entitled, in addition to any other relief as
may be granted, to court costs and reasonable attorneys'fees as determined by a
Court of competent jurisdiction. This provision shall be deemed to be a separate
contract between the parties and shall survive any default, termination or forfeiture
of this Agreement.
Meridian City Council Meeting Agenda April 24, 2018 – Page 556 of 717
shall not have the right to assign, transfer, hypothecate or sell any of its rights under
this Agreement except upon the prior express written consent of CITY.
29. Payment Request:
Payment requests shall be submitted to City of Meridian through the City's project
management software. The Project Manager will compare the invoice against the
Payment Schedule in the Agreement for compliance. Upon approval that the work
has been done and is in compliance with the Agreement, the Project Managerwill
approve the pay request for processing. City of Meridian payment terms are Net 30
from the date City receives a correct invoice. Final payment will not be released
until the City has received a tax release from the Tax Commission.
30. Cleanup:
Contractor shall keep the worksite clean and free from debris. At completion of
work and prior to requesting final inspection, the Contractor shall remove alltraces
of waste materials and debris resulting from the work. Final payment will not be
made if cleanup has not been performed.
31. Order of Precedence:
The order or precedence shall be the contract agreement, the lnvitation for Bid
document, then the winning bidders submitted bid document.
32. Compliance with Laws:
ln performing the scope of work required hereunder, CONTRACTOR shall comply
with all applicable laws, ordinances, and codes of Federal, State, and local
governments.
33. Applicable Law:
This Agreement shall be governed by and construed and enforced in accordance
with the laws of the State of ldaho, and the ordinances of the City of Meridian.
34. Notices:
Any and all notices required to be given by either of the parties hereto, unless
othenarise stated in this agreement, shall be in writing and be deemed
communicated when mailed in the United States mail, certified, return receipt
requested, addressed as follows:
W CHATEAU STREET LIGHTING
Project 6003.82
page 10 of 13
Meridian City Council Meeting Agenda April 24, 2018 – Page 557 of 717
CITY CONTRACTOR
City of Meridian Quality Electric, Inc.
Purchasing Specialist Attn: Don Rye
33 E Broadway Ave 5272 Irving St.
Meridian, ID 83642 Boise, ID 83706
208-489-0416 Phone: 208-375-1300 Ext 1123
Email: don@geidaho.com
Idaho Public Works License # C -10145-U-4-
(16000)
Either party may change their address for the purpose of this paragraph by giving
written notice of such change to the other in the manner herein provided.
35. Approval Required:
This Agreement shall not become effective or binding until approved by the City of
Meridian.
CITY OF MERIDIAN QUALITY ELECTRIC, INC.
BY: BY: ) pn -\
TA i�l MY
72z-,l
��o,
Dated: Ll z Dated: t�
Approved by Council: L/ / "� l / ')0CV
Attest:
C.JAY LES,I Y CLERK
Purchasing Approval
BY:
KEITH W ; S, Purchasing Manager
Dated:: L� / O z l g
Project Manager
Al Christy
W CHATEAU STREET LIGHTING
Project 6003.82
WARI
Dated
QOr;jE� AUGvsT'
lw
= cily of
)IAN' ---
SEAL P/
the
7
N STEWART, City Engineer
q111 1(19
page 11 of 13
EXHIBIT A
SCOPE OF WORK
REFER TO INVITATION TO BID PW.1831.6003.82
ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the
Invitation to Bid Package # PW-l831-6003.82, are by this reference
made a part hereof.
SPECIFICATIONS / SCOPE OF WORK
All construction work shall be done in accordance with the current version
of the ldaho Standards for Public Works Construction (SPWC), the 2013
City of Arleridian Supplemental Specifications to the ISPWC (and any
Addendums).
See separate attached documents:
Plans - W Chateau Street Lighting by tvlurraysmith, lnc.
dated lt/arch 2018 1ro pasesy
Special Provisions and/or Technical Specifications by
Murraysmith, lnc. dated 31112018 & Prevailing Wage
Determination dated 311212018 (4'l pases).
o Streetlight construction will be funded by CDBG Federal
Grant and requires Prevailing Wages be paid for
construction. Prevailing Wage Determination is included
to ensure accurate engineer cost estimate for the
construction phase of the project.
