Loading...
HomeMy WebLinkAboutEwing Company - Well 32 Pumping Facity and ConstructionCONTRACT FOR PUBLIC WORKS CONSTRUCTION WELL 32 PUMPING FACILITY PROJECT # 1OO14.G THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this 17th day of April, 2018, and entered into by and between the City of Meridian, a municipal corporation organized under the laws of the State ol ldaho, hereinafter reterred to as "C|TY", 33 East Broadway Avenue, Meridian, ldaho 83642, and The Ewino Co.. lnc., hereinafter referred to as "CONTRACTOR", whose business address is and whose Public Works Contractor License # is PWC-C-12003. INTRODUCTION Whereas, the City has a need for services involving well pumpinq facilitv construction; and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration ol the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS 1. Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Contract and receipt of the City's written notice to proceed, all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Exhibit "A" and incorporated herein by this reference, together with any amendments that may be agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data liles, are the property ol the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. lf any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrighted by the Contractor, the City reserves a royalty{ree, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. The Contractor WELL 32 PUMPING FAclLlrY page 1 of l4 Proiect 10014.G Meridian City Council Meeting Agenda April 17, 2018 – Page 383 of 491 represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part ol the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1 .4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in a timely manner in accordance with a Schedule of Work, which the parties hereto shall agree to. The Schedule ol Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall be compensated on a Not-To-Exceed basis as provided in Exhibit B "Payment Schedule" attached hereto and by reference made a part hereol lor the Not-To-Exceed amount ol $805,823.00. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, ol fees earned and costs incurred lor services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportalion, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue ol this Agreement to consideration in the form ol overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves ol absence ol any type or kind whatsoever. 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a) completion of the agreed upon work, (b) or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time ol termination is listed in Exhibit A. 3.2 Should Contractor delault in the performance of this Agreement or materially breach any of its provisions, City, at City's option, may terminate this Agreement by giving written notification to Contractor. WELL 32 PUMPING FACILITY page 2 of 14 Project 100'14.G Meridian City Council Meeting Agenda April 17, 2018 – Page 384 of 491 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Exhibit B o{ this Agreement on the date due, Contractor, at the Contractor's option, may terminate this Agreement il the failure is not remedied by the City within thirty (30) days from the date payment is due. 4. Liquidated Damages: Substantial Completion shall be accomplished within 150 (one hundred fifty) calendar days lrom Notice to Proceed. This project shall be considered Substantially Complete when the Owner has full and unrestricted use and benefit of the facilities, both from an operational and safety standpoint, and only minor incidental work, corrections or repairs remain for the physical completion of the total contract. Contractor shall be liable to the City lor any delay beyond this time period in the amount o1 $300.00 (three hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. Upon receipt ot a Notice to Proceed, the Contractor shall have 180 (one hundred eighty) calendar days to complete the work as described herein. Contractor shall be liable to the City lor any delay beyond this time period in the amount of $300.00 (three hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. See Milestones listed in the Payment Schedule for Substantial Completion. 5. Termination: 5.1 lf , through any cause, CONTRACTOR, its off icers, employees, or agents fails to lulf ill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act ol misconduct in the performance o{ this contract, or il the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the elfective date thereol at least fifteen (15) days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty (60) days notice to CITY. ln the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation lor any work satisfactorily complete hereunder. 5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to the CITY {or damages sustained by the CITY by virtue of any breach of this WELL 32 PUMPING FACILITY page 3 of '14 Project 1 0014.G Meridian City Council Meeting Agenda April 17, 2018 – Page 385 of 491 Agreement by CONTRACTOR, and the CITY may withhold any payments to CONTRACTOR for the purposes ol set-ofl until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR oI its liability to the CITY for damages. 