Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Public Works Construction Agreement with Alta Construction for NW 2nd Water and Sewer Replacements
CONTRACT FOR PUBLIC WORKS CONSTRUCTION NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION PROJECT # 10515.d THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made this day of May, 2016, and entered into by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho, hereinafter referred to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and Alta Construction, Inc, hereinafter referred to as "CONTRACTOR", whose business address is 619 N. Cloverdale, Rd, Boise, ID 83713 and whose Public Works Contractor License # is C-003938. INTRODUCTION Whereas, the City has a need for services involving NW 2ND STREET WATER AND SEWER REPLACEMENT CONSTRUCTION: and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS 1. Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Contract and receipt of the City's written notice to proceed, all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Exhibit "A" and incorporated herein by this reference, together with any amendments that may be agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. If any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrighted by the Contractor, the City reserves a royalty -free, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. The Contractor NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 1 of 13 Project 10515A represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part of the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in a timely manner in accordance with a Schedule of Work, which the parties hereto shall agree to. The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall be compensated on a Not -To -Exceed basis as provided in Exhibit B "Payment Schedule" attached hereto and by reference made a part hereof for the Not -To -Exceed amount of $448,492.67. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, of fees earned and costs incurred for services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a) completion of the agreed upon work, (b) or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time of termination is listed in Exhibit A. 3.2 Should Contractor default in the performance of this Agreement or materially breach any of its provisions, City, at City's option, may terminate this Agreement by giving written notification to Contractor. NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 2 of 13 Project 10515A 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's option, may terminate this Agreement if the failure is not remedied by the City within thirty (30) days from the date payment is due. 4. Liquidated Damages: Substantial Completion shall be accomplished within 60 (sixty) calendar days from Notice to Proceed. This project shall be considered Substantially Complete when the Owner has full and unrestricted use and benefit of the facilities, both from an operational and safety standpoint, and only minor incidental work, corrections or repairs remain for the physical completion of the total contract. Contractor shall be liable to the City for any delay beyond this time period in the amount of $200.00 (two hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. Upon receipt of a Notice to Proceed, the Contractor shall have 75 (seventy five) calendar days to complete the work as described herein. Contractor shall be liable to the City for any delay beyond this time period in the amount of $200.00 (two hundred dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. See Milestones listed in the Payment Schedule for Substantial Completion. 5. Termination: 5.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails to fulfill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen (15) days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty (60) days notice to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation for any work satisfactorily complete hereunder. 5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to the CITY for damages sustained by the CITY by virtue of any breach of this NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 3 of 13 Project 10515.d Agreement by CONTRACTOR, and the CITY may withhold any payments to CONTRACTOR for the purposes of set-off until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR of its liability to the CITY for damages. 6. Independent Contractor: 6.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided in Exhibit A, Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 6.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 6.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of Contractor in fulfillment of this Agreement. If in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. 7. Sub -Contractors: Contractor shall require that all of its sub -contractors be licensed per State of Idaho Statute # 54-1901 8. Removal of Unsatisfactory Employees: The Contractor shall only furnish employees who are competent and skilled for work under this contract. If, in the opinion of the City, an employee of the Contractor is incompetent or disorderly, refuses to perform in accordance with the terms and conditions of the contract, threatens or uses abusive language while on City property, or is otherwise unsatisfactory, that employee shall be removed from all work under this contract. 9. Indemnification and Insurance: 9.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's elected officials, officers, employees, agents, and volunteers from and for any and all losses, claims, actions, judgments for damages, or injury to persons or property NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 4 of 13 Project 10515.d and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall maintain, and specifically agrees that it will maintain, throughout the term of this Agreement, liability insurance in which the CITY shall be named an additional insured in the minimum amounts as follow: General Liability One Million Dollars ($1,000,000) per incident or occurrence, Automobile Liability Insurance One Million Dollars ($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or judgments for damages or injury to persons or property and other costs, including litigation costs and attorneys' fees, arising out of, resulting from , or in connection with the performance of this Agreement by the Contractor or Contractor's officers, employs, agents, representatives or subcontractors and resulting in or attributable to personal injury, death, or damage or destruction to tangible or intangible property, including use of. CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (10) days prior to the date Contractor begins performance of it's obligations under this Agreement. In the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. 9.2 Insurance is to be placed with an Idaho admitted insurer with a Best's rating of no less than A-. 9.3 Any deductibles, self-insured retention, or named insureds must be declared in writing and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 9.4 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City or the City's elected officers, officials, employees and volunteers shall be excess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 5 of 13 Project 10515A 9.5 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 9.6 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 9.7 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 10. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. 11. Bonds: Payment and Performance Bonds are required on all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. Contractor is required to furnish faithful performance and payment bonds in the amount of 100% of the contract price issued by surety licensed to do business in the State of Idaho. In the event that the contract is subsequently terminated for failure to perform, the contractor and/or surety will be liable and assessed for any and all costs for the re -procurement of the contract services. 12. Warranty: All construction and equipment provided under this agreement shall be warranted for 2 years from the date of the City of Meridian acceptance per the ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items found to be defective during a warranty inspection and subsequently corrected will require an additional two (2) year warranty from the date of City's acceptance of the corrected work. 13. Changes: The CITY may, from time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the same formalities as this Agreement. 14. Taxes: The City of Meridian is exempt from Federal and State taxes and will execute the required exemption certificates for items purchased and used by the City. Items purchased by the City and used by a contractor are subject to Use Tax. All other NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 6 of 13 Project 10515A taxes are the responsibility of the Contractor and are to be included in the Contractor's Bid pricing. 15. Meridian Stormwater Specifications: All construction projects require either a Storm Water Pollution Prevention Plan (SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of Meridian Construction Stormwater Management Program (CSWMP) manual. The CSWMP manual containing the procedures and guidelines can be found at this address: htta://www.meridiancity.ora/environmental.asr)x?id=13618. Contractor shall retain all stormwater and erosion control documentation generated on site during construction including the SWPPP manual, field inspections and amendments. Prior to final acceptance of the job by the City the contractor shall return the field SWPPP manual and field inspection documents to the City for review. A completed Contractor Request to File Project N.O.T. with the EPA form shall be provided to the City with the documents. These documents shall be retained, reviewed and approved by the City prior to final acceptance of the project. 16. ACHD: Contractor shall be responsible for coordinating with the City to obtain appropriate ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs due to Contractor's violation of any ACHD policy. City shall certify to ACHD that Contractor is authorized to obtain a Temporary Highway and Right -of -Way Use Permit from ACHD on City's behalf. The parties acknowledge and agree that the scope of the agency granted by such certification is limited to, and conterminous with, the term and scope of this Agreement. 17. Reports and Information: 17.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 17.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement for a minimum of four (4) years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographic and every other means of recording upon any tangible thing, any form of communication or representation including letters, words, pictures, sounds or symbols or any combination thereof. 18. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 7 of 13 Project 10515A 19. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 20. Equal Employment Opportunity: In performing the work herein, Contractor agrees to comply with the provisions of Title VI and VII of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code Section 2176. Specifically, the Contractor agrees not to discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. Contractor will take affirmative action during employment or training to insure that employees are treated without regard to race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. In performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. 21. Employment of Bona Fide Idaho Residents: Contractor must comply with Idaho State Statute 44-1002 which states that the Contractor employ ninety-five percent (95%) bona fide Idaho residents. 22. Advice of Attorney: Each party warrants and represents that in executing this Agreement. It has received independent legal advice from its attorney's or the opportunity to seek such advice. 23. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. 24. Construction and Severability: If any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 25. Waiver of Default: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 8 of 13 Project 10515.d Agreement is modified as provided above. 26. Entire Agreement: This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. 27. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent of CITY. 28. Payment Request: Payment requests shall be submitted to City of Meridian through the City's project management software. The Project Manager will compare the invoice against the Payment Schedule in the Agreement for compliance. Upon approval that the work has been done and is in compliance with the Agreement, the Project Manager will approve the pay request for processing. City of Meridian payment terms are Net 30 from the date City receives a correct invoice. Final payment will not be released until the City has received a tax release from the Tax Commission. 29. Cleanup: Contractor shall keep the worksite clean and free from debris. At completion of work and prior to requesting final inspection, the Contractor shall remove all traces of waste materials and debris resulting from the work. Final payment will not be made if cleanup has not been performed. 30. Order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted bid document. 31. Compliance with Laws: In performing the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 32. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 33. Notices: Any and all notices required to be given by either of the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 9 of 13 Project 10515.d communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY City of Meridian Purchasing Manager 33 E Broadway Ave Meridian, ID 83642 208-489-0417 CONTRACTOR ALTA CONSTRUCTION, INC Attn: Justin King 619 N. Cloverdale Rd Boise, ID 83713 Phone: 208-853-1720 Email: jkingCa�altaedge.com Idaho Public Works License #C-003938 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. 34. Approval Required: This Agreement shall not become effective or binding until approved by the City of Meridian. CITY OF -DIA ally Dated: - Approved by Counci Attest: ALTA CONSTRUCTION, INC ' city 0 r � v FF J? 0 CFNTB, eSJQ Purchasing Approval R °1 BY: , , � ; yz� � KEITH TTS, urchasing Manager Dated::���/� Project Manager Austin Petersen nt BY: WA T, Engineering Dated:: NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 10 of 13 Project 10515A EXHIBIT A SCOPE OF WORK REFER TO INVITATION TO BID PW -1630-10515.d ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation to Bid Package # PW -1630-10515.d, are by this reference made a part hereof. All construction work shall be done in accordance with the 2012 version of the Idaho Standards for Public Works Construction (ISPWC), the 2013 City of Meridian Supplemental Specifications to the ISPWC (and any Addendums). Water and Sewer Main Replacement — NW 2nd Street Railroad St to 200' North of Pine Ave This project includes: the installation of approximately 1300' of new water main and 1400' of 8" sewer main, 14 water meters and water service lines, and 28 sewer service lines to connect existing properties to the new sewer line. See separate documents: • PLANS — NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION by Civil Survey Consultants, Inc signed and stamped March 14, 2016 (9 pages) • Special Provisions for NW 2nd Street Sewer and Water Line Replacement —Construction Project dated March 11, 2016 by Civil Survey Consultants, Inc. (87 pages) NW 2ND STREET WATER AND SEWER REPLACEMENT- CONSTRUCTION page 11 of 13 Project 10515A Exhibit B MILESTONE / PAYMENT SCHEDULE A. Total and complete compensation for this Agreement shall not exceed $448,492.67. NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 12 of 13 Project 10515A MILEST{flNlDTES/ACHE©ULE' Milestone 1 Substantial Completion 60 Days from Notice to Proceed Milestone 2 Final Completion 75 Days from Notice to Proceed .PRtGINO SCHEDULES°� Contract includes furnishing all labor, materials, equipment, and incidentals as required for the NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION per IFB PW - 1630 -10515A NOT TO EXCEED CONTRACT TOTAL ....................... $448.492.67 Contract is a not to exceed amount. Line item pricing below will be used for invoice verification and any additional increases or decreases in work requested by city. The City will pay the contractor based on actual quantities of each item of work in accordance with the contract documents. IC '91 'Schedule Item No. Description Quantity Unit Unit Price 205.4.1.8.1. Dewatering 1 LS $ 11,500.00 303.4.1.A.1. Exploratory Excavation 16 HR $ 258.75 (Pre -Approval Required) 306.4.1.D.1. Imported Trench Backfill, Type A 1,000 TON $ 9.89 (Pre -Approval Required) 307.4.1.E.1. Type C Surface Restoration 292 SY $ 13.66 307.4.1.G. i Type nP "Surface Restoration — 450 SY $ 37.28 .a. NW 2 Street Shoulders 307.4.1.G.1.b. Type "P" Surface Restoration — 180 SY $ 51.33 Idaho and Broadway Avenue 307.4.1.1-1.1. Full Width Surface Restoration 4,153 SY $ 20.44 401.4.1.A.1.a. 6" PVC, AWWA C900, DR 18 44 LF $ 30.31 Water Main 401.4.1.A.1.b. 8" PVC, AWWA C900, DR -I8 1,256 LF $ 27.19 Water Main 402.4.1.A.1.a. 6" Gate Valve 3 EA $ 797.33 402.4.1.A.1.b. 8" Gate Valve 8 EA $ 1,046.50 403.4.1.A.1. Fire Hydrant Assembly 3 EA $ 2,438.00 404.4.1.A.1.a. 3/4"0 Standard Water Service Connection 11 EA $ 1,181.36 404.4.1.A.i.b. 1"0 Standard Water Service Connection 2 EA $ 1,000.50 404.4.1.A.i.c. 1 2"0 Standard Water Service Connection 1 EA $ 3,266.00 NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 12 of 13 Project 10515A 501.4.1.B.1.a. 8" PVC, ASTM D3034, DR35, Sanitary Sewer Pipe 1,246 LF $ 38.25 501.4.1.B.1.b. Pi PVC, AWWA C900, Water Class Sanitary Sewer 125 LF $ 43.12 502.4.1.A.1. 48" Standard Sanitary Sewer Manhole, Type A 6 EA $ 3,308.16 503.4.1.A.3.a. 4" Sewer Service Cleanout 30 EA $ 115.00 503.4.1.A.3.b. 6" Sewer Service Cleanout 4 EA $ 140.87 504.4.1.A.1.a. 4" PVC, ASTM D3034, Sewer Service Pipe 2,826 LF $ 24.41 504.4.1.A.i.b. 6" PVC, ASTM D3034, Sewer Service Pipe 389 LF $ 13.71 504.4.1.D.i.a. 4" Sewer Service Connection to Main 26 EA $ 92.00 504.4.1.D.i.b. 6" Sewer Service Connection to Main 2 EA $ 224.25 706.4.1.G.1. Concrete Repair 75 SY $ 38.80 1001.4.2.A.1. Staging Area 1 EA $ 575.00 1003.4.1.G.1. Straw Wattle 65 LF $ 5.30 1006.4.1.C.1. Inlet Protection 16 EA $ 57.50 1103.4.1.A.1. Traffic Control 1 LS $ 10,700.00 2010.4.1.A.1. Mobilization 1 LS $ 42,150.00 SP-1 Lawn Sod Restoration 645 SF $ 2.85 SP-2 Abandon Existing Water Main 9 EA $ 370.55 SP-3 Abandon Existing Water Service 14 EA $ 98.57 SP-4 Connect Existing Water Lines to New Water Service 12 EA $ 210.83 SP-5 Install New Main in Existing Steel Casing 44 LF $ 32.40 SP-6a 1"G Water Service Line Main to Meter 47 LF $ 12.00 SP-6b 2"0 Water Service Line Main to Meter 29 LF $ 25.40 SP-7 Reroute Plumbing in Crawl Space 1 EA $ 4,280.00 SP-8 Traffic Rated Vault and Lid 3 EA $ 360.33 SP-9a 2"0 (IPS) HDPE, PE 3408/4710, DR11, Water Service Sleeve 17 LF $ 19.61 SP-9b 6" PVC, AWWA C900, DR25, Sewer Service Sleeve 54 LF $ 6.38 SP-10 Water Service Line Meter to Buildin 279 LF $ 12.15 SP-11 Locate Existing Service Line with CCTV Inspection 3 LA $ 285.33 SP-12 Drainage Structure Per Detail on Sheet 2 1 EA $ 2,485.15 NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION page 13 of 13 Project 10515.d Z 0 9 ' _ J 8 b b n zroN ox.°mi 1.n 1N3W3JV9d3U 3NI7 U31VM T U3M39 mon n.wium •° ca°z � o SaMAMS arms (LKV Saaamf)x8 DMIMSNea 133ULS CINE MN a a ONI 'SINVITISN0D [SAUS 'IIAID W 3� NVICIIa3W d0 AlICI &�4Z8'M q Seg € {E6 Y § wwg 888LLvaF��� �ielljl4� $ oaLi ro- g� W AIR. �4� 8 2ro.�ggF ?. F ti I— Z Z W Z V� aJ �o L d� WaSN Z ® �WNN W � ��N� � LL. C4 F4 O N 3::R �- __ �j�.. •. F v t/�a Z 01 °� O � Wd v � N Z 0 9 ' _ J 8 b b n zroN ox.°mi 1.n 1N3W3JV9d3U 3NI7 U31VM T U3M39 mon n.wium •° ca°z � o SaMAMS arms (LKV Saaamf)x8 DMIMSNea 133ULS CINE MN a a ONI 'SINVITISN0D [SAUS 'IIAID W 3� NVICIIa3W d0 AlICI &�4Z8'M q Seg € {E6 Y § wwg 888LLvaF��� �ielljl4� $ oaLi ro- g� W AIR. �4� 8 2ro.�ggF ?. F ti sm a __ �j�.. •. �__ �� ■•III n FP a p+, uunn i:nuu: �nnnu� p ' I lnuu! �I111111111 II�i' (O� Cp��'GJ j �ti,,J��li� m- N �I ISI_. • � L (r A �w���.� ���� sm a p � 8 FP a _A 3 o @00 O a m��� p (O� Cp��'GJ j ",M-4M.oz) o��3 eo �b� mween uvoa Now& W" SlItl130 ONtl S310N NOIlOflillSNO'J I a, 1NM33VUM 3N1I H31VM V M3M3S w "o I ;69Z saoaanans arm aNr saaata�rta oru)TnsNoo 133NiS ONZ MN " 'DNI `SINVITISMOD AHAWIS 'IIAIDtz NVI01213W d0 AlIO £ s ron carom sr,a55vaa a s& 4 v> a =e8 e o� ljli s8LL 13 M"it p autjHi�ki�l a 6$$ U ear$ i F18118¢ g Q�� III a;' �"�3xYn m 9 i iry' d$c34gN 3 U, o Hal Z `s ?P3s1 o � €F @ Rk ha o Ins ; o Ig-n� n E ig Ed $$5 8 : °� m 2 0 0 • Ey mo a �_ �° b� mo o � 0 1 a` s W a3c ` a 2 3 m ` $ S'' .Y N 6 •"� 8N u c : E � £■2 E� $ $ '� g £ c g � y � 3's S$$9x' sa b n g� 2m o �@ gm g e � p� a �� • € � � gmm �� gE 2 f Id b ` y S _X gg@@E • 9 eEZ a$ �j3 a c a as r 3s s no ggqnz)a3n ° c �� avod Hvwrc3n •s saaL SaOUMS QNn a" saaamDma `JNISMS= 'ONI `SINV,L'IIISNOO IaAWIS TAIO �IYOOISS ayyl9NJSt 31q Na ron alvei sHosn3a z E 4ys ig3 8 H IN 8 SSa G €a �tl E� ° Eg IjII g' i� 8 �go b § H zS 55 iii e 4 tl $ 'I Il a Ia = H whi e l -g AE IN fl1v pv i 4 4 133H5 335 � 1y 1 � i0L+4t) 3NI1 H�1Vt1 9 OV'ld3H 3N1'I H31VM V 213M3S 133HJLS CINZ AAN a "' n � NVI4R13W d0 ALIO a h G � �e a e © � IN 9 OV'ld3H 3N1'I H31VM V 213M3S 133HJLS CINZ AAN a "' n � NVI4R13W d0 ALIO a h o��3d 't*+bo aibaeM Mr owal SNYI IUM 1N3W30V ld3U 3N11 M31VM 'S H3M3S "Oa HUM" 'S E694 $ 0 was Ow3u ssoaaeans Mn OW saaaxioxa 9xLL7flsxoJ 133M1S ONZ MN ' 'SLNVLIfISi10D xRAiIIIS IIAID NV1a1M3W d0 A110 s N v usvaa smm�va oj� �3F� =dg 2zry ns a�w d ne kgs yn� Q1 gp9 a S j;pig vNv1 n�n y� i;�0 11 n��� p @ @1 $ nl e3 a.o i ippgg I gg., �n��'r!� s $k - s3g� 1, Ism ���Ih �9 h � IN v�n€ �� t§�� ��� � �� I NUNN i1 1 1 Fly g$ 1 { s v Li A 8_ a zz orm sN 0.9 .... zrnss .....z e m ' ZT-m t... a" NN -IN ',0 .'00'58+pI zin-vvv(eoz) NVId 10HIN09 OIddVMlOlivol m O�Y�d 0 �o Q;v>�M OYON mm NY Wim IsOE69Z q�/f✓c'. 1NSMOV Id3M 3NIl M31VM V M3M3S " y`I SHOAMMs arm aNY SHSSNIONS JMUSNOS 193MIS 0NZ MN ao ONI `SINVI IISM03 A'3AHIIS 'IIAIJ rw" """° suoawa NVIOIM3W d0 A110 3 o - J� �gm g N toe is e$SW ?e • dam anis "j o rn �a nFa SPRnuE sty CL se - a i &&pal Q t p B _ u 3.- ado m� 19: I$ ebn w 11H Ll u z 133a1s NIYW N LIU L w — — a 3 OYOH NMOWN N 13� 1g N r t o I� Fee 1i °TII 133211S OHC MN [:A 13381S H14 MN a � F-1 F 0 8 0 LL H 'S yo 'o0 o� w o12 tz go L I 133uis M W -M 1332119 ONZ MN Ij w� w __ 313381S ONE MN CL w p > F--1 — f 2m j G 9 (6) 8 z N N °TII 133211S OHC MN [:A 13381S H14 MN a � F-1 F 0 8 0 LL H 'S yo 'o0 o� w o12 tz go L I 133uis M W -M 1332119 ONZ MN Ij w� w __ 313381S ONE MN CL w p > F--1 — f 2m j G 9 (6) 8 mcr-aae(eoz) �3a •� p3q"d°' zrocc anm nrwinrn Ntlld 10211NO3 1N3W1039 ONtl NOISOil3 00 Ddu �� OVOn Anartnn 'S t69L � Iii 1N3W39tl9d3a 3NIl H31VM W t13M3S " o SaoaaAans aam aw Saamma Dumnswo 133a1S ONE MN 'ONI 'SINVITISNOO XaAHnS 'IIAIO 49; W Ntl10R13W d0 A.LIO s d t=n SNOISN3tl �_ -l•.I$ d' 7 / owl] 888$p (Sa §ySp�EE;aaS8 �ttmol SAI • � - _ Kd uZ1 tc �I� z Iry W 3fa0iV qfN 'A i _ OaWW UJ C LCL L(/L J wONWM= (A T I I o I— 3 Z a Zz F g Q Q �1 o W LD It p IS g E 8 i b e d p S � ° 41 ,�1 �g AN g �g� a PRIN,im ° , I € gags, eg g a.1 Ea :�€g m e o is € f� a�"";;� Mpg gal= a � 'g ° p s g® 6 x<� dig' ag48 gI3 $ e � 93 h G8 Vd $.S ° ` R �3 ";-� �' °% F$� gee a #aagr 9g x5e€3¢k�� € �`<kt 8 �d a�gy a wig ��s=° ga eg k§a ^ Nil gg��8�6S-< ��< ii gi 3 4 € a a gag �s 4a �9a�� A q b ` d €F 6wg g 7`�§< Hi a�g g z�i. p s 3a@ g 3j Q �g` sang Fad �Sx�z d g�a�11g�:gQ V� a s€ 8 ao v s:J�fig ala !£ agig g g1a2 xh, �s OWNER CITY MERIDIAN 33 E. BROADWAY AVENUE, SUITE 200 MERIDIAN, IDAHO 83642 (208) 898.5500 CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 —IA00�, ae �ack�n�ca1 & ear (501 With 160 ..1sww d �nsttiiUt`! 11t Au1 `' ; 011 1, ©� G� a� nvna `eats\tuc e e Ce0 ub�itt� 4 °��i d� Vei a e P%9103 / i one Y on9ineet iette� dated ►e eC to epi to: pi t o"Al", tevitiVie��ies •Ch1�i at 01'etriaa� itis iws CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT GENERAL PROVISIONS 1. BASIS OF PAYMENT Except as modified herein, the various work items called for on the "Bid Schedule" will be performed, measured and paid for as indicated on said Bid Schedule and as provided in the C:urreiit I-dition of the Idaho StandArds For Public Works Construction (18PWC); the Cityoof ,do ed -AC11D S'upplemegts. The Contractor is required to be a current holder of the Idaho Standards For Public Works Construction, Meridian Supplemental Specifications and Drawings, and all ACHD supplements. Any work required to complete the project but not specifically included in a bid item shall be considered incidental to the project and no separate payment shall be made. 2. DAMAGE The Contractor will be responsible for retaining and protecting all fire hydrants, mail boxes, sprinkler systems, shrubs, sod, landscaping, trees, fences, etc., within the construction limits, unless otherwise shown on the plans. The Contractor will also be responsible for retaining and protecting all improvements outside the construction limits. Any items damaged shall be promptly repaired or replaced to a condition "equal to or better" than existed prior to construction by the Contractor. The cost to complete such repairs shall be considered as incidental to the cost of the project and no separate payment will be made. 3. PROJECT MAINTENANCE The Contractor will be responsible for project maintenance throughout the life of the contract. This responsibility includes, but is not limited to, dust control, maintenance of irrigation facilities, blading, maintenance of detours, maintenance of all intersecting street approaches, proper and adequate drainage, access for emergency equipment and appropriate access for property owners. The cost of all maintenance work shall be considered incidental to other project work and no separate payment will be made. 4. COORDINATION It shall be the Contractor's responsibility to contact and work with the property owners, irrigation districts, ditch riders, utility companies, and any other parties as necessary to coordinate and ,install improvements required by this project. This coordination effort shall include, but not be limited to, coordination with utility companies in their efforts to relocate their facilities as a result NW. 2ND Street Sewer and Water line Replacement Project #10515A of this project, and working other than normal working hours to permit the relocation of the utilities and construction of the required improvements within the time frame of this contract. Utility information is shown only for surface features. The information shown is for reference purposes only and does not necessarily represent actual field conditions. The Engineer assumes no liability for the accuracy of the information shown, or conflicts due to inaccurate or incomplete utility information. The Contractor shall call Dig Line a minimum of 48 hours prior to any excavation to request utility locations at 1-800-342-1585. The Contractor shall expose all existing utility crossings to verify locations and elevations prior to any other construction that may affect those utilities. The cost associated with exposing the existing utilities is considered incidental to the project and no separate payment will be made unless otherwise specified on plans. Contractor shall coordinate all work with property owners and complete all work within existing public utilities or irrigation easements. All disturbed surfaces shall be restored to a condition equal to or better than existed prior to construction. All surface restoration shall be considered incidental to the project and no separate payment will be made. 5. ACCESS TO PROJECT Local access, business, and emergency vehicle access shall be maintained at all tunes. 