Loading...
HomeMy WebLinkAboutPublic Works Construction Agreement with Riverside Inc for Well 29 Production Well ConstructionCONTRACT FOR PUBLIC WORKS CONSTRUCTION WELL 29 PRODUCTION WELL - CONSTRUCTION PROJECT # 10461.f THIS CONTRACT FOR PUBLIC WORKS CONSTRUCTION is made thisday of April, 2016, and entered Into by and between the City of Meridian, a municipal corporation organized under the laws of the State of Idaho, hereinafter referred to as "CITY", 33 East Broadway Avenue, Meridian, Idaho 83642, and Riverside, Inc, hereinafter referred to as "CONTRACTOR", whose business address is P O Box'720 Parma ID 83660 and whose Public Works Contractor License # is C -11115-A-1-4. INTRODUCTION Whereas, the City has a need for services involving WELL 29 PRODUCTION WELL - CONSTRUCTION; and WHEREAS, the Contractor is specially trained, experienced and competent to perform and has agreed to provide such services; NOW, THEREFORE, in consideration of the mutual promises, covenants, terms and conditions hereinafter contained, the parties agree as follows: TERMS AND CONDITIONS 1. Scope of Work: 1.1 CONTRACTOR shall perform and furnish to the City upon execution of this Contract and receipt of the City's written notice to proceed, all services and work, and comply in all respects, as specified in the document titled "Scope of Work" a copy of which is attached hereto as Exhibit "A" and incorporated herein by this reference, together with any amendments that may be agreed to in writing by the parties. 1.2 All documents, drawings and written work product prepared or produced by the Contractor under this Agreement, including without limitation electronic data files, are the property of the Contractor; provided, however, the City shall have the right to reproduce, publish and use all such work, or any part thereof, in any manner and for any purposes whatsoever and to authorize others to do so. If any such work is copyrightable, the Contractor may copyright the same, except that, as to any work which is copyrighted by the Contractor, the City reserves a royalty -free, non-exclusive, and irrevocable license to reproduce, publish and use such work, or any part thereof, and to authorize others to do so. 1.3 The Contractor shall provide services and work under this Agreement consistent with the requirements and standards established by applicable federal, state and city laws, ordinances, regulations and resolutions. The Contractor represents and warrants that it will perform its work in accordance with generally accepted industry standards and practices for the profession or professions that are used in performance of this WELL 29 PRODUCTION WELL - CONSTRUCTION page 1 of 12 Project 10461.E Agreement and that are in effect at the time of performance of this Agreement. Except for that representation and any representations made or contained in any proposal submitted by the Contractor and any reports or opinions prepared or issued as part of the work performed by the Contractor under this Agreement, Contractor makes no other warranties, either express or implied, as part of this Agreement. 1.4 Services and work provided by the Contractor at the City's request under this Agreement will be performed in a timely manner in accordance with a Schedule of Work, which the parties hereto shall agree to. The Schedule of Work may be revised from time to time upon mutual written consent of the parties. 2. Consideration 2.1 The Contractor shall be compensated on a Not -To -Exceed basis as provided in Exhibit B "Payment Schedule" attached hereto and by reference made a part hereof for the Not -To -Exceed amount of $232,295.00. 2.2 The Contractor shall provide the City with a monthly statement and supporting invoices, as the work warrants, of fees earned and costs incurred for services provided during the billing period, which the City will pay within 30 days of receipt of a correct invoice and approval by the City. The City will not withhold any Federal or State income taxes or Social Security Tax from any payment made by City to Contractor under the terms and conditions of this Agreement. Payment of all taxes and other assessments on such sums is the sole responsibility of Contractor. 2.3 Except as expressly provided in this Agreement, Contractor shall not be entitled to receive from the City any additional consideration, compensation, salary, wages, or other type of remuneration for services rendered under this Agreement including, but not limited to, meals, lodging, transportation, drawings, renderings or mockups. Specifically, Contractor shall not be entitled by virtue of this Agreement to consideration in the form of overtime, health insurance benefits, retirement benefits, paid holidays or other paid leaves of absence of any type or kind whatsoever. 3. Term: 3.1 This agreement shall become effective upon execution by both parties, and shall expire upon (a) completion of the agreed upon work, (b) or unless sooner terminated as provided in Sections 3.2, 3.3, and Section 4 below or unless some other method or time of termination is listed in Exhibit A. 3.2 Should Contractor default in the performance of this Agreement or materially breach any of its provisions, City, at City's option, may terminate this Agreement by giving written notification to Contractor. 3.3 Should City fail to pay Contractor all or any part of the compensation set forth in Exhibit B of this Agreement on the date due, Contractor, at the Contractor's option, may terminate this Agreement if the failure is not remedied by the City within thirty (30) days from the date payment is due. WELL 29 PRODUCTION WELL - CONSTRUCTION page 2 of 12 Project 10461.E 4. Liquidated Damages: Substantial Completion shall be accomplished within 50 (fifty) calendar days from Notice to Proceed. This project shall be considered Substantially Complete when the Owner has full and unrestricted use and benefit of the facilities, both from an operational and safety standpoint, and only minor incidental work, corrections or repairs remain for the physical completion of the total contract. Contractor shall be liable to the City for any delay beyond this time period in the amount of $150.00 (one hundred fifty dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. Upon receipt of a Notice to Proceed, the Contractor shall have 60 (sixty) calendar days to complete the work as described herein. Contractor shall be liable to the City for any delay beyond this time period in the amount of $150.00 (one hundred fifty dollars) per calendar day. Such payment shall be construed to be liquidated damages by the Contractor in lieu of any claim or damage because of such delay and not be construed as a penalty. See Milestones listed in the Payment Schedule for Substantial Completion. 5. Termination: 5.1 If, through any cause, CONTRACTOR, its officers, employees, or agents fails to fulfill in a timely and proper manner its obligations under this Agreement, violates any of the covenants, agreements, or stipulations of this Agreement, falsifies any record or document required to be prepared under this agreement, engages in fraud, dishonesty, or any other act of misconduct in the performance of this contract, or if the City Council determines that termination of this Agreement is in the best interest of CITY, the CITY shall thereupon have the right to terminate this Agreement by giving written notice to CONTRACTOR of such termination and specifying the effective date thereof at least fifteen (15) days before the effective date of such termination. CONTRACTOR may terminate this agreement at any time by giving at least sixty (60) days notice to CITY. In the event of any termination of this Agreement, all finished or unfinished documents, data, and reports prepared by CONTRACTOR under this Agreement shall, at the option of the CITY, become its property, and CONTRACTOR shall be entitled to receive just and equitable compensation for any work satisfactorily complete hereunder. 5.2 Notwithstanding the above, CONTRACTOR shall not be relieved of liability to the CITY for damages sustained by the CITY by virtue of any breach of this Agreement by CONTRACTOR, and the CITY may withhold any payments to CONTRACTOR for the purposes of set-off until such time as the exact amount of damages due the CITY from CONTRACTOR is determined. This provision shall survive the termination of this agreement and shall not relieve CONTRACTOR of its liability to the CITY for damages. 