" CDBG Supplemental General Conditions (12 pases).
W CHATEAU STREET LIGHTING
Projecl6003.82
page 12 of 13
Meridian City Council Meeting Agenda April 24, 2018 – Page 559 of 717
Exhibit B
MILESTONE / PAYMENT SCHEDULE
A. Total and complete compensation for this Agreement shall not exceed$00 667.58
W CHATEAU STREET LIGHTING
Project 6003.82
Milestone 1 Substantial Com pletion 60 Days from Notice to Proceed
[Vlilestone 2 Final Completion 90 Days from Notice to Proceed
Contract includes furnishing all labor, materials, equipment, and incidentals as required for the
W CHATEAU STREET LIGHTING per IFB PW-1831-6003.82
NOT TO EXCEED CONTRACT TOTAL....$ 66.667.s8:
a not to exceed amount. Line item pricing below will be used for invoice verification and any
additional increases or decreases in work requested by city. The City will pay the contractor based on
actual quantities of each item of work in accordance with the contract documents.
Contract is
Item No Description Quantity Unit Unit Price
1 lnstall City provided 25'Pole & LED Fixture 14 EA $26,705.00
2 Conduit & Conductors 641 LF $29,520.00
J Junction Box '15 EA $9,750.00
4 Use Tax on City Provided Poles (0.06)14 EA $31.83
5 Use Tax on Oty Provided Fixtures (0.06)14 EA $17.64
page 13 of 13
MILESTONE
PRICING SCHEDULE
Contract Pricing.Schedule
Meridian City Council Meeting Agenda April 24, 2018 – Page 560 of 717
View Details - Entity Overview I System for Award Management
Username Password
Page i of 1
actrvated. R6d or FAoq to learn more about this plceas cha.ge,
Entity
Dashbes?d*
Quality Electric, Inc.
DUiS: O4369a1ta CAG: Co.le. OPVCS
€xrr.:ion Dat j 05/02/208
Plrpo.€ of t.cirlratio.: lll Awar&
Entity Overview
Ertty ReoisEauo. suBmarY
Entitv Reoistration
, Core Data
' Assertions
' Reos & Certs
' eoG
Exc us ons
, Aatrve Exclusions
' Inactive Exclusions
' Excluded Familv
lvlembers
rlrcrNmpruca
am: Quality Ehdric, Irc.
alEin€ss Typ€: 8lgn€ss o. OEanizatio.r
Las! Updated By: .lay BinEe
ReEist6tion stab.: Aclve
Activauo. Dater 06/022017
Erpirauon Dats 06/022018
D"*
6(
susF.o, n'i:
fuabo':'r'-ttt\ |
4rgli"Kp,t'
a
!3r"r v1 P.r2.20180106 1123
Search Reaords
Data Aaaess
Check Status
About
Help
DLsclainrers
Access biliV
FAPllS.gov
GSA.gov/lAE
GSA.9ov
USA.gov
p.no.+g u .ulrrized &tN(s 4," subi.cl t ds p s.B a.trfr '^atcn!g
('m*ar oll*utton
5225lruinq 5t
Bolsq :D, a37O5-12O9,
UNITEO STAIES
Active Erdusion R@rds? No
https://www.sam.gov/portal/sAMi?navigationalstate:JBPNS_rO0ABXdcACJqYXZheC5...4n8120t8Meridian City Council Meeting Agenda April 24, 2018 – Page 561 of 717
Meridian City Council Meeting Agenda April 24, 2018 – Page 562 of 717
Meridian City Council Meeting Agenda April 24, 2018 – Page 563 of 717
Meridian City Council Meeting Agenda April 24, 2018 – Page 564 of 717
Meridian City Council Meeting Agenda April 24, 2018 – Page 565 of 717