6. QUANTITY PAYMENT Payment will be made for the actual quantity of each bid item completely installed and accepted by the Owner. Payment will be based upon the units specified for each item at the unit prices shown in the bid schedule or approved change order. 7. COMPACTION Compaction requirements shall be in accordance with Section 204 — Structural Excavation and Compacting Backfill, Section 306 - Trench Backfill, and applicable sections of Division 800 — Aggregates & Asphalts, of the ISPWC Specifications. The cost to complete this work including watering and drying shall be considered incidental to the cost of the project and no additional payment shall be made. Contractor shall provide compaction testing of all materials by an independent thirty party testing firm. A copy of testing results shall be provided to the City Public Works Inspector. All trench excavation and backfill shall conform to Division 300 of the ISPWC. All excavation and trenching shall meet OSHA requirements and the applicable portions of Division 300 "Trenching". All cost to complete trench excavation and backfill is considered incidental to the pipe installation bid item and no separate payment will be made. NW. 2ND Street Sewer and Water line Replacement Project #10515A 8. LANDSCAPING The Contractor shall maintain the existing landscaping in the same condition as found. If the contractor is unable to work around the landscaping then the work shall be completed and the contractor shall repair or replace the landscaping to an "as good or better condition" than existed before work started. The Contractor shall retain and protect any sprinkler systems encountered, unless specifically designated otherwise. The cost of this work shall be considered incidental to the project. All work to remove and reinstall existing trees or bushes shall be completed by a licensed landscape contractor. Removed trees or bushes that Contractor plans to reinstall shall be properly bedded and irrigated during construction activities. If existing trees and bushes are replaced with a new tree or bush, they shall be of same type and property owner shall approve items prior to Contractor planting items. Each new tree shall have a minimum caliper of 2 -inches. MISCELLANEOUS The Contractor shall repair or pay the owner to repair, any utility damaged during construction. The Contractor shall repair any sprinkler systems damaged during construction. The cost of these repairs, unless specifically identified as a bid item, shall be considered as incidental to the cost of the project, and no separate payment will be made. Removing and resetting of any existing street signs, fences, mailboxes, or miscellaneous items as required shall be incidental to the project and no separate payment shall be made. The Contractor shall perform, coordinate and schedule various construction tasks such that adequate protection is provided to all existing and new underground utilities. 10. HIGH VOLTAGE, OVERHEAD, POWER LINES The Contractor's attention is directed to, and compliance is required with, the requirements of Title 55, chapter 24, Idaho Code, which regulates certain work by contractors near high voltage, overhead, power lines. 11. SURVEYING The Owner will provide one set of horizontal control construction stakes for each new water service vault, fire hydrant, water main bend and at 100' intervals along water main. Horizontal and vertical control construction stakes shall be provided for each new sewer manhole and at one intermediate point on the new sewer main when the distance between manholes is greater than 300'. Each new sewer service line shall also be staked at the right-of-way line with horizontal and vertical control provided. It shall be the Contractor's responsibility to protect construction stakes once requested by the Contractor. Construction stakes destroyed after being requested by the Contractor shall be restored at Contractor's expense. These costs shall be deducted from progress payments. The NW. 2ND Street Sewer and Water line Replacement Project #10515A Contractor shall remove all construction stakes remaining at project completion. The cost to remove stakes shall be considered incidental to the project. Contractor shall preserve all survey land monuments. If monuments are disturbed, Contractor shall be responsible for having a licensed professional surveyor reestablish monuments. Cost shall be considered incidental to project. If Contractor fails to have monuments reestablished the Owner shall contract with a licensed survey to reestablish disturbed monuments and the cost shall be deducted from the final payment. 12. TESTING Contractor shall provide compaction testing of all materials by an independent thirty party testing firm. A copy of testing results shall be provided to the City Public Works Inspector Trenches and asphalt shall be tested per the appropriate section of the ISPWC. Re -testing necessitated by the failure of quality assurance testing of materials placed by the Contractor shall be at the Contractor's expense. These costs shall be deducted from progress payments. 13. ON-SITE SUPERVISION The General Contractor shall provide competent on-site supervision during any and all construction activities by his forces or subcontractors. The superintendent shall be identified at the preeonstruction conference, and at a minimum be on-site fiom notice to'proceed date to the substantial completion date. If for any reason the superintendent needs to be replaced by the General Contractor, a written notice must be submitted to the Owner within (5) five working days before the event occurs. 14. PERMITS The Contractor, at his own expense, shall procure all permits, certificates and licenses required of him by law for execution of the work. He shall comply with all federal, state, or local laws, ordinances or rules and regulations relating to the performance of the work. He shall file such reports of construction as required by law. The cost for this work is considered incidental to the project and no separate payment will be made. Contractor shall be responsible for obtaining an ACRD right of way permit (which is a no cost permit) and provide a copy of permit to the City of Meridian Project Manager prior to construction. Contractor shall be responsible for obtaining a City of Meridian Building Department permit (which is a no cost permit) for each property where contractor is hooking the new water or sewer service line to the existing water or sewer service line. NW. 2ND Street Sewer and Water line Replacement Project #10515A 15. SERVICE INTERUPTIONS Contractor shall provide continuous sewer and water service to all affected properties. Service disruptions of less than 4 hours may be acceptable with prior approval from the city. Property owners shall be notified of any service disruptions a minimum of 48 hours in advance. 16. PRIVATE PROPERTY ACCESS Prior to starting work outside the public right-of-way the Contractor shall obtain written permission from the property owner to access each property and take pictures of each individual property. After all work is complete the Contractor shall take pictures of each individual property and have each property owner provide written documentation that their property has been restored to an acceptable level. A copy of the pictures and written documentation shall be provided to the City. Contractor shall notify each property owner a minimum of 48 hours in advance of starting work on their property and/or any service interruptions. The Contractor shall be responsible for having each property owner sign the release form provided in Appendix B of these documents. The form shall be signed once all work has been completed. Final payment shall not be made by the City of Meridian until a copy of each form has been provided to the City. SPECIAL PROVISIONS 307.4.1.G.1. — TYPE P SURFACE RESTORATION ON PAGE 6 OF SECTION 307 OF THE ISPWC, PART 3.8.K, add the following: The existing paved shoulders along NW 2" a Street south of Broadway Avenue shall be regraded and repaved per the detail on sheet 2 of the plans. The Ada County Highway District would like to use this section to regrade the shoulders and provide positive drainage to existing or new drainage structures. Contractor shall coordinate this work with the Ada County Highway District and provide this work under their direction. 2. 205.4.1.B.1. — DEWATERING ON PAGE I OF SECTION 205 OF THE ISPWC, PART 1.4.A, replace the entire section with the following: The Contractor shall prepare a dewatering plan that will dewater all trenches to draw the groundwater to one foot below the bottom of the trench. The plan shall include a statement of the method, installation and operation details of the proposed method, disposal location, schedule, erosion and siltation control. Include a description of the program to monitor water quality during dewatering. Contractor shall prepare a contingency plan for equipment or power failure and unexpected flow conditions. The Contractor shall submit the dewatering plan to the City of Meridian for review and approval. The dewatering plan must be approved by the City of Meridian and the Idaho Department of Environmental Quality (IDEQ) prior to starting work. NW. 2ND Street Sewer and Water line Replacement Project #10515A ON PAGE 2 OF SECTION 205 OF THE ISPWC, PART 3.2, add the following: As of the project bidding, the City does not anticipate there to be a disturbance of more than one acre of total area. If the Contractor plans on disturbing more than one acre, the Contractor will be required to prepare a SWPPP and all dewatering shall conform to the EPA Construction Stormwater General Permit for the project. Turbidity monitoring may then be required if there is a direct discharge to a water body that is impaired due to sedimentation/siltation. IDEQ and EPA will review the Notice of Intent (NOI) submitted by the Contractor and will then notify the Contractor if they will be required to perform turbidity monitoring. NOI's must be filed by both the Contractor and the City of Meridian. Disturbance area shall include all stockpile areas and haul routes, even if they are off-site. The Owner has not secured permits to discharge water to any irrigation or storm drain system. Contractor shall be responsible for securing any necessary approvals from governing irrigation district, Ada County Highway District, and property owner's prior to starting construction. ON PAGE 3 OF SECTION 205 OF THE ISPWC, PART 4. 1, add the following: Partial payment for Dewatering shall be made as follows: 1) 50% of the contract unit price will be made on the first progress payment. 2) Remaining 50% of contract unit price will be made on second progress payment. 3. 303.4.1.A.1. — EXPLORATORY EXCAVATION (PRE -APPROVAL REQUIRED) ON PAGE 1 OF SECTION 303 OF THE ISPWC, PART LLA, replace the entire section with the following: This item includes furnishing all materials, equipment and labor necessary to locate existing sewer service line when the existing line is not located within 4' of the location shown on the plans. This item will not be paid if the existing service line is located within 4' of the location shown on the plans. Prior to starting exploratory excavation, the Contractor shall receive prior approval from the City of Meridian Inspector. ON PAGE 3 OF SECTION 303 OF THE ISPWC, PART 4. LA, add the following: Payment will not be made for the exploratory excavation without prior approval by the City of Meridian Inspector. 4. 306.4.1.C.1. — IMPORTED TRENCH BACKFILL, TYPE A ON PAGE 1 OF SECTION 306 OF THE ISPWC, PART 1, add the following: This item shall only be used when excavated trench materials are deemed unsuitable for use. The Contractor is not required to remove all trench excavation materials from the site and replace NW. 2N1) Street Sewer and Water line Replacement Project #10515A them with imported trench backfill. Prior to importing trench backfill, the Contractor shall receive prior approval from the City of Meridian Inspector. ON PAGE 3 OF SECTION 306 OF THE ISPWC, PART 3, add the following: The Contractor shall handle and store all excavated trench materials in such a manner as to preserve the quality of the materials. If materials are not preserved and therefore deemed unsuitable for use, Contractor shall import suitable materials at no additional cost to the City. ON PAGE 7 OF SECTION 306 OF THE ISPWC, PART 4, add the following: Payment will not be made for the imported trench backfill without prior approval by the City of Meridian Inspector. 5. 401.4.1.A.1. — WATER MAIN ON PAGE 1 OF SECTION 401 OF THE ISPWC, PART 1.1.C, add the following, Contractor shall provide a high line water service by-pass system as required to provide continuous water service. The system layout and all materials shall be preapproved by the City of Meridian Water Division. Contractor shall disinfect the system as directed by the City of Meridian Water Division and Public Works Inspector. ON PAGE 17 OF SECTION 401 OF THE ISPWC, PART 4.1.A., add the following, Fittings are called out on the plans in order to aid the Contractor in understanding the intent of the planned construction. All required fittings are considered incidental to the pipe bid item and no separate payment will be made. Any additional fittings required to complete the work which are not shown on the plans shall be furnished and installed by the Contractor under the pipe bid item and no separate payment will be made. The Contractor may provide fittings differing from those called for on the plans with the approval of the Meridian Public Works Department. The Contractor shall provide all materials, equipment, and labor necessary to make adjustments at non -potable pipe crossings to install water main in accordance with the Idaho Rules for Public Drinking Water Systems (IDAPA 58.01.08). ON PAGE 1 OF SECTION 401 OF THE ISPWC, PART 3.9, add the following, Flushing and disinfection shall be in accordance with section 401.3.9 of the City of Meridian Supplemental Specification and Drawings to the ISPWC. Heavily chlorinated water (above normal system residuals) shall be flushed through a dechlorinator such as a Romac Dechlorinator (378-0320) or other commercial device capable of dechlorinating the disinfection water concentration and flow encountered. Contractor shall receive permission in writing from land owner, irrigation district or storm drain system owner prior to discharging to land, irrigation facility or storm drain system. NW. 2ND Street Sewer and Water line Replacement Project #10515A Flushing shall also be in accordance with the Idaho Department of Enviromnental Quality (IDEQ) Guidance for Public Water System Disposal of Water from Construction, Maintenance, and Operations. This document can be found at: hPi?. wwrv.dec,J tI17:i_1 1%1»�rs-dispt� a(- E���I�irtccry0 14,1 c1f 6. 402.4.1.A.1. — GATE VALVE, ON PAGE 4 OF SECTION 402 OF THE ISPWC, PART 2.7, add the following: Valve box lids within Pine Avenue shall be a non -pop lid as manufactured by SW Services. Lid shall be blue in color and stamped "WATER". ON PAGE 4 OF SECTION 402 OF THE ISPWC, PART 3.2, add the following: Contractor shall protect and retain valve covers through all phases of construction. Preliminary adjustments may be required to allow placing of base courses and paving over the valve boxes. Valve boxes shall be adjusted to final grade and the concrete collar constructed after paving is completed. 7. 403.4.1.A.1. — FIRE HYDRANT ASSEMBLY ON PAGE 3 OF SECTION 403, PART 2.3.A., replace the entire section with the following: Hydrants shall be furnished with two layers of factory applied red polyurethane epoxy, alkyd, or epoxy base coat. Acrylic top coat shall be Kelly Moore Paint Company, No. 5780-562 or approved equal. Hydrants shall be installed per Meridian SD -W7. 404.4.1.A.1. — WATER SERVICE CONNECTION ON PAGE 1 OF SECTION 404, PART 1. 1, add the following: This item shall include adjusting the cover to final grade once all roadway and landscape construction is completed. Vault lid shall be set in accordance with Meridian SD -W5. ON PAGE 5 OF SECTION 404, PART 3.2, add the following: Contact Meridian Public Works Inspector a minimum of five (5) days prior to installing the service connection to coordinate meter delivery and installation. 9, 501.4.1.13.1. — SANITARY SEWER PIPE ON PAGE 5 OF SECTION 501 OF THE ISPWC, PART 3, add the following: NW. 2ND Street Sewer and Water line Replacement Project #10515A Contractor shall handle and store all excavated trench materials in such a manner as to preserve the quality of the materials. If materials are not preserved and therefore deemed unsuitable for use, Contractor shall import suitable materials at no additional cost to the City. Sewage shall only be allowed to flow in new pipe once it has been tested and approved by the City of Meridian. 10. 502ALAA. — SEWER MANHOLE ON PAGE 4 OF SECTION 502 OF THE ISPWC, PART 3, add the following: Contractor shall protect and retain manhole covers through all phases of construction. Preliminary adjustments may be required to allow placing of base courses and paving over the manhole covers. Manhole covers shall be adjusted to final grade and the concrete collar constructed after paving is completed. ON PAGE 4 OF SECTION 502 OF THE ISPWC, PART 3.3, add the following: The existing sewer main in Broadway Avenue is a clay pipe sliplined with an HDPE pipe. The clay pipe shall be cut back as necessary to allow the HDPE pipe to be connected to the new manhole. Prior to backfilling, the annular space between the existing clay and HDPE sewer mains shall be filled with a low strength grout in accordance with Section 508 of the ISPWC at each exposed point. The grout shall extend a minimum distance of twenty-four (24") inches into the annular space. 11. 503.4.1.A.3. — SEWER SERVICE CLEANOUT ON PAGE 2 OF SECTION 503 OF THE ISPWC, PART 2.2.A, add the following: Nonbolt-down covers per ISPWC SD -506B shall be used in all areas (including lawn areas) except a threaded PVC cap may be used in landscape planter areas and when cleanout is placed next to building when approved by the property owner. ON PAGE 2 OF SECTION 503 OF THE ISPWC, PART 3. 1, add the following: Cleanout shown on project documents are approximations and all required cleanouts may not be shown. Cleanouts shall be added and located as needed to meet Idaho Plumbing Code and City of Meridian Building Department requirements. At a minimum one existing or new cleanout shall be provided at the connection point to the existing service line. Existing cleanouts shall be adjusted as needed to complete the connection to the existing service line. Cleanouts shall be installed as needed to allow the service line to be properly cleaned and CCTV inspectioned when necessary. ON PAGE 3 OF SECTION 503 OF THE ISPWC, PART 3.4, add the following: Covers shall be adjusted to final grade after final grading is completed. Nonbolt-down covers shall be set flush with finished grade. Threaded PVC cap shall be set four inches above finished NW. 2ND Street Sewer and Water line Replacement Project #10515A grade. A concrete collar shall only be required when cleanout is placed in pavement, gravel driveways and other potential traffic areas. 12. 504.4.1.A.1. — SEWER SERVICE PIPE ON PAGE 3 OF SECTION 504 OF THE ISPWC, PART 3, add the following: All surface restoration, landscape restoration, sprinkler repair, fence repair and other necessary site repairs outside the public right-of-way shall be considered incidental to this bid item. Abandoning of the existing sewer service line shall also be considered incidental to this bid item. All work to install the service line that occurs outside the public right-of-way shall be inspected by the City of Meridian Building Department. Contractor shall coordinate inspection with building department. The City of Meridian Public Works Department shall inspect all sewer line work within the public right-of-way. Contractor shall be responsible for all necessary coordinating with property owner to complete project. This shall include but not be limited to the moving of automibles and other items that the property owner prefers to move themselves. ON PAGE 3 OF SECTION 504 OF THE ISPWC, PART 3, add the following: Prior to starting work outside the public right-of-way the Contractor shall obtain written permission from the property owner to access each property and take pictures of each individual property. After all work is complete the Contractor shall take pictures of each individual property and have each property owner provide written documentation that their property has been restored to an acceptable level. A copy of the pictures and written documentation shall be provided to the City. Contractor shall notify each property owner a minimum of 48 hours in advance of starting work on their property and/or any service interruptions. The Contractor shall be responsible for having each property owner sign the release form provided in Appendix B of these docwnents. The form shall be signed once all work has been completed. Final payment shall not be made by the City of Meridian until a copy of each form has been provided to the City. The connection point to the existing sewer service may be other than shown on plans with approval of owner and engineer. The location of the existing sewer service lines are approximations based on existing sewer main CCTV inspections and home inspections. The existing service line locations and the new connection point may differ from those shown on the plans. Contractor shall verify the location of the existing service line prior to starting the installation of the new service line. The new services lines shall be installed at a minimum slope of 2% if possible. The minimum slope shall never be flatter than 1%. NW 2ND Street Sewer and Water line Replacement Project 410515A Abandoning of the existing sewer service line shall not occur until the new service line has been inspected and approved for use by the Building Department. The existing service line shall plugged with 12" of concrete downstream of the new connection. Contractor shall repair or replace all surfaces, fences, sprinkler and other items damaged during construction. All lawn repairs outside the public right-of-way shall be sod (no seed allowed) per bid item SP -1 but considered incidental to bid item 504.4.1.A.1. Pavement and concrete repairs outside public right-of-way shall match existing asphalt, concrete, and base thickness. All concrete repair shall occur from existing joint to existing joint. 13. 706.4.I.G.1. — CONCRETE REPAIR ON PAGE 3 OF SECTION 706 OF THE ISPWC, PART 3, add the following: All pedestrian ramps damaged during construction shall be reconstructed with ADA detectable warning domes in accordance with the ISPWC, ACHD supplements, and ADA requirements. All concrete repair shall occur from existing joint to existing joint. ON PAGE 7 OF SECTION 706 OF THE ISPWC, PART 4.1.G., add the following: Construction limits for this item shall be as shown on the plans. Any concrete repair required beyond the specified construction limits shall be made by the Contractor at his expense and no separate payment will be made unless preapproved by the City of Meridian. 14. 1001.4.2.A.1. — STAGING AREA ON PAGE 1 OF SECTION 1001 OF THE ISPWC, PART 1.1, add the following: This item shall also include furnishing all materials, equipment and labor required to provide storm water management during construction in accordance with the City of Meridian's Construction Storm Water Management Program. See Appendix A. ON PAGE 1 OF SECTION 1001 OF THE ISPWC, PART 1.1, add the following: The Erosion and Sediment Control Plan (ESCP) was prepared by the Design Engineer and is part of the plans. The ESCP has been preliminarily approved by the Ada County Highway District (ACHD) Storm Water Department and the City of Meridian Surface Water Administrator. The Contractor will need to submit the ESCP to ACHD for final approval. The Contractor shall make any required changes to the ESCP to reflect actual construction activities and to get final approval fiom ACHD. A copy of the final ESCP approved by ACHD for the right-of-way permit shall be provided to the City of Meridian prior to starting work. Coordinate erosion and sediment control activities with the City Project Manager, City Inspector and or Surface Water Administrator. A Stormwater Pollution Prevention Plan (SWPPP) shall be required for this project under EPA coverage. A SWPPP has been prepared by the Design Engineer and has been preliminarily approved by the City of Meridian Surface Water Administrator. The Contractor shall amend the NW. 2ND Street Sewer and Water line Replacement Project #10515A SWPPP (or the current EPA SWPPP template shall be completed) to include Contractor specific information and for site specific conditions and/or changes in BMP's as necessary. The Contractor shall submit the SWPPP to the City for review and approval prior to starting earth disturbing activities. See appendix for additional requirements. Contractor is responsible for installing, maintaining, removing and disposing of all Best Management Practices (BMPs) and for all documentation required to keep the ESCP current. All items that are not specifically itemized on the bid schedule shall be considered incidental to the proj ect. Contractor shall be responsible for providing all storm water management in accordance with all local, state, and federal laws. Contractor shall determine expected area of disturbance and apply for applicable permits. Contractor shall prepare and submit Storm Water Pollution Prevention Plan (SWPPP), Notice of Intent, Notice of Termination, and any other required forms to the EPA as required. 