6. Independent Contractor: 6.1 In all matters pertaining to this agreement, CONTRACTOR shall be acting as an independent contractor, and neither CONTRACTOR nor any officer, employee or agent of CONTRACTOR will be deemed an employee of CITY. Except as expressly provided WELL 29 PRODUCTION WELL - CONSTRUCTION page 3 of 12 Project 10461.E in Exhibit A, Contractor has no authority or responsibility to exercise any rights or power vested in the City and therefore has no authority to bind or incur any obligation on behalf of the City. The selection and designation of the personnel of the CITY in the performance of this agreement shall be made by the CITY. 6.2 Contractor, its agents, officers, and employees are and at all times during the term of this Agreement shall represent and conduct themselves as independent contractors and not as employees of the City. 6.3 Contractor shall determine the method, details and means of performing the work and services to be provided by Contractor under this Agreement. Contractor shall be responsible to City only for the requirements and results specified in this Agreement and, except as expressly provided in this Agreement, shall not be subjected to City's control with respect to the physical action or activities of Contractor in fulfillment of this Agreement. If in the performance of this Agreement any third persons are employed by Contractor, such persons shall be entirely and exclusively under the direction and supervision and control of the Contractor. 7. Sub -Contractors: Contractor shall require that all of its sub -contractors be licensed per State of Idaho Statute # 54-1901 8. Removal of Unsatisfactory Employees: The Contractor shall only furnish employees who are competent and skilled for work under this contract. If, in the opinion of the City, an employee of the Contractor is incompetent or disorderly, refuses to perform in accordance with the terms and conditions of the contract, threatens or uses abusive language while on City property, or is otherwise unsatisfactory, that employee shall be removed from all work under this contract. 9. Indemnification and Insurance: 9.1 CONTRACTOR shall indemnify and save and hold harmless CITY and it's elected officials, officers, employees, agents, and volunteers from and for any and all losses, claims, actions, judgments for damages, or injury to persons or property and losses and expenses and other costs including litigation costs and attorney's fees, arising out of, resulting from, or in connection with the performance of this Agreement by the CONTRACTOR, its servants, agents, officers, employees, guests, and business invitees, and not caused by or arising out of the tortious conduct of CITY or its employees. CONTRACTOR shall maintain and specifically agrees that it will maintain throughout the term of this Agreement liability insurance in which the CITY shall be named an additional insured in the minimum amounts as follow: General Liability One Million Dollars ($1,000,000) per incident or occurrence, Automobile Liability Insurance One Million Dollars ($1,000,000) per incident or occurrence and Workers' Compensation Insurance, in the statutory limits as required by law.. The limits of insurance shall not be deemed a limitation of the covenants to indemnify and save and hold harmless CITY; and if CITY becomes liable for an amount in excess of the insurance limits, herein provided, CONTRACTOR covenants and agrees to indemnify and save and hold harmless CITY from and for all such losses, claims, actions, or WELL 29 PRODUCTION WELL - CONSTRUCTION page 4 of 12 Project 10461.f judgments for damages or injury to persons or property and other costs, including litigation costs and attorneys' fees, arising out of, resulting from , or in connection with the performance of this Agreement by the Contractor or Contractor's officers, employs, agents, representatives or subcontractors and resulting in or attributable to personal injury, death, or damage or destruction to tangible or intangible property, including use of. CONTRACTOR shall provide CITY with a Certificate of Insurance, or other proof of insurance evidencing CONTRACTOR'S compliance with the requirements of this paragraph and file such proof of insurance with the CITY at least ten (10) days prior to the date Contractor begins performance of it's obligations under this Agreement. In the event the insurance minimums are changed, CONTRACTOR shall immediately submit proof of compliance with the changed limits. Evidence of all insurance shall be submitted to the City Purchasing Agent with a copy to Meridian City Accounting, 33 East Broadway Avenue, Meridian, Idaho 83642. 9.2 Insurance is to be placed with an Idaho admitted insurer with a Best's rating of no less than A-. 9.3 Any deductibles, self-insured retention, or named insureds must be declared in writing and approved by the City. At the option of the City, either; the insurer shall reduce or eliminate such deductibles, self-insured retentions or named insureds; or the Contractor shall provide a bond, cash or letter of credit guaranteeing payment of losses and related investigations, claim administration and defense expenses. 9.4 To the extent of the indemnity in this contract, Contractor's Insurance coverage shall be primary insurance regarding the City's elected officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City or the City's elected officers, officials, employees and volunteers shall be excess of the Contractor's insurance and shall not contribute with Contractor's insurance except as to the extent of City's negligence. 9.5 The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 9.6 All insurance coverages for subcontractors shall be subject to all of the insurance and indemnity requirements stated herein. 9.7 The limits of insurance described herein shall not limit the liability of the Contractor and Contractor's agents, representatives, employees or subcontractors. 10. Time is of the Essence: The parties hereto acknowledge and agree that time is strictly of the essence with respect to each and every term, condition and provision hereof, and that the failure to timely perform any of the obligations hereunder shall constitute a breach of, and a default under, this Agreement by the party so failing to perform. 11. Bonds: Payment and Performance Bonds are required on all Public Works Improvement Projects per the ISPWC and the City of Meridian Supplemental Specifications & Drawings to the ISPWC, which by this reference are made a part hereof. Contractor is WELL 29 PRODUCTION WELL - CONSTRUCTION page 5 of 12 Project 10461.E required to furnish faithful performance and payment bonds in the amount of 100% of the contract price issued by surety licensed to do business in the State of Idaho. In the event that the contract is subsequently terminated for failure to perform, the contractor and/or surety will be liable and assessed for any and all costs for the re -procurement of the contract services. 12. Warranty: All construction and equipment provided under this agreement shall be warranted for 2 years from the date of the City of Meridian acceptance per the ISPWC and the Meridian Supplemental Specifications & Drawings to the ISPWC and any modifications, which by this reference are made a part hereof. All items found to be defective during a warranty inspection and subsequently corrected will require an additional two (2) year warranty from the date of City's acceptance of the corrected work. 13. Changes: The CITY may, from time to time, request changes in the Scope of Work to be performed hereunder. Such changes, including any increase or decrease in the amount of CONTRACTOR'S compensation, which are mutually agreed upon by and between the CITY and CONTRACTOR, shall be incorporated in written amendments which shall be executed with the same formalities as this Agreement. 14. Taxes: The City of Meridian is exempt from Federal and State taxes and will execute the required exemption certificates for items purchased and used by the City. Items purchased by the City and used by a contractor are subject to Use Tax. All other taxes are the responsibility of the Contractor and are to be included in the Contractor's Bid pricing. 