6. lndependentContractor: 6..1 ln all matters pertaining to this agreement, CONTRACTOR shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided in Exhibit A, Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel o{ the CITY in the performance of this agreemenl shall be made by the CITY. 6.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees ol the City. 6.3 Contractor shall determine the method, details and means ol perlorming the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only lor the requirements and results specilied in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities oJ Contractor in f ulf illment of this Agreement. lf in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. 7. Sub-Contractors: Contractor shall require that all ol its sub-contractors be licensed per State ol ldaho Statute # 54-1901 8. Removal of Unsatisfactory Employees: The Contractor shall only f urnish employees who are competent and skilled for work under this contract. lf, in the opinion of the City, an employee of the Contractor is incompetent or disorderly, refuses to perform in accordance with the terms and conditions of the contract, threatens or uses abusive language while on City property, or is otherwise unsatisfactory, that employee shall be removed from all work under this contract. WELL 32 PUMPING FACILIry Project 10014.G page 4 of '14 Meridian City Council Meeting Agenda April 17, 2018 – Page 386 of 491 9. lndemnification and lnsurance: 9.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's elected oflicials, officers, employees, agents, and volunteers from and lor any and all losses, claims, actions, judgments for damages, or injury to persons or property and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, o{ficers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct ol CITY or its employ ees. CONTRACTOR shall m aintain. and specilicallv aorees th at it will maintain. throuqhout the te rm of this Aqreement. liabilitv insurance. in which the CITY shall be n amed an additional insured in the minimum amounts as {ollow: General Liabil ity One lvlillion Dollars ($1,000,000) per incident or occurrence, Automobile Liability lnsurance One tvlillion Dollars (g.l ,000,000) per incident or occurrence and Workers' Compensation lnsurance, in the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or judgments lor damages or injury to persons or property and other costs, including litigation costs and attorneys' fees, arising out of, resulting from , or in connection with the performance of this Agreement by the Contractor or Contractor's officers, employs, agents, representatives or subcontractors and resulting in or attributable to personal injury, death, or damage or destruction to tangible or intangible property, including use ol. CONTRACTOR shall provide CITY with a Certificate of lnsurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (1 0) days prior to the date Contractor begins per{ormance of it's obligations under this Agreement. ln the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limrts. Evidence ol all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Ir/eridian, ldaho 83642. 9.2 lnsurance is to be placed with an ldaho admitted insurer with a Best's rating o1 no less than A-. 9.3 Any deductibles, self-insured retention, or named insureds must be declared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter ol credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 9.4 To the extent of the indemnity in this contract, Contractor's lnsurance coverage shall be primary insurance regarding the City's elected officers, olficials, employees and volunteers. Any insurance or self-insurance maintained by the City WELL 32 PUMPING FACILITY Project 10014.G page5ofl4 Meridian City Council Meeting Agenda April 17, 2018 – Page 387 of 491 or the City's elected officers, officials, employees and volunteers shall be excess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 9.5 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 9.6 All insurance coverages lor subcontractors shall be sublect to all ol the insurance and indemnity requirements stated herein. 9.7 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 10. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respecl to each and every term, condition and provision hereof , and that the fallure to timely perform any of the obligations hereunder shall constitute a breach of , and a delault under, this Agreement by the party so lailing to perform. 11. Bonds: Payment and Performance Bonds are required on all Public Works lmprovement Projects per the ISPWC and the City ol tr/eridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. Contractor is required to lurnish faithlul performance and payment bonds in the amount of 100% o{ the contract price issued by surety licensed to do business in the State of ldaho with a Best's rating of no less than A-. ln the event that the contract is subsequently terminated for failure to perform, the contractor and/or surety will be liable and assessed lor any and all costs for the re-procurement of the contract services. 