15. 1103.4. LA, 1. — TRAFFIC CONTROL ON PAGE 5 OF SECTION 1103 OF THE ISPWC, PART 3.1.13, add the following: The traffic control plan was prepared for demonstration purposes and to assist the Contractor in obtaining an ACHD right-of-way permit prior to starting work. The traffic control plan has not been approved by ACHD and additional traffic control items may be required by ACRD. Contractor shall modify traffic control plan and provide all required traffic control items as required by ACHD. ON PAGE 7 OF SECTION 1103 OF THE ISPWC, PART 4.1.A., replace the entire section with: Payment for Traffic Control shall be on a lump sum basis. Partial payment for Partial payment shall be made as follows: 1) 50% of the contract unit price will be made on the first progress payment. 2) Remaining 50% of contract unit price will be made on second progress payment. 16. 2010.4.1.A.1. — MOBILIZATION ON PAGE 1 OF SECTION 2010 OF THE ISPWC, PART 2.1.A., replace the entire section with: Project information signs shall be furnished, installed and subsequently removed at each end of the project. Signs shall be prepared in accordance with ACHD permit, City of Meridian requirements, and ISPWC Standard Drawing SD -2010C. ON PAGE 2 OF SECTION 2010 OF THE ISPWC, PART 4.1.A., replace the entire section with: Payment for Mobilization shall be on a lump sum basis. Partial payment for Mobilization shall be made as follows: 1) 50% of the contract unit price will be made on the first progress payment. 2) Remaining 50% of contract unit price will be made on second progress payment. 17. SP -1 — LAWN SOD RESTORATION Description: This item includes furnishing all materials, equipment, and labor necessary to restore existing sod surfaces or establish new sod surfaces at the locations specifically shown on NW. 2ND Street Sewer and Water line Replacement Project ##10515A the plans. All other existing sod areas damaged during construction shall be restored and considered incidental to the project. Materials: Fertilizers shall comply with the following chemical analysis: 15% to 20% Nitrogen (N) 20% to 25% Phosphorous (P2O5) 2% to 10% Potassium (K2O) Sod shall consist of Merrion, Parks, Delta or Windsor Kentucky Bluegrass or combinations of approved fine textured grasses suitable for the area to be sodded and closely matching adjacent grass. Workmanship: The lawn areas shall be tilled to a minimum depth of 6 inches by such means as will loosen the soil and bring it to condition suitable for fine grading. Prior to and during the operation, the surface shall be made free of vegetative growth. All stones, hard clods, roots, sticks, debris and other matter encountered during tilling which are detrimental to the preparation of a good seed bed, or which are toxic to the growth of grass, shall be removed. Four inches of topsoil shall then be placed under the areas to receive sod. The area shall be floated and rolled to bring it to the finished grade. All irregularities in the surface that form pockets where water will stand shall be smoothed out to provide good drainage. The finished grade of lawn area adjacent to walks, curbs, driveways and pavements shall be approximately 1 inch below adjacent grades. Fertilizers shall be spread evenly over the cultivated areas at a rate of 4 pounds per 1,000 square feet and shall be uniformly incorporated into the upper 3 inches of the soil, after which the areas shall be worked as necessary to provide a smooth, firm but friable lawn bed at the established grades. Sod shall be placed in straight strips. The joints between strips shall be butted together, tight and without gaps. Sod shall be placed in a manner to stagger the end joints of the rolls. The sod shall be rolled with a 100 -pound roller after placement. The surface of the finished sod shall be smooth, uniform and mowable. Contractor shall repair any damaged sprinkler systems and adjust all disturbed sprinkler heads. Measurement and Payment: Lawn Sod Restoration shall be on a square foot basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Construction limits for this item shall be as shown on the plans. Any sod restoration required beyond the specified construction limits shall be made by the Contractor at his expense and no separate payment will be made unless preapproved by the City. Payment for this item shall be made under: SP -1 Lawn Sod Restoration....,. ........ ..................:.......,..,.. .......Per Square Foot NW. 21D Street Sewer and Water line Replacement Project #10515A 18. SP -2 — ABANDON EXISTING WATER MAIN Description: This section of the specifications includes furnishing all materials, equipment and labor necessary to. abandon existing water main at the -locations shown on the plans, In, addition to 6andoning the existing water main in NW 21"1 Street there is an existing 2" water line in the Alley north of Pine Avenue and to the east of NW 2"" Street that shall be abandoned tinder this bid item. The 2" line shall be disconnected from the existing water main in Pine Avenue and disconnection shall be completed in accordance with these specifications and City of Meridian Water Division approval. Workmanship: All water mains shall be abandoned in place. Abandoning an existing main shall only occur following the completion of the new replacement main, and transferring all service connections to the new main. Abandonment shall consist of excavating the existing main at each location that the connection to the existing system shall be terminated. The contractor shall then disconnect the main to be abandoned and remove a minimum of five feet of the existing main line. Contractor shall install a mechanical joint cap or plug, or blind flange as applicable with a thrust block on abandoned and retained water main lines. As an alternative, the existing water main may be filled at each end with one foot of concrete. In cases where there is an existing valve, the valve shall be completely removed and a cap, plug, or blind flange installed as appropriate complete with thrust block. Contractor shall allow the City to inspect all removed materials and the City shall determine which materials they wish to retain. Contractor shall deliver all materials the City wishes to retain to the City Water Department storage yard. Contractor shall remove all other materials from the job site and dispose of them at an appropriate site. Measurement and Payment: Abandon Existing Water Main shall be on a per each basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -2 Abandon Existing Water Main... .... , .... ., .... . ............ . .....Per Each 19. SP -3 — ABANDON EXISTING WATER SERVICE Description: This item includes furnishing all materials, equipment, and labor necessary to abandon existing water service at the locations shown on the plans. Workmanship: Existing water services shall only be abandoned once the new water service has been installed, disinfected, tested, and put in service. Abandoned service pipe and shall be removed to the extent possible, without performing significant amounts of additional unnecessary excavation. No additional payments will be made for surface restoration necessary to remove service pipe. NW. 2 N1 Street Sewer and Water line Replacement Project #10515A Contractor shall remove the existing meter vault and any appurtenances. Meter vault area shall be backfilled and the surface repaired to match adjoining surfaces. Contractor shall allow the City to inspect all removed materials and the City shall determine which materials they wish to retain. Contractor shall deliver all materials the City wishes to retain to the City Water Department storage yard. Contractor shall remove all other materials from the job site and dispose of them at an appropriate site. Measurement and Payment: Abandon Existing Water Service shall be on per each basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -3 ABANDON EXISTING WATER SERVICE ................... i ..................... Per Each 20. SP -4 — CONNECT EXISTING WATER LINES TO NEW WATER SERVICE Description: This item includes furnishing all materials, equipment and labor necessary to connect existing water lines on property owner side of meter to new water service as shown on the plans. Workmanship: Existing potable water lines to buildings and existing irrigation lines shall be disconnected from the existing water meter and connected to the new water service connection provided under bid item 404.4.I.A.1. The existing lines shall only be disconnected from the existing water services and connected to the new water service once the new water service connections are complete and approved for service by the city. Existing water line sizes may not match new water service connection installed under bid item 404A.1.A.1. Contractor shall provide all fittings required to complete connection. Contractor shall repair or replace landscaping, sprinkler systems, or other items damaged during construction. Measurement and Payment: Connect Existing Water Lines to New Water Service shall be on a per each basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -4 Connect Existing Water Lines to New Water Service................................Per Each 21. SP -5 — INSTALL NEW MAIN IN EXISTING STEEL CASING Description: This item includes furnishing all materials, equipment and labor necessary to install the new water main or sewer main inside the existing steel casing pipe at the locations shown on the plans. This item shall include, pipe skids, joint restraints, end seals and all appurtenances required for a complete and workable installation. NW. 2ND Street Sewer and Water line Replacement Project #10515A Materials: Carrier pipe skids shall be Calpico Model PX spacers or approved equivalent. Joint restraints shall be Uni-Flange Series 1350 or approved equal. Contractor shall verify joint restraints fit inside casing and adjust casing size as necessary prior to ordering casing. The ends of the annular space shall be sealed with 1/8" thick neoprene seal boots attached to the pipe with stainless steel worm gear bands. Workmanship: The casing pipe shall be installed at the same slope as the carrier pipe and the carrier pipe shall be centered inside the casing pipe. Joint restraints shall be installed on water main at each joint inside casing. The annular space between the casing and carrier pipes shall be filled in accordance with the ISPWC and City of Meridian Supplemental Specifications. The existing casing pipe has a 3/8" thick steel plate tack welded to each end. The contractor shall cut off tack welds and grind them smooth. Measurement and Payment: Install New Main in Existing Steel Casing shall be on a per linear foot basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -5 Install New Main in Existing Steel Casing............... ......Per Linear Foot 22. SP -6 — WATER SERVICE LINE (MAIN TO METER) Description: This item includes furnishing all materials, equipment and labor necessary to install a new water service line at the locations shown on the plans. This item shall include connecting an existing water service to the new water main. This item shall be used when the existing meter is to be retained. When the existing meter is to be replaced the service line shall be furnished and installed under Bid Item 404.4.1.A.1, Workmanship: City of Meridian Specifications prohibit the splicing of water service lines therefore a new line shall be installed continuous from the new water main to the existing meter setter unless identified on the plans and approved by the City of Meridian. Transferring the connection of a service from an existing main to a new main shall only occur after the new main is completed, pressure tested, disinfected and approved for service. Transferring the service shall consist of excavating the service at the water meter, excavation of a trench from the existing meter to the new water main, furnishing and installing a tapping saddle and corporation stop, furnishing and installing a new service line from the new main to the existing meter setter, making all connections, and backfilling the trench. The existing service pipe shall be removed to the extent possible, without performing significant amounts of additional unnecessary excavation, and disconnected by closing the corporation stop at the existing main if possible, or sealed by installing a cap or plug on the end of the pipe to allow the existing main to remain in service until all service connections are completely transferred. NW. 2ND Street Sewer and Water line Replacement Project #10515A Measurement and Payment: Water Service Line shall be on a per linear foot basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -6 Water Service Line ..................... . . . . . . _ .Per Linear Foot 23. SP -7 — REROUTE PLUMBING IN CRAWL SPACE Description: This item includes furnishing all materials, equipment and labor necessary to reroute plumbing in crawl space at the locations identified on the plans to allow the building sewer to be turned around to drain toward the road instead of towards the back of the property. This item includes connecting the new plumbing to the new service line installed to the building under bid item 504.4.1.A.1 This item has been identified on the plans when it has been determined that the new sewer main in the road is not deep enough to run the new sewer line around the outside of the building to the existing service line at the back of the building. All work shall be inspected by the City of Meridian Building Department. Contractor shall coordinate inspection with building department. Contractor shall be responsible for coordinate this item with property owner and obtaining permission to enter the home or business. Measurement and Payment: Reroute Plumbing in Crawl Space shall be on a per each basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -7 Reroute Plumbing in Crawl Space , . , . , .., .. . ...... . ......... . .. . .........Per Each 24. SP -8 — TRAFFIC RATED VAULT AND LID Description: This item includes furnishing all materials, equipment, and labor necessary to upgrade water service vault and lid in bid item 404.4.1.A.1. to traffic rated. Materials: The Contractor shall furnish all materials in accordance with Meridian SD -W1. Workmanship: The Contractor shall install all materials in accordance with Meridian SD-Wl. Meter vault lid shall be set in accordance with Meridian SD -W5. Measurement and Payment: Traffic Rated Vault and Lid shall be on a per each basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: NW. 21 Street Sewer and Water line Replacement Project #10515A SP -8 Traffic Rated Vault and Lid.. ..... . , .::... .........Per Each 25. SP -9 — SERVICE SLEEVE Description: This item includes furnishing all materials, equipment, and labor necessary to sleeve water and sewer service lines at the locations shown on the plans. Materials: Water tight end seals shall be 1/8" thick neoprene seal boots attached to the pipe with stainless steel worm gear bands. Workmanship: Carrier pipe skids are not required. The ends of the annular space on all sleeves shall be sealed with water tight seal boots. The entire annular space between the carrier pipe and the sleeve shall not be filled. Measurement and Payment: Water Service Sleeve shall be on a per linear foot basis and shall include all labor, equipment, and materials necessary for the completion of the bid item. Payment for this item shall be made under: SP -9 Service Sleeve....... . .. . ..... ......... a ................... . .Per Linear Foot 26. SP -10 —NEW WATER SERVICE LINE (METER TO BUILDING) Description: This item includes furnishing all materials, equipment and labor necessary for the installation of a new water service line regardless of size, between the meter and the building. New service line size shall match existing service line size on property owner side of meter. If this item has not been identified on the plans, then it shall only be completed when directed to do so by the City of Meridian Public Works Inspector. If it has not been identified on the plans then this item shall only be used when the City determines that there is a problem with the existing service line on the property owner side of the meter and it needs to be replaced. Workmanship: Contractor shall locate existing service line and replace it from the meter up to a point 5' from the outside of the existing building, or a point identified by the City. The new service line shall be connected to the new service connection installed under bid item 404. LA. L. Contractor shall take pictures of each individual property before and after starting work on each property. After all work is complete Contractor shall have each property owner provide written documentation that their property has been restored to an acceptable level. A copy of the pictures and written documentation shall be provided to the City. All surface restoration, landscape restoration, sprinkler repair, fence repair and other necessary site repairs outside the public right-of-way shall be considered incidental to this bid item. NW. 2ND Street Sewer and Water line Replacement Project #10515A All work to install the service line that occurs outside the public right-of-way shall be inspected by the City of Meridian Building Department. Contractor shall coordinate inspection with building department. Installation of the new service line shall be coordinated with the City of Meridian and the property owner. The installation shall not be made until approval is received from the City and the property owner. All work to install the sei vice line that occurs outside the public -right -way shall be inspected by the City of Meridian Building Department. The City of Meridian Public Works Department will inspect all work within the public right-of- way. Service line installation and testing shall be in accordance with the City of Meridian Building Department regulations and the local plumbing code. Measurement and Payment: New Water Service Line shall be on a per linear foot basis and shall include all labor, equipment, and materials necessary for completion of the bid item. Payment for this item shall be made under: SP -10 New Water Service Line ... ............. ........................................ Per Linear Foot 27. SP -11— LOCATE EXISTING SERVICE LINE WITH CCTV Description: This item includes furnishing all materials, equipment and labor necessary to complete a CCTV inspection on existing sewer service lines only at the locations identified on the plans. The CCTV inspection shall be used to locate the existing service line and identify the point of connection to the new service line. Workmanship: Contractor shall be responsible for the reliability of the locating equipment that is used and the accuracy of the locate. If the locate is found to be inaccurate then the Contractor shall be responsible for additional locate services and/or exploratory excavation required to find the existing service line. Additional payments shall not be made by the City of Meridian. Contractor shall be responsible for coordinate this item with property owner and obtaining permission to enter the home or business. Measurement and Payment: Locate Existing Service Line with CCTV shall be on a per each basis and shall include all labor, equipment, and materials necessary for completion of the bid item. Payment for this item shall be made under: SP -1 I Locate Existing Service Line with CCTV........ . ......... ......Per Each NW. 2" Street Sewer and Water line Replacement Project #10515A 28. SP -12 — DRAINAGE STRUCTURE PER DETAIL ON SHEET 2. Description: This item includes furnishing all materials, equipment and labor necessary for the installation of a drainage structure at the locations shown on the plans. ACHD has identified a low spot in the existing aphalt shoulder where there is significant puddling that occurs during storm events. A picture of the area after a storm event has been included at the end of this bid item. The structure shall be placed in the low spot and the surrounding area shall be regraded to provide positive drainage to the structure as needed to eliminate future puddling in this area. Materials; Shall be per the detail on sheet 2 of the plans, ISPWC and ACHD supplement to the ISP WC. Workmanship: Contractor shall coordinate structure location, site regrading limits and inspection with ACHD Project Inspector. Measurement and Payment: Drainage Structure per Detail on Sheet 2 shall be on a per each basis and shall include all labor, equipment, and materials necessary for completion of the bid item. Payment for this item shall be made under: SP -12 Drainage Structure per Detail on Sheet 2.. ..................................•.Per Each NW, 2ND Street Sewer and Water line Replacement ion Storm W515A f I APPENDIX A CONSTRUCTION STORM WATER MANAGEMENT PROGRAM (CSWMP) FOR CITY OF MERIDIAN CONTRUCTION PROJECTS Revised July 2, 2013 NW. 2ND Street Sewer and Water line Replacement Project #10515A CITY CAPITAL IMPROVEMENT PROJECTS WATER POLLUTION CONTROL GENERAL Water pollution control work shall conform to the provisions in the latest edition of the Construction Stormwater Management Program (CSWMP) For City of Meridian Construction Projects and all other local, State and Federal requirements for prevention of stormwater pollution from construction activity including, but not limited to, the U.S. Environmental Protection Agency (EPA) Construction General Permit (CGP). The Contractor shall obtain other National Pollutant Discharge Elimination System (NPDES) permits that apply to activities and mobile operations within or outside of the project limits including asphalt batch plants, material borrow areas, concrete plants, staging areas, storage yards, or access roads. Copies of additional required coverage permits shall be maintained with the stormwater management plan. The Contractor shall perform water pollution control work in conformance with the requirements of the CSWMP; any Stormwater Pollution Prevention Plan (SWPPP) or Erosion Sediment Control Plan (SSCP) as well as the Construction General Permit (CGP) and its addenda in effect on the day Notice of Award is dated, or which became effective during the life of the construction project as directed by the EPA. The CGP and other references to Federal documents related to performing water pollution control work are available from the Environmental Protection Agency's (EPA) web site at: ht# ):Ilcf ub.e a. ov/ii dcs/Storinwater/e ).cfni EROSION AND SEDIMENT CONTROL PLANS For City construction projects that do not require coverage under the CGP, the Design Consultant shall prepare an Erosion and Sediment Control Plan (ESCP). The ESCP will be a simplified version of the SWPPP associated with larger projects and include the following components: ■ Project name, location map, and responsible Contractor; ■ Project description; ■ Identification of potential pollutants and potential impacts on water quality; and, ■ Plan drawings depicting storm water management strategy, including the management of wastes and non -storm water discharges. For City construction projects that do not require coverage under the CGP, and are constructed entirely within the Ada County Highway District (ACRD) right of way, the Design Consultant shall prepare the Erosion and Sediment Control Plan (ESOP) to meet ACHD's storm water management requirements identified in the District's Municipal Separate Storm Sewer System (MS4) permit. A-1 CSWMP - Appendix A_Revfsed Juty 2, 2013.doc A substantially complete ESCP will be submitted by the Design Engineer to the City Project Manager prior to the beginning of bidding process for City approval. The Public Works Environmental staff will review and approve the ESCP prior to the start of bid process. Upon bid award and prior to implementation on site, the Contractor shall review and amend the substantially complete ESCP for site specific conditions and/or changes in BMP's as necessary, submit a Final ESCP to the City for review and approval, and implement the Final ESCP on site. The Final ESCP shall be updated as required throughout construction phase using a modification process similar to that for SWPPPs. The ESCP will be active on each City Project until the City accepts the work. All ESCP inspections and end of project processes shall follow the SWPPP process noted below. STORM WATER POLLUTION PREVENTION PLAN (SWPPP) For projects requiring coverage under the CGP, the Design Consultant shall develop and provide to the City Project Manager for bid documents, a substantially complete SWPPP document. The Public Works Environmental staff will review and approve all substantially complete SWPPP's prior to inclusion into the bid documents. Upon bid award, the Contractor shall review and amend the bid SWPPP to include contractor specific information such as duly authorized forms and for site specific conditions and/or changes in BMP's as necessary, submit a Final SWPPP to the City for review/approval and implement the SWPPP on site. The Public Works Environmental staff will review and approve all Final SWPPP's prior to either operator filing an NOI and implementation on site. The substantially complete SWPPP and Final SWPPP must be in color, hole punched and inserted into a hard cover three ring binder, must follow the formatting of the latest EPA SWPPP template, must be site specific, shall conform to the requirements in the current CGP and shall include water pollution control practices for storm water and non -storm water from areas within and outside of the job site related to construction activities for this contract such as: 1. Staging areas. 2. Storage yards. 3. Access roads. 