15. Meridian Stormwater Specifications: All construction projects require either a Storm Water Pollution Prevention Plan (SWPPP) or an erosion sediment control plan (ESCP) as specified in the City of Meridian Construction Stormwater Management Program (CSWMP) manual. The CSWMP manual containing the procedures and guidelines can be found at this address: http://www.meridiancity.orci/environmental.aspx?id=l 3618. Contractor shall retain all stormwater and erosion control documentation generated on site during construction including the SWPPP manual, field inspections and amendments. Prior to final acceptance of the job by the City the contractor shall return the field SWPPP manual and field inspection documents to the City for review. A completed Contractor Request to File Project N.O.T. with the EPA form shall be provided to the City with the documents. These documents shall be retained, reviewed and approved by the City prior to final acceptance of the project. 16. ACHD: WELL 29 PRODUCTION WELL - CONSTRUCTION page 6 of 12 Project 10461.f Contractor shall be responsible for coordinating with the City to obtain appropriate ACHD permit(s) and will reimburse the City for fees, fines, or penalties City incurs due to Contractor's violation of any ACHD policy. City shall certify to ACHD that Contractor is authorized to obtain a Temporary Highway and Right -of -Way Use Permit from ACHD on City's behalf. The parties acknowledge and agree that the scope of the agency granted by such certification is limited to, and conterminous with, the term and scope of this Agreement. 17. Reports and Information: 17.1 At such times and in such forms as the CITY may require, there shall be furnished to the CITY such statements, records, reports, data and information as the CITY may request pertaining to matters covered by this Agreement. 17.2 Contractor shall maintain all writings, documents and records prepared or compiled in connection with the performance of this Agreement for a minimum of four (4) years from the termination or completion of this or Agreement. This includes any handwriting, typewriting, printing, photo static, photographic and every other means of recording upon any tangible thing, any form of communication or representation including letters, words, pictures, sounds or symbols or any combination thereof. 18. Audits and Inspections: At any time during normal business hours and as often as the CITY may deem necessary, there shall be made available to the CITY for examination all of CONTRACTOR'S records with respect to all matters covered by this Agreement. CONTRACTOR shall permit the CITY to audit, examine, and make excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement. 19. Publication, Reproduction and Use of Material: No material produced in whole or in part under this Agreement shall be subject to copyright in the United States or in any other country. The CITY shall have unrestricted authority to publish, disclose and otherwise use, in whole or in part, any reports, data or other materials prepared under this Agreement. 20. Equal Employment Opportunity: In performing the work herein, Contractor agrees to comply with the provisions of Title VI and VII of the Civil Rights Act, Revenue Sharing Act Title 31, U.S. Code Section 2176. Specifically, the Contractor agrees not to discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. Contractor will take affirmative action during employment or training to insure that employees are treated without regard to race, color, religion, sex, national origin, age, political affiliation, marital status, or handicap. In performing the Work required herein, CONTRACTOR shall not unlawfully discriminate in violation of any federal, state or local law, rule or regulation against any person on the basis of race, color, religion, sex, national origin or ancestry, age or disability. WELL 29 PRODUCTION WELL - CONSTRUCTION page 7 of 12 Project 10461.E 21. Employment of Bona Fide Idaho Residents: Contractor must comply with Idaho State Statute 44-1002 which states that the Contractor employ ninety-five percent (95%) bona fide Idaho residents. 22. Advice of Attorney: Each party warrants and represents that in executing this Agreement. It has received independent legal advice from its attorney's or the opportunity to seek such advice. 23. Attorney Fees: Should any litigation be commenced between the parties hereto concerning this Agreement, the prevailing party shall be entitled, in addition to any other relief as may be granted, to court costs and reasonable attorneys' fees as determined by a Court of competent jurisdiction. This provision shall be deemed to be a separate contract between the parties and shall survive any default, termination or forfeiture of this Agreement. 24. Construction and Severability: If any part of this Agreement is held to be invalid or unenforceable, such holding will not affect the validity or enforceability of any other part of this Agreement so long as the remainder of the Agreement is reasonably capable of completion. 25. Waiver of Default: Waiver of default by either party to this Agreement shall not be deemed to be waiver of any subsequent default. Waiver or breach of any provision of this Agreement shall not be deemed to be a waiver of any other or subsequent breach, and shall not be construed to be a modification of the terms of this Agreement unless this Agreement is modified as provided above. 26. Entire Agreement: This Agreement contains the entire agreement of the parties and supersedes any and all other agreements or understandings, oral of written, whether previous to the execution hereof or contemporaneous herewith. 27. Assignment: It is expressly agreed and understood by the parties hereto, that CONTRACTOR shall not have the right to assign, transfer, hypothecate or sell any of its rights under this Agreement except upon the prior express written consent of CITY. 28. Payment Request: Payment requests shall be submitted to City of Meridian through the City's project management software. The Project Manager will compare the invoice against the Payment Schedule in the Agreement for compliance. Upon approval that the work has been done and is in compliance with the Agreement, the Project Manager will approve WELL 29 PRODUCTION WELL - CONSTRUCTION page 8 of 12 Project 10461.f the pay request for processing. City of Meridian payment terms are Net 30 from the date City receives a correct invoice. Final payment will not be released until the City has received a tax release from the Tax Commission. 29. Cleanup: Contractor shall keep the worksite clean and free from debris. At completion of work and prior to requesting final inspection, the Contractor shall remove all traces of waste materials and debris resulting from the work. Final payment will not be made if cleanup has not been performed. 30. Order of Precedence: The order or precedence shall be the contract agreement, the Invitation for Bid document, then the winning bidders submitted bid document. 31. Compliance with Laws: In performing the scope of work required hereunder, CONTRACTOR shall comply with all applicable laws, ordinances, and codes of Federal, State, and local governments. 32. Applicable Law: This Agreement shall be governed by and construed and enforced in accordance with the laws of the State of Idaho, and the ordinances of the City of Meridian. 