12. Warranty: All construction and equipment provided under this agreement shall be warranted for 2 years lrom the date ol the City of Meridian acceptance per the ISPWC and the IVleridian Supplemental Specilications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items lound to be defective during a warranty inspection and subsequently corrected will require an additional two (2) year warranty from the date o{ City's acceptance ol the corrected work. 13. Changes: The CITY may, lrom time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the WELL 32 PUMPING FAClLlry page 6 of 14 Project 10014.G Meridian City Council Meeting Agenda April 17, 2018 – Page 388 of 491 amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the same lormalities as this Agreement. 14- Taxes: The City of ltleridian is exempt lrom Federal and State taxes and will execute the required exemption certificates for items purchased and used by the City. ltems purchased by the City and used by a contractor are subject to Use Tax. All other taxes are the responsibility of the Contractor and are to be included in the Contractor's Bid pricing. 15. Meridian StormwaterSpecifications: All construction projects require either a Storm Water Pollution Prevention Plan (SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of It/eridian Construction Stormwater Management Program (CSWIUP) manual. The CSW[/P manual containing the procedures and guidelines can be found at this address htto://www. meridiancitv.oro envr ronmental.aspx?id=1 361 B. Contractor shall retain all stormwater and erosion control documentation generated on site during construction including the SWPPP manual, field inspections and amendments. Prior to linal acceptance of the job by the City the contractor shall return the field SWPPP manual and field inspection documents to the City for review. A completed Contractor Request to File Project N.O.T. with the EPA form shall be provided to the City with the documents. These documents shall be retained, reviewed and approved by the City prior to f inal acceptance of the project. 16. ACHD: Contractor shall be responsible for coordinating with the City to obtain appropriate ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs due to Contractor's violation of any ACHD policy. City shall certify to ACHD that Contractor is authorized to obtain a Temporary Highway and Right-ol-Way Use Permit from ACHD on City's behalf. The parties acknowledge and agree that the scope of the agency granted by such certification is limited to, and conterminous with, the term and scope of this Agreement. 17. Reports and lnformation: 17.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 17.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement lor a minimum of lour (4) years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographic and every WELL 32 PUI\ilPING FACILITY Project 10014.G page 7 of 14 Meridian City Council Meeting Agenda April 17, 2018 – Page 389 of 491 other means o, recording upon any tangible thing, any form oJ communication or representation including letters, words, pictures, sounds or symbols or any combination thereof . 18. Audits and lnspections: At any time during normal business hours and as olten as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. 19. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 20. Equal Employment Opportunity: ln perlorming the work herein, Contractor agrees to comply with the provisions of Title Vl and Vll of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code Section 2176. Specifically, the Contractor agrees not to discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. Contractor will take aflirmative action during employment or training to insure that employees are treated without regard to race, color, religion, sex, nalional origin, age, political alfiliation, marital status, or handicap. ln performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of any 1ederal, state or local law, rule or regulation against any person on the basis ol race, color, religion, sex, national origin or ancestry, age or disability. 21. Employment of Bona Fide ldaho Residents: Contractor must comply with ldaho State Statute 44-1002 which states that the Contractor employ ninety{ive percent (95%) bona fide ldaho residents. 22. Advice of Attorney: Each party warrants and represents that in executing this Agreement. lt has received independent legal advice from its attorney's or the opportunity to seek such advice. WELL 32 PUN,4PING FACILITY Project 10014.c pageBofl4 Meridian City Council Meeting Agenda April 17, 2018 – Page 390 of 491 23. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other reliel as may be granted, to court costs and reasonable attorneys'fees as determined by a Court o{ competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture oJ this Agreement. ll any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder ol the Agreement is reasonably capable of completion. 