4. Disturbed areas. The SWPPP shall include a schedule that: A. Describes when work activities that could cause water pollution will be performed. B. Identifies soil stabilization and sediment control practices for disturbed soil area. C. Includes dates when these practices will be complete. The SWPPP shall include temporary water pollution control practices and their associated contract items of work as shown on the plans or specified in these special provisions. A-2 CSWMP - Appendix A_Reyked July Z 2013.dor A substantially complete SWPPP will be submitted to the City Project Manager by the Design Consultant prior to the beginning of bidding process for City approval. The Public Works Environmental staff will review, request any necessary changes to, and approve the substantially complete SWPPP prior to the start of bids. Upon Notice to Proceed, Contractor shall have 10 days to provide the necessary Contractor related information to be included in the substantially complete SWPPP. Contractor related information will include, but may not be limited to; Operator information, responsible person information and training, amended substantially complete SWPPP for site specific conditions and/or changes in BMP's as necessary. Once the Contractor completes review of the substantially complete SWPPP and provides the necessary Contractor related information and makes proposed changes, the Contractor shall submit the updated substantially complete SWPPP for approval to the City Project Manager. The Contractor shall allow 10 days for the City's Public Works Environmental staff review. If revisions are required, the City will provide comments and specify the date that the review stopped. The Contractor shall revise and resubmit the Final SWPPP within 10 days of receipt of the City's comments. The City's review will resume when the updated substantially complete SWPPP, with changes, is resubmitted. When the City approves the Final SWPPP, the Contractor shall submit two copies of the approved Final SWPPP to the City. Upon completion of a Final SWPPP, the City and the Contractor shall coordinate together to submit separate Notices of Intent (NOI) to EPA Region 10. The SWPPP shall be updated as required throughout construction phase using a similar amendment process as stated in the EPA CGP. The SWPPP will be active on each City Project until the City accepts the work or until the City releases the contractor from responsibility as an operator as defined in the EPA CGP. The Contractor shall not perform earth disturbing activities, as defined in the current version of the EPA CGP, that may cause water pollution until the Final SWPPP has been approved by the City, both the Contractor and the City meet the required waiting period as defined by the current EPA CGP after filing separate NOIs, and a preconstruction SWPPP inspection with the Contractor and City has been conducted and meets the approval of the City Inspector. The City's review and approval shall not waive any contract requirements and shall not relieve the Contractor from complying with Federal, State and local laws, regulations, and requirements. The Contractor shall modify the Final SWPPP, as required by current versions of the City CSWMP and the EPA CGP throughout the life of the project to meet site requirements. If there is a change in construction schedule or activities, the Contractor shall prepare a modification to the Final SWPPP to identify additional or revised water pollution control practices. The Contractor shall submit the modification to the City Project Manager who will forward to the Public Works Environmental staff for review within a time agreed to by the City not to exceed the number of days specified for the preparation of the Final SWPPP. The City will review the modification within the same time allotted for the review of the Final SWPPP. If directed by the City or requested in writing by the Contractor and approved by the City, changes to the water pollution control work specified in these special provisions will be allowed. Changes may include addition of new water pollution control practices. The Contractor shall incorporate these changes in the Final SWPPP. A-3 CSWMP - Appendix A_Rewbed July Z 2013.doc The Contractor shall keep a copy of the approved Final SWPPP and all modifications at the job site. The Final SWPPP and all modifications shall be made available when requested by a representative of the EPA; a state, tribal or local agency approving sediment and erosion plans, grading plans, or storm water management plans; local government officials; the operator of a municipal separate storm sewer receiving discharges from the site; and representatives of the U.S. Fish and Wildlife Service or the National Marine Fisheries Service to the requestor. Requests from the public shall be directed to the City. IMPLEMENTATION REQUIREMENTS The Contractor's responsibility for SWPPP implementation shall continue throughout any temporary suspension of work ordered by the City. The Contractor shall provide a qualified responsible person with applicable qualifications to update SWPPPs, conduct and record inspections, and to meet other CGP requirements. A qualified responsible person shall, at minimum, possess a City of Boise Responsible Person certification and either be certified through the International Erosion Control Association as a Certified Professional in Erosion and Sediment Control or Certified Professional in Stormwater Quality; have completed a 4 -hour stormwater erosion & sediment control training such as the Idaho Transportation Department's Resident Engineer Stormwater training, or other similar government agency training; or have similar comparable experience and certification through another recognized agency. A copy of the certification shall be provided in the SWPPP. At a minimum, the Owner and the Contractor shall sign and certify the SWPPP and all associated stormwater management documentation in accordance with the CGP. If the ranking corporate officer does not sign the SWPPP and all associated stormwater management documentation, then they must be signed by a duly authorized person so designated by the Contractor in a formal letter on corporate letterhead. If the Contractor or the City identifies a deficiency in the implementation of the approved Final SWPPP, the deficiency shall be corrected in accordance with the current EPA CGP,. The deficiency shall be corrected before the onset of precipitation. If the Contractor fails to correct the deficiency by the agreed date or before the onset of precipitation, the City may correct the deficiency and deduct the cost of correcting deficiencies from payments. If the Contractor fails to conform to the provisions of this section, "Water Pollution Control," the City Inspector, Project Manager or Surface Water Program Administrator may order the suspension of work (at Contractor's expense) until the project complies with the requirements of this section. The Contractor shall construct water pollution control items identified in the SWPPP. The Contractor shall maintain the water pollution control items until the City has accepted the project and the Contractor has filed an NOT with the EPA. The Contractor can only file an NOT after receiving authorization to do so by the City. A-4 CSWMP- Appendix A_Revised July 2, 201 Moc INSPECTION AND MAINTENANCE Weekly storm water management inspections will be conducted on City construction sites. The Contractor and the City will perform weekly storm water management inspections together. One copy of the City's Inspection Form or the current version of the EPA's Stormwater Construction Site Inspection Report will be completed by both the City and the Contractor, including signatures, during the weekly storm water management inspection. Alternate inspection forms may be utilized, provided they have been previously reviewed and approved for use by the City at the time of finalizing the SWPPP. The Contractor shall inspect the water pollution control practices identified in the SWPPP as follows: A. Before a forecasted storm, B. After precipitation that causes site runoff, C. At 24-hour intervals during extended precipitation, D. On a predetermined schedule, a minimum of once every 7 days. The Contractor shall oversee the maintenance of the water pollution control practices. REPORTING REQUIREMENTS If the Contractor identifies discharges into surface waters or drainage systems causing or potentially causing pollution, or if the project receives a written notice or order from a regulatory agency, the Contractor shall immediately inform the City Inspector and Project Manager. The Contractor shall submit a written report to the Project Manager within 7 days of the discharge, notice or order. The report shall include the following information: A. The date, time, location, and nature of the operation, type of discharge and quantity, and the cause of the notice or order. B. The water pollution control practices used before the discharge, or before receiving the notice or order. C. The date of placement and type of additional or altered water pollution control practices placed after the discharge, or after receiving the notice or order. D. A maintenance schedule for affected water pollution control practices. PROJECT COMPLETION The City may authorize removal of the Contractor from further storm water management obligations once the construction is completed. Contractor must submit a completed "Contractor Request to File Project Notice of Termination" for City review to the Project Manager. The Contractor Request to File Project Notice of Termination is included in Appendix D of the City's CSWMP. Upon completion of construction and City approval of the "Contractor Request to File Project Notice of Termination", the Contractor may submit their NOT thereby shifting responsibility for final stabilization to the City. The NOT serves as notification that construction activities with a potential to release pollutants are complete and that the construction site is A-5 CMP-Appeedfx A_Revlsed Jury 2, 2013.doe stabilized, and that stormwater inspections and documents are complete and accurate in accordance with the provisions of the CGP. END OF PROJECT DOCUMENTATION Before the City accepts the project and before final payment, contractor must supply the City with a copy of all storm water management documentation associated with the project including the field copy of the SWPPP, completed inspection forms and any other documentation to meet the requirements of the CGP. The copies must be in color, 3 ring hole punched and inserted into a hard cover three ring binder, and must follow the formatting of the EPA SWPPP template. PAYMENT During each estimate period the Contractor fails to conform to the provisions in this section, "Water Pollution Control," or fails to implement water pollution control practices the City may withhold payment. The contract price presented in the schedule of values for preparing and implementing the storm water pollution prevention plan shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all the work involved in preparing, obtaining approval of, and amending the SWPPP, as specified in the Standard Specifications and these special provisions, and as directed by the City or City's Duly Authorized Representative. The contract price is a fixed price and any changes to the project for additional storm water pollution prevention to comply with the CGP after the start of construction will be at the Contractor's expense. The contract price shall be itemized and stated as in "Measurement and Payment" parts of Division 1000 of the ISPWC. Payments for storm water pollution prevention will be made as follows; A. Upon City approval of the SWPPP and a preconstruction SWPPP Inspection with a Project Compliance rating of 1, 50 percent of the contract item price for storm water pollution prevention may be included in Contractors progress payment request. B. Upon City acceptance of the project, the remaining 50 percent of the contract item price for storm water pollution prevention may be included in Contractor's progress payment request. Implementation of water pollution control practices in areas outside the project limits not specifically provided for in the SWPPP or in these special provisions will not be paid for. a-6 CSWMP-Appendix A_Revised July Z 2013.doe APPENDIX B PROPERTY OWNER RELEASE FORM NW. 2ND Street Sewer and Water line Replacement Project #10515A Property Owner Name: Property Address: CITY OF MERIDIAN PROPERTY OWNER RELEASE FORM CONTRACTOR CERTIFICATION hereinafter referred to as "CONTRACTOR", entered into an Agreement with the City of Meridian, hereafter referred to as "CITY", to perform and furnish all services and work in association with the City of Meridian project CONTRACTOR review of the completed restoration work effort was performed on Day of , 2016 at (P.M.) (A.M.). It is my opinion the area has been satisfactorily restored to a condition equal to or better than condition prior to construction. Authorized Contractor Signature Date PROPERTY OWNER RELEASE 11 (property owner's name), have reviewed the CONTRACTOR'S restoration work operation on the subject property and it has been performed to a satisfactory condition, including, but not limited to: • Backfill and compaction • Repair/replacement of items damaged by CONTRACTOR • Removal of construction debris including rocks and stones • Utility repair • Surface restoration completed • Irrigation/drainage conveyance systems functional Property Owner Name (Printed) Property Owner Name (Signature) Date NW. 2ND Street Sewer and Water line Replacement Project #10515A APPENDIX C INDIVIDUAL SEWER SERVICE SUPPLEMENTAL INFORMATION NW. 2ND Street Sewer and Water line Replacement Project #10515A TABLE OF CONTENTS Service Connection Property Address Sheet Number # 1 605 NW 2" Street 1-2 #2A 606 NW 2nd Street 3-5 #2B 606 NW 2"d Street 3-5 #3 615 NW 2nd Street 6-7 #4 711 NW 2"d Street 8-9 #5 717 NW 2nd Street 10-11 #6 724 NW 2nd Street 12-13 #7 131 W Idaho Avenue 14-15 #8 203 W Idaho Avenue 16-17 #9 801 NW 2nd Street 18-21 #10 813 NW 2nd Street 22-23 #11 821 NW 2nd Street 24-25 #12 205 W Pine Avenue 26-27 #13 830 NW 2nd Street 28-29 #14 140 W Pine Avenue 30-32 #15 903 NW 2"d Street 33-34 #16 907 NW 2nd Street 35-38 #17 921 NW 2nd Street 35-38 #18 914 NW 2nd Street 39-40 #19 223 W. Broadway Avenue 41-42 #20 703 NW 2nd Street 43-44 #21 133 W. Broadway Avenue 45-46 #22 132 W. Broadwa Avenue 47-48 #23 127 W Idaho Street 49-50 #24 128 W Idaho Street 51-52 #25 123 W Idaho Street 53-54 NW. 2ND Street Sewer and Water line Replacement Project #10515A S 1 INSTALL N CLEANOUT Jj I ABANDON EXISTIN SEWER LINE PHOTO NUMBER AND LOCATION 605 NW 2ND STREET NO BASEMENT SEWER SERVICE CONNECTION #1 "-4" SEWER SERVICE J P EP -- --- NW 12ND TREET CONNECT TO EXISTING SEWER SERVICE. INSTALL NEW CLEANOUT. ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SCALE: 1 "=20' CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 605 NW 2ND STREET FILE: DESIGN/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 1 NEW SERVICL LII1IL (APPROX.) NEW SERVICE (APPROX.) LINE' PHOTO NUMBER 0 CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 flifill. F-Rm.cft. _t CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 605 NW 2ND STREET 54 Tr DI NW 2ND STREET DRAINAGE SWALE . . . . . . . . . . 4" SEWER SERVICE 606 NW 2ND STREET NO BASEMENT INSTALL NEW CLEANOUT SEWER SERVICE I CONNECTION #2B 11 CONNECT TO EXISTING ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SEWER SERVICE. 4 INSTALL NEW CLEANOUT. PHOTO NUMBER AND LOCATION i SCALE: 1 "=20' ABANDON EXISTING SEWER LINE -INSTALL NEW SEWER SERVICE CLEANOUT CONNETION #2A ABANDON EXISTIN SEWER LINE CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 N CT TO EXISTING SEWER SERVICE. ADJUST AS NECESSARY.-----[--- - ECESSARY.---_. ---` CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 606 NW 2ND STREET FILE: DESIGNAOT PLA DWG I DATE_ JAN. 2016 1 SHEET: NEW JLfNV IIJL (APPROX.) "rW SERVICE LINE 'PROX.) PHOTO NUMBER 0 CI'T'Y OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 606 NW 2ND STREET FII F• DESIGN /I OT PIAN.DWG I DATE: JAN. 2016 1 SHEET: 4 of 54 t PHOTO NUMBER 10. 07 2015 A, CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER Q3 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 606 NW 2ND STREET TE: JAN. 2016 1 SHEET: 5 of 54 A2 1 i r I it ABANDON EXISTING, SEWER LINE } INSTALL NEW CLEANOUT 4" SEWER SERVICE 615 NW 2ND STRE NO BASEMENT 1 CONNECT TO EXISTING SEWER SERVICE. INSTALL NEWS CLEANOUT. ` ALL ET REST LAND REST SPRI SURFACE ORATION, SCAPE ORATION, NKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE SEWER SERVICE LINE BID ITEM. CONNECTION #3 i. EP SCALE: 1 "=20' 11 NW 2ND STREET PHOTO NUMBER AND LOCATION CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 615 NW 2ND STREET NEW SERVICE LnmL- (APPROX.) NEW SERVICE (APPROX.) PHOTO NUMBER/2\ CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER 0 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 615 NW 2ND STREET ABANDON EXISTING SEWER LINE V) CONNECT TO EXISTING INSTALL NEW SEWER SERVICE. CLEANOUT INSTALL NEW CLEANOUT. 1� f 4" SEWERSERVICE ALL SURFACE RESTORATION, LANDSCAPE 711 NW 2ND STREET ' RESTORATION, SPRINKLER REPAIR, BASEMENT FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION SEWER SERVICE OUTSIDE PUBLIC CONNECTION4 RIGHT-OF-WAY # SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. J SCALE: 1 "=20' .f EP f 15 NW 2ND STREET PHOTO NUMBER AND LOCATION CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 711 NW 2ND STREET FILE: DESIGN/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 8 of 54 I NEW SERVI(,L LIIVL (APPROX.) NEW SERVICE LINE (APPROX.) 1 1 I%d I w IV4fYlUL-I\ J/ 1 PHOTO NUMBER 0 CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 711 NW 2ND STREET FILE: DESIGN LOT PLAN.DWG I DATE: JAN. 2016 SHEET: 9 of 10 ABANDON EXISTING SEWER LINE CONNECT TO EXIS PING SEWER SERVICE. 41 INSTALL NEW CLEANOUT. 4" SEWER SERVICE 1 I --INSTALL NEW CLEANOUT A 717 NW 2ND STREET NO BASEMENT SEWER SERVICE CONNECTION #5 __-p 7�- - --- E NW -2ND REET [A4 �16 CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER AND LOCATION ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 717 NW 2ND STREET 6 1 SHEET: 10 of 54 PHOTO NUMBER 0 NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS. INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER A NEW SERVICE LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 717 NW 2ND STREET SHEET: 11 15 NW 2ND STREET EP I CONNECT TO XISTING SEWER SERVIC . INSTALL NEW CLEANOUT. I ABANDON EXISTIN SEWER LINE V) l I i 1E EP -- EP i 0 724 NW 2ND STREET NO BASEMENT SEWER SERVICE CONNECTION #6 I N STALL THIS HOME IS A SLAB ON GRADE AND IT IS UNKNOWN WHERE THE EXISTING SEWER LINE EXITS THE HOME. CONTRACTOR SHALL HAVE A CCTV INSPECTION DONE ON LINE TO LOCATE THE EXISTING LINE AND DETERMINE CONNECTION POINT. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 'PHOTO NUMBER - AND LOCATION -- 4" SEWER SERVICE ALL SURFACE RESTORATION, [ LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY _ SHALL BE INCIDENTA TO SEWER SERVICE LINE BID ITEM. CSCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 724 NW 2ND STREET DESIGN/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: NEW SERVICE LINE (APPROX.) PHOTO NUMBERA2 NEW SERVICE LINEI (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER Qj CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 724 NW 2ND STREET FILE: DESIGNILOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 13 of 54 PHOTO NUMBER ZE AND LOCATION 161 NW 2ND STREET P1U/1114VV17 L/\IJI II1V SEWER LINE CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 I W m Z W Q O 0 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT—OF—WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SEWER SERVICE CONNECTION #7 SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 131 W. IDAHO AVENUE !m i nT Pum nwr, I DATF- JAN. 2016 1 SHEET: 14 NEW (APP r.rr�� nor i u�r iv�rr au�vwE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER 0 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 131 W. IDAHO AVENUE JAN. 2016 1 SHEET: 1 16 1 � ABANDON EXISTING SEWER LINE I CONNECT TO EXISTING SEWER SERVICE. l 203 W IDAHO AVE NO BASEMENT SEWER SERV CONNECTION 4" SEWER SERVICE EP EP W NW 2ND STREET PHOTO NUMBER AND LOCATION CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 FILE: W Z W Q O Q 0 1-3 a Lu ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SCALE: 1 "=20' f 17 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 203 W. IDAHO AVENUE -N/LOT PLAN.DWG DATE: JAN. 2016 1 SHEET: CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER A 1VGW SERVICE LINE (APPROX.) NEW SERVICE LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 203 W. IDAHO AVENUE JAN. 2016_1 SHEET: 17 of 54 UD I - PHOTO NUMBER AND LOCATION 4 ABANDON EXIST -� SEWER LINE -F'7q A INSTALL NEW-/ CLEANOUT 1 I S ABANDON EXISTI SEWER LINE CONNECT TO EXISTING SEWER SERVICE. INSTALL NEW CLEANOUT. f '- NEW 4"� CONNECT TO CONNECT TO SERVICE EXISTING SERVICE EXISTING SERVICE 801 NW 2ND STREET NO BASEMENT SEWER SERVICE CONNETION #9 INSTALL NEW CLEANOUT 6" SEWER SERVICE w ASPH DW ER — A - NW 1 2ND STREET 18 a CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SCALE: 1 "=20' - . �wllI EP - T CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 801 NW 2ND STREET :m A nT PI Awn= I !'TATE: JAN. 2016 1 SHEET: 18 of 54 ^1r%u rm%)I^r 1 1k 1r 114u -vv .�U-rAvl%.� LINE (APPROX.) i 01 , wll t CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER 0 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 801 NW 2ND STREET PLAN.DWG I DATE: JAN. 2016 1 SHEET: 19 of 54 1.4C SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER Q3 114L -vv OF -11%V E LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 801 NW 2ND STREET FILE: DESIGN/LOT PLAN.DWG I DATE: JAN. 2016_) SHEET: 20 of 54 NEW SERVICE L-1111L- (APPROX.) NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 801 NW 2ND STREET DATE: JAN. 2016 1 SHEET: PHOTO NUMBER AND LOCATION ABANDON EXISTI SEWER LINE %CONNECT TO EXISTING .%� 1 SEWER SERVICE. S — JG� - - 813 NW 2ND STREET BASEMENT SEWER SERVICE CONNECTION #10 4" SEWER SERVICE I � EP —w- 18 Qf NW 2ND STREET EP f FP CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 813 NW 2ND STREET FILE: DESIGN/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 22 of NEW OL. 1'L- (APPROX.) III L.. -. LI.✓ICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC - 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBERAJ CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 813 NW 2ND STREET DATE: JAN. 2016 1 SHEET: 23 of 54 CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 EXACT LOCATION OF EXISTING SEWER LINE TO SHOP IS UNKNOWN. CONTRACTOR SHALL MAKE SURE THAT LINE WITH DRAIN TO NEW SERVICE LINE. ADJUST CONNECTION AS NECESSARY. JNECT TO EXISTING VER SERVICE. TALL NEW ANOUT. DON EXISTING :R LINE OTO NUMBER D LOCATION SCALE: 1 "=20' ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 821 NW 2ND STREET ,N/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 24 of 54 NEWCrr��i�r.r 1 lKir PHOTO NUMBER ,& NEW SERVICE LINE (APPROX.) PHOTO NUMBER Q CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 821 NW 2ND STREET FILE: DESIGN LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 25 of 54 ABANDON EXISTING SEWER LINE \— RETAIN SEWER LINE FROM' SHOP CONFIRM LINE IS CONNECTED TO NEW SEWER SERVICE PHOTO NUMBER ,;Z��AND LOCATION CONNECT TO EXISTING SEWER SERVICE. 205 W PINE AVE NO BASEMENT SEWER SERVICE CONNECTION #12 wo-m `— 4" SEWER SERVICE Z I - EP 2 NW 2ND STREET EP 0 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT—OF—WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. 20 W Z W Q W Z s1 SCALE: 1 "=20' CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 205 W. PINE AVENUE FILE: DESIGN/LOT PLAN.DWG i DATE: JAN. 2016 1 SHEET: 26 of 54 PHOTO NUMBERA2 NEW SERVICE LINE " PHOTO NUMBER (APPROX.) NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER/J\ NEW SERVICE LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 205 W. PINE AVENUE FILE: DESIGN/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 27 of 54 NW 2ND STREET _F- EP I EP . _. —To" T� `7 W SEWER SERVICE j CONNECTION #13 Q LLJ Z_ 830 NW 2ND STREET 4", SEWER SERVICE ABANDON EX SEWER LINE B 1 NO BASEMENT INSTALL NEW CLEANOUT �- PHOTO NUMBER AND LOCATION CONNECT TO EXISTING SCALE: 1 "=20' SEWER SERVICE. ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 830 NW 2ND STREET FII F.nFSI(;N/I OT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 28 of 54 NE,., „ ,„r- 1 lir, .iERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER 0 CITY OF MERIDIANI NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 830 NW 2ND STREET of 0 Ld D Z W No NW 2ND ISTREET 21 EP — - -- - EP EP v P/�L ®i I � 140 W PINE AVE 4" SEWER SERVICE NO BASEMENT PHOTO NUMBE SEWER SERVICE /AND LOCATION CONNECTION #14 f I INSTALL NEW CONNECT TO EXISTING �® SEWER SERVICE. ADJUST AS NECESSARY. CLEANOUT 1 '-ABANDON EXISTING I SEWER LINE I SCALE: 1 "=20' ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 140 W. PINE AVENUE of NEW SERVICE LINE (APPROX.) PHOTO NUMBERA2 NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER 0 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 140 W. PINE AVENUE JAN. 2016 1 SHEET: NEW SERVICE L1114L (APPROX.) NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER Q3 CITY OF MERIDIANI NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 140 W. PINE AVENUE pilit of PHOTO NUMBER AND LOCATION ABANDON EXISTING SEWER LINE 903 NW 2ND STREET CONNECT TO EXISTING BASEMENT SEWER SERVICE. INSTALL NEW CLEANOUT. 4" SEWER SERVICE m Z W > Q W Z x.- - C7 - W-1 NW 2ND STREET 21 ER EP �X —x — IT IS UNKNOWN WHERE THE EXISTING SEWER LINE EXITS THE HOME. CONTRACTOR SHALL HAVE A CCN INSPECTION DONE ON LINE TO LOCATE THE EXISTING LINE AND DETERMINE CONNECTION POINT. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 SEWER SERVICE CONNECTION #15 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 903 NW 2ND STREET :W A nT PI AN_DWC 1 DATE: JAN. 2016 1 SHEET: 33 of NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBERAJ 114u-.. 