33. Notices: Any and all notices required to be given by either of the parties hereto, unless otherwise stated in this agreement, shall be in writing and be deemed communicated when mailed in the United States mail, certified, return receipt requested, addressed as follows: CITY CONTRACTOR City of Meridian Riverside, Inc Purchasing Manager Attn: Terry Daugherty 33 E Broadway Ave P O Box 720 Meridian, ID 83642 Parma, ID 83660 208-489-0417 Phone: 208-722-6731 Email: cods@rscicorp.net or terry@rscicorp.net Idaho Public Works License #C -11115-A-1-4 Idaho Well Drillers License #: 333 Either party may change their address for the purpose of this paragraph by giving written notice of such change to the other in the manner herein provided. WELL 29 PRODUCTION WELL - CONSTRUCTION page 9 of 12 Project 10461.f 34. Approval Required: This Agreement shall not become effective or binding until approved by the City of Meridian. CITY OF BY: TAMMY de WF::,E"� , MA Approved by Council: (t V Purchasing Approval BY: KEIT A , Purchasing Manager Dated::r` Project Manager Dean Stacey WELL 29 PRODUCTION WELL - CONSTRUCTION Project 10461.f I to GQ�Ogp'SED A UCGsry' 'O�Z+ CtcY of E IDlAN� IDAHO SEAL 9T�q e TRE Departrrient dpiroval BY:.r� � WA REN ST WART, Engineering Manager Dated:: -3232 page 10 of 12 EXHIBIT A SCOPE OF WORK REFER TO INVITATION TO BID PW -1619-10461.f ALL ADDENDUMS, ATTACHMENTS, AND EXHIBITS included in the Invitation to Bid Package # PW -1619-10461.f, are by this reference made a part hereof. SPECIFICATIONS / SCOPE OF WORK All construction work shall be done in accordance with the 2012 version of the Idaho Standards for Public Works Construction (ISPWC), the 2013 City of Meridian Supplemental Specifications to the ISPWC (and any Addendums). See separate attached documents: • Technical Specifications City of Meridian Municipal Supply Well 29 by SPF Water Engineering dated January 18, 2016 (25 pages) • Clarification to Technical Specifications dated January 18, 2016 for the Construction of City of Meridian Municipal Supply Well 29 (1 page) • Site Map (1 page) • Well 29 Preliminary Design (1 page) WELL 29 PRODUCTION WELL - CONSTRUCTION page 11 of 12 Project 10461.E Exhibit B MILESTONE / PAYMENT SCHEDULE A. Total and complete compensation for this Agreement shall not exceed $232,295.00 n MILESTONE`DATESLSCHED;ULE , Milestone 1 Substantial Completion 50 Days from Notice to Proceed Milestone 2 Final Completion 60 Days from Notice to Proceed PRICING SCHEDULE Contract includes furnishing all labor, materials, equipment, and incidentals as required for the WELL 29 PRODUCTION WELL - CONSTRUCTION per IFB PW -1619-10461.f NOT TO EXCEED CONTRACT TOTAL ....................... $232,295.00 Contract is a not to exceed amount. Line item pricing below will be used for invoice verification and any additional increases or decreases in work requested by city. The City will pay the contractor based on actual quantities of each item of work in accordance with the contract documents. x � Contract Pr�cn Schedule � " Item No. Description Quantity Unit Unit Price 1 Stormwater Management 1 LS $3,000 2 Mobilization and Demobilization 1 LS $20,500 3 Install pit run work pad 185 CY $45 4 Drill for, furnish, install, and seal 24 -inch surface casing 65 LF $425 5 Drill 8 -inch pilot borehole 405 LF $83- 6 Geophysical logging 1 LS $3,500 7 Ream for 23 -inch borehole 260 LF $65 8 Furnish and install PVC casing 328 LF $105 9 Furnish and install bentonite/cement grout seal 325 LF $41 10 Ream for 15 -inch borehole 145 LF $37 11 Furnish and install 9 -inch, stainless steel well screen 100 LF $120 12 Furnish and install 9 -inch "tight -wrap" stainless steel headpipe/blank 70 LF $125 13 Furnish and install sand filter pack 170 LF $65 14 Furnish and install packer 1 LS $7,500 15 Install and remove test pump 1 LS $6,000 16 Mechanical and pump development 32 HR $285 17 Test pumping 28 HR $285 18 Video log 1 LS $1,700 19 Disinfection 1 LS $1,000 20 Rig time 2 HR $300 WELL 29 PRODUCTION WELL - CONSTRUCTION page 12 of 12 Project 10461.f w 7. ad W M 13 c O v c O U M O a N R F - z M O a m sqn asuaDI-I aapiaa pa # O!"1 puOB P!8 wnpuapp pauOig cc O ❑ z LU > 0 a I nn enu' ■� m 0 a Performance Bond RF(7-tiVE 3 0 2016 F 1 N /`i ir Document A312 TM -2010 CONTRACTOR: (Name, legal status and address) Riverside, Inc. PO Box 720 Parma, ID 83660 OWNER: (Name, legal status and address) City of Meridian 33 E. Broadway Avenue Meridian, ID 83642 CONSTRUCTION CONTRACT Date: April 5, 2016 SURETY: (Name, legal status and principal place of business) Old Republic Surety Company 10220 SW Greenburg Rd., Suite 640 Portland, OR 97223 Amount: Two Hundred Thirty -Two Thousand Two Hundred Ninety -Five and No/100ths Dollars - - - ($232,295.00) Description: (Name and location) Well 29 Production Well - Construction Project # 10461.f Meridian, ID 83642 BOND Date: April 5, 2016 (Not earlier than Construction Contract Date) Bond No. YCN2161308 This document has Important legal consequences. Consultation with an attorney Is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form, This Is not a single combined Performance and Payment Bond. Amount: Two Hundred Thirty -Two Thousand Two Hundred Ninety -Five and No/100ths Dollars - - - ($232,295.00) Modifications to this Bond: M None ❑ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: orp rate Seal) Company: (Corporate Seal) Riverside, Inc. Old Republic Coomnpany41W�eel_o4 Signature: Signature. NameG�r�y # Ao % Name Ruby cFe_ and Title: l/ ��G /%C Si Q/e,� * and Title: Attorney -in -Fact (Any additional s:gnatufes-app ear on the last page of this Performance Bond.) (FOR INFORMATION ONLY—Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Ward Insurance Agency, Inc. (Architect, Engineer or otherparty;) P0Box 10167 Eugene OR 97440 Phone: (541) 687-1117 Inst, AIA Document A312° — 2010, The American Institute of Architects, 001110 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract,. which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default, Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice, if the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and ,3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5,1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. tnit. AIA Documant A312T" —2010. The American institute of Architects. § 7 if the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14,2 Construction Contract, The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14,3 Contractor Default, Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with is material term of the Construction Contract. § 14.4 Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 151f this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Init. AIA Document A3121' —2010. The American Institute of Architects. § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of'aclded parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address Address CAUTION: You should sign an original AIA Contract Documont, on which this text appoars In RED. An original assures that ohangaa will not ba obscured. lalt. AIA 4ocoment A312*" — 2010. The American InstiMe otArchitects. 4 M, - Document A3121M - 2010 Payment Bond CONTRACTOR: (Name, legal status and address) Riverside, Inc. PO Box 720 Parma, ID 83660 OWNER: (Name, legal status and address) City of Meridian 33 E. Broadway Avenue Meridian, ID 83642 CONSTRUCTION CONTRACT Date: April 5, 2016 SURETY: (Name, legal status and principal place of business) Old Republic Surety Company 10220 SW Greenburg Rd., Suite 640 Portland, OR 97223 Amount: Two Hundred Thirty -Two Thousand Two Hundred Ninety -Five and No/100ths Dollars - - - ($232,295.00) Description: (Name and location) Well 29 Production Well - Construction Project # 10461.f Meridian, ID 83642 BOND Date: April 5, 2016 (Not earlier than Construction Contract Date) Bond No. YCN2161308 This document has important legal consequences. Consultation with an attorney is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. Amount: Two Hundred Thirty -Two Thousand Two Hundred Ninety -Five and No/100ths Dollars - - - ($232,295.00) Modifications to this Bond: M None ❑ See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: ( orate Seal Company: (Corporate Seal) Riverside, Inc. Old Republic Surety Company�����'�-'(- Signature: Signature: Name�r -p 'y Name Ruby M. skell and Title: 0- �%�G S�Gt ��'j ,/_ and Title: Attorney -I -Fact (Any additional signatures appear on the last page of this Payment Bond) (FOR INFORMATION ONLY-- Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Ward Insurance Agency, Inc. (Architect, Engineer orotherparty) PO Box 10167 Eugene OR 97440 Phone: (541) 687-1117 Init. AIA Document A212- —2010. The American institute of AroNteots, 001110 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5. l .1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. if, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums round to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. (nit. . AIA Document A3121" — 2010. The American Institute of Architects. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears.,Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant, An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and cnginecring services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be assorted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. Init. AIA Document AM` —2010. The American Instituto of ArCMitacts. 