25. Waiver of Default: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver ol any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent ol CITY. 28. Payment Request: Payment requests shall be submitted to City of Meridian through the City's project management soJtware. The Project Manager will compare the invoice against the Payment Schedule in the Agreement lor compliance. Upon approval that the work has been done and is in compliance with the Agreement, the Prolect Manager will approve the pay request for processing. City of lvleridian payment terms are Net 30 from the date City receives a correct invoice. Final payment will not be released until the City has received a tax release lrom the Tax Commission. 29. Cleanup: Contractor shall keep the worksite clean and free lrom debris WELL 32 PUMPING FACILIry Project 10014.G At completion ol page 9 of 14 24. ConstructionandSeverability: 26. Entire Agreement: 27. Assignment: Meridian City Council Meeting Agenda April 17, 2018 – Page 391 of 491 work and prior to requesting final inspection, the Contractor shall remove all traces ol waste materials and debris resulting f rom the work. Final payment will not be made il cleanup has not been performed. 30. Order of Precedence: The order or precedence shall be the contract agreement, the lnvitation for Bid document, then the winning bidders submitted bid document. 31. Compliance with Laws: ln perlorming the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 32.Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of ldaho, and the ordinances o{ the City of ltrleridian. Notices: Any and all notices required to be given by either ol the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: 33. CITY City of lvleridian Purchasing lvlanager 33 E Broadway Ave l\4eridian, lD 83642 208-489-0417 CONTRACTOR NATUE OF CONTRACTOR Attn: John R. Ewing 1500 Eldorado, Ste. 4 Boise, lD 83704 Phone: 208-377-1500 Email: bids@ewingcompany.com ldaho Public Works License #PWC-C-12003 Either party may change their address lor the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 34. Approval Required: This Agreement shall not become eflective or binding until approved by the City of lt/eridian. WELL 32 PUMPING FACILITY Prolecl 1 0014.G page 10 of 14 Meridian City Council Meeting Agenda April 17, 2018 – Page 392 of 491 CITY OF MERIDIAN THE EWING ,COMPANY, INC. BY: BY: i v ' TAMMY deWE YOR JOHN R. EWING, PRESIDENT l(� !f y Dated:____ ! lj Dated: V 0 Approved by Council: Ll �( r Attest: C.JAY OLES a Y CLERK Purchasing Approval BY: KEITH ATTS, Purc acing Manager Dated:: y11 Project Manager Dean Stacey WELL 32 PUMPING FACILITY Project 10014.G Depa e4Apr BY: W REN STE RT, City Engineer Dated:: L / page 11 of 14 EXH!BIT A SCOPE OF WORK REFER TO INVITATION TO BID PW-l827-10014.G ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the lnvitation to Bid Package # PW-1827-10014.G, are by this reference made a part hereof. SPECIFICATIONS i SCOPE OF WORK All construction work shall be done in accordance with the current version of the ldaho Standards for Public Works Construction (ISPWC), the 2013 City of Atleridian Supplemental Specifications to the ISPWC (and any Addendums). See separate attached documents: Plans - WELL NO. 32 PUIVPING FACILITY by Keller Associates daled 12-5-2017 1oz pasesl Technical Specifications by Keller Associates dated December 2017 (406 pages) WELL 32 PUMPING FACILITY Projecl '10014.G a a page 12 of 14 Meridian City Council Meeting Agenda April 17, 2018 – Page 394 of 491 A Exhibit B MILESTONE / PAYMENT SCHEDULE Total and complete compensation for this Agreement shall not exceed $805,823.00. Milestone 1 Substantial Completion 150 Days f rom Notice to Proceed [/ilestone 2 Final Completion 180 Days from Notice to Proceed Contract includes lurnishing all labor, materials, equipment, and incidentals as required for the WELL 32 PUMPING FACILITY - Construction per IFB PW-1827-10014.G NOT TO EXCEED CONTRACT TOTAL $805-823J0 Contracl is a not to exceed amounl. Line ilem pricing below will be used lor invoice verilicalion and any additional increases or decreases in work requested by cily. The Cily will pay the contractor based on actual quantities ol each ilem ol work in accordance with the contract documents. Item No.Description Quantity Unil Unit Price Mobiliation/General Requirements 1 LS $64,350 C1 Detention Pond 1 LS $19,800 c2 Valve Vault - Structure 1 LS $7,449 Manholes 1 LS $8,928 C4 Site Concrete and Pavino 1 LS $32,767 C5 lvliscellaneous Site Work 1 LS $o tro Yard Pipinq and Valves 1 LS $69,981 bl Foundation 1 LS $23,962 QC CIVIU 1 LS $28,599 QA 1 LS $4,727 S4 Doors 1 LS $13,761 S5 Skylights 1 LS $1 1,978 S6 lvliscellaneous Structural/Architectural 1 LS $56,1 99 l\,4'1 lnterior Mechanical Piping/Valves 1 LS $33,098 M2 Well Pump 1 LS $57,459 M3 Well Pum p Motor 1 LS $19,894 [,44 Well Pump Column 1 LS $19,591 NT5 C h lorin e Tank 1 LS $2,530 tvt6 Chlorine Pum 1 LS $5,720 WELL 32 PUMPING FACILIry Projecl 1 0014.G page13of14 MILESTONE DATES/SCHEDULE PRICING SCHEDULE Contract Pricing Schedule Roof Meridian City Council Meeting Agenda April 17, 2018 – Page 395 of 491 IVIPl Trench Drains, Sinks, Shower, Etc .l LS $27,260 [,4H1 HVAC .l LS $,6+5sO E1 Site Electrical 1 LS $6,600 E2 Generator 1 LS $76,534 E3 Transfer Switch 1 LS $8,666 E4 Main Switch Board 1 LS $32,450 E5 Miscellaneous Electrical 1 LS $48,950 I lnstrumentation and Controls 1 LS $61,050 d3,fza e WELL 32 PUMPING FACILITY Project 10014.G page 14 ot 14 Meridian City Council Meeting Agenda April 17, 2018 – Page 396 of 491