1.3u- E LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 903 NW 2ND STREET FILE: DESIGN LOT PLAN.DWG I DATE: JAN. 2016 1 SH --- C:}- ----- ,. `i CONNECT TO EXISTING ABANDON EXISTINGSEWER SERVICE. SEWER LINE ABANDON EXISTING�� SEWER LINE CONNECT TO EXISTING ® L] SEWER SERVICE. ri 907 NW 2ND STREET BASEMENT SEWER SERVICE �u I CONNECTION #16 PHOTO NUMBER AND LOCATION INSTALL NEW CLEANOUT Le 6 SEWER SERVICE CONFIRM EXISTING Q SIZE AND MATCH SEEPAGE BED � 4" SEWER SERVICEPIL �� I`" 921 NW 2ND STREET NO BASEMENT SEWER SERVICE CONNECTION #17 SCALE: 1 "=20' Q NW 2ND/ STREET o —- / 22 CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 FILE: DESI J CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 907 & 921 NW 2ND STREET 4.1 NEW SERVICL- LII\L (APPROX.) rnviv IVumor-m/j\ vv1vvl PHOTO NUMBER 0 SERVICE LINE 'ROX.) CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 907 & 921 NW 2ND STREET FILE: DESIGN LOT PLAN.DWG I DATE=: JAN. 2016 1 SHEET: 36 of 54 NEW SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER NEW SERVICE LINE (APPROX.) PHOTO NUMBER CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 907 & 921 NW 2ND STREET 37 of NEW SERVICE LINE (APPROX.) PRESSURE IRRIGATION SERVICE AND VALVES CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 t PHOTO NUMBER 0 NEW SERVICE LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 907 & 921 NW 2ND STREET FILE: DESIGN/LOT PLAN.DWG i DATE: JAN. 2016 SHEET: 38 of 54J CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 914 NW 2ND STREET h n'r of AM nun I We're. .IAAI ')AiF, I iQW1797i- NW 2ND STREET PHOTO NUMBER AND L CATION FR EP EP - ALL SURFACE + RESTORATION, LANDSCAPE CONC DW RESTORATION, SPRINKLER REPAIR, \N FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION 'f r DON'T PLACE LINE OUTSIDE PUBLIC RIGHT-OF-WAY IN THIS AREA PER SHALL BE INCIDENTAL 914 NW 2ND STREET PROPERTY OWNER TO SEWER SERVICE LINE BID ITEM. BASEMENT SEWER SERVICE WATER SERVICE CONNECTION #18 % 4" SEWER SERVICE I CONNECT TO EXISTING WATER SERVICE. '"INSTALL NEW THE EXISTING 2" CONNECT TO EXISTING CLEANOUT WATER LINE IN = SEWER SERVICE. THE ALLEY ` INSTALL NEW CONNECTS TO THE CLEANOUT. WATER MAIN IN PINE AVENUE. ABANDON EXISTING THE 2" WATER �' SEWER LINE LINE SHALL BE 3 ABANDONED IN PINE AVENUE AT THE WATER MAIN ABANDON EXISTING SCALE: 1 "=20' AND AT THE TWO WATER SERVICE EXISTING WATER Q� ABANDON EXISTING SERVICES SHOWN WATER SERVICE ON THIS SHEET. EG _ EG _ _ _ _ _ALLEY� EG w ' EG EC .�_ __ EG - - �� ___ EG �ti� EG ABANDON EXISTING 2" WATER LINE CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 914 NW 2ND STREET h n'r of AM nun I We're. .IAAI ')AiF, I iQW1797i- NEW WATER SERVICE LINE (APPROX.) NEW SEWEF' LINE DON'T PLACE LI IN THIS AREA PER PROPERTY OWNER PHOTO NUMbLK U NEW SEWER SERVICE LINE (APPROX.) ►,r,.i ,.ieTrn SERVICE X.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER 0 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 914 NW 2ND STREET 54 ABANDON EXISTING SEWER LINE s / L. — CONNECT TO EXISTING -- SEWER SERVICE. INSTALL NEW CLEANOUT. -FfL- S 4" SEWER SERVICE -.a-- A 223 W BROADWAY AVE NO BASEMENT SEWER SERVICE CONNECTION #19 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT–OF–WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 R PHOTO NUMBER AND LOCATION SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 223 W. BROADWAY AVENUE ;N/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 41 of 54 NEW SEWER SERVICE LINE (APPROX.) CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 IV LYy .)t- rrER SERVICE LINE (APPROX.) -- - �.-___—.O.07 . Z� 01� 5 PHOTO NUMBERAJ CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 223 W. BROADWAY AVENUE E: DESIGN LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: Ij 14" SEWER SERVICE I � PHOTO NUMBER AND LOCATION CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 S - SCALE: 1 "=20' n /a V— ABANDON EXISTING SEWER LINE ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. rCONNECT TO EXISTING 1 SEWER SERVICE. -41R,;- - - I 1 CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 703 NW 2ND STREET .Kl I nT PI AN.DWG I DATE: JAN. 2016 1 SHEET: �t Y L NEW SEWER SERVICE PHOTO NUMBERA2 LINE (APPROX.) .ice,., e+ruirn `'r-RVICE CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBERAJ CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 703 NW 2ND STREET FILE: DESIGN/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 44 of 54 NW 2ND STREET i1 I I PHOTO NUMBER AND LOCATION ABANDON EXISTIN SEWER LINE J INSTALL NEW rz CLEANOUT 4" SEWER SERVICE LCONNECT TO EXISTING SEWER SERVICE. r 133 W BROADWAY AVE �I NO BASEMENT SEWER SERVICE CONNECTION #21 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 m I,{L 0 SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 133 W. BROADWAY AVENUE ; /I OT PI.AN.DWG I DATE: JAN. 2016 1 SHEET: NEW SEWER JLIlV IVL LINE (APPROX.) A Ir11/ elruirn clr- RVICE CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 PHOTO NUMBER Q CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 133 W. BROADWAY AVENUE 16 1 SHEET: 46 of 54 W I W � i > � Q C) Q O 0 ry m 1 rn G — aJ; S i 14" SEWER SERVICE PHOTO NUMBER AND LOCATION INSTALL NEW CLEANOUT S CONNECT TO EXISTING SEWER SERVICE. INSTALL NEW CLEANOUT. ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT—OF—WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 FILE: 132 W BROADWAY AVE NO BASEMENT SEWER SERVICE CONNECTION #22 S-A ABANDON EXISTING I SEWER LINE SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 132 W. BROADWAY AVENUE 3N/LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: NEW Sr,.,�� LI PHOTO NUMBERZ2 NEW SEWER SERVICE LINE (APPROX.) PHOTO NUMBERAJ CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 132 W. BROADWAY AVENUE e.re.—1 /, r Ml ♦►l nuin I nATr. IAhl ^IA1 A I CL rCrT. 127 W. IDAHO AVE NO BASEMENT { — S ONNECT TO EXISTING EWER SERVICE. PHOTO NUMBER AND LOCATION ABANDON EXISTING SEWER LINE SEWER SERVICE CONNECTION #23 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT—OF—WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 O Q 0 4" SEWER SERVICE SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 127 W. IDAHO AVENUE :N 11 OT PI AN_DWG I DATE: JAN. 2016 1 SHEET: 49 PHOTO NUMBERA2 PHOTO NUMBER Q3 NEW SEWER SERVICE LINE (APPROX.) NEW SEWER SERVICE LINE (APPROX.) mi CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 NEW SEWER SERVICE PHOTO NUMBER ,& LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 127 W. IDAHO AVENUE ru r. nrcin-m !, r1T Di of nwr. I nATF JAN. 2016 1 SHEET: 50 of 54 Jr - CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 NEW SEWER SERVICE PHOTO NUMBER ,& LINE (APPROX.) CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 127 W. IDAHO AVENUE ru r. nrcin-m !, r1T Di of nwr. I nATF JAN. 2016 1 SHEET: 50 of 54 + v LLJ z W Q TO 1 0 cn L� + M V d A 128 W. IDAHO AVE NO BASEMENT f ' SEWER SERVICE CONNECTION #24 AND LOCATION SCALE: 1 "=20' CIVIL SURVEY CONSULTANTS, INC. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 L CONNECT TO EXISTING 4" SEWER SERVICE SEWER SERVICE. INSTALL NEW CLEANOUT. ABANDON EXISTIN SEWER LINE ALLEY A2 ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT—OF—WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 128 W. IDAHO AVENUE ��, ���� ���� it �' '�� — � �?�. _ � ►'�. �,� int a i r n � tiK'r3 � Jy ,•�' I 4 V�ntl' ;= r,vt� I�� FILE: DESIGN LOT PLAN.DWG I DATE: JAN. 2016 1 SHEET: 52 caf 54 128 W. IDAHO AVE 0 - S -rte-- -- - CONNECT TO EXISTING - SEWER SERVICE. INSTALL NEW CLEANOUT. NO BASEMENT SEWER SERVICE CONNECTION #25 4" SEWER SERVICE PHOTO NUMBER AND LOCATION r ABANDON EXISTING SEWER LINE ALL SURFACE RESTORATION, LANDSCAPE RESTORATION, SPRINKLER REPAIR, FENCE REPAIR AND OTHER NECESSARY SITE RESTORATION OUTSIDE PUBLIC RIGHT-OF-WAY SHALL BE INCIDENTAL TO SEWER SERVICE LINE BID ITEM. CIVIL SURVEY CONSULTANTS, INC.. 2893 S. MERIDIAN ROAD MERIDIAN, IDAHO 83642 (208)888-4312 c) + m v �cn IV SCALE: 1 "=20' CITY OF MERIDIAN NW 2ND STREET SEWER AND WATER LINE REPLACEMENT 123 W. IDAHO AVENUE ;N LOT PLAN.DWG I DATE: JAN. 2016 SHEET: 53 of 54 NEW SEWER SEF" LINE (APPI k PHOTO NUMBERA2 NEW SEWER SERVICE LINE (APPROX.) e.Ylyl`� .r.,- 1. .. �� r� L .• n ...4 � '„�. - V � .. _ �F.: = ....n t PHOTO NUMBER ,& CITY OF MERIDIAN CIVIL SURVEY CONSULTANTS, INC. NW 2ND STREET 2893 S. MERIDIAN ROAD SEWER AND WATER LINE REPLACEMENT MERIDIAN, IDAHO 83642 (208)888-4312 123 W. IDAHO AVENUE rig r_ MrLnl;4,1 11 £nY Ml AM nWf^_ I nATr- .IAN 9nIA I CHFF - Wl W 0 M N (O r O N W H od W a 0 W D 0 C N E d v m d 3 a� U) 06 d U) v C N Z Q Z ij 0 LO 0 I. W 00 Z a FO H Z O Q 0 EB sgng # 0!-1 puns Pis pau6ig w O 0 Z W ti 0 0 0 co co LO o N 06 O O On N I- M It 0) co 0) 00LcoN 't co 0) N dt LO (C) co Et} Gq EF} X X X X x x x x x x x x x x x x c 0 U M o _ L o a� a) 7 .� .�UodU U 0 M to (1) C) a) Q m U Q Y Q) C d a Q BOND PERFORMANCE Travelers Casualty and Surety Company of America Hartford, Connecticut 06183 Bond No.: 106478619 M'A— — —1 " W �- PIY 10 2016 - CONTRACTOR: DEpSURETY: (Name, legal status and address) (Name, legal status and principal place of business) Alta Construction, Inc. 619 N. Cloverdale Rd. Boise, ID 83713 OWNER: (Name, legal status and address) City of Meridian 33 E. Broadway Ave., Suite 106 Meridian, ID 83642 fJ ft Travelers Casualty and Surety Company of America One Tower Square Hartford, CT 06183 CONSTRUCTION CONTRACT Date: May 17, 2016 Amount: $ 448,492.67 Four Hundred Forty Eight Thousand Four Hundred Ninety Two Dollars and 67/100 Description: (Name and location) NW 2nd Street Water and Sewer Replacement - Construction BOND Date. May 17, 2016 (Not earlier than Construction Contract Date) Amount: $ 448,492.67 Four Hundred Forty Eight Thousand Four Hundred Ninety Two Dollars and 67/100 Modifications to this Bond: None See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: Alta Construction, Ino�Company: Travelers Casualty and Surety Company of America (Corporate C4 Seal) ••.•` N . Tr '•.,, _ (Corporate Seal) S;�R � 6 ' : � Q•••• ••• � i� // ��`���0 SUIS ` 2 Signature: `t +' • - ; O WE. Name and : ® Name and Brenda J. SmitK/ coNt�. r Title:q Z Title: Attorney -in -Fact (Any additional signatures �ppe •on the i+ st pogCpDphis Performances Bond,) (FOR INFORMATION ONL�'r;;,�lam. ada sand telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE. (Architect, Engineer or other party:) PayneWest Insurance, Inc. 960 Broadway Avenue, Suite 100 Boise, ID 83706 208-424-2900 The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition 1 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5 4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition 2 § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations tinder this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: Company: (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: (Corporate Seal) The Company executing this bond vouches that this document conforms to American institute of Architects Document A312, 2010 edition 3 PAYMENT Travelers Casualty and Surety Company of America BOND Hartford, Connecticut 06183 Bond No.: 106478619 CONTRACTOR:— SURETY: - (Name, legal status and addre (Name, legal status and principal place of business) Alta Construction, Inc. f`IAY 10 2016 Travelers Casualty and Surety Company of America 619 N. Cloverdale Rd. FINANCE ET One Tower Square Boise, ID 83713 Hartford, CT 06183 OWNER: (Name, legal status and address) City of Meridian 33 E. Broadway Ave., Suite 106 Meridian, ID 83642 CONSTRUCTION CONTRACT Date: May 17, 2016 Amount: $ 448,492.67 Four Hundred Forty Eight Thousand Four Hundred Ninety Two Dollars and 67/100 Description: (Name and location) NW 2nd Street Water and Sewer Replacement - Construction BOND Date: May 17, 2016 (Not earlier than Construction Contract Date) Amount: $ 448,492.67 Four Hundred Forty Eight Thousand Four Hundred Ninety Two Dollars and 67/100 )�+�a..•� Modifications to this Bond: None 0 See Section 18 CONTRACTOR AS PRIN;01 ` '••. ��r R SURETY Company: Alta Const CT •''.,., "••�O '•� Company: Travelers Casualty and Surety Company of America (Corpor$e-S afj Rp o (Corporate Seal) - RST . Signature: - : ..- • ® Signature: Name andk4k: Name and Brenda J. Smith canN. Title: \ s tb �� •• •• * ; Title: Attorney -in -Fact (An additional si naturi�s e last'page of -this Payment Bond.) unmet �� ,.,,, (FOR INFORMATION ONLY — Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party:) PayneWest Insurance, Inc. 960 Broadway Avenue, Suite 100 Boise, ID 83706 208-424-2900 The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition I § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnities and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens.or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § b If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition 2 Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § I 1 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suitor action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shalt be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: . i the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents, § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition 3 § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL, Company: (Corporate Seal) Signature: Name and Title: Address: SURETY Company: Signature: Name and Title: Address: (Corporate Seal) The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312, 2010 edition 4 TRAVELERS POWER OF ATTORNEY Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company Surety Bond No. 106478619 OR Project Description: NW 2nd Street Water and Sewer Replacement - Construction St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company Principal: Alta Construction, Inc. Obligee: City of Meridian KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, St, Paul Guardian Insurance Company, St. Paul Mercury insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint Brenda J. Smith of the City of Boise , State of ID , their true and lawful Attorney -in -Fact, to sign, execute, seal and acknowledge the surety bond(s) referenced above. IN WITNESS WHEREOF, the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this 10th day of September, 2012. Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Fire and Marine Insurance Company St Paul Guardian Insurance Company St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company Off,}' � •r �' Ciy,�"y � * �4' �oas�Y3y� � cJ�-.'�Afr��� `rte �" � 4. `u14&� 4 E'er'_ { 'qo � a • L rt N' 4 ' ¢9}`ti../ State of Connecticut City of Hartford ss. By: �-- Robert L. Raney, Senior Vice President On this the 10th day of September, 2012, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, and that he, as such, being authorized so to do, executed the foregoing Instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. In Witness Whereof, I hereunto set my hand and official seal. My Commission expires the 30th day of June, 2016. o.t�rq„ �`f� ncuv�..e.. e 3�.�nAa:u9.�t' 'n �tlello * Marie C. Tetreault, Notary Public This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St, Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, which resolutions are now in full force and effect, reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys -in -Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her; and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary; and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory In the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached. I, Kevin E. Hughes, the undersigned, Assistant Secretary, of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, do hereby certify that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 17th day of May , 2016 Kevin E. Hughes, Assistant Secretary Cwv. Slr 4WDW:N)�t g yS rS . aKi • s r • �' AN1 To verify the authenticity of this Power of Attorney, call 1-800-421-3880 or contact us at www.travelersboiid.com. Please refer to the Attorney4h-Fact number, the above-named individuals and the details of the bond to which the power is attached. ALTACON-01 SMAHR CERTIFICATE OF LIABILITY INSURANCE DATE {MMIDD/YYYY)5/6/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such end sement s). PRODUCER ;d �'IVED Boise Office " ' "� PayneWest Insurance, Inc. f uj 960 Broadway Avenue Suite 100 �� Y Q 2016 Boise, ID 83706 CONTACT NAME: PHONE 208 424-2900 AIC, No : 208 424-2999 A/c No Ext: ( ) ( ) A DRI ESS: INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: Trumbull Insurance Company v INSURED Alta Construction, Inc. 619 N. Cloverdale Rd. Boise, ID 83713 INSURER B: Hartford Ins CO Of Midwest g INSURERC: INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE A D INSD S BR WVD POLICY NUMBER POLICY EFF MM/DDIYYYY POLICY EXP MMIDD/YYYY LIMITS A X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE r OCCUR X X 52 UEA GZ7884 01/23/2016 01/23/2017 EACH OCCURRENCE $ 1,000,000 DA ETO RENTED 300 000 PREMISES Ea occurrence $ , MED EXP (Any one person) $ 10,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: POLICY F3q jE 0 LOC OTHER: GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG $ 2,000,000 $ A AUTOMOBILE LIABILITY X ANY AUTO ALL OWNEDSCHEDULED AUTOS AUTOS NON -OWNED HIRED AUTOS AUTOS X X 52 UEA GZ7884 01/23/2016 01/23/2017 COMBINED SINGLE LIMIT Ea accident $ 1,000,000 BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE $ Per accident $ A X UMBRELLA LIAB EXCESS LIAB X OCCUR CLAIMS -MADE 52 UEA GZ7884 01/23/2016 01/23/2017 EACH OCCURRENCE $ 2,000,000 AGGREGATE $ DED I I RETENTION $ $ 2,000,000 B WORKERS COMPENSATIONPER AND EMPLOYERS' LIABILITY Y / N ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? ❑ (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below N / A X 52 WEA 100453 01/23/2016 , 01/23/2017 OTH- X STATUTE X ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE- EA EMPLOYE $ 1,000,000 E.L. DISEASE- POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS/ LOCATIONS /VEHICLES (ACORD 101, Additional Remarks Schedule, maybe attached if more space is required) RE: Project - NW 2ND STREET WATER AND SEWER REPLACEMENT - CONSTRUCTION CGRTIRICATE HOLDER CANCELLATION ACORD 25 (2014/01) ©1988-2014 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Cit of Meridian Y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 33 East Broadway Avenue Meridian, ID 83642 AUTHORIZED REPRESENTATIVE A14— ACORD 25 (2014/01) ©1988-2014 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD • 1 1 1 . 1 • TO Various provisions in this policy restrict coverage. Read the entire policy carefully to determine rights, duties and what is and is not covered. Throughout this policy the words "you" and "your" refer to the Named Insured shown in the Declarations, and any other person or organization qualifying as a Named Insured under this policy. The words "we", "us" and "our" refer to the stock insurance company member of The Hartford providing this insurance. The word "insured" means any person or organization qualifying as such under Section II — Who Is An Insured. Other words and phrases that appear in quotation marks have special meaning. Refer to Section V —Definitions. SECTION I — COVERAGES COVERAGE A BODILY INJURY AND PROPERTY DAMAGE LIABILITY 1. Insuring Agreement a. We will pay those sums that the insured becomes legally obligated to pay as damages because of "bodily injury" or "property damage" to which this insurance applies. We will have the right and duty to defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit" seeking damages for "bodily injury" or "property damage" to which this insurance does not apply. We may, at our discretion, investigate any "occurrence" and settle any claim or "suit" that may result. But: (1) The amount we will pay for damages is limited as described in Section III — Limits Of Insurance; and (2) Our right and duty to defend ends when we have used up the applicable limit of insurance in the payment of judgments or settlements under Coverages A or B or medical expenses under Coverage C. No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Supplementary Payments — Coverages A and B. b. This insurance applies to "bodily injury" and "property damage" only if: (1) The "bodily injury" or "property damage" is caused by an "occurrence" that takes place in the "coverage territory"; (2) The "bodily injury" or "property damage" occurs during the policy period; and (3) Prior to the policy period, no insured listed under Paragraph 1. of Section II — Who Is An Insured and no "employee" authorized by you to give or receive notice of an "occurrence" or claim, knew that the "bodily injury" or "property damage" had occurred, in whole or in part. If such a listed insured or authorized "employee" knew, prior to the policy period, that the "bodily injury" or "property damage" occurred, then any continuation, change or resumption of such "bodily injury" or "property damage" during or after the policy period will be deemed to have been known prior to the policy period. c. "Bodily injury" or "property damage" will be deemed to have been known to have occurred at the earliest time when any insured listed under Paragraph 1. of Section II — Who Is An Insured or any "employee" authorized by you to give or receive notice of an "occurrence" or claim: (1) Reports all, or any part, of the "bodily injury" or "property damage" to us or any other insurer; (2) Receives a written or verbal demand or claim for damages because of the "bodily injury" or "property damage"; or (3) Becomes aware by any other means that "bodily injury" or "property damage" has occurred or has begun to occur. d. Damages because of "bodily injury" include damages claimed by any person or organization for care, loss of services or death resulting at any time from the "bodily injury". e. Incidental Medical Malpractice (1) "Bodily injury" arising out of the rendering of or failure to render professional health care services as a physician, dentist, nurse, emergency medical technician or paramedic shall be deemed to be caused by an "occurrence", but only if: (a) The physician, dentist, nurse, emergency medical technician or paramedic is employed by you to provide such services; and (b) You are not engaged in the business or occupation of providing such services. HG 00 01 06 05 Page 1 of 18 © 2005 The Hartford (Includes copyrighted material of Insurance Services Office, Inc. with its permission.) (2) For the purpose of determining the limits of insurance for incidental medical malpractice, any act or omission together with all related acts or omissions in the furnishing of these services to any one person will be considered one "occurrence". 2. Exclusions This insurance does not apply to: a. Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. b. Contractual Liability "Bodily injury" or "property damage" for which the insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages: (1) That the insured would have in the absence of the contract or agreement; or (2) Assumed in a contract or agreement that is an "insured contract", provided the "bodily injury" or "property damage" occurs subsequent to the execution of the contract or agreement. Solely for the purposes of liability assumed in an "insured contract", reasonable attorney fees and necessary litigation expenses incurred by or for a party other than an insured are deemed to be damages because of "bodily injury" or "property damage", provided: (a) Liability to such party for, or for the cost of, that party's defense has also been assumed in the same "insured contract"; and (b) Such attorney fees and litigation expenses are for defense of that party against a civil or alternative dispute resolution proceeding in which damages to which this insurance applies are alleged. c. Liquor Liability "Bodily injury" or "property damage" for which any insured may be held liable by reason of: (1) Causing or contributing to the intoxication of any person; (2) The furnishing of alcoholic beverages to a person under the legal drinking age or under the influence of alcohol; or (3) Any statute, ordinance or regulation relating to the sale, gift, distribution or use of alcoholic beverages. This exclusion applies only if you are in the business of manufacturing, distributing, selling, serving or furnishing alcoholic beverages. d. Workers' Compensation And Similar Laws Any obligation of the insured under a workers' compensation, disability benefits or unemployment compensation law or any similar law. e. Employer's Liability "Bodily injury" to: (1) An "employee" of the insured arising out of and in the course of: (a) Employment by the insured; or (b) Performing duties related to the conduct of the insured's business; or (2) The spouse, child, parent, brother or sister of that "employee" as a consequence of Paragraph (1) above. This exclusion applies: (1) Whether the insured may be liable as an employer or in any other capacity; and (2) To any obligation to share damages with or repay someone else who must pay damages because of the injury. This exclusion does not apply to liability assumed by the insured under an "insured contract". f. Pollution (1) "Bodily injury" or "property damage" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants": (a) At or from any premises, site or location which is or was at any time owned or occupied by, or rented or loaned to, any insured. However, this subparagraph does not apply to: (i) "Bodily injury" if sustained within a building and caused by smoke, fumes, vapor or soot produced by or originating from equipment that is used to heat, cool or dehumidify the building, or equipment that is used to heat water for personal use, by the building's occupants or their guests; (ii) "Bodily injury" or "property damage" for which you may be held liable, if you are a contractor and the owner or lessee of such premises, site or location has been added to your policy as an additional insured with respect to your ongoing operations performed for that additional insured at that premises, site or location and such premises, site or location is not and never was owned or occupied by, or rented or loaned to, any insured, other than that additional insured; or Page 2 of 18 HG 00 01 06 05 (iii) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; (b) At or from any premises, site or location which is or was at any time used by or for any insured or others for the handling, storage, disposal, processing or treatment of waste; (c) Which are or were at any time transported, handled, stored, treated, disposed of, or processed as waste by or for: (i) Any insured; or (ii) Any person or organization for whom you may be legally responsible; (d) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the "pollutants" are brought on or to the premises, site or location in connection with such operations by such insured, contractor or subcontractor. However, this subparagraph does not apply to: (i) "Bodily injury" or "property damage" arising out of the escape of fuels, lubricants or other operating fluids which are needed to perform the normal electrical, hydraulic or mechanical functions necessary for the operation of "mobile equipment" or its parts, if such fuels, lubricants or other operating fluids escape from a vehicle part designed to hold, store or receive them. This exception does not apply if the "bodily injury" or "property damage" arises out of the intentional discharge, dispersal or release of the fuels, lubricants or other operating fluids, or if such fuels, lubricants or other operating fluids are brought on or to the premises, site or location with the intent that they be discharged, dispersed or released as part of the operations being performed by such insured, contractor or subcontractor; (ii) "Bodily injury" or "property damage" sustained within a building and caused by the release of gases, fumes or vapors from materials brought into that building in connection with operations being performed by you or on your behalf by a contractor or subcontractor; or (iii) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; or (e) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the operations are to test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants". (2) Any loss, cost or expense arising out of any: (a) Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or (b) Claim or suit by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants". However, this paragraph does not apply to liability for damages because of "property damage" that the insured would have in the absence of such request, demand, order or statutory or regulatory requirement, or such claim or "suit" by or on behalf of a governmental authority. g. Aircraft, Auto Or Watercraft "Bodily injury" or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft owned or operated by or rented or loaned to any insured. Use includes operation and "loading or unloading". This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage" involved the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft that is owned or operated by or rented or loaned to any insured. This exclusion does not apply to: (1) A watercraft while ashore on premises you own or rent; (2) A watercraft you do not own that is: (a) Less than 51 feet long; and (b) Not being used to carry persons for a charge; (3) Parking an "auto" on, or on the ways next to, premises you own or rent, provided the "auto" is not owned by or rented or loaned to you or the insured; HG 00 01 06 05 Page 3 of 18 (4) Liability assumed under any "insured contract" for the ownership, maintenance or use of aircraft or watercraft; (5) "Bodily injury" or "property damage" arising out of the operation of any of the equipment listed in Paragraph f.