7 § 16,4 Owner Default, Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.6 Contract Documents, All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address Signature: Name and Title: Address CAUTION: You should sign an original AIA Contract Document, on which this text appears in RI:CI. An original assures that changes will not be obscured, Init. AIA Document A312"' —2010. The American Inatituts of Archlteots. '4�� "® CERTIFICATE OF LIABILITY INSURANCE D3/31/2016Y) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 77 77 Ward Insurance Agency F PO BOX 10167 RE MANk�}§.3 0 rjg�1 f 0 NAME: CT Sandy Graham PHONE (541) 687-1117 FAX (541)342-8260 A1C No Ext): AIC No -MAIL sand @wardinsurance.net ADDRESS: y INSURER(S) AFFORDING COVERAGE NAIC # INSURERA:Idaho State Insurance ELmd Eugene OR 9744 INSURED INSURER B: INSURER C: Riverside, Inc. P 0 Box 720 INSURER D: INSURER E: GENERAL AGGREGATE $ Parma ID 83660 INSURER F: COVERAGES CERTIFICATE NUMBER:15/16 WC REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSID SUBR WVD POLICY NUMBER POLICY EFF MM/DDIYYYY POLICY EXP MMIDD/YYYY LIMITS COMMERCIAL GENERAL LIABILITY CLAIMS -MADE OCCUR EACH OCCURRENCE $ D -A AGE TO RENTED PREMISES Ea occurrence $ MED EXP (Any one person) $ PERSONAL & ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER: PRO - POLICY JECT LOC OTHER: GENERAL AGGREGATE $ PRODUCTS - COMP/OP AGG $ $ AUTOMOBILE LIABILITY ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS HIRED AUTOS NON -OWNED AUTOS COMBINED SINGLE LIMIT $ Ea accident _ BODILY INJURY (Per person) $ BODILY INJURY Pident $ (Per accident) ( ) PROPERTY DAMAGE $ Per accident UMBRELLA LIAB EXCESS LIAB OCCUR CLAIMS -MADE EACH OCCURRENCE $ AGGREGATE $ DED RETENTION $ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below NIA 629237 7/1/2015 7/1/2016 PERTOERTH- STAUTE E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYE$ 1 000 000 Id E.L. DISEASE- POLICY LIMIT 1 $ 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Re: Project #10461.f - Well 29 Production Well - Constuction RI IrII.H 1 C nULUCR City of Meridian Purchasing Manager 33 E Broadway Ave Meridian, ID 83642 ACORD 25 (2014/01) INS025 (201401) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Christensen/SANDY ©1988-2014 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD '4�!Rbr CERTIFICATE OF LIABILITY INSURANCE FDATE (MM/DD/YYYY) TYPE OF INSURANCE 3/30/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER,;. �. -1 T u %NAME: CONTACT Krist Martin Y Ward Insurance Agency t PHONE o Ext: (541) 687-1117 �C No: (541)342-8280 R_ PO Box 10167 gD�RIESS:kristy@wardinsurance.net �i,,AAR 3 6 INSURERS AFFORDING COVERAGE NAIC # INSURER A:Liberty Northwest 01814 Eugene OR 97440 INSURED ( i INSURER B :Federal Insurance Company20281 Riverside, Inc.` 9/7/2016 INSURERC: P O Box 720 INSURERD: INSURER E: Parma ID 83660 INSURER F: COVERAGES CERTIFICATE NUMBER:15/16-1 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. IN SR LTR TYPE OF INSURANCE ADDL SUER POLICY NUMBER MMIDDYNYrr MMIDD� LIMITS A X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE ❑X OCCUR EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTED 100 000 PREMISES Ea occurrence $ MED EXP (Any one person) $ 5,000 X Y C11164364 9/7/2015 9/7/2016 PERSONAL &ADV INJURY $ 1,000,000 GENT AGGREGATE LIMIT APPLIES PER: O- X POLICY ❑PRJECT LOC GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OPAGG $ 2,000,000 $ OTHER: AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ 1,000,000 A X ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS 011164369 HIRED AUTO PD 9/7/2015 9/7/2016 BODILY INJURY (Per person) $ BODILY INJURY Per accident $ ( ) X HIRED AUTOS LXAUUTOSWNED $1,000 COMP. DED. PROPERTYr accidentDAMAGE $ Pe $ $1,000 COLL. DED. X UMBRELLA LIAB I X OCCUR EACH OCCURRENCE $ 4,000,000 AGGREGATE $ 4,000,000 A EXCESS LIAB CLAIMS -MADE DED RETENTION $ C11164364 9/7/2015 9/7/2016 WORKERS COMPENSATIONPER AND EMPLOYERS' LIABILITY Y / N ANY PROPRIETOR/PARTNER/EXECUTIVEE.L. OFFICER/MEMBER EXCLUDED? ❑ N / A OTH- STATUTE ER EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYE $ (Mandatory In NH) If yes, describe under E.L. DISEASE - POLICY LIMIT $ DESCRIPTION OF OPERATIONS below B INLAND MARINE 06643024 9/7/2015 9/7/2016 JIB & BOOM OVERLOAD COV. LEASED/RENTED EQUIPMENT LIMIT:$100,000 $1,000 DED. DESCRIPTION OF OPERATIONS /LOCATIONS /VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space Is required) Re: Well 29 Production Well - Construction The City of Meridian, its servants, agents, officers, employees, guests, and business invitees are included as additional insured on a primary and non-contributory basis with waiver of subrogation per attached CG8416; per project aggregate also applies per attached form. Completed operations applies per attached CG8583. All applies where required by written contract agreement. All is subject to policy terms, limits, conditions, and exclusions. City of Meridian Purchasing Dept 33 E Broadway Ave Ste 106 Meridian, ID 83642 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Doc DuMars/EMILY ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD I N S025 (901401 ) C11164364 RIVERSIDI INC 9/7!2015 COMMERCIAL GENERAL LIABILITY CG 841612 03 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. GENERAL LIABILITY MASTER PAK PLUS@ FOR CONSTRUCTION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART INDEX S b ect Blanket Additional Insured (Owners, Lessees or Contractors) Fire, Lightning, Explosion and Sprinkler Leakage Damage to Premises You Rent Non -Owned Watercraft Supplementary Payments (Bail Bonds) Personal And Advertising Injury - Electronic Publication Extension Aggregate Limits (Per Location) Aggregate Limits (Per Project) Voluntary Property Damage Coverage Off Premises Care, Custody or Control Coverage Newly Formed or Acquired Organizations Duties in the Event of Occurrence, Offense, Claim or Suit Bodily Injury (Mental Anguish) Waiver of Transfer of Rights of Recovery Against Others Medical Payments Broad Named Insured Broadened Mobile Equipment Incidental Malpractice Liability Non -Owned Aircraft Property Damage - Elevators CG 8416 12 03 Includes copyrighted material of ISO Properties, Inc„ with its permission. E Sao 00 2 3 4 4 5 5 5 6 6 7 7 8 8 8 8 8 8 9 9 Page 1 of 9 1. BLANKET ADDITIONAL INSURED (Owners, Lessees Or Contractors) (Includes a Primary/Non-Contributory provision) Section iI - Who Is An Insured is amended to include as an insured any person or organization whom you are required to name as an additional insured on this policy in a written contract or written agreement, The written contract or written agreement must be currently in effect or becoming effective during the term of this policy and executed prior to the "bodily injury," "property damage" or "personal and advertising injury." The insurance provided the additional insured is limited as follows: A. The person or organization is only an additional insured with respect to liability: 1. Arising out of real property, as described in a written contract or written agreement, that you own, rent, lease or occupy; or 2. Caused by your ongoing operations performed for the additional insured. The insurance provided the additional insured in 1.A.2. above does not apply to: a. Coverage A - Bodily Injury and Property Damage Liability, Coverage B - personal! and Advertising Injury Liability or defense coverage under the Supplementary Payments arising out of an architect's, engineers or surveyor's rendering of or failure to render any professional services including: (1) The preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; and (2) Supervisory, inspection, architectural or engineering activities. b. "Bodily injury" or "property damage" occurring after: (1) All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) that was performed by or on behalf of the additional insured(s) at the site where the covered operations have been completed; or (2) That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another Contractor or subcontractor engaged in performing operations for a principal as part of the same project. B. The limits of insurance applicable to the additional insured are those specified in a written contract or written agreement or the limits of Insurance as stated in the Declarations of this policy and defined in Section III - Limits Of Insurance of this policy, whichever are less. These limits are Inclusive of and not in addition to the limits of insurance available under this policy. C. The insurance provided the additional insured does not apply to the liability resulting