(2) or f.(3) of the definition of "mobile equipment"; or (6) An aircraft that is not owned by any insured and is hired, chartered or loaned with a paid crew. However, this exception does not apply if the insured has any other insurance for such "bodily injury" or "property damage", whether the other insurance is primary, excess, contingent or on any other basis. h. Mobile Equipment "Bodily injury" or "property damage" arising out of: (1) The transportation of "mobile equipment" by an "auto" owned or operated by or rented or loaned to any insured; or (2) The use of "mobile equipment" in, or while in practice for, or while being prepared for, any prearranged racing, speed, demolition, or stunting activity. L War "Bodily injury" or "property damage", however caused, arising, directly or indirectly, out of: (1) War, including undeclared or civil war; (2) Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or (3) Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these. j. Damage To Property "Property damage" to: (1) Property you own, rent, or occupy, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to another's property; (2) Premises you sell, give away or abandon, if the "property damage" arises out of any part of those premises; (3) Property loaned to you; (4) Personal property in the care, custody or control of the insured; (5) That particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the "property damage" arises out of those operations; or (6) That particular part of any property that must be restored, repaired or replaced because "your work" was incorrectly performed on it. Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire) to premises, including the contents of such premises, rented to you for a period of 7 or fewer consecutive days. A separate limit of insurance applies to Damage To Premises Rented To You as described in Section III — Limits Of Insurance. Paragraph (2) of this exclusion does not apply if the premises are "your work" and were never occupied, rented or held for rental by you. Paragraphs (3) and (4) of this exclusion do not apply to "property damage" arising from the use of elevators. Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement. Paragraphs (3) and (4) of this exclusion do not apply to "property damage" to borrowed equipment while not being used to perform operations at the job site. Paragraph (6) of this exclusion does not apply to "property damage" included in the "products - completed operations hazard". k. Damage To Your Product "Property damage" to "your product" arising out of it or any part of it. 1. Damage To Your Work "Property damage" to "your work" arising out of it or any part of it and included in the "products - completed operations hazard". This exclusion does not apply if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor. m. Damage To Impaired Property Or Property Not Physically Injured "Property damage" to "impaired property" or property that has not been physically injured, arising out of: (1) A defect, deficiency, inadequacy or dangerous condition in "your product" or "your work"; or (2) A delay or failure by you or anyone acting on your behalf to perform a contract or agreement in accordance with its terms. This exclusion does not apply to the loss of use of other property arising out of sudden and accidental physical injury to "your product" or "your work" after it has been put to its intended use. Page 4 of 18 HG 00 01 06 05 n. Recall Of Products, Work Or Impaired Property Damages claimed for any loss, cost or expense incurred by you or others for the loss of use, withdrawal, recall, inspection, repair, replacement, adjustment, removal or disposal of: (1) "Your product"; (2) "Your work"; or (3) "Impaired property"; if such product, work, or property is withdrawn or recalled from the market or from use by any person or organization because of a known or suspected defect, deficiency, inadequacy or dangerous condition in it. o. Personal And Advertising Injury "Bodily injury" arising out of "personal and advertising injury". p. Electronic Data Damages arising out of the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate electronic data. As used in this exclusion, electronic data means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software, including systems and applications software, hard or floppy disks, CD- ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. q. Employment -Related Practices "Bodily injury" to: (1) A person arising out of any "employment— related practices"; or (2) The spouse, child, parent, brother or sister of that person as a consequence of "bodily injury" to that person at whom any "employment- related practices" are directed. This exclusion applies: (1) Whether the insured may be liable as an employer or in any other capacity; and (2) To any obligation tc repay someone else because of the injury. r. Asbestos share damages with or who must pay damages (1) "Bodily injury" or "property damage" arising out of the "asbestos hazard". (2) Any damages, judgments, settlements, loss, costs or expenses that: (a) May be awarded or incurred by reason of any claim or suit alleging actual or threatened injury or damage of any nature or kind to persons or property which would not have occurred in whole or in part but for the "asbestos hazard"; (b) Arise out of any request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, encapsulate, contain, treat, detoxify or neutralize or in any way respond to or assess the effects of an "asbestos hazard"; or (c) Arise out of any claim or suit for damages because of testing for, monitoring, cleaning up, removing, encapsulating, containing, treating, detoxifying or neutralizing or in any way responding to or assessing the effects of an "asbestos hazard". Damage To Premises Rented To You — Exception For Damage By Fire, Lightning Or Explosion Exclusions c. through h. and j. through n. do not apply to damage by fire, lightning or explosion to premises while rented to you or temporarily occupied by you with permission of the owner. A separate limit of insurance applies to this coverage as described in Section III — Limits Of Insurance. COVERAGE B PERSONAL AND ADVERTISING INJURY LIABILITY 1. Insuring Agreement a. We will pay those sums that the insured becomes legally obligated to pay as damages because of "personal and advertising injury" to which this insurance applies. We will have the right and duty to defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit' seeking damages for "personal and advertising injury" to which this insurance does not apply. We may, at our discretion, investigate any offense and settle any claim or "suit' that may result. But: (1) The amount we will pay for damages is limited as described in Section III — Limits Of Insurance; and (2) Our right and duty to defend end when we have used up the applicable limit of insurance in the payment of judgments or settlements under Coverages A or B or medical expenses under Coverage C. No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Supplementary Payments — Coverages A and B. b. This insurance applies to "personal and advertising injury" caused by an offense arising out of your business but only if the offense was committed in the "coverage territory" during the policy period. HG 00 01 06 05 Page 5 of 18 2. Exclusions This insurance does not apply to: a. Knowing Violation Of Rights Of Another "Personal and advertising injury" arising out of an offense committed by, at the direction or with the consent or acquiescence of the insured with the expectation of inflicting "personal and advertising injury". b. Material Published With Knowledge Of Falsity "Personal and advertising injury" arising out of oral, written or electronic publication of material, if done by or at the direction of the insured with knowledge of its falsity. c. Material Published Prior To Policy Period "Personal and advertising injury" arising out of oral, written or electronic publication of material whose first publication took place before the beginning of the policy period. d. Criminal Acts "Personal and advertising injury" arising out of a criminal act committed by or at the direction of the insured. e. Contractual Liability "Personal and advertising injury" for which the insured has assumed liability in a contract or agreement. This exclusion does not apply to liability for damages that the insured would have in the absence of the contract or agreement. f. Breach Of Contract "Personal and advertising injury" arising out of a breach of contract, except an implied contract to use another's "advertising idea" in your "advertisement". g. Quality Or Performance Of Goods — Failure To Conform To Statements "Personal and advertising injury" arising out of the failure of goods, products or services to conform with any statement of quality or performance made in your "advertisement". h. Wrong Description Of Prices "Personal and advertising injury" arising out of the wrong description of the price of goods, products or services. i. Infringement Of Intellectual Property Rights "Personal and advertising injury" arising out of any violation of any intellectual property rights such as copyright, patent, trademark, trade name, trade secret, service mark or other designation of origin or authenticity. However, this exclusion does not apply to infringement, in your "advertisement", of: (1) Copyright; (2) Slogan, unless the slogan is also a trademark, trade name, service mark or other designation of origin or authenticity; or (3) Title of any literary or artistic work. Insureds In Media And Internet Type Businesses "Personal and advertising injury" committed by an insured whose business is: (1) Advertising, broadcasting, publishing or telecasting; (2) Designing or determining content of web sites for others; or (3) An Internet search, access, content or service provider. However, this exclusion does not apply to Paragraphs 17.a., b. and c. of "personal and advertising injury" under the Definitions Section. For the purposes of this exclusion, placing an "advertisement" for or linking to others on your web site, by itself, is not considered the business of advertising, broadcasting, publishing or telecasting. k. Electronic Chatrooms Or Bulletin Boards "Personal and advertising injury" arising out of an electronic chatroom or bulletin board the insured hosts, owns, or over which the insured exercises control. I. Unauthorized Use Of Another's Name Or Product "Personal and advertising injury" arising out of the unauthorized use of another's name or product in your e-mail address, domain name or metatags, or any other similar tactics to mislead another's potential customers. m. Pollution "Personal and advertising injury" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "'pollutants" at any time. n. Pollution -Related Any loss, cost or expense arising out of any: (1) Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or (2) Claim or suit by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants". Page 6 of 18 HG 00 01 06 05 o. War "Personal and advertising injury", however caused, arising, directly or indirectly, out of: (1) War, including undeclared or civil war; (2) Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or (3) Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these. p. Internet Advertisements And Content Of Others "Personal and advertising injury" arising out of: (1) An "advertisement" for others on your web site; (2) Placing a link to a web site of others on your web site; (3) Content, including information, sounds, text, graphics, or images from a web site of others displayed within a frame or border on your web site; or (4) Computer code, software or programming used to enable: (a) Your web site; or (b) The presentation or functionality of an "advertisement" or other content on your web site. q. Right Of Privacy Created By Statute "Personal and advertising injury" arising out of the violation of a person's right of privacy created by any state or federal act. However, this exclusion does not apply to liability for damages that the insured would have in the absence of such state or federal act. r. Violation Of Anti -Trust law "Personal and advertising injury" arising out of a violation of any anti-trust law. S. Securities "Personal and advertising injury" arising out of the fluctuation in price or value of any stocks, bonds or other securities. t. Discrimination Or Humiliation "Personal and advertising injury" arising out of discrimination or humiliation committed by or at the direction of any "executive officer", director, stockholder, partner or member of the insured. u. Employment -Related Practices "Personal and advertising injury" to: (1) A person arising out of any "employment— related practices"; or (2) The spouse, child, parent, brother or sister of that person as a consequence of "personal and advertising injury" to that person at whom any "employment-related practices" are directed. This exclusion applies: (1) Whether the insured may be liable as an employer or in any other capacity; and (2) To any obligation to share damages with or repay someone else who must pay damages because of the injury. v. Asbestos (1) "Personal and advertising injury" arising out of the "asbestos hazard". (2) Any damages, judgments, settlements, loss, costs or expenses that: (a) May be awarded or incurred by reason of any claim or suit alleging actual or threatened injury or damage of any nature or kind to persons or property which would not have occurred in whole or in part but for the "asbestos hazard"; (b) Arise out of any request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, encapsulate, contain, treat, detoxify or neutralize or in any way respond to or assess the effects of an "asbestos hazard"; or (c) Arise out of any claim or suit for damages because of testing for, monitoring, cleaning up, removing, encapsulating, containing, treating, detoxifying or neutralizing or in any way responding to or assessing the effects of an "asbestos hazard". COVERAGE C MEDICAL PAYMENTS 1. Insuring Agreement a. We will pay medical expenses as described below for "bodily injury" caused by an accident: (1) On premises you own or rent; (2) On ways next to premises you own or rent; or (3) Because of your operations; provided that: (1) The accident takes place in the "coverage territory" and during the policy period; (2) The expenses are incurred and reported to us within three years of the date of the accident; and (3) The injured person submits to examination, at our expense, by physicians of our choice as often as we reasonably require. HG 00 01 06 05 Page 7 of 18 b. We will make these payments regardless of fault. These payments will not exceed the applicable limit of insurance. We will pay reasonable expenses for: (1) First aid administered at the time of an accident; (2) Necessary medical, surgical, x-ray and dental services, including prosthetic devices; and (3) Necessary ambulance, hospital, professional nursing and funeral services. 2. Exclusions We will not pay expenses for "bodily injury": a. Any Insured To any insured, except "volunteer workers". b. Hired Person To a person hired to do work for or on behalf of any insured or a tenant of any insured. c. Injury On Normally Occupied Premises To a person injured on that part of premises you own or rent that the person normally occupies. d. Workers Compensation And Similar Laws To a person, whether or not an "employee" of any insured, if benefits for the "bodily injury" are payable or must be provided under a workers' compensation or disability benefits law or a similar law. e. Athletics Activities To a person injured while practicing, instructing or participating in any physical exercises or games, sports, or athletic contests. f. Products -Completed Operations Hazard Included within the "products -completed operations hazard". g. Coverage A Exclusions Excluded under Coverage A. SUPPLEMENTARY PAYMENTS — COVERAGES A AND B 1. We will pay, with respect to any claim we investigate or settle, or any "suit" against an insured we defend: a. All expenses we incur. b. Up to $1,000 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. c. The cost of appeal bonds or bonds to release attachments, but only for bond amounts within the applicable limit of insurance. We do not have to furnish these bonds. d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. e. All costs taxed against the insured in the "suit". f. Prejudgment interest awarded against the insured on that part of the judgment we pay. If we make an offer to pay the applicable limit of insurance, we will not pay any prejudgment interest based on that period of time after the offer. g. All interest on the full amount of any judgment that accrues after entry of the judgment and before we have paid, offered to pay, or deposited in court the part of the judgment that is within the applicable limit of insurance. These payments will not reduce the limits of insurance. 2. If we defend an insured against a "suit" and an indemnitee of the insured is also named as a party to the "suit", we will defend that indemnitee if all of the following conditions are met: a. The "suit" against the indemnitee seeks damages for which the insured has assumed the liability of the indemnitee in a contract or agreement that is an "insured contract"; b. This insurance applies to such liability assumed by the insured; c. The obligation to defend, or the cost of the defense of, that indemnitee, has also been assumed by the insured in the same "insured contract"; d. The allegations in the "suit" and the information we know about the "occurrence" are such that no conflict appears to exist between the interests of the insured and the interests of the indemnitee; e. The indemnitee and the insured ask us to conduct and control the defense of that indemnitee against such "suit" and agree that we can assign the same counsel to defend the insured and the indemnitee; and f. The indemnitee: (1) Agrees in writing to: (a) Cooperate with us in the investigation, settlement or defense of the "suit"; (b) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the "suit"; (c) Notify any other insurer whose coverage is available to the indemnitee; and (d) Cooperate with us with respect to coordinating other applicable insurance available to the indemnitee; and (2) Provides us with written authorization to: (a) Obtain records and other information related to the "suit"; and (b) Conduct and control the defense of the indemnitee in such "suit". So long as the above conditions are met, attorneys' fees incurred by us in the defense of that indemnitee, Page 8 of 18 HG 00 01 06 05 necessary litigation expenses incurred by us and necessary litigation expenses incurred by the indemnitee at our request will be paid as Supplementary Payments. Notwithstanding the provisions of Paragraph 2.b.(2) of Section I — Coverage A — Bodily Injury And Property Damage Liability, such payments will not be deemed to be damages for "bodily injury" and "property damage" and will not reduce the limits of insurance. Our obligation to defend an insured's indemnitee and to pay for attorneys' fees and necessary litigation expenses as Supplementary Payments ends when: a. We have used up the applicable limit of insurance in the payment of judgments or settlements; or b. The conditions set forth above, or the terms of the agreement described in Paragraph f. above, are no longer met. SECTION II —WHO IS AN INSURED 1. If you are designated in the Declarations as: a. An individual, you and your spouse are insureds, but only with respect to the conduct of a business of which you are the sole owner. b. A partnership or joint venture, you are an insured. Your members, your partners, and their spouses are also insureds, but only with respect to the conduct of your business. c. A limited liability company, you are an insured. Your members are also insureds, but only with respect to the conduct of your business. Your managers are insureds, but only with respect to their duties as your managers. d. An organization other than a partnership, joint venture or limited liability company, you are an insured. Your "executive officers" and directors are insureds, but only with respect to their duties as your officers or directors. Your stockholders are also insureds, but only with respect to their liability as stockholders. e. A trust, you are an insured. Your trustees are also insureds, but only with respect to their duties as trustees. 2. Each of the following is also an insured: a. Employees and Volunteer workers Your "volunteer workers" only while performing duties related to the conduct of your business, or your "employees", other than either your "executive officers" (if you are an organization other than a partnership, joint venture or limited liability company) or your managers (if you are a limited liability company), but only for acts within the scope of their employment by you or while performing duties related to the conduct of your business. However, none of these "employees" or "volunteer workers" are insureds for: (1) "Bodily injury" or "personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), to a co -"employee" while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co -"employee" or that "volunteer worker" as a consequence of Paragraph (1)(a) above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1)(a) or (b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. If you are not in the business of providing professional health care services, Paragraph (d) does not apply to any nurse, emergency medical technician or paramedic employed by you to provide such services. (2) "Property damage" to property: (a) Owned, occupied or used by, (b) Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or any member (if you are a limited liability company). b. Real Estate Manager Any person (other than your "employee" or "volunteer worker"), or any organization while acting as your real estate manager. c. Temporary Custodians of Your Property Any person or organization having proper temporary custody of your property if you die, but only: (1) With respect to liability arising out of the maintenance or use of that property; and (2) Until your legal representative has been appointed. d. Legal Representative If You Die Your legal representative if you die, but only with respect to duties as such. That representative will HG 00 01 06 05 Page 9 of 18 have all your rights and duties under this Coverage Part. e. Unnamed Subsidiary Any subsidiary, and subsidiary thereof, of yours which is a legally incorporated entity of which you own a financial interest of more than 50% of the voting stock on the effective date of the Coverage Part. The insurance afforded herein for any subsidiary not named in this Coverage Part as a named insured does not apply to injury or damage with respect to which an insured under this Coverage Part is also an insured under another policy or would be an insured under such policy but for its termination or the exhaustion of its limits of insurance. 3. Newly Acquired or Formed Organization Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and over which you maintain financial interest of more than 50% of the voting stock, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier; b. Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization; and c. Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. 4. Mobile Equipment With respect to "mobile equipment" registered in your name under any motor vehicle registration law, any person is an insured while driving such equipment along a public highway with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the equipment, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person driving the equipment; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. S. Nonowned Watercraft With respect to watercraft you do not own that is less than 51 feet long and is not being used to carry persons for a charge, any person is an insured while operating such watercraft with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the watercraft, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co -"employee" of the person operating the watercraft; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 6. Additional Insureds When Required By Written Contract, Written Agreement Or Permit The following person(s) or organization(s) are an additional insured when you have agreed, in a written contract, written agreement or because of a permit issued by a state or political subdivision, that such person or organization be added as an additional insured on your policy, provided the injury or damage occurs subsequent to the execution of the contract or agreement. A person or organization is an additional insured under this provision only for that period of time required by the contract or agreement. However, no such person or organization is an insured under this provision if such person or organization is included as an insured by an endorsement issued by us and made a part of this Coverage Part. a. Vendors Any person(s) or organization(s) (referred to below as vendor), but only with respect to "bodily injury" or "property damage" arising out of "your products" which are distributed or sold in the regular course of the vendor's business and only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products - completed operations hazard". (1) The insurance afforded the vendor is subject to the following additional exclusions: This insurance does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; Page 10 of 18 HG 00 01 06 05 (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor; (d) Repackaging, except when unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container; (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: (i) The exceptions contained in Sub- paragraphs (d) or (f); or (ii) Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization, from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. b. Lessors of Equipment (1) Any person or organization from whom you lease equipment; but only with respect to their liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person or organization. (2) With respect to the insurance afforded to these additional insureds this insurance does not apply to any "occurrence" which takes place after the equipment lease expires. c. Lessors of Land or Premises Any person or organization from whom you lease land or premises, but only with respect to liability arising out of the ownership, maintenance or use of that part of the land or premises leased to you. With respect to the insurance afforded these additional insureds the following additional exclusions apply: This insurance does not apply to: 1. Any "occurrence" which takes place after you cease to lease that land; or 2. Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. d. Architects, Engineers or Surveyors Any architect, engineer, or surveyor, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In connection with your premises; or (2) In the performance of your ongoing operations performed by you or on your behalf. With respect to the insurance afforded these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or the failure to render any professional services by or for you, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or 2. Supervisory, inspection, architectural or engineering activities. e. Permits Issued By State Or Political Subdivisions Any state or political subdivision, but only with respect to operations performed by you or on your behalf for which the state or political subdivision has issued a permit. With respect to the insurance afforded these additional insureds, this insurance does not apply to: (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the state or municipality; or, (2) "Bodily injury" or "property damage" included within the "products -completed operations hazard". HG 00 01 06 05 Page 11 of 18 f. Any Other Party Any other person or organization who is not an insured under Paragraphs a. through e. above, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In the performance of your ongoing operations; (2) In connection with your premises owned by or rented to you; or (3) In connection with "your work" and included within the "products -completed operations hazard", but only if (a) The written contract or agreement requires you to provide such coverage to such additional insured; and (b) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". With respect to the insurance afforded to these additional insureds, this insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. The limits of insurance that apply to additional insureds under this provision is described in Section III — Limits Of Insurance. How this insurance applies when other insurance is available to the additional insured is described in the Other Insurance Condition in Section IV — Commercial General Liability Conditions. No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations. SECTION III — LIMITS OF INSURANCE 1. The Most We will Pay The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 2. General Aggregate Limit The General Aggregate Limit is the most we will pay for the sum of: a. Medical expenses under Coverage C; b. Damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products -completed operations hazard"; and c. Damages under Coverage B. 3. Products -Completed Operations Aggregate Limit The Products -Completed Operations Aggregate Limit is the most we will pay under Coverage A for damages because of "bodily injury" and "property damage" included in the "products -completed operations hazard". 4. Personal and Advertising Injury Limit Subject to 2. above, the Personal and Advertising Injury Limit is the most we will pay under Coverage B for the sum of all damages because of all "personal and advertising injury" sustained by any one person or organization. 5. Each Occurrence Limit Subject to 2. or 3. above, whichever applies, the Each Occurrence Limit is the most we will pay for the sum of: a. Damages under Coverage A; and b. Medical expenses under Coverage C because of all "bodily injury" and "property damage" arising out of any one "occurrence". 6. Damage To Premises Rented To You Limit Subject to 5. above, the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of "property damage" to any one premises, while rented to you, or in the case of damage by fire, lightning or explosion, while rented to you or temporarily occupied by you with permission of the owner. In the case of damage by fire, lightning or explosion, the Damage to Premises Rented To You Limit applies to all damage proximately caused by the same event, whether such damage results from fire, lightning or explosion or any combination of these. 7. Medical Expense Limit Subject to 5. above, the Medical Expense Limit is the most we will pay under Coverage C for all medical expenses because of "bodily injury" sustained by any one person. 8. How Limits Apply To Additional Insureds If you have agreed in a written contract or written agreement that another person or organization be Page 12 of 18 HG 00 01 06 05 added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: a. The limits of insurance specified in the written contract or written agreement; or b. The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. The Limits of Insurance of this Coverage Part apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for purposes of determining the Limits of Insurance. SECTION IV — COMMERCIAL GENERAL LIABILITY CONDITIONS 1. Bankruptcy Bankruptcy or insolvency of the insured or of the insured's estate will not relieve us of our obligations under this Coverage Part. 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit a. Notice Of Occurrence Or Offense You or any additional insured must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. To the extent possible, notice should include: (1) How, when and where the "occurrence" or offense took place; (2) The names and addresses of any injured persons and witnesses; and (3) The nature and location of any injury or damage arising out of the "occurrence" or offense. b. Notice Of Claim If a claim is made or "suit" is brought against any insured, you or any additional insured must: (1) Immediately record the specifics of the claim or "suit" and the date received; and (2) Notify us as soon as practicable. You or any additional insured must see to it that we receive written notice of the claim or "suit" as soon as practicable. c. Assistance And Cooperation Of The Insured You and any other involved insured must: (1) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or "suit"; (2) Authorize us to obtain records and other information; (3) Cooperate with us in the investigation or settlement of the claim or defense against the "suit"; and (4) Assist us, upon our request, in the enforcement of any right against any person or organization which may be liable to the insured because of injury or damage to which this insurance may also apply. d. Obligations At The Insureds Own Cost No insured will, except at that insured's own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent. e. Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance. f. Knowledge Of An Occurrence, Offense, Claim Or Suit Paragraphs a. and b. apply to you or to any additional insured only when such "occurrence", offense, claim or "suit" is known to: (1) You or any additional insured that is an individual; (2) Any partner, if you or an additional insured is a partnership; (3) Any manager, if you or an additional insured is a limited liability company; (4) Any "executive officer" or insurance manager, if you or an additional insured is a corporation; (5) Any trustee, if you or an additional insured is a trust; or (6) Any elected or appointed official, if you or an additional insured is a political subdivision or public entity. This duty applies separately to you and any additional insured. 3. Legal Action Against Us No person or organization has a right under this Coverage Part: a. To join us as a party or otherwise bring us into a "suit" asking for damages from an insured; or b. To sue us on this Coverage Part unless all of its terms have been fully complied with. A person or organization may sue us to recover on an agreed settlement or on a final judgment against an insured; but we will not be liable for damages that are not payable under the terms of this Coverage Part or HG 00 01 06 05 Page 13 of 18 that are in excess of the applicable limit of insurance. An agreed settlement means a settlement and release of liability signed by us, the insured and the claimant or the claimant's legal representative. 4. Other Insurance If other valid and collectible insurance is available to the insured for a loss we cover under Coverages A or B of this Coverage Part, our obligations are limited as follows: a. Primary Insurance This insurance is primary except when b. below applies. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. b. Excess Insurance This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis: (1) Your Work That is Fire, Extended Coverage, Builder's Risk, Installation Risk or similar coverage for "your work"; (2) Premises Rented To You That is fire, lightning or explosion insurance for premises rented to you or temporarily occupied by you with permission of the owner; (3) Tenant Liability That is insurance purchased by you to cover your liability as a tenant for "property damage" to premises rented to you or temporarily occupied by you with permission of the owner; (4) Aircraft, Auto Or Watercraft If the loss arises out of the maintenance or use of aircraft, "autos" or watercraft to the extent not subject to Exclusion g. of Section I — Coverage A — Bodily Injury And Property Damage Liability; (5) Property Damage to Borrowed Equipment Or Use Of Elevators If the loss arises out of "property damage" to borrowed equipment or the use of elevators to the extent not subject to Exclusion j. of Section - Coverage A - Bodily Injury And Property Damage Liability; (6) When You Are Added As An Additional Insured To Other Insurance Any other insurance available to you covering liability for damages arising out of the premises or operations, or products and completed operations, for which you have been added as an additional insured by that insurance; or (7) When You Add Others As An Additional Insured To This Insurance Any other insurance available to an additional insured. However, the following provisions apply to other insurance available to any person or organization who is an additional insured under this coverage part. (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. (b) Primary And Non -Contributory To Other Insurance When Required By Contract If you have agreed in a written contract, written agreement, or permit that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (a) and (b) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty under Coverages A or B to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self-insured amounts under all that other insurance. We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part. c. Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. Page 14 of 18 HG 00 01 06 05 If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. 5. Premium Audit a. We will compute all premiums for this Coverage Part in accordance with our rules and rates. b. Premium shown in this Coverage Part as advance premium is a deposit premium only. At the close of each audit period we will compute the earned premium for that period and send notice to the first Named Insured. The due date for audit and retrospective premiums is the date shown as the due date on the bill. If the sum of the advance and audit premiums paid for the policy period is greater than the earned premium, we will return the excess to the first Named Insured. c. The first Named Insured must keep records of the information we need for premium computation, and send us copies at such times as we may request. 6. Representations a. When You Accept This Policy By accepting this policy, you agree: (1) The statements in the Declarations are accurate and complete; (2) Those statements are based upon representations you made to us; and (3) We have issued this policy in reliance upon your representations. b. Unintentional Failure To Disclose Hazards If unintentionally you should fail to disclose all hazards relating to the conduct of your business that exist at the inception date of this Coverage Part, we shall not deny coverage under this Coverage Part because of such failure. 7. Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Coverage Part to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom claim is made or "suit" is brought. 8. Transfer Of Rights Of Recovery Against Others To Us a. Transfer of Rights Of Recovery If the insured has rights to recover all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. b. Waiver Of Rights Of Recovery (Waiver Of Subrogation) If the insured has waived any rights of recovery against any person or organization for all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, we also waive that right, provided the insured waived their rights of recovery against such person or organization in a contract, agreement or permit that was executed prior to the injury or damage. 9. When We Do Not Renew If we decide not to renew this Coverage Part, we will mail or deliver to the first Named Insured shown in the Declarations written notice of the nonrenewal not less than 30 days before the expiration date. If notice is mailed, proof of mailing will be sufficient proof of notice. SECTION V — DEFINITIONS 1. "Advertisement" means the widespread public dissemination of information or images that has the purpose of inducing the sale of goods, products or services through: a. (1) Radio; (2) Television; (3) Billboard; (4) Magazine; (5) Newspaper; or b. Any other publication that is given widespread public distribution. However, "advertisement" does not include: a. The design, printed material, information or images contained in, on or upon the packaging or labeling of any goods or products; or b. An interactive conversation between or among persons through a computer network. 2. "Advertising idea" means any idea for an "advertisement". 3. "Asbestos hazard" means an exposure or threat of exposure to the actual or alleged properties of asbestos and includes the mere presence of asbestos in any form. 4. "Auto" means a land motor vehicle, trailer or semitrailer designed for travel on public roads, including any attached machinery or equipment. But "auto" does not include "mobile equipment". 5. "Bodily injury" means physical: a. Injury; b. Sickness; or c. Disease sustained by a person and, if arising out of the above, mental anguish or death at any time. HG 00 01 06 05 Page 15 of 18 6. "Coverage territory" means: a. The United States of America (including its territories and possessions), Puerto Rico and Canada; b. International waters or airspace, but only if the injury or damage occurs in the course of travel or transportation between any places included in a. above; or c. All other parts of the world if the injury or damage arises out of: (1) Goods or products made or sold by you in the territory described in a. above; (2) The activities of a person whose home is in the territory described in a. above, but is away for a short time on your business; or (3) "Personal and advertising injury" offenses that take place through the Internet or similar electronic means of communication provided the insured's responsibility to pay damages is determined in the United States of America (including its territories and possessions), Puerto Rico or Canada, in a "suit" on the merits according to the substantive law in such territory or in a settlement we agree to. 7. "Employee" includes a "leased worker". "Employee" does not include a "temporary worker". 8. "Employment -Related Practices" means: a. Refusal to employ a person; b. Termination of a person's employment; or c. Employment-related practices, policies, acts or omissions, such as coercion, demotion, evaluation, reassignment, discipline, defamation, harassment, humiliation or discrimination directed at a person. 9. "Executive officer" means a person holding any of the officer positions created by your charter, constitution, by-laws or any other similar governing document. 10. "Hostile fire" means one which becomes uncontrollable or breaks out from where it was intended to be. 11. "Impaired property" means tangible property, other than "your product" or "your work", that cannot be used or is less useful because: a. It incorporates "your product" or "your work" that is known or thought to be defective, deficient, inadequate or dangerous; or b. You have failed to fulfill the terms of a contract or agreement; if such property can be restored to use by: a. The repair, replacement, adjustment or removal of "your product" or "your work"; or b. Your fulfilling the terms of the contractor agreement. 12. "Insured contract" means: a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning or explosion to premises while rented to you or temporarily occupied by you with permission of the owner is subject to the Damage to Premises Rented To You Limit described in Section III — Limits of Insurance; b. A sidetrack agreement; c. Any easement or license agreement, including an easement or license agreement in connection with construction or demolition operations on or within 50 feet of a railroad; d. An obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality; e. An elevator maintenance agreement; f. That part of any other contract or agreement pertaining to your business (including an indemnification of a municipality in connection with work performed for a municipality) under which you assume the tort liability of another party to pay for "bodily injury" or "property damage" to a third person or organization, provided the "bodily injury" or "property damage" is caused, in whole or in part, by you or by those acting on your behalf. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement. Paragraph f. includes that part of any contract or agreement that indemnifies a railroad for "bodily injury" or "property damage" arising out of construction or demolition operations, within 50 feet of any railroad property and affecting any railroad bridge or trestle, tracks, road -beds, tunnel, underpass or crossing. However, Paragraph f. does not include that part of any contract or agreement: (1) That indemnifies an architect, engineer or surveyor for injury or damage arising out of: (a) Preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (b) Giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage; or (2) Under which the insured, if an architect, engineer or surveyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in (1) above and supervisory, inspection, architectural or engineering activities. 13. "Leased worker" means a person leased to you by a labor leasing firm under an agreement between you and the labor leasing firm, to perform duties related to the conduct of your business. "Leased worker" does not include a "temporary worker". 14."Loading or unloading" means the handling of property: a. After it is moved from the place where it is accepted for movement into or onto an aircraft, watercraft or "auto"; Page 16 of 18 HG 00 01 06 05 b. While it is in or on an aircraft, watercraft or "auto"; or c. While it is being moved from an aircraft, watercraft or "auto" to the place where it is finally delivered; but "loading or unloading" does not include the movement of property by means of a mechanical device, other than a hand truck, that is not attached to the aircraft, watercraft or "auto". 15."Mobile equipment" means any of the following types of land vehicles, including any attached machinery or equipment: a. Bulldozers, farm machinery, forklifts and other vehicles designed for use principally off public roads; b. Vehicles maintained for use solely on or next to premises you own or rent; c. Vehicles that travel on crawler treads; d. Vehicles, whether self-propelled or not, maintained primarily to provide mobility to permanently mounted: (1) Power cranes, shovels, loaders, diggers or drills; or (2) Road construction or resurfacing equipment such as graders, scrapers or rollers; e. Vehicles not described in a., b., c. or d. above that are not self-propelled and are maintained primarily to provide mobility to permanently attached equipment of the following types: (1) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment; or (2) Cherry pickers and similar devices used to raise or lower workers; f. Vehicles not described in a., b., c. or d. above maintained primarily for purposes other than the transportation of persons or cargo. However, self-propelled vehicles with the following types of permanently attached equipment are not "mobile equipment" but will be considered "autos": (1) Equipment, of at least 1,000 pounds gross vehicle weight, designed primarily for: (a) Snow removal; (b) Road maintenance, but not construction or resurfacing; or (c) Street cleaning; (2) Cherry pickers and similar devices mounted on automobile or truck chassis and used to raise or lower workers; and (3) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment. 16."Occurrence" means an accident, including continuous or repeated exposure to substantially the same general harmful conditions. 17. "Personal and advertising injury" means injury, including consequential "bodily injury", arising out of one or more of the following offenses: a. False arrest, detention or imprisonment; b. Malicious prosecution; c. The wrongful eviction from, wrongful entry into, or invasion of the right of private occupancy of a room, dwelling or premises that a person occupies, committed by or on behalf of its owner, landlord or lessor; d. Oral, written or electronic publication of material that slanders or libels a person or organization or disparages a person's or organization's goods, products or services; e. Oral, written or electronic publication of material that violates a person's right of privacy; f. Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement"; g. Infringement of copyright, slogan, or title of any literary or artistic work, in your "advertisement'; or h. Discrimination or humiliation that results in injury to the feelings or reputation of a natural person. 18."Pollutants" mean any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapor, soot, fumes, acids, alkalis, chemicals and waste. Waste includes materials to be recycled, reconditioned or reclaimed. 19. "Products -completed operations hazard": a. Includes all "bodily injury" and "property damage" occurring away from premises you own or rent and arising out of "your product" or "your work" except: (1) Products that are still in your physical possession; or (2) Work that has not yet been completed or abandoned. However, "your work" will be deemed completed at the earliest of the following times: (a) When all of the work called for in your contract has been completed. (b) When all of the work to be done at the job site has been completed if your contract calls for work at more than one job site. (c) When that part of the work done at a job site has been put to its intended use by any person or organization other than another contractor or subcontractor working on the same project. Work that may need service, maintenance, correction, repair or replacement, but which is otherwise complete, will be treated as completed. HG 00 01 06 05 Page 17 of 18 b. Does not include "bodily injury" or "property damage" arising out of: (1) The transportation of property, unless the injury or damage arises out of a condition in or on a vehicle not owned or operated by you, and that condition was created by the "loading or unloading" of that vehicle by any insured; (2) The existence of tools, uninstalled equipment or abandoned or unused materials; or (3) Products or operations for which the classification, listed in the Declarations or in a policy schedule, states that products - completed operations are subject to the General Aggregate Limit. 20. "Property damage" means: a. Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use shall be deemed to occur at the time of the physical injury that caused it; or b. Loss of use of tangible property that is not physically injured. All such loss of use shall be deemed to occur at the time of the 'occurrence" that caused it. As used in this definition, computerized or electronically stored data, programs or software are not tangible property. Electronic data means information, facts or programs: a. Stored as or on; b. Created or used on; or c. Transmitted to or from; computer software, including systems and applications software, hard or floppy disks, CD- ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. 21. "Suit" means a civil proceeding in which damages because of "bodily injury", "property damage" or "personal and advertising injury" to which this insurance applies are alleged. "Suit" includes: a. An arbitration proceeding in which such damages are claimed and to which the insured must submit or does submit with our consent; or b. Any other alternative dispute resolution proceeding in which such damages are claimed and to which the insured submits with our consent. 22. "Temporary worker" means a person who is furnished to you to substitute for a permanent "employee" on leave or to meet seasonal or short- term workload conditions. 