from the sole negligence of the additional insured. CG 8416 12 03 Includes copyrighted material of ISO Properties, Inc., with its permission. Page 2 of 9 EM 00 D. As respects the coverage provided to the additional insured under this endorsement, Section IV - Conditions is amended as follows: 1. The following is added to Condition 2. Duties In The Event Of Occurrence, Offense, Claim, or Suit: An additional insured under this endorsement will as soon as practicable; a. Give written notice of an "occurrence" or an offense, that may result in a claim or "suit" under this insurance to us; b. Tender the defense and indemnity of any claim or "suit" to a[[ insurers whom also have insurance available to the additional insured; and c. Agree to make available any other insurance which the additional insured has for a loss we cover under this Coverage Part, 2. The following is added to Condition 3. Legal Action Against Us: We have no duty to defend or indemnify an additional insured under this endorsement until we receive written notice of a claim or "suit" from the additional insured, 3. The following is added to Paragraph a., Primary Insurance of Condition 4. Other Insurance: If the additional insured's policy has an Other Insurance provision making its policy excess, and a Named Insured has agreed in a written contract or written agreement to provide the additional insured coverage on a primary and noncontributory basis, this policy shall be primary and we will not seek contribution from the additional insured's policy for damages we cover, 4. The following is added to Paragraph b,, Excess Insurance of Condition 4. Other Insurance: Except as provided in Paragraph 4.a. Primary Insurance as amended above, any coverage provided hereunder shall be excess over any other valid and collectible insurance available to the additional insured whether primary, excess, contingent or on any other basis. In the event an additional insured has other coverage available for an"occurrence" by virtue of also being an additional insured on other policies, this insurance is excess over those other policies, 2. FIRE, LIGHTNING, EXPLOSION AND SPRINKLER LEAKAGE DAMAGE TO PREMISES YOU RENT If Damage To Premises Rented To You under Coverage A is not otherwise excluded from this policy, the following applies: A. The last paragraph of 2. Exclusions of Section I - Coverage A is replaced by the following: if Damage To Premises Rented To You is not otherwise excluded, Exclusions c. through n. do not apply to damage by fire, lightning, "explosion" or sprinkler leakage to premises while rented to you or temporarily occupied by you with permission of the owner. A separate limit of insurance applies to this coverage as described in Section III - Limits Of Insurance. B. Paragraph 6. of Section III - Limits Of Insurance is replaced by the following: 6. Subject to S. above, the higher of $300,000 or the Damage To Premises Rented To You Limit shown in the Summary of Limits and Charges section of this policy is the most we will pay under Coverage A for damages because of "property damage" to premises rented to you or temporarily occupied by you with the permission of the owner arising out of any one fire, lightning, "explosion" or sprinkler leakage incident. CG 8416 12 03 Includes copyrighted material or ISO Properties, Inc., with its permission. Page 3 of 9 E 602 00 C. Paragraph b.(1)(b) of Condition 4. Other Insurance (Section IV — Conditions) is replaced by the following: (1) That is l=ire, lightning, Explosion or Sprinkler Leakage insurance for premises rented to you or temporarily occupied by you with the permission of the owner, D. Paragraph 9.a. of the definition of "insured contract" in Section V- Definitions is replaced by the following: 9. "Insured contract" means: a. A contract for the lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damages by fire, lightning, "explosion" or sprinkler leakage to premises while rented to you or temporarily occupied by you with the permission of the owner is not an "insured contract"; E. The following definition is added to Section V - Definitions: "Explosion" means a sudden release of expanding pressure accompanied by a noise, a bursting forth of material and evidence of the scattering of debris to locations further than would have resulted by gravity alone. "Explosion" does not include any of the following: 1. Artificially generated electrical current including electrical arcing that disturbs electrical devices, appliances or wires; 2. Rupture or bursting of water pipes; 3. Explosion of steam boilers, steam pipes, steam engines or steam turbines owned or leased by you, or operated under your control; or 4. Rupture or bursting caused by centrifugal force. 3. NON -OWNED WATERCRAFT Subparagraph g.(2) of Paragraph 2,, Exclusions of Section I - Coverage A is replaced by the following: (2) A watercraft you do not own that is: (a) less than 51 feet long; and (b) Not being used to carry persons or property for a charge; 4. SUPPLEMENTARY PAYMENTS in the Supplementary Payments - Coverages A and 8 provision: The limit for the cost of bail bonds in Paragraph 1.b. is changed from $250 to $1000. CG 8416 12 03 Includes capyrlghted material or ISO Propertles, Inc,, with its permisslon. Page 4 of 9 E 603 DO PERSONAL. AND ADVERTISING INJURY - ELECTRONIC PUBLICATION EXTENSION Paragraphs 14.b., d. and e, of Section V - Definitions are replaced by the following: b. Malicious prosecution or abuse of process; d. Oral, written, televised, videotaped or electronic publication of material that slanders or libels a person or organization or disparages a person's or organization's goods, products or services; e. Oral, written, televised, videotaped or electronic publication of material that violates a person's right of privacy; The following is added to Paragraph 14. "Personal and Advertising injury" of Section V - Definitions: h. Discrimination or humiliation that results in injury to the feelings or reputation of a natural person, but only if such discrimination or humiliation is: (1) Not done intentionally by or at the direction of; (a) An insured; or (b) Any "executive officer" director, stockholder, partner or member of the insured; and (2) Not directly or indirectly related to the employment, prospective employment or termination of employment of any person or persons by any insured. Subparagraphs b, and c, of 2., Exclusions of Section I - Coverage B , Personal And Advertising Injury Liability are replaced by the following; b. Material Published With Knowledge Of Falsity Personal and advertising injury" arising out of oral, written, televised, videotaped or electronic publication of material, if done by or at the direction of the insured with knowledge of its falsity; c. Material Published Prior To Policy Period Personal and advertising injury" arising out of oral, written, televised, videotaped or electronic publication of material whose first publication took place before the beginning of the policy period; 6. AGGREGATE LIMITS OF INSURANCE (PER LOCATION) The General Aggregate Limit under Section III Limits Of Insurance applies separately to each of your "locations" owned by or rented to you or temporarily occupied by you with the permission of the owner. "Location" means premises involving the same or connecting lots, or premises whose connection is interrupted only by a street, roadway, waterway or right-of-way of a railroad, 7. AGGREGATE LIMITS OF INSURANCE (PER PROJECT) The General Aggregate Limit under Section Ill Limits Of insurance applies separately to each of your projects away from premises owned by or rented to you. CG 8416 12 03 Includes copyrighted material of 150 Properties, Inc., with its permission, Page 5 of 9 E M 00 8. VOLUNTARY PROPERTY DAMAGE COVERAGE At your request, we will pay for "loss" to property of others caused by your business operations. The most we will pay for this coverage is $500 each "occurrence," The "loss" must occur during the policy period. The "occurrence" must take place in the "coverage territory". "Loss" means unintended damage or destruction, "Loss" does not mean disappearance, abstraction or theft, This coverage does not apply to: 1. Damage arising out of the use of any "auto"; 2. Property you own, occupy, rent or lease from others; or 3. Property on your premises for sale, service, repair or storage. None of the other policy exclusions apply to this coverage. If the policy to which this endorsement Is attached is written with a property damage liability deductible, the deductible shall apply to Voluntary Property Damage. The limit of coverage stated above shall not be reduced by the amount of this deductible. 