23. "Volunteer worker" means a person who a. Is not your "employee"; b. Donates his or her work; c. Acts at the direction of and within the scope of duties determined by you; and d. Is not paid a fee, salary or other compensation by you or anyone else for their work performed for you. 24. "Your product": a. Means: (1) Any goods or products, other than real property, manufactured, sold, handled, distributed or disposed of by: (a) You; (b) Others trading under your name; or (c) A person or organization whose business or assets you have acquired; and (2) Containers (other than vehicles), materials, parts or equipment furnished in connection with such goods or products. b. Includes (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your product"; and (2) The providing of or failure to provide warnings or instructions. c. Does not include vending machines or other property rented to or located for the use of others but not sold. 25. "Your work": a. Means: (1) Work or operations performed by you or on your behalf; and (2) Materials, parts or equipment furnished in connection with such work or operations. b. Includes (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your work", and (2) The providing of or failure to provide warnings or instructions. Page 18 of 18 HG 00 01 06 05 COMMERCIAL AUTOMOBILE HA 99 16 03 12 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. • • • : ' • ! s �I_Z•T:� & : k A: Q1 k I This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM To the extent that the provisions of this endorsement provide broader benefits to the "insured" than other provisions of the Coverage Form, the provisions of this endorsement apply. 1. BROAD FORM INSURED d. Any "employee" of yours while using a A. Subsidiaries and Newly Acquired or covered "auto" you don't own, hire or Formed Organizations borrow in your business or your The Named Insured shown in the personal affairs. Declarations is amended to include: C. Lessors as Insureds (1) Any legal business entity other than a Paragraph A.1. - WHO IS AN INSURED - of partnership or joint venture, formed as a Section II - Liability Coverage is amended to subsidiary in which you have an add: ownership interest of more than 50% on e. The lessor of a covered "auto" while the the effective date of the Coverage Form. "auto" is leased to you under a written However, the Named Insured does not agreement if: include any subsidiary that is an (1) The agreement requires you to "insured" under any other automobile "insured" provide direct primary insurance for policy or would be an under the lessor and such a policy but for its termination or the exhaustion of its Limit of Insurance. (2) The "auto" is leased without a driver. (2) Any organization that is acquired or Such a leased "auto" will be considered a formed by you and over which you covered "auto" you own and not a covered maintain majority ownership. However, "auto" you hire. the Named Insured does not include any D. Additional Insured if Required by Contract newly formed or acquired organization: (1) Paragraph A.1. - WHO IS AN INSURED (a) That is a partnership or joint - of Section II - Liability Coverage is venture, amended to add: (b) That is an "insured" under any other f. When you have agreed, in a written policy, contract or written agreement, that a (c) That has exhausted its Limit of person or organization be added as Insurance under any other policy, or an additional insured on your (d) 180 days or more after its business auto policy, such person or acquisition or formation by you, organization is an "insured", but only unless you have given us notice of to the extent such person or the acquisition or formation. organization is liable for "bodily Coverage does not apply to "bodily injury" or "property damage" caused injury" or "property damage" that results by the conduct of an "insured" under from an "accident" that occurred before paragraphs a. or b. of Who Is An you formed or acquired the organization. Insured with regard to the ownership, maintenance or use of a B. Employees as Insureds covered auto. Paragraph A.1. - WHO IS AN INSURED - of SECTION II - LIABILITY COVERAGE is amended to add: © 2011, The Hartford (Includes copyrighted material Form HA 99 16 0312 of ISO Properties, Inc., with its permission.) Page 1 of 5 The insurance afforded to any such additional insured applies only if the "bodily injury" or "property damage" occurs: (1) During the policy period, and (2) Subsequent to the execution of such written contract, and (3) Prior to the expiration of the period of time that the written contract requires such insurance be provided to the additional insured. (2) How Limits Apply If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: (a) The limits of insurance specified in the written contract or written agreement; or (b) The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. (3) Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non- contributory with the additional insured's own insurance. (4) Duties in The Event Of Accident, Claim, Suit or Loss If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the additional insured shall be required to comply with the provisions in LOSS CONDITIONS 2. - DUTIES IN THE EVENT OF ACCIDENT, CLAIM , SUIT OR LOSS — OF SECTION IV — BUSINESS AUTO CONDITIONS, in the same manner as the Named Insured. E. Primary and Non -Contributory if Required by Contract Only with respect to insurance provided to an additional insured in I.D. - Additional Insured If Required by Contract, the following provisions apply: (3) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in Other Insurance 5.d. (4) Primary And Non -Contributory To Other Insurance When Required By Contract If you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (3) and (4) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self-insured amounts under all that other insurance. We will share the remaining loss, if any, by the method described in Other Insurance 5.d. 2. AUTOS RENTED BY EMPLOYEES Any "auto" hired or rented by your "employee" on your behalf and at your direction will be considered an "auto" you hire. The OTHER INSURANCE Condition is amended by adding the following: © 2011, The Hartford (Includes copyrighted material Form HA 9916 0312 of ISO Properties, Inc., with its permission.) Page 2 of 5 If an "employee's" personal insurance also applies on an excess basis to a covered "auto" hired or rented by your "employee" on your behalf and at your direction, this insurance will be primary to the "employee's" personal insurance. 3. AMENDED FELLOW EMPLOYEE EXCLUSION EXCLUSION 5. - FELLOW EMPLOYEE - of SECTION II - LIABILITY COVERAGE does not apply if you have workers' compensation insurance in -force covering all of your "employees". Coverage is excess over any other collectible insurance. 4. HIRED AUTO PHYSICAL DAMAGE COVERAGE If hired "autos" are covered "autos" for Liability Coverage and if Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form for any "auto" you own, then the Physical Damage Coverages provided are extended to "autos" you hire or borrow, subject to the following limit. The most we will pay for "loss" to any hired "auto" is: (1) $100,000; (2) The actual cash value of the damaged or stolen property at the time of the "loss"; or (3) The cost of repairing or replacing the damaged or stolen property, whichever is smallest, minus a deductible. The deductible will be equal to the largest deductible applicable to any owned "auto" for that coverage. No deductible applies to "loss" caused by fire or lightning. Hired Auto Physical Damage coverage is excess over any other collectible insurance. Subject to the above limit, deductible and excess provisions, we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own. We will also cover loss of use of the hired "auto" if it results from an "accident", you are legally liable and the lessor incurs an actual financial loss, subject to a maximum of $1000 per "accident". This extension of coverage does not apply to any "auto" you hire or borrow from any of your "employees", partners (if you are a partnership), members (if you are a limited liability company), or members of their households. 5. PHYSICAL DAMAGE - ADDITIONAL TEMPORARY TRANSPORTATION EXPENSE COVERAGE Paragraph AA.a. of SECTION III - PHYSICAL DAMAGE COVERAGE is amended to provide a limit of $50 per day and a maximum limit of $1,000. 6. LOAN/LEASE GAP COVERAGE Under SECTION III - PHYSICAL DAMAGE COVERAGE, in the event of a total "loss" to a covered "auto", we will pay your additional legal obligation for any difference between the actual cash value of the "auto" at the time of the "loss" and the "outstanding balance" of the loan/lease. "Outstanding balance" means the amount you owe on the loan/lease at the time of "loss" less any amounts representing taxes; overdue payments; penalties, interest or charges resulting from overdue payments; additional mileage charges; excess wear and tear charges; lease termination fees; security deposits not returned by the lessor; costs for extended warranties, credit life Insurance, health, accident or disability insurance purchased with the loan or lease; and carry-over balances from previous loans or leases. 7. AIRBAG COVERAGE Under Paragraph B. EXCLUSIONS - of SECTION III - PHYSICAL DAMAGE COVERAGE, the following is added: The exclusion relating to mechanical breakdown does not apply to the accidental discharge of an airbag. 8. ELECTRONIC EQUIPMENT - BROADENED COVERAGE a. The exceptions to Paragraphs B.4 - EXCLUSIONS - of SECTION III - PHYSICAL DAMAGE COVERAGE are replaced by the following: Exclusions 4.c. and 4.d. do not apply to equipment designed to be operated solely by use of the power from the "auto's" electrical system that, at the time of "loss", is: (1) Permanently installed in or upon the covered "auto"; (2) Removable from a housing unit which is permanently installed in or upon the covered "auto"; (3) An integral part of the same unit housing any electronic equipment described in Paragraphs (1) and (2) above; or ©2011, The Hartford (Includes copyrighted material Form HA 99 16 0312 of ISO Properties, Inc., with its permission.) Page 3 of 5 (4) Necessary for the normal operation of the covered "auto" or the monitoring of the covered "auto's" operating system. b. Section III — Version CA 00 01 03 10 of the Business Auto Coverage Form, Physical Damage Coverage, Limit of Insurance, Paragraph C.2 and Version CA 00 01 10 01 of the Business Auto Coverage Form, Physical Damage Coverage, Limit of Insurance, Paragraph C are each amended to add the following: $1,500 is the most we will pay for "loss" in any one "accident" to all electronic equipment (other than equipment designed solely for the reproduction of sound, and accessories used with such equipment) that reproduces, receives or transmits audio, visual or data signals which, at the time of "loss", is: (1) Permanently installed in or upon the covered "auto" in a housing, opening or other location that is not normally used by the "auto" manufacturer for the installation of such equipment; (2) Removable from a permanently installed housing unit as described in Paragraph 2.a. above or is an integral part of that equipment; or (3) An integral part of such equipment. c. For each covered "auto", should loss be limited to electronic equipment only, our obligation to pay for, repair, return or replace damaged or stolen electronic equipment will be reduced by the applicable deductible shown in the Declarations, or $250, whichever deductible is less. 9. EXTRA EXPENSE - BROADENED COVERAGE Under Paragraph A. - COVERAGE - of SECTION III - PHYSICAL DAMAGE COVERAGE, we will pay for the expense of returning a stolen covered "auto" to you. 10. GLASS REPAIR -WAIVER OF DEDUCTIBLE Under Paragraph D. - DEDUCTIBLE - of SECTION III - PHYSICAL DAMAGE COVERAGE, the following is added: If another Hartford Financial Services Group, Inc. company policy or coverage form that is not an automobile policy or coverage form applies to the same "accident", the following applies: (1) If the deductible under this Business Auto Coverage Form is the smaller (or smallest) deductible, it will be waived; (2) If the deductible under this Business Auto Coverage Form is not the smaller (or smallest) deductible, it will be reduced by the amount of the smaller (or smallest) deductible. 12. AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS The requirement in LOSS CONDITIONS 2.a. - DUTIES IN THE EVENT OF ACCIDENT,CLAIM, SUIT OR LOSS - of SECTION IV - BUSINESS AUTO CONDITIONS that you must notify us of an "accident" applies only when the "accident" is known to: (1) You, if you are an individual; (2) A partner, if you are a partnership; (3) A member, if you are a limited liability company; or (4) An executive officer or insurance manager, if you are a corporation. 13. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS If you unintentionally fail to disclose any hazards existing at the inception date of your policy, we will not deny coverage under this Coverage Form because of such failure. 14. HIRED AUTO - COVERAGE TERRITORY Paragraph e. of GENERAL CONDITIONS 7. - POLICY PERIOD, COVERAGE TERRITORY - of SECTION IV - BUSINESS AUTO CONDITIONS is replaced by the following: e. For short-term hired "autos", the coverage territory with respect to Liability Coverage is anywhere in the world provided that if the "insured's" responsibility to pay damages for "bodily injury" or "property damage" is determined in a "suit," the "suit" is brought in the United States of America, the territories and possessions of the United States of America, Puerto Rico or Canada or in a settlement we agree to. No deductible applies to glass damage if the 15. WAIVER OF SUBROGATION glass is repaired rather than replaced. TRANSFER OF RIGHTS OF RECOVERY 11. TWO OR MORE DEDUCTIBLES AGAINST OTHERS TO US - of SECTION IV - Under Paragraph D. - DEDUCTIBLE - of SECTION BUSINESS AUTO CONDITIONS is amended by III - PHYSICAL DAMAGE COVERAGE, the adding the following: following is added: © 2011, The Hartford (Includes copyrighted material Form HA 99 16 0312 of ISO Properties, Inc., with its permission.) Page 4 of 5 We waive any right of recovery we may have against any person or organization with whom you have a written contract that requires such waiver because of payments we make for damages under this Coverage Form. 16. RESULTANT MENTAL ANGUISH COVERAGE The definition of "bodily injury" in SECTION V - DEFINITIONS is replaced by the following: "Bodily injury" means bodily injury, sickness or disease sustained by any person, including mental anguish or death resulting from any of these. 17. EXTENDED CANCELLATION CONDITION Paragraph 2. of the COMMON POLICY CONDITIONS - CANCELLATION - applies except as follows: If we cancel for any reason other than nonpayment of premium, we will mail or deliver to the first Named Insured written notice of cancellation at least 60 days before the effective date of cancellation. 18. HYBRID, ELECTRIC, OR NATURAL GAS VEHICLE PAYMENT COVERAGE In the event of a total loss to a "non -hybrid" auto for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended as follows: a. If the auto is replaced with a "hybrid" auto or an auto powered solely by electricity or natural gas, we will pay an additional 10%, to a maximum of $2,500, of the "non -hybrid" auto's actual cash value or replacement cost, whichever is less, b.The auto must be replaced and a copy of a bill of sale or new lease agreement received by us within 60 calendar days of the date of "loss," c. Regardless of the number of autos deemed a total loss, the most we will pay under this Hybrid, Electric, or Natural Gas Vehicle Payment Coverage provision for any one "loss" is $10,000. For the purposes of the coverage provision, a.A "non -hybrid" auto is defined as an auto that uses only an internal combustion engine to move the auto but does not include autos powered solely by electricity or natural gas. b.A "hybrid" auto is defined as an auto with an internal combustion engine and one or more electric motors; and that uses the internal combustion engine and one or more electric motors to move the auto, or the internal combustion engine to charge one or more electric motors, which move the auto. 19. VEHICLE WRAP COVERAGE In the event of a total loss to an "auto" for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended to add the following: In addition to the actual cash value of the "auto", we will pay up to $1,000 for vinyl vehicle wraps which are displayed on the covered "auto" at the time of total loss. Regardless of the number of autos deemed a total loss, the most we will pay under this Vehicle Wrap Coverage provision for any one "loss" is $5,000. For purposes of this coverage provision, signs or other graphics painted or magnetically affixed to the vehicle are not considered vehicle wraps. © 2011, The Hartford (Includes copyrighted material Form HA 99 16 03 12 of ISO Properties, Inc., with its permission.) Page 5 of 5 011 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT Policy Number: 52 WEA 100453 Endorsement Number: 1 Effective Date: 01/23/2016 Effective hour is the same as stated on the Information Page of the policy. Named Insured and Address: Alta Construction, Inc. 619 N. Cloverdale Rd. Boise, ID 83713 We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. SCHEDULE Countersigned by Form WC 00 03 13 Printed in U.S.A. Authorized Representative 1+ 1 1\-C-1111 1 Home I Setup an Account I Log In Licensee I V� Username Passrionl LOGIN ® REMEMBER ME Forgot Password Permits Search Pay Fees Licenses Search Trade Licenses Search Public Works Inspections Schedule Cancel Elevators Search Elevators Violations Search Shopping Cart Pay All Fees Paid Items Contact Contact us Page 1 of 1 Public Works Search f) Search Again Download Results Printable View Company Name License Number Work Category(s) I License Typ-1 usApplicant Name ALTA Construction, Inc. 003938 00001, 00002, 00003 1, 2, 3, 5 UNLIMITED I ACTIVE ALTAR Constructio ,First Pre, Page: 1 of 1 Next Last _-, Details - License Number: 003938 Lic Info IlFees $3,775.00 Registration #: 003938 Issue: 7/13/2015 Expire: 6/30/2016 Type: PUBLIC WORKS Sub -Type: UNLIMITED Status: ACTIVE Company: ALTA Construction, Inc. Phone: (208) 853-1720 Cell: (208) 954-6616 Pager: Fax: (208) 853-6588 Owner Name: The Division of Building Safety, makes every effort to produce and publish the most current and accurate Information possible No warranties, expressed or implied, are provided for the data herein, its use, or its interpretation. Utilization of this website indicates understanding and acceptance of this statement 1-800-955-3044, 1090 E tNatertovrer Sl, Suite 150 Meridian ID 83642 HOME I CONTACT https://web.dbs.idaho.gov/eTRAKiT3/Custom/Idaho_PublicWorksSearchRslts.aspx 5/3/2016 11Jov0 v icwiiig Dullness nntity Page 1 of 3 IDAHO SECRETARY OF STATE X Viewing Business Entity Lawerence Denney, Secretary of State [ New Search ] [ Back to Summary ] [ Get a certificate of existence for ALTA CONSTRUCTION INC ] [ Monitor ALTA CONSTRUCTION, INC. business filings ] ALF 0 RUC T 0 ® XN® 619 N CLOVERDALE ROAD BOISE, ID 83713 Type of Business: CORPORATION, GENERAL BUSINESS Status: GOODSTANDING 15 Apr 1992 State of Origin: IDAHO Date of 27 Jan 1977 Origination/Authorization: Current Registered Agent: ERIK MATHIASON 619 N CLOVERDALE RD BOISE, ID 83713 Organizational ID / Filing C54953 Number: Number of Authorized Stock 1 Shares: Date of Last Annual Report: 23 Feb 2016 Annual Report Due: Jan 2017 Original Filing: [ Help Me Print/View TIFF ] Filed 27 Jan 1977 INCORPORATION View Image (PDF format) View Image (TIFF format], Amendments: [ Help Me Print/View TIFF ] Amendment Filed 11 Sep OTHER - View Image (PDF format) View 1980 R/A Image View Document Online (TIFF format) Amendment Filed 04 Jun REINSTATEMENT View Image View Document Online (PDF format) 1982 View Image (TIFF format) Amendment Filed 18 Aug REINSTATEMENT View Image (PDF format) 1983 View Image (TIFF format) Amendment Filed 15 Apr REINSTATEMENT View Image (PDF format) 1992 View Image (TIFF format) [ Help Me Print/View TIFF ] Report for year 2016 ANNUAL REPORT View Document Online Report for year 2015 ANNUAL REPORT View Document Online Report for year 2014 ANNUAL REPORT View Document Online Report for year 2013 ANNUAL REPORT View Document Online https://www.accessidaho.org/public/sos/corp/C54953.html 5/3/2016 v 1cw1119 DU6111GJJ JJ11LILy Page 2 of 3 Report for year 2012 ANNUAL REPORT View Document Online Report for year 2012 CHNG View Image (PDF format) View RA/RO Image (TIFF format) Report for year 2011 ANNUAL REPORT View Document Online Report for year 2010 ANNUAL REPORT View Document Online Report for year 2009 ANNUAL View Image (PDF format) View REPORT Image (TIFF forma Report for year 2009 CHNG OFF/DIR Report for year 2008 ANNUAL REPORT Report for year 2007 ANNUAL REPORT Report for year 2006 ANNUAL REPORT Report for year 2005 ANNUAL REPORT Report for year 2004 ANNUAL REPORT Report for year 2002 ANNUAL REPORT Report for year 2001 ANNUAL REPORT Report for year 2000 ANNUAL REPORT Report for year 1999 ANNUAL REPORT Report for year 1998 ANNUAL REPORT Report for year 1997 ANNUAL REPORT Report for year 1996 ANNUAL REPORT Report for year 1995 ANNUAL REPORT View Image (PDF format) View View Image (TIFF format) Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View ANNUAL Image (TIFF format) View Image (PDF format) View Image (TIFF format) Image (TIFF forma View Image (PDF format) View Image (TIFF format) View Image (PDF format) View REINSTATEMENT View Image (PDF format) Image (TIFF format) View Image (PDF format) View Report for year 1990 Image (TIFF format) View Image (PDF format) View REPORT Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) Report for year 1995 MISCELLANEOUS View I_mage (PDF format View Image (TIFF format) Report for year 1994 ANNUAL View Image (PDF format) View REPORT Image (TIFF format) Report for year 1993 ANNUAL View Image (PDF format) View REPORT Image (TIFF format) Report for year 1992 ANNUAL View Image (PDF format) View REPORT Image (TIFF format) Report for year 1991 REINSTATEMENT View Image (PDF format) View Image (TIFF format) Report for year 1990 ANNUAL View Image (PDF format) View REPORT Image (TIFF format) https://www.accessidaho.org/public/sos/corp/C54953.html 5/3/2016 LU�u v il�Wlll,-' I-uaIllUbN 11,11«Ly Report for year 1989 ANNUAL REPORT Report for year 1988 ANNUAL REPORT Report for year 1987 ANNUAL REPORT Idaho Secretary of State's Main Page Page 3 of 3 View Image_ (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) View Image (PDF format) View Image (TIFF format) State of Idaho Home Page Comments, questions or suggestions can be emailed to: sosinfo(&sos.idaho.gov https://www.accessidaho.org/public/sos/corp/C54953.html 5/3/2016 ro x 1 4J S4 O a N P+ a x w -) " H r U o ro w N •n � ao m I 0 O t3 N V � tH -01 a) 4 H O V Gv) 4-1 04 W C1 N o C k I o ro H O U) O1 0 Q) ll-) N C rl W a) P P: 4-1 O 4J q v 4) ro W 44 to O H a 4) 1) C Cts •�i S4 [A a) a) P a �4 ro a) H � ro 4, 4J O U } FZ4 34 U o`P dY 61P of dP dAdP m o o dY o`? oP 1%0 oW dP 0 0 0 0 N 0 �i o O O o 0 0 0 O O o o r o m O o O o O o 0 N d H H m m r M m m N to M ko O O o O o N O O ri O o 0 0 O O m r rl N m m m H O M o M m to -1 M to m m Lo m 'm Ln O u o 0 0 o O O o o m o o M O m o O o O O O O O lD O O r Ln N o d o m o O o o t0 N O m r m io m O m m O r N N O Ln m m v N N d H m m m r M m m N to M ko �o O O Ln o m O O O O o o O O O O O m o m m o u) O Ln m o 0 o O O N r O N N r r N N O Ln m m Qo O r H m -4 Io m m m N to M m l0 m m m In m Ln N v) N -i N m r c N m m m H O M M m to -1 M to 0. M. N N r r m m H H v <r H ri H H m m M M Ln n M M Ln n M M m m M M M M Ln Ln M M Ln O o o m o o O O o o m o o N N M O o o m m o LO O to m Qo O O r r r N O r H N o r r N N to O m r r m r "o Ln -cl, o m -i r m m m m m O M M m to o -w m m Lo m 'm . N U) r M r o N m N N 1 -1 M �o Ln m m M r w fl H rl H 4J m W W Vd 4Jd I I -P I m m I u) u) rt v) -P 4j 1 43 1 4-1 Pi 4) U) 43 i4 b, 4' 0 41 ' 4j z A C A a) q v q 10 v q a) 0 0 0 o r al C. -H Gt v) a) C. ZS a) Id -P -rl a) FS a) 4J a) 41 a) I i o Fo ro -1 0541 v (d v) f~ -1 FiH F N •rl (1) •moi a) -H (1) -H F1 a) a N a) p a rd -moi P, a) H a) S4 a) 4) ro u+� u4) U4) a a) u ur1 u a u ro u ro um ro ro ro ro ro ro f~ ro 3 ro -H >4 (o u (0 u a 4-3 H 4) —1 4-) x x f -I a) r1 F4 7. .-i ro 0 H i4 W -1 10 H .-I Fi � a m a co a En a a4 a) n a a) a x 4J a) a) a a a o o ro v ro �J ro o 0 3 a)0 4) 3 1 (L) Pi v q a) 4) P 4-10.'i 4) 0.i 4) iia F4 Pi N 1 Pi 1 td '3 a) P: Pi RS P' 10 Pi b) '� 0 44 4P 44 H x a x.' U] 4-1 C', H m + 0 •i a) •li I~ U -H 4J U H ro 0 f~ >~ C a) q w >, 1 A 0 a 0 a is 0 a a) a) ro -11 H 4) q 'H A zf a) q a -H 4� Z m u) 41'0 ro r rO a) ro 0 r, -H q O -,1 � C O -ri 4) 0� 3 u) z a p a a a a -1 a- ro x ro ro 'l a a r1 a� ro 111 i44 P N apo 0 X 4 D 4J u TS O '0 u r r H 0 U H I uu s4o uoq s40b) m H H Hro Nr0 1~a >4ro>4 H-11 s4 -Am a 4-J q 0 N is a) tS I a) of _f a) q r a) a) a) A a) N N N N a) r1 W a) t,' a) a) a) 4-1 Z O '� a) a) N a) a) N a) N q a) N 4J ro W 4) S -i f -I i4 N a) -H 41 U 4) -.-i ro ,"� O gg ro rd ro a) -P a CO t7 m U W U) 0 n G4 m rC D m m 3P: CO z4-) Z u) 3 x I u) u) 1 m 3 -Q' W 4 cf) H a a ro w U q w m U1 in U) \o N m Ln Ln LO r M M m O M M M lfl co m r1 H r1 r H -1 -4 O r1 H rl M dw d• to Ln Ln LO Qo w to O O o O O O O O O o o O O (D Ln rl H H �-1 •-i .--1 .-i H rl H r-1 .--i rl o) N N ro a ro x I 4J ii O R 1x P. k W +) �O O a) CD N O ro N 0 O CD a a" M fo O � �11 IDI •u in U o N N V is (n N E O -V O n 4 W N N U W I N 1 o N CD � to o ro � I U) O O N Ol i4 m W � M D a 44 O a~ 41 +0 ro +) dF dP oW oa o%-o`F N a\a o\o o`P l0 o;o r-1 O m O O Ln In O O 61 61 O m O O O Ln -1 O r -I O O NO O O N N N W O G' O ri O O o O O O O J -J -11 O 'r r -I 61 dl a) P: to - U H P] a) (L) p P4 v' V' O O O m OD m s M ri O O O O C� C l of 1-� -ri v ri m r -I lfl lfl t0 a) s •� M M M 25 ro m r> a 1 m m m O O O m o -1 O rn rn rn S4 O O Lc) M u7 O N ro a O v` h O N m m O O O row m in �o Co c o O O m r -f m I� N O O O C.' U 61 dl O M m N N N U �r v+ O m O -i O t` r 'c. U) M ri O M Lf O N N to 4J P of �o O O N m m v v v' v' 1� In Ln m C l9 lO l0 O M m L[) L<7 N lD M ri M M M -W Ln, Ln (L' 3 a) z S I m p O -A J +) 41 10 m I rC w n U. m Sa s q (1) 0) 41 41 a) q 41 w a) a a m + •i r a) v ro m 0) O aN aa))�ro arclcro) a�} 11 `° roN �p ro� 3 kx Nz saw ro m 3 R H r a4 q 3 O 4J 1 z3 P a, a) m ro (o �l ro a) -ri v x - m E ul+1 PxPx xa 0z 14 m1 d M + � � m + a 0) � aa) a) 1 O +) es ro (1)z zt ro a a) H u b a) -r�i N •rrA N a) 10 Q' H H r -I �El -V U -1 41 2 ZS ri ri C U -ri ro U H q + C)� m uro sam r, 4 ua,b) PM�4 q z _ O '�4 'z3O N a ) a) •ri a) H a) Z W 4) CL 41 8 4),0 m 4J •,A +) G (d m ro g O '5 m `!. rd -i a) `S ro a1 'S a >C -i m ,^s P: N N U) W q W I HW ro a S� 44 F ro W O u q E ro U ro ro lD N to Lc) O h l0 r-1 N I` O M LO Ln Ln In N Ln O O O O OCD O O O Ln -1 ri H ri ci H O1