9. OFF PREMISES CARL, CUSTODY OR CONTROL COVERAGE A. We will pay those sums that you become legally obligated to pay as damages because of "property damage" to personal property of others while in your or your "employees" care, custody or control or real property of others over which you or your "employees" are exercising physical control if the "property damage" arises out of your business operations. This Coverage is subject to sections B., C., D. and E. below. B. Exclusions This insurance shall not apply to: 1. "Property damage" of property at premises owned, rented, leased, operated or used by you; 2. "Property damage" of property while in transit; 3. The cost of repairing or replacing: (a) Any of your work defectively or incorrectly done by you or by others on your behalf; or (b) Any product manufactured, sold or supplied by you, unless the "property damage" is caused directly by you after delivery of the product or completion of the work and resulting from a subsequent undertaking; or 4. 'Property damage" of property caused by or arising out of the "products -completed operations hazard". C. Limits Of Insurance - The most we will pay for "property damage" under this Section 9. is $25,000 for each "occurrence". The most we will pay for the sum of all damages covered under this Section 9, because of "property damage" is an annual aggregate limit of $25,000. The Limits Of Insurance provided under this Section 9, are inclusive of and not in addition to any other limits provided in the policy or endorsements attached to it. D. Deductible - We will not pay for "property damage" In any one "occurrence" until the amount of "property damage" exceeds $250. If the policy to which this endorsement is attached contains a "property damage" deductible, that deductible shall apply if it is greater than $250. E. In the event of "property damage covered by this endorsement, you shall, if requested by us, replace the property or furnish the labor and materials necessary for repairs thereto at your actual cost, excluding profit or overhead charges. CG 8¢16 12 03 Includes copyrighted material of ISO Properties, Inc., with its permission. Page 6 of 9 E 005 00 10. NEWLY FORMED OR ACQUIRED ORGANIZATIONS A. Paragraph 4. of Section Il - Who is An Insured is deleted and replaced by the following: 4. Any business entity acquired by you or incorporated or organized by you under the laws of any individual state of the United States of America over which you maintain majority ownership interest exceeding fifty percent. Such acquired or newly formed organization will qualify as a Named Insured if there is no similar insurance available to that entity. However: a. Coverage under this provision applies only until the expiration of the policy period in which the entity was acquired or incorporated or organized by you. b. Coverage A does not apply to "bodily injury" or "property damage" that occurred before the entity was acquired or incorporated or organized by you. c. Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before the entity was acquired or incorporated or organized by you. d. Records and descriptions of operations must be maintained by the first Named Insured. B. This Section 10. does not apply to newly forted or acquired organizations if coverage is excluded either by provisions of the Coverage Part or by other endorsement(s) attached to it. 11. DUTIES IN THE EVENT OF OCCURRENCE, OFFENSE, CLAIM OR SUiT A. The requirements in Section IV - Conditions, Paragraph 2.a., that you must see to it that we are notified of an "occurrence" applies only when the "occurrence" is known to: 1. You, if you are an Individual; 2. A partner, if you are a partnership; 3. A member or manager, if you are a limited liability company; 4. An executive officer or designee, if you are a corporation; 5. A trustee, if you are a trust; or 6. A designee, if you are any other type of organization. B. The requirements in Section IV - Conditions Paragraph 2.b. that you must see to it that we receive written notice of a claim or "suit" will not be considered breached unless the breach occurs after such claim or "suit" is known to: 1. You, if you are an individual; 2. A partner, if you are a partnership; 3. A member or manager if you are a limited liability company; 4. An executive officer or designee, if you area corporation; 5. A trustee, if you are a trust; or 6. A designee, if you are any other type of organization. Knowledge of an "occurrence," claim or "suit" by the agent, servant or "employee" of any insured shalt not in itself constitute knowledge of the insured unless an officer or designee shall have received notice from its agent, servant or "employee". 12. BODILY INJURY Paragraph 3. of the definition of "bodily injury" in the Section V - Definitions is replaced by the following: 3. "Bodily injury" means bodily injury, sickness or disease sustained by a person, including mental anguish or death resulting from any of these at any time. CG 8416 12 03 Includes copyrighted material of ISO Properties, Inc., with its permission. Page i of 9 E 606 00 13, WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against any person or organization for whom you perform work under a written contract that requires you to obtain this agreement from us. This agreement shall not operate directly or indirectly to benefit anyone not named in the agreement. 14. MEDICAL PAYMENTS If Coverage C Medical Payments is not otherwise excluded, the Medical Expense Limit provided by this policy shall be the greater of: A. $10,000; or B. The amount shown in the Declarations. 15. BROAD NAMED INSURED Paragraph 2.a.(1)(d) of Section 11- Who Is An insured is replaced by the following: (d) Arising out of his or her providing or failing to provide professional health care services, However, this exclusion does not apply to nurses, emergency medical technicians or paramedics who are employed by you to provide medical or paramedical services to your employees. 16. BROADENED MOBILE EQUIPMENT Paragraph 12.f.(1) of Section V - Definitions is replaced by the following: (1) Equipment designed primarily for: (a) Snow removal; (b) Road maintenance, but not construction or resurfacing; or (c) Street cleaning provided that vehicles have a Gross Vehicle Weight of 1,040 pounds or greater; 17. INCIDENTAL MALPRACTICE LIABILITY Paragraph 3. of Section V - Definitions is replaced by the following: 3. "Bodily injury" means bodily injury, sickness, disease or "incidental medical malpractice" sustained by a person, including mental anguish or death resuiting from any of these at any time. The following is added to Section V - Definitions: 23. "Incidental medical malpractice" means injury arising out of the negligent rendering or failure to render medical or paramedical services to persons by any physician, dentist, nurse, emergency medical technician or paramedic who is employed by you to provide such services to your employees, provided you are not engaged in the business or occupation of providing any services referred to in this definition. 18. NON -OWNED AIRCRAFT The following is added to Subparagraph g. of 2., Exclusions of Section I - Coverage A Bodily Injury And Property Damage Liability: (6) An aircraft with a paid crew, that is hired, chartered or loaned but is not owned by any insured. CG 8416 12 03 Includes copyrighted material of 150 Properties, Inc., with Its permisslon, E 607 as Page 8 of 9 19, PROPERTY DAMAGE - ELEVATORS The following Is added to Subparagraph j, of 2., Exclusions of Section I - Coverage A Bodily injury And Property Damage Liability: Paragraphs (3) and (4) of this exclusion do not apply to damages that result from the use of elevators. All other terms and conditions of your policy remain unchanged. CGe X416 12 03 Includes copyrighted material or ISO Properties, Inc., with its permission. Page 9 of 9 C11-16-43-64 RIVERSIDE INC 09/07/15 COMMERCIAL GENERAL LIABILITY CG 8583 10 05 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE REAL) IT CAREFULLY. BLANKET ADDITIONAL INSURED CONTRACTORS - PRODUCTS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. Section 11 - Who Is An Insured is amended to include as an additional insured any person(s) or organization(s) whom you have agreed to add as an additional insured in a written contract or written agreement, but only with respect to liability for "bodily injury" or "property damage" caused by "your work" performed for that additional insured and included in the "products -completed operation hazard". B. The following additional provisions apply to the additional insured: 1. When the Named Insured is required to add an additional insured on this policy in a written contract or written agreement; the written contract or written agreement must be: a. Currently in effect or becoming effective during the term of this policy; b. Executed prior to the "bodily injury," or "property damage"; and c. Between a Named Insured and the additional insured. 2. That person or organization is an additional insured only for liability caused by your negligence specifically resulting from "your work" for the additional insured which is the subject of the written contract or written agreement. No coverage applies for any liability due to negligence attributable to any person or entity other than the Named Insured, the Named Insured's employees or subcontractors. 3. The Limits of Insurance applicable to the additional insured are the lesser of: a. Those specified in the written contract or written agreement, or b. Those provided by this policy and defined in Section III - Limits Of Insurance. These Limits of Insurance are inclusive of, and not in addition to, the Limits Of Insurance shown in the Declarations and defined in Section III - Limits Of Insurance. 4. The insurance provided to the additional insured does not apply to: "Bodily injury" or "property damage" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: a. The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawing and specifications; and b. Supervisory, inspection, architectural or engineering activities. CG 8583 10 05 Includes Copyrighted Material of ISO Properties, Inc., with its permission. Page 1 Of 2 F FaK nn 5. The following replaces Exclusion I. under Paragraph 2., Exculsions of Section 1— Coverage A -- Bodily Injury And Property Damage Liability: I. Damage To Your Work This insurance does not apply to "property damage" to "your work" arising out of it or any part of it and included in the "product -completed operations hazard". 6. We have no ditty to defend or indemnify an additional insured under this endorsement: a. For any liability due to negligence attributable to any person or entity other than the Named Insured, the Named Insured's employees or subcontractors. b. For any loss which occurs prior to our Named Insured commencing operations at the location of the loss. c. Until we receive written notice of a claim or "suit" from the additional insured as required in Section IV — Conditions, Duties in The Event Of Occurrence, Offense Claim Or Suit. C. Section IV - Conditions are amended as follows: 1. The following is added to Paragraph 2., Duties In The Event of Occurrence, Offense, Claim or Suit: An additional insured under this endorsement must comply with all provisions of this section. 2. As respects the coverage provided underthis endorsement, Paragraph 4.b., Other Insurance is deleted and replaced by the following: 4. Other Insurance b. Excess Insurance This insurance is excess over any other insurance naming the additional insured as an insured whether primary, excess, contingent or on any other basis unless the written contract or agreement described in A. above specifically requires that this insurance be provided on either a primary basis or a primary and non-contributory basis. CG 8583 10 05 Includes Copyrighted Material of ISO Properties, Inc., with its permission. Page 2 of 2 Boa �� eTRAKiT Page 1 of 1 Home 1 Setup an Account 1 Log In Lieensee V Username PassnroM LOGIN ❑ REMEMBER ME Forgot Password Permits Apply Search Pay Fees Licenses Search Trade Licenses Search Public Works Inspections Schedule Cancel Elevators Search Elevators Violations Search Shopping Cart Pay All Fees Paid Items Contact Contact us Public Works Search P Search Again Download Results Printable View hr t EPre� Details - License Number: PWC -C-11115 Lic InfoFees $1,950.00 Registration M PWC -C-11115 Issue: 8/20/2015 Expire: 6/30/2016 Type: PUBLIC WORKS Sub -Type: A Status: ACTIVE Company: Riverside, Inc. Phone: (208) 722-6731 Cell: Pager: Fax: (208) 722-6736 Owner Name: Page: 1 of 1 Next jLastj The Division of Building Safety, makes every effort to produce and publish gie most current and accurate information possible. No warranties, expressed or implied, are provided for the data herein, fts use, or its interpretation. Utilization of (his website Indicates understanding and acceptance of (his statement 1-800-955-3044, 1090 E Watertower St, Suite 150 Meridian ID 63642 HOME 1 CONTACT https://web.dbs.idaho.gov/eTRAKiT3/Custom/ldaho PublicWorksSearchRslts.aspx 3/18/2016 IDSOS Viewing Business Entity Page I of 2 IDAHO SECRETARY OF STATE Viewing Business Entity Lawerence Denney, Secretary of State New Search Back to Summary ] Get a certificate of existence for RIVERSIDE, INC. [ Monitor RIVERSjIDE, INC. business filings RIVERSIDE,INC. P 0 BOX 720 PARMA, ID 83660 Type of Business: CORPORATION, GENERAL BUSINESS Status: GOODSTANDING 14 Jan 1993 State of Origin: IDAHO Date of 14 Jan 1993 Origination/Authorization: Initial Registered Agent: DENNIS D DAUGHERTY 111 S ROSWELL BLVD PARMA, ID 83660 Organizational ID / Filing C100751 Number: Number of Authorized Stock 2400 Shares: Date of Last Annual Report: 13 Nov 2015 Annual Report Due: Jan 2017 [ Help Me PrintZView TIFF ] Filed 14 Jan 1993 INCORPORATION View Image (PDF format) View Image (TIFF format) [ Help Me Print/View TIFF ] Report for year 2016 ANNUAL REPORT View Document Online Report for year 2015 ANNUAL REPORT View Document Online Report for year 2014 ANNUAL REPORT View Document Online Report for year 2013 ANNUAL REPORT View Document Online Report for year 2012 ANNUAL REPORT View Document Online Report for year 2011 ANNUAL REPORT View Document Online Report for year 2010 ANNUAL REPORT View Document Online Report for year 2009 ANNUAL View Image (PDF format) View REPORT Image (TIFF format) Report for year 2008 ANNUAL REPORT View Document Online Report for year 2007 ANNUAL View Image (PDF format) View REPORT Image (TIFF format) Report for year 2006 https://www.accessidaho.org/public/sos/corp/Cl00751.html 3/18/2016 IDSOS Viewing Business Entity ANNUAL REPORT Report for year 2005 ANNUAL REPORT Report for year 2004 ANNUAL REPORT Report for year 2001 ANNUAL REPORT Report for year 2000 ANNUAL REPORT Report for year 1999 ANNUAL REPORT Report for year 1998 ANNUAL REPORT Report for year 1997 ANNUAL REPORT Report for year 1996 ANNUAL REPORT Report for year 1995 ANNUAL REPORT Report for year 1994 ANNUAL REPORT Report for year 1993 ANNUAL REPORT Page 2 of 2 View Image (PDF format) View Idaho Secretary of State's Main Page State of Idaho Nome Page Comments, questions or suggestions can be emailed to: sosinfoCa)sos.idaho.aov https://www.accessidaho.org/public/sos/corp/C 100751.htm1 3/18/2016 Image (TIFF format) _View Image (PDF formats View Imaqe (TIFF format) View Imaqe (PDF format) View Imaqe (TIFF format) View Imaqe (PDF format, View Imaqe (TIFF format) View Image (PDF format) View Image (TIFF format View Image (PDF formats View Imaqe (TIFF format View Image PDF formats View Image (TIFF format) View Imaqe (PDF format) View Image (TIFF format View Image (PDF format View Imaqe (TIFF format) View Imaqe (PDF format) View Imaqe (TIFF format) View Image (PDF format) View Image (TIFF format) View Imaqe (PDF format) View Image (TIFF format) Idaho Secretary of State's Main Page State of Idaho Nome Page Comments, questions or suggestions can be emailed to: sosinfoCa)sos.idaho.aov https://www.accessidaho.org/public/sos/corp/C 100751.htm1 3/18/2016 Q Q) 0 0 O O o O W 0 0 o N N N O G r O o O u)w Ln !J •r +J N C O H W W OJ m v ro U j S -I CA N a, a W T 41 41 ro x +� is o N 'moi o 0 0 0 0 0 0 a) N C rl in a)r r r a v ro ll� v M m (N a fA r � N o a o 0 0 0 0 0 a A g m Sa 0 O o O o fao 0 0 0 0 0 'd y 4J M ?� ro O o 0 0 o •.i � N U a +� C u� rn <r c c U1 Np, N43 W El R 14 N TS ko to41 <r o o ro ul H q o o g y o OF o 0 C -4 4J a w w 0 +� I G m �j +' o ro Q ro Ga ro cs ro - O a N m O H 0 W 5 F rtl m rn v mH r -i N N U 4JN Q Z o r -1o -1 u) 10w a � 3 a � Q 0 w a P4